Reduction in scope of agreement for fault Sample Clauses

A 'Reduction in scope of agreement for fault' clause allows the parties to limit or adjust the obligations and responsibilities under a contract if one party is at fault, such as through a breach or failure to perform. In practice, this clause may permit the non-breaching party to reduce the scope of work, services, or deliverables required, or to withhold certain payments that correspond to the affected portion of the agreement. The core function of this clause is to provide a fair and structured remedy when a party fails to meet its contractual obligations, thereby minimizing further risk and clarifying the consequences of fault.
Reduction in scope of agreement for fault. 19.1.1 If the Grantee does not comply with an obligation under this Agreement and the Commonwealth believes that the non‐compliance is incapable of remedy, or if the Grantee has failed to comply with a notice to remedy, the Commonwealth may by written notice reduce the scope of the Agreement. 19.1.2 The Grantee agrees, on receipt of the notice of reduction, to: (a) stop or reduce the performance of the Grantee’s obligations as specified in the notice; (b) take all available steps to minimise loss resulting from the reduction; (c) continue performing any part of the Activity or the Agreement not affected by the notice if requested to do so by the Commonwealth; (d) report on, and return any part of the Grant to the Commonwealth, or otherwise deal with the Grant, as directed by the Commonwealth. 19.1.3 In the event of reduction under clause 19.1.1, the amount of the Grant will be reduced in proportion to the reduction in the scope of the Agreement.
View SourceView Similar (225)
Reduction in scope of agreement for fault. 19.1.1 If the Grantee does not comply with an obligation under this Agreement and the Commonwealth believes that the non‐compliance is incapable of remedy, or if the Grantee has failed to comply with a notice to remedy, the Commonwealth may by written notice reduce the scope of the Agreement. 19.1.2 The Grantee agrees, on receipt of the notice of reduction, to:
View SourceView Similar (47)

Related to Reduction in scope of agreement for fault

  • Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.

  • Scope of Agreement Nothing in this Agreement shall be deemed to entitle Executive to continued employment with the Company or its Subsidiaries, and if Executive’s employment with the Company shall terminate prior to a Change in Control, Executive shall have no further rights under this Agreement (except as otherwise provided hereunder); provided, however, that any termination of Executive’s employment during the Termination Period shall be subject to all of the provisions of this Agreement.

  • Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants: a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals: (1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency; (2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and (4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.

  • Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.