Schedule and Planning Requirements – Integrated Master Schedule Clause Samples

Schedule and Planning Requirements – Integrated Master Schedule. The Contractor shall prepare and submit an IMS in hardcopy and in electronic format (Microsoft Project and Adobe Acrobat portable document file (.pdf)). The following are minimum Government requirements for the IMS: • Presents a realistic sequence and timing of all activities and documents necessary to demonstrate achievement of the PO within the PP. • Organized in a WBS aligned with the CLINs/Sub-CLINs in Section B of the awarded contract and includes, but is not limited to, the following columns in the prescribed order shown below, or as required by the PM/COR: o Installation Name: Identify EESOH-MIS Installation Name per Table 1. o Site Number: Identify EESOH-MIS Site Number per Table 1 and Site Alias, if applicable. o CLIN/Sub-CLIN: Identify CLIN and/or Sub-CLIN per Section B of the contract. o Note Sub-CLINs for compliance activities (routine regulatory requirements to comply with binding agreements) are denoted as ####CX and Sub-CLINs for performance activities (remedial advancement or progress towards the PO) are denoted as ####AX. o WBS Element Number Designation/Code. o Task Description: Include detailed description of all activities (e.g., meetings, permitting, site access, work plans, mobilization, field work, documents, reviews, coordination with stakeholders, etc.) associated with achievement of the PO and a clear indication of regulatory (CERCLA, RCRA, and/or State Program) phase completions (e.g., RIP Achieved, RC Achieved, etc.) and PO achievement. o Start and Finish Dates: Document Start date and Finish date for each required activity and document including appropriate durations and realistic Government and Regulatory review periods. a. Include an obligation date, notice to proceed date, or projected award date as the first activity for each Sub-CLIN. b. Include a clearly identified final field work (e.g., FINAL FIELD ACTIVITY) Start date and Finish Date for each site (i.e., indicate when the final set of field activities such as injections, groundwater sampling, or others will be complete).
View Source

Related to Schedule and Planning Requirements – Integrated Master Schedule

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • SCHEDULE AND MILESTONES The Parties shall execute one (1) Annex concurrently with this Umbrella Agreement. The initial Annex and any subsequent Annexes will be performed on the schedule and in accordance with the milestones set forth in each respective Annex.

  • Training Requirements Grantee will: A. Authorize and require staff (including volunteers) to attend training, conferences, and meetings as directed by DSHS. B. Appropriately budget funds to meet training requirements in a timely manner, and ensure staff and volunteers are trained as specified in the training requirements listed at ▇▇▇▇▇://▇▇▇.▇▇▇▇.▇▇▇▇▇.▇▇▇/hivstd/training/ and as otherwise specified by DSHS. Grantee shall document that these training requirements are met. C. Follow the appropriate DSHS POPS by funding opportunity (as per Section I: General Requirements for All Grantees) for training and observation requirements.

  • Geographic Area and Sector Specific Allowances, Conditions and Exceptions The following allowances and conditions shall apply where relevant. Where the Employer does work which falls under the following headings, the Employer agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.