Review of DPR Clause Samples

The 'Review of DPR' clause establishes the process and requirements for examining and approving the Detailed Project Report (DPR) within a contract or project framework. Typically, this clause outlines the timeline for submission, the parties responsible for conducting the review, and the criteria or standards the DPR must meet. For example, it may specify that the project owner or an independent consultant will assess the DPR for completeness, technical adequacy, and compliance with project objectives. The core function of this clause is to ensure that the DPR is thoroughly vetted before project execution, thereby minimizing misunderstandings, design errors, or scope gaps that could lead to disputes or delays later in the project.
Review of DPR. The Contractor shall submit the DPR including the Dredging Management Plan for review of the Independent Engineer within 75 (seventy five) days of Appointed Date. The Independent Engineer shall review the DPR submitted by the Contractor and provide its observations and suggestions on the same including the observations of the Authority in respect thereof within 15 (fifteen) Days from the date of the receipt of such DPR. In the event that the Independent Engineer and/or Authority has observed that the DPR is not in conformity with the Scope of Work, the Contractor shall promptly and without any undue delay revise and resubmit the DPR or satisfy the Independent Engineer and/or Authority with regards its compliance within 7 (seven) Days of receiving observations and suggestions from the Independent Engineer. If the Independent Engineer does not make any observation/comments with respect to the DPR submitted to it by the Contractor within 7 (seven) Days of the submission, it shall be deemed that the Independent Engineer has no suggestions to make with respect to the DPR and the Contractor shall be entitled to proceed with the Project accordingly. The Contractor shall not be entitled to any extension of time for completing implementation or any other relief on account of delay caused due to providing any clarification or in resubmitting the DPR. Provided, however, that the Authority at its sole discretion may suitably extend such time period or provide relief (excluding any liquidated damages or financial compensation paid by the Authority to the Contractor) to compensate for any such delay not attributable to the Contractor. The Contractor shall not change approved DPR under this Contract, without submitting such revised DPR for the review of the Independent Engineer/ Authority. Notwithstanding the review by the Independent Engineer, the Contractor shall be responsible for any defect and/or deficiency in the DPR relating to the Project or any part thereof, and accordingly, the Contractor shall at all times remain responsible for its obligations under this Contract. Within 90 (ninety) days of COD, the Contractor shall furnish to the Authority and the Independent Engineer a complete set of final survey charts as proof of satisfying the requirement of assured LAD for the entire stretch of the Project Site, in 2 (two) hard copies of and in its editable digital format or in such other medium and manner as may be acceptable to the Authority, reflecting the Project a...
View SourceView Similar (5)

Related to Review of DPR

  • Review of Decision Within sixty (60) days after the Secretary’s receipt of a request for review, he or she will review the Company’s determination. After considering all materials presented by the Claimant, the Secretary will render a written opinion, written in a manner calculated to be understood by the Claimant, setting forth the specific reasons for the decision and containing specific references to the pertinent provisions of this Agreement on which the decision is based. If special circumstances require that the sixty (60) day time period be extended, the Secretary will so notify the Claimant and will render the decision as soon as possible, but no later than one hundred twenty (120) days after receipt of the request for review.

  • Review of Agreement Each party acknowledges that it has had time to review this agreement and, as desired, consult with counsel. In the interpretation of this agreement, no adverse presumption shall be made against any party on the basis that it has prepared, or participated in the preparation of, this agreement.

  • ADB’s Review of Procurement Decisions 11. All contracts procured under international competitive bidding procedures and contracts for consulting services shall be subject to prior review by ADB, unless otherwise agreed between the Borrower and ADB and set forth in the Procurement Plan.

  • Review of assessment The assessment of the applicable percentage should be subject to annual review or earlier on the basis of a reasonable request for such a review. The process of review shall be in accordance with the procedures for assessing capacity under the Supported Wage System.

  • Review of Documents Borrower has reviewed: (a) the Note, (b) the Security Instrument, (c) the Commitment Letter, and (d) all other Loan Documents.