Common use of Scope of Work Clause in Contracts

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional Attachments/Assurances”. Otherwise, remove this section if not applicable. XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth hereinherein [and Attachments 1, 2, 3 to this SOW Agreement]. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. . In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. XXXXXXXX The maximum amount payable under this SOW Agreement agreement is $ . In no case shall the total amount payable, including any change orders or amendments that may arise, exceed $100,000. Submit invoices to: State of Vermont, [CONTRACTING AGENCY], [CONTRACTING AGENCY ADDRESS], Montpelier, VT. 05633. Invoice should include Name of Project and Contract PO which is at top of this Form. [The State shall retain 10% of each payment to hold until the satisfactory completion of the Project by the prescribed time and to the satisfaction of the State. Payment of retained fees shall occur [one month after the completion date upon receipt of invoicing from Contractor] [MODIFY AS NEEDED], provided State has accepted all deliverables under this SOW Agreement.] Payments of invoices to the Contractor shall be made in accordance with as outlined below: Deliverable A Deliverable B Deliverable C Deliverable D [ADD IF APPLICABLE] For services performed at an hourly rate on a time and materials basis, State shall pay Contractor at the rate of $ per hour, however, total payment provisions in for services shall not exceed $ . [ADD IF APPLICABLE:] The State shall not be responsible for any expenses of the Master Agreement as further supplemented hereinContractor. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional Attachments/Assurances”. Otherwise, remove this section if not applicable. XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING. 3. Invoices shall include the SOW Agreement # and Master Agreement # which appear atop the first page of this SOW Agreement. 4. DELETE SECTION OR REVISE TABLE AS NEEDED For fixed price deliverables, Contractor shall be paid in accordance with the payment schedule included below. Amount shall be inclusive of any and all Contractor costs and expenses. SERVICES Deliverable Deadline Invoice Amount Deliverable A Deliverable B Deliverable C Deliverable D 5. DELETE SECTION OR REVISE HIGHLIGHTED AREAS AS NEEDED For services performed on a time and materials basis, Contractor shall be paid in accordance with the schedule of rates set forth in the Master Agreement, which may be set forth herein for reference. Total payment for time and materials services shall not exceed $ . INSERT RATES FROM MASTER AGREEMENT 6. DELETE OR REVISE AS NEEDED The State shall withhold 10% of each payment as retainage. Upon completion of the SOW Project in accordance with the prescribed project timeline, and to the satisfaction of the State, Contractor may submit a single invoice for the amount of retainage. 7. The State shall not be responsible for reimbursement of any expenses of the Contractor.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING. 3. Invoices shall include the SOW Agreement # and Master Agreement # which appear atop the first page of this SOW Agreement. 4. DELETE SECTION OR REVISE TABLE AS NEEDED For fixed price deliverables, Contractor shall be paid in accordance with the payment schedule included below. Amount shall be inclusive of any and all Contractor costs and expenses. SERVICES Deliverable Deadline Invoice Amount Deliverable A Deliverable B Deliverable C Deliverable D 5. DELETE SECTION OR REVISE HIGHLIGHTED AREAS AS NEEDED For services performed on a time and materials basis, Contractor shall be paid in accordance with the schedule of rates set forth in the Master Agreement, which may be set forth herein for reference. Total payment for time and materials services shall not exceed $ . INSERT RATES FROM MASTER AGREEMENT 6. DELETE OR REVISE AS NEEDED The State shall withhold 10% of each payment as retainage. Upon completion of the SOW Project in accordance with the prescribed project timeline, and to the satisfaction of the State, Contractor may submit a single invoice for the amount of retainage. 7. The State shall not be responsible for reimbursement of any expenses of the Contractor.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional ttachments/Assurances”. Otherwise, remove this section if not applicable. XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth hereinherein [and Attachments 1, 2, 3 to this SOW Agreement]. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. . In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. [INDICATE STATE RESOURCES AND CENTRAL POINT OF CONTACT] [INDICATE KEY CONTRACTOR STAFF AND CONTRACTOR PROJECT MANAGER] [INDICATE PROJECT MANAGEMENT METHODOLOGY, IF APPLICABLE] PROJECT MANAGEMENT/BUSINESS ANALYST/ENTERPRISE ARCHITECT SERVICES  This SOW Agreement for Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices Services shall be made submitted to the State of Vermont Office of the Attorney General for a determination in accordance with 3 V.S.A. § 342 that such engagement is not contrary to the payment provisions in spirit and intent of the Master Agreement as further supplemented herein. 2classification plan and merit system principles and standards provided by Chapter 13 of Title 3 of the Vermont Statutes. Contractor Further, there shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.be no limitation of liability, including a waiver of consequential, indirect, special, punitive or exemplary damages, or disclaimers of warranty without approval from the Office of the Attorney General. XXXXXXXXXXX XXXXXXX XXXXXXXX

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth hereinherein [and Attachments 1, 2, 3 to this SOW Agreement]. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. . In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. XXXXXXXXXXX XXXXXXX XXXXXXXX Any change to an SOW Agreement that alters one or more aspects of the Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate may require a formal change order. Modifications to Project scope, schedule, deliverables, or cost may require an amendment of the applicable SOW Agreement. While such changes may typically incur additional costs and possible delays relative to the Project schedule, some changes may result in less cost to the State Resources (i.e.; the State decides we no longer need a deliverable in whole or part) or less effort on the part of the Contractor. Change orders will be developed jointly and Central Point of Contact Indicate Key Contractor Staff and Contractor every effort will be made to adhere to the project management plan. The Project Manager Indicate for the State and the Project Management MethodologyManager for Contractor w ill decide whether a formal request for a change (“Change Request”), is necessary. If Applicable XXXXXXX XXXXXXXX 1a Change Request is necessary, the Project Manager for requesting party will prepare a Change Request in a form acceptable to the State detailing the effort involved in implementing the change, the total cost or associated savings to the State, of implementing the change, and the effect, if any, of implementing the change on the Project schedule. Once completed, the Change Request will be submitted to the non-requesting party for review. The non-requesting party will make its best efforts to either approve or deny the Change Request in writing within ten (10) business days. No scope of work modifications shall be performed until a change order is executed and approved by the applicable Contracting Agency. In no event shall any delay in the approval or denial of a change request or the execution of a change order constitute a deemed approval by the State. The maximum amount payable under this SOW Agreement agreement is $ . In no case shall the total amount payable, including any change orders or amendments that may arise, exceed $100,000. Submit invoices to: State of Vermont, [CONTRACTING AGENCY], [CONTRACTING AGENCY ADDRESS], Montpelier, VT. 05633. Invoice should include Name of Project and Contract PO which is at top of this Form. [The State shall retain 10% of each payment to hold until the satisfactory completion of the Project by the prescribed time and to the satisfaction of the State. Payment of retained fees shall occur [one month after the completion date upon receipt of invoicing from Contractor] [MODIFY AS NEEDED], provided State has accepted all deliverables under this SOW Agreement.] Payments of invoices to the Contractor shall be made in accordance with as outlined below: Deliverable A Deliverable B Deliverable C Deliverable D [ADD IF APPLICABLE] For services performed at an hourly rate on a time and materials basis, State shall pay Contractor at the rate of $ per hour, however, total payment provisions in for services shall not exceed $ . The State shall not be responsible for any expenses of the Master Agreement as further supplemented hereinContractor. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth hereinherein [and Attachments 1, 2, 3 to this SOW Agreement]. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. . In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. XXXXXXXXXXX XXXXXXX XXXXXXXX Any change to an SOW Agreement that alters one or more aspects of the Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate may require a formal change order. Modifications to Project scope, schedule, deliverables, or cost may require an amendment of the applicable SOW Agreement. While such changes may typically incur additional costs and possible delays relative to the Project schedule, some changes may result in less cost to the State Resources (i.e.; the State decides we no longer need a deliverable in whole or part) or less effort on the part of the Contractor. Change orders will be developed jointly and Central Point of Contact Indicate Key Contractor Staff and Contractor every effort will be made to adhere to the project management plan. The Project Manager Indicate for the State and the Project Management MethodologyManager for Contractor will decide whether a formal request for a change (“Change Request”), is necessary. If Applicable XXXXXXX XXXXXXXX 1a Change Request is necessary, the Project Manager for requesting party will prepare a Change Request in a form acceptable to the State detailing the effort involved in implementing the change, the total cost or associated savings to the State, of implementing the change, and the effect, if any, of implementing the change on the Project schedule. Once completed, the Change Request will be submitted to the non-requesting party for review. The non-requesting party will make its best efforts to either approve or deny the Change Request in writing within ten (10) business days. No scope of work modifications shall be performed until a change order is executed and approved by the applicable Contracting Agency. In no event shall any delay in the approval or denial of a change request or the execution of a change order constitute a deemed approval by the State. The maximum amount payable under this SOW Agreement agreement is $ . In no case shall the total amount payable, including any change orders or amendments that may arise, exceed $100,000. Submit invoices to: State of Vermont, [CONTRACTING AGENCY], [CONTRACTING AGENCY ADDRESS], Montpelier, VT. 05633. Invoice should include Name of Project and Contract PO which is at top of this Form. [The State shall retain 10% of each payment to hold until the satisfactory completion of the Project by the prescribed time and to the satisfaction of the State. Payment of retained fees shall occur [one month after the completion date upon receipt of invoicing from Contractor] [MODIFY AS NEEDED], provided State has accepted all deliverables under this SOW Agreement.] Payments of invoices to the Contractor shall be made in accordance with as outlined below: Deliverable A Deliverable B Deliverable C Deliverable D [ADD IF APPLICABLE] For services performed at an hourly rate on a time and materials basis, State shall pay Contractor at the rate of $ per hour, however, total payment provisions in for services shall not exceed $ . The State shall not be responsible for any expenses of the Master Agreement as further supplemented hereinContractor. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth hereinherein [and Attachments 1, 2, 3 to this SOW Agreement]. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. . In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. [INDICATE STATE RESOURCES AND CENTRAL POINT OF CONTACT] [INDICATE KEY CONTRACTOR STAFF AND CONTRACTOR PROJECT MANAGER] [INDICATE PROJECT MANAGEMENT METHODOLOGY, IF APPLICABLE] PROJECT MANAGEMENT/BUSINESS ANALYST/ENTERPRISE ARCHITECT SERVICES • This SOW Agreement for Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices Services shall be made submitted to the State of Vermont Office of the Attorney General for a determination in accordance with 3 V.S.A. § 342 that such engagement is not contrary to the payment provisions in spirit and intent of the Master Agreement as further supplemented herein. 2classification plan and merit system principles and standards provided by Chapter 13 of Title 3 of the Vermont Statutes. Contractor Further, there shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.be no limitation of liability, including a waiver of consequential, indirect, special, punitive or exemplary damages, or disclaimers of warranty without approval from the Office of the Attorney General. XXXXXXXXXXX XXXXXXX XXXXXXXX

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth hereinherein [and Attachments 1, 2, 3 to this SOW Agreement]. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. . In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. XXXXXXXXXXX XXXXXXX XXXXXXXX Any change to an SOW Agreement that alters one or more aspects of the Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate may require a formal change order. Modifications to Project scope, schedule, deliverables, or cost may require an amendment of the applicable SOW Agreement. While such changes may typically incur additional costs and possible delays relative to the Project schedule, some changes may result in less cost to the State Resources (i.e.; the State decides we no longer need a deliverable in whole or part) or less effort on the part of the Contractor. Change orders will be developed jointly and Central Point of Contact Indicate Key Contractor Staff and Contractor every effort will be made to adhere to the project management plan. The Project Manager Indicate for the State and the Project Management MethodologyManager for Contractor will decide whether a formal request for a change (“Change Request”), is necessary. If Applicable XXXXXXX XXXXXXXX 1a Change Request is necessary, the Project Manager for requesting party will prepare a Change Request in a form acceptable to the State detailing the effort involved in implementing the change, the total cost or associated savings to the State, of implementing the change, and the effect, if any, of implementing the change on the Project schedule. Once completed, the Change Request will be submitted to the non-requesting party for review. The non-requesting party will make its best efforts to either approve or deny the Change Request in writing within ten (10) business days. No scope of work modifications shall be performed until a change order is executed and approved by the applicable Contracting Agency. In no event shall any delay in the approval or denial of a change request or the execution of a change order constitute a deemed approval by the State. The maximum amount payable under this SOW Agreement agreement is $ . In no case shall the total amount payable, including any change orders or amendments that may arise, exceed $100,000. Submit invoices to: State of Vermont, [CONTRACTING AGENCY], [CONTRACTING AGENCY ADDRESS], Montpelier, VT. 05633. Invoice should include Name of Project and Contract PO which is at top of this Form. [The State shall retain 10% of each payment to hold until the satisfactory completion of the Project by the prescribed time and to the satisfaction of the State. Payment of retained fees shall occur [one month after the completion date upon receipt of invoicing from Contractor] [MODIFY AS NEEDED], provided State has accepted all deliverables under this SOW Agreement.] Deliverable A Deliverable B Deliverable C Deliverable D Payments of invoices to the Contractor shall be made in accordance with as outlined below: [ADD IF APPLICA BLE] For services performed at an hourly rate on a time and materials basis, State shall pay Contractor at the rate of $ per hour, however, total payment provisions in for services shall not exceed $ . The State shall not be responsible for any expenses of the Master Agreement as further supplemented hereinContractor. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent onsistent with the items noticed in the SOW RFP section “Additional ttachments/Assurances”. Otherwise, remove this section if not applicable. XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shallThis is a future phase. On completion of Phase 1 Services, in full satisfaction the City intends to evaluate and make a determination whether to amend this Agreement to authorize Phase 2. If authorized, Phase 2 will consist of development of an Airport Business Plan (ABP). An ABP is a document that uses a logical and disciplined structure to set out goals, objectives, and actions plans that drive the day-to- day operation and management of the specific requirements airport. It includes mission, vision and values statements, goals (driven by a strengths, weaknesses, opportunities and threats analysis), objectives and action plans. CONSULTANT shall perform the Services so as to complete each milestone within the number of this SOW days/weeks specified below. The time to complete each milestone may be increased or decreased by mutual written agreement of the project managers for CONSULTANT and CITY so long as all work is completed within the term of the Agreement. CONSULTANT shall provide a detailed schedule of work consistent with the schedule below within 2 weeks of receipt of the notice to proceed. From NTP Highest and Best Use Analysis TBD FBO Options Analysis TBD FBO Interim Plan one to three years FBO Lease Agreements TBD Rate (Fee) Study TBD Airport Rent Study TBD Rules and Regulations, provide Minimum Standards, and Leasing Policy TBD Define Current and Potential Uses and Services at the Airport TBD Public Outreach and Participation on-going Phase 2 Milestones/Tasks (if authorized) Completion No. of Days/Weeks/Years From NTP Airport Business Plan TBD The CITY agrees to compensate the CONSULTANT for professional services set forth herein. These services shall be provided performed in accordance with the Master Agreement terms and conditions of this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed and as set forth in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor budget schedule below. Compensation for Phase 1 Services shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated be paid by the State. The Contractor Project Manager shall work directly with the State Project Manager CITY to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports CONSULTANT on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made fixed fee basis in accordance with the Budget Schedule - Phase 1. Compensation for Additional Services shall be paid by the City to CONSULTANT based on the hourly rate schedule attached as exhibit C-1. The compensation to be paid to CONSULTANT under this Agreement for all services described in Exhibit “A” (Scope of Work – Phase 1) and reimbursable expenses shall not exceed $166,371.00. CONSULTANT agrees to complete all Phase 1 Services, including reimbursable expenses, within this amount. In the event CITY authorizes any Additional Services, the maximum compensation for all Phase 1 Services including reimbursable expenses and Additional Services shall not exceed $183,008.10. Any work performed or expenses incurred for which payment provisions would result in a total exceeding the Master Agreement maximum amount of compensation set forth herein shall be at no cost to the CITY. CONSULTANT shall perform the tasks and categories of work as further supplemented herein. outlined and budgeted below. The CITY’s Project Manager may approve in writing the transfer of budget amounts between any of the tasks or categories listed below provided the total compensation for Basic Services, including reimbursable expenses, does not exceed $166,371.00 and the total compensation for Additional Services does not exceed $16,637.10. 1-D (1): Highest and Best Use Analysis $18,368 1-D (2): FBO Options Analysis $19,920 1-D (X): FBO Interim Plan $7,360 1-G: FBO Lease Agreements $8,740 1-J (1): Rate (Fee) Study $17,980 1-J (2): Airport Rent Study $15,040 2: Rules and Regulations, Minimum Standards, and Leasing Policy $72,953 2-A: Define Current and Potential Uses and Services at the Airport $6,010 3: Public Outreach and Participation Included Sub-total Phase 1 Services $166,371.00 Total Phase 1 Services and Reimbursable expenses $166,371.00 Additional Services (Not to Exceed) $16,637.10 Maximum Total Compensation $183,008.10 The administrative, overhead, secretarial time or secretarial overtime, word processing, photocopying, in-house printing, insurance and other ordinary business expenses are included within the scope of payment for services and are not reimbursable expenses. Contractor CITY shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.reimburse CONSULTANT for the following reimbursable expenses at cost. Expenses for which CONSULTANT shall be reimbursed are:

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional Attachments/Assurances”. Otherwise, remove this section if not applicable. XXXXXXXXXX XXXXXXXXXXX XXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shallshall supply all labor, in full satisfaction of the specific requirements of this SOW Agreementtools, provide the transportation, materials, equipment and permits as necessary and required to perform services set forth as described herein. These Full pest management services shall are to be provided rendered by the Contractor covering the actual performance of insect, rodent, and small animal management work for interiors and exteriors of facilities in accordance with the Master Agreement and this SOW Agreementitems that follow. List clauses here and/or cross reference Special additional requirements apply to the attachments included with this SOWital, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX see specifications herein. The Contractor shall provide a project manager licensed New Hampshire pest control personnel to work perform the services described herein. The phrase complete complex service, is defined as the primary point control of contact with any infestation, both prevention and control, to be carried out in all parts of the Statebuilding complex including, but not limited to, all alleyways, trailers, garages, kitchens, kitchenettes, janitor closets, restrooms, storage areas, and building exteriors. As a part The term pest management, is defined as the eradication of its project management dutiesexisting infestations using the newest while at the same time reducing the volume and toxicity of pesticides used and human environmental exposure to pesticides. The phrase preventative pest management, is defined as the act of preventative measures within practical limits using the newest IPM techniques. Prior to initiation of service, the Contractor Project Manager shall submit to the agency, an IPM Plan for each building or site which will attend be approved by the agency contact. The Contractor shall be on site to initiate service within an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetingsworking days following notice of approval. Such meetings may include If the Project Management TeamIPM Plan is incomplete or disapproved, the Contract Administrator, Contractor shall have an agreed upon number of working days to submit revisions. 1. Problems and potential problems for each location; 2. Recommended integrated pest management preventive measures; 3. Recommended integrated pest management resolutions; 4. Rate and time of application; 5. Any indication of any other consultants, elected officialspertinent information relation to pest management; and 6. Contractor shall inspect each site location within the first month and will establish a schedule consultation with the agency contact for providing the required services. The schedule shall be adhered to throughout the life of the contract unless changed by agreement with the agency. Pest management and preventative management shall include, and be applied to all locations, all non-wood destroying insects including but not limited to roaches (all species), crickets, silverfish, pavement ants, centipedes, millipedes, ground beetles, spiders, wasps, yellow jackets, hornets, bees, fleas, cicada killers, box elder bugs, earwigs, clothes moths, flies, ants, grain insects, pill bugs, sow bugs, and members of the gnat family. The management and preventative management of all wood destroying insects including, but not limited to powder post beetles, wood boring beetles, ▇▇▇▇▇▇▇▇▇ ants, ▇▇▇▇▇▇▇▇▇ bees, and termites. ▇▇▇▇▇▇▇▇▇ ants are included with IPM, all other stakeholders WDIs require corrective service at an additional cost. The management and preventative management of all rodents and small animals including but not limited to rats, mice, voles, bats, squirrels, skunks, rabbits, groundhogs, and snakes. Rats, mice, moles are included with IPM, all other small animals handled by wildlife service at an additional cost. Populations of the following pests will be considered special optional services, separate from the specifications of this contract: Tick Control, Mosquito Control, Bird Control, and Honey Bee Relocation. Chemicals to be used in this service shall be registered with the New Hampshire Division of Pesticide Control. The Approved Products listing may be checked by calling (▇▇▇) ▇▇▇-▇▇▇▇ or on-line at ▇▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇.▇▇▇/publications-forms/documents/registered-pesticide-products.pdf The Contractor is required to supply any equipment, such as designated rodent traps, and to maintain the traps or pick them up (and dispose of contents) as part of this contract. The Contractor shall minimize the use of pesticides whenever possible. These applications shall be restricted to unique situations where no alternative measures are available or practical and non- chemical options have been exhausted. The Contractor shall not use any pesticide until after inspections or monitoring indicate the presence of pests that exceed action thresholds and non-chemical control methods or action have not reduce the pest population to below the action threshold. The Contractor shall provide a written report explaining the identity of the target pest, the need for such treatment, the time and specific place of treatment, the pesticide to be used, the method of application, what precautions should be taken to ensure employees safety, and the steps taken to ensure the containment of the pesticide to the site of application. The Contractor shall employ the least hazardous material, most precise application technique, and minimum quantity of pesticide necessary to achieve control. All equipment and chemicals must be in strict compliance with the New Hampshire Pesticides Controls statute, the Rules of New Hampshire Pesticide Control Boards, the Occupational Safety and and other regulatory agencies. The Contractor used at the agency. The Contractor shall provide current labels for all pesticides to be used as well as brand names of pesticide application equipment, rodent bait boxes, pest monitoring devices, pest surveillance and detection equipment, and any other pest control devices or equipment that may be used to provide services. The Contractor may be requested to perform emergency service(s) that are beyond routine service requests. The Contractor shall respond to these exceptional circumstances and complete the necessary work within two (2) business days after receipt of the request. The Contractor shall furnish the Department of Corrections, New Hampshire State Prison the following services: NHSP requires the Contractor to complete a Contractor Orientation as part the IPM plan. The orientation is required for all technicians that provide pest control services to NHSP. The contractor shall a minimum of two (2) technicians who have completed the orientation available. This orientation shall be provided by NHSP and the contractor shall attend at no cost to the state. The Contractor shall provide training to NHSP staff. This training shall teach staff on best practice methods in identifying and controlling pests. This training shall be provided as part of the preventative pest control process and shall be provided at no cost to the state. The Contactor shall provide scheduled and non-scheduled pest control to rid and keep clean all the present buildings; buildings may be added or deleted. NHH may require the Contractor to rid of pests not listed in the fixed price section. This service shall be provided at an hourly rate. The Contractor shall be compensated for any traps that may be required, at a rate of cost plus twenty-five (25) percent over the Contractor Invoices shall contain all appropriate information detailing the list and net prices and amount discounted. Emergency Services shall be provided within twenty-four (24) hours of contact. Services shall be provided within two (2) business days of contact. The Contractor shall provide all pest control supplies and equipment as dictated herein. Every effort shall be made by the Contractor to significantly reduce the use of pesticides whenever the Contractor Pest Control Services Manual. Traps should be placed in areas most likely to be frequented by pests but should be strategically located so as not to interfere with operations. All trap placements should be recorded on a detailed Trap Management Log. The Trap Management Log shall be filed within the Pest Control Services Manual. When vacuuming pests or pest control material/residue, a HEPA vacuum shall be used. The Contractor shall dispose of unused or waste pesticides in accordance with applicable State and Federal laws and regulations. The Contractor shall be responsible for inspecting all buildings and disposal areas for the purpose of locating problem areas. Problem areas may include, but are not limited to, wet locations, food source areas, structure issues, and penetration spots. All findings must be reported in writing via the Commercial Service and Inspection Report to the facility contact or designee listing problem areas and corrective measures to be taken. The Contractor shall take a proactive approach to reducing the risk of pest infestations at NHSP. The NHSP facility contact or their designee shall be responsible in notifying the Contractor of any known problem areas or infestations. NHDOC 22,960 Monthly ▇▇▇▇ ▇▇▇▇▇▇▇▇ PPO District Office ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇. ▇▇▇-▇▇▇-▇▇▇▇ Concord Except as otherwise provided in this Scope of Services, all services performed under this Contract shall be performed between the hours of 8:00 A.M. and 4:00 P.M. unless other arrangements are made in advance with the State. The Contractor Project Manager Any deviation in work hours shall work directly with be pre-approved by the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertakenContracting Officer. The report will also contain items such as the current status State requires ten-day advance knowledge of the project’s technical progress said work schedules to provide security and contractual obligations; achievements access to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented hereinrespective work areas. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shalleligible and approved Scope of Work for the project or projects under this Agreement is described in this attachment below. In the event of a conflict between this Attachment B, Scope of Work, and any other terms or conditions of this Agreement, this Attachment B is subsequent to all other terms and conditions of this Agreement. Any changes to this scope must be approved by THC after review of a written request to THC by Subgrantee and executed in full satisfaction an amendment to this Agreement. Send scope of work change requests to ▇▇▇-▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇▇. Please include your subgrant agreement number on all correspondence. The Contracted Service Provider(s) shall prepare an investigative study research design that delineates primary documentation tasks and establishes preliminary fieldwork methodology. The Contracted Services Provider(s) shall follow the Texas Department of Transportation (TxDOT) Documentation Standard for Historical Studies Research Design (DS) Documentation Standard for Preparing an Historic Resources Research Design, as applicable, and shall consult with THC if issues arise related to the DS. The Contracted Services Provider(s) shall develop a draft fieldwork methodology. The draft fieldwork methodology shall address how the Contracted Services Provider(s) will conduct field investigations, which shall document historic-age properties. The Contracted Services Provider(s) shall develop a draft public involvement plan. The public involvement plan shall identify potential interested parties in the county and outline efforts to involve them in the research and review of the specific requirements of this SOW Agreement, provide the services set forth hereinhistoric resources survey. These services parties may include, but are not limited to, the county historical commission (CHC), certified local government (CLG) staff, local and statewide historic preservation organizations, and local history museums, libraries, or repositories. The public involvement plan shall incorporate at least two (2) stakeholder meetings held within the county to be surveyed. The public involvement plan shall identify the location of the first stakeholder meeting and propose one (1) primary and one (1) alternate date and time; the date of the second stakeholder meeting will be dependent on the completion of the survey fieldwork. The Contracted Service Provider(s) shall ensure the availability of the proposed location for the primary and alternate times. The first stakeholder meeting shall be provided led by the Contracted Service Provider(s) who will provide information on the purpose and goals of the historic resource survey, the research design, the preliminary fieldwork methodology, the draft historic context, and the draft geographic survey scope. The first stakeholder meeting shall provide an opportunity for the stakeholders to express their views on the historic resources survey. The Contracted Service Provider(s) shall be prepared to collect information that the stakeholders might bring to the meeting, by means of scanning, copying, or photographing. The second stakeholder meeting shall be led by the Contracted Service Provider(s) who will provide information on the results of the historic resources survey report, including the historic context, fieldwork, and evaluations. The second stakeholder meeting shall provide an opportunity for the stakeholders to express their views on the historic resources survey. The Contracted Services Provider(s) shall submit the Task 1 draft deliverables - investigative study research design, draft fieldwork methodology and draft public involvement plan - in accordance Adobe PDF plus the native file formats used, such as Microsoft Word or Adobe InDesign, submitted via email to ▇▇▇-▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇▇ attention HIM-ESHPF Program Manager. The Contracted Services Provider(s) is/are responsible for quality assurance and quality control of the deliverables before they are submitted to the THC for review. The Contracted Services Provider(s) shall allow THC a minimum of thirty (30) calendar days to review and comment on the draft deliverables for this task before acceptance. Based on THC’s review of the deliverable, THC may require additional consultation and revision of the deliverable before its acceptance. Upon THC review and acceptance of the Task 1 deliverables, the Contracted Services Provider(s) shall develop a draft historic context report specific to the county, a draft countywide survey plan, a draft geographic survey scope recommendation, and a final public involvement plan. The Contracted Services Provider(s) shall consult with the Master Agreement THC during the development of the deliverable for this task. A historic context report shall be understood as a narrative that includes information based on cultural themes, specific chronological periods, and this SOW Agreementa defined geographic area. List clauses here It describes the broad patterns of community development, considering history, architecture, archeology, engineering, and culture, and identifies specific resource types (buildings, structures, sites, objects, and/or cross reference districts) that represent those patterns. Work will conform with National Park Service’s National Register Bulletin 39: Researching a Historic Property. Based on the appropriate historic context, including the identified Period(s) of Significance and Area(s) of Significance, the Contracted Service Provider(s) shall develop a draft countywide survey plan and develop a draft geographic survey scope recommending specific communities, locations, areas, and/or themes in which to conduct the initial phase of field investigations. The identified geographic scope shall be of reasonable scale that completion of a windshield-level field investigation by the Contracted Service Provider(s) is feasible before the end of the Contract period and within the Contract budget. The draft geographic survey scope shall also propose how future phases of field investigations covering the remainder of the county should be organized. After addressing any THC comments regarding the Task 1 deliverable of the draft public involvement plan, the Contracted Services Provider(s) shall submit the final public involvement plan. The Contracted Services Provider(s) shall submit the Task 2 draft deliverables – the draft historic context report, draft countywide survey plan, draft geographic survey scope and final public involvement plan - in Adobe PDF plus the native file formats used, such as Microsoft Word or Adobe InDesign, submitted via email to ▇▇▇-▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇▇ attention HIM-ESHPF Program Manager. The Contracted Services Provider(s) is/are responsible for quality assurance and quality control of the deliverables before they are submitted to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the StateTHC for review. The Contractor Project Manager Contracted Services Provider(s) shall work directly with allow THC a minimum of thirty (30) calendar days to review and comment on the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processesdraft deliverables for this task before acceptance. Contractor shall deliver written status reports Based on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status THC’s review of the project’s technical progress deliverable, THC may require additional consultation and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method revision of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented hereinbefore its acceptance. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent onsistent with the items noticed in the SOW RFP section “Additional ttachments/Assurances”. Otherwise, remove this section if not applicable. XXXXXXXXXX XXXXXXXXXXX XXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shallCM CONSULTANT will serve as the CITY’S full time construction representative. The CM CONSULTANT will be responsible for providing construction management, in full satisfaction inspection, quality assurance, technical and administrative services for the management and administration of the specific requirements construction contract, as well as oversight of this SOW Agreementactivities taken by outside entities in connection with the project. The scope of work for the CM CONSULTANT contract shall include assuring that the materials incorporated into the construction of the PROJECT conform to the applicable provisions of the CONTRACT DOCUMENTS. The CM CONSULTANT shall perform the oversight of testing and reviews required to ensure that the materials incorporated into the construction of the PROJECT conform to the CONTRACT DOCUMENTS. The CM CONSULTANT scope of services shall include services related to the following aspects of the PROJECT: • Construction Contract Management, Inspection and Quality Assurance; Construction Contract Management, Inspection and Quality Assurance: The CM CONSULTANT shall provide the day-to-day, ongoing management, administration and inspection services set forth herein. These services shall be provided required to ensure the PROJECT is constructed in accordance with the Master Agreement CONTRACT DOCUMENTS and this SOW Agreementapplicable statutes, regulations and procedures for construction using federal funds. List clauses here The CM CONSULTANT will also need to work with the assigned City Engineer. The CM CONSULTANT shall be responsible for providing inspection services during contractor working hours. The CM CONSULTANT shall be responsible for compiling and organizing the information and documentation required to be kept on file and/or cross reference submitted to the attachments included with this SOWCity’s Public Works Director. The CM CONSULTANT shall provide monthly updates in a method approved by the City and to the CITY regarding the ongoing and upcoming activities that impact, consistent with or may impact, the items noticed use of the project area by the public, nearby property owners, and tenants of properties in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status vicinity of the project’s technical progress . The CM CONSULTANT shall be responsible for creating and contractual obligations; achievements maintaining documents and logs of activities related to date; risk management activities; unresolved issues; requirements the construction of the PROJECT in accordance with generally accepted practices for the administration of federally-assisted construction contracts. The CM will also assist and/or conduct with biweekly construction meetings throughout the duration of the project. The CM shall also provide weekly project updates to resolve unresolved issues; action items; problems; installation the City in a method approved by the City. The CM shall not have control over, charge of or responsibility for the construction means, methods, techniques, sequences or procedures, or for safety precautions and maintenance results; and significant changes to programs in connection with the Work, nor shall the CM be responsible for the Construction Contractor’s organization or method of operation, failure to perform the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made Work in accordance with the payment provisions requirements of the Contract Documents. The CM shall be responsible for the CM’s negligent acts or omissions, but shall not have control over or charge of and shall not be responsible for acts or omissions of the Construction Contractor or of any other persons or entities performing portions of the Work. It is understood that the CM’s action in providing service as described in this Agreement is a service of the Master Agreement CM for the sole benefit of the Owner and, by performing as further supplemented provided herein, the CM is not acting in a manner so as to assume responsibility or liability, in whole or in part, for all or any part of the construction for this project or its compliance with the Contract Documents. No action taken by the CM shall relieve the Construction Contractor or any other persons or entities performing portions of the Work from its obligation to perform the work in strict conformity with the requirements of the Contract Documents, and in strict conformity with all other applicable laws, codes, rules and regulations. CM will endeavor to assure that all warranties and appropriate certifications have been received, assembled, and delivered to the Owner. The CM shall report to the Owner in writing any decisions it is aware of concerning disputes between the CM, contractors, any interested party and/or the Owner relating to the acceptability of the work, or the interpretation of the requirements of the Contract Documents pertaining to the furnishing and performing of the work. Said disputes must be reported to the Owner in writing within 3 business days or sooner to avoid project timeline delays. The Owner shall furnish to the CM the Contract Documents, including but not limited to, the contract for construction, plans and specifications. Upon request by the CM, the Owner agrees to furnish as-built plans and specifications, utility maps and other information necessary for the CM to perform it services if such information is available to the Owner and is feasible for and agreeable to the Owner to furnish. Owner agrees to cause Construction Contractor to provide documents and information necessary for the CM to perform its services. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. With respect to Contractor performances and obligations under this agreement "Scope of Work" includes: means the Documentation and all project-specific, and customer-specific specifications, functional descriptions, use-cases, Contractor’s written proposals and representations made to NYULH, and NYULH’s reasonable business requirements, as reasonably known or ascertainable by Contractor in its exercise of due diligence. The parties will develop a final Scope of Work and project schedule, which will remain in alignment with the RFP proposal and Contractor’s response thereto (and Scope of Work, as defined herein), and which will be further mutually developed, based on discussions additional design specifications defined by the parties throughout the project phases. (Equipment Procurement) The Contractor shall, shall furnish all equipment and components required for the as approved by NYULH in full satisfaction writing. The Contractor shall not place any firm orders for equipment without NYULH’s written notice to proceed. Prior to ordering major equipment or components of the specific requirements such as monitors and video recording equipment, the Contractor shall perform due diligence to determine the availability and release dates for the latest revisions of this SOW Agreementsuch equipment (“Latest Models”). The Contractor shall consult with NYULH regarding the availability and cost of the Latest Models, provide as NYULH intends to incorporate the services set forth hereinLatest Models into the Contract Documents whenever feasible in NYULH’s sole discretion. These services The Contractor shall diligently keep track of equipment availability and obtain commitments from manufacturers and suppliers to ensure delivery within thirty (30) days of Contractor placing its order. To ensure the use of Latest Models as directed by NYULH, equipment will not be ordered more than sixty (60) days prior to the actual installation date. The equipment shall be provided delivered directly to the Project site or to a warehouse acceptable to NYULH for staging or storage prior to delivery to the Project site. If delivered to a warehouse, the Contractor will be responsible for the coordination of the delivery to the warehouse and the subsequent coordination and delivery of equipment from the warehouse to the Project site. The Contractor shall be responsible for the cost of all warehousing, risk of loss, and delivery of the equipment from the warehouse to the Project site. Fabricated and assembled equipment shall be wrapped and sealed in polyethylene and appropriately boxed for shipment. Standard components shall be shipped in manufacturer's original packing. Boxes shall clearly indicate the equipment contained, "front", "top", "fragile", nature of components and Project location. The Contractor shall identify and ▇▇▇▇ all equipment, materials and component parts as being dedicated to this Contract and the property of NYULH and shall cause all manufacturers of the equipment to do the same. All equipment and component parts shall not constitute inventory of the Contractor or any manufacturer of the equipment, and no creditor of the Contractor or manufacturer shall have any rights therein. The Contractor shall maintain, and cause all manufacturers of the equipment to maintain all equipment and component parts free of liens, claims or encumbrances of any nature and shall not use such equipment or component parts as security for any financing or other transaction. Any payment to the Contractor for manufactured and suitably stored equipment not yet delivered to the Project site as may be agreed to by NYULH in its sole discretion shall be conditioned upon submission by the Contractor of bills of sale or such other procedures satisfactory to NYULH to establish NYULH’s title to such materials or equipment or otherwise protect NYULH’s interest. The Contractor warrants that it has the ability to assign and shall assign all manufacturers’ warranties on the equipment to NYULH. The Contractor warrants that it will promptly complete and file all necessary forms with the applicable manufacturers to ensure recognition of all warranties NYULH may be entitled to. NYULH shall be entitled to invoke all rights and remedies contained in any manufacturer documents or materials and will be considered a third-party beneficiary with respect to Contractor’s agreements with any of its equipment manufacturers or other contractors. Notwithstanding anything to the contrary contained in any other documents, including any correspondence, shrink-wrap, end-user licenses or click-wrap agreements, this Contract shall supersede any terms and conditions purporting to govern the use of the . (Installation, Configuration and Acceptance) Installation and Configuration. When applicable, Contractor will install and/or configure the Work in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point Scope of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etcWork.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth hereinherein [and Attachments 1, 2, 3 to this SOW Agreement]. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. . In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. [INDICATE STATE RESOURCES AND CENTRAL POINT OF CONTACT] [INDICATE KEY CONTRACTOR STAFF AND CONTRACTOR PROJECT MANAGER] [INDICATE PROJECT MANAGEMENT METHODOLOGY, IF APPLICABLE] PROJECT MANAGEMENT/BUSINESS ANALYST/ENTERPRISE ARCHITECT SERVICES • This SOW Agreement for Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED Services shall be submitted to the State of Vermont Office of the Attorney General for a determination in accordance with 3 V.S.A. § 342 that such engagement is not contrary to the spirit and intent of the classification plan and merit system principles and standards provided by Chapter 13 of Title 3 of the Vermont Statutes. Further, there shall be no limitation of liability, including a waiver of consequential, indirect, special, punitive or exemplary damages, or disclaimers of warranty without approval from the Office of the Attorney General. XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. XXXXXXXX The maximum amount payable under this SOW Agreement agreement is $ . In no case shall the total amount payable, including any change orders or amendments that may arise, exceed $100,000. Submit invoices to: State of Vermont, [CONTRACTING AGENCY], [CONTRACTING AGENCY ADDRESS], Montpelier, VT. 05633. Invoice should include Name of Project and Contract PO which is at top of this Form. [The State shall retain 10% of each payment to hold until the satisfactory completion of the Project by the prescribed time and to the satisfaction of the State. Payment of retained fees shall occur [one month after the completion date upon receipt of invoicing from Contractor] [MODIFY AS NEEDED], provided State has accepted all deliverables under this SOW Agreement.] Payments of invoices to the Contractor shall be made in accordance with as outlined below: Deliverable A Deliverable B Deliverable C Deliverable D [ADD IF APPLICABLE] For services performed at an hourly rate on a time and materials basis, State shall pay Contractor at the rate of $ per hour, however, total payment provisions in for services shall not exceed $ . [ADD IF APPLICABLE:] The State shall not be responsible for any expenses of the Master Agreement as further supplemented hereinContractor. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shalleligible and approved Scope of Work for the project or projects under this Agreement is described in this attachment below. In the event of a conflict between this Attachment B, Scope of Work, and any other terms or conditions of this Agreement, this Attachment B is subsequent to all other terms and conditions of this Agreement. Any changes to this scope must be approved by THC after review of a written request to THC by Subgrantee and executed in full satisfaction an amendment to this Agreement. Send scope of work change requests to ▇▇▇-▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇▇. Please include your subgrant agreement number on all correspondence. The Contracted Service Provider(s) shall prepare an investigative study research design that delineates primary documentation tasks and establishes preliminary fieldwork methodology. The Contracted Services Provider(s) shall follow the Texas Department of Transportation (TxDOT) Documentation Standard for Historical Studies Research Design (DS) Documentation Standard for Preparing an Historic Resources Research Design, as applicable, and shall consult with THC if issues arise related to the DS. The Contracted Services Provider(s) shall develop a draft fieldwork methodology. The draft fieldwork methodology shall address how the Contracted Services Provider(s) will conduct field investigations, which shall document historic-age properties. The Contracted Services Provider(s) shall develop a draft public involvement plan. The public involvement plan shall identify potential interested parties in the county and outline efforts to involve them in the research and review of the specific requirements of this SOW Agreement, provide the services set forth hereinhistoric resources survey. These services parties may include, but are not limited to, the county historical commission (CHC), certified local government (CLG) staff, local and statewide historic preservation organizations, and local history museums, libraries, or repositories. The public involvement plan shall incorporate at least two (2) stakeholder meetings held within the county to be surveyed. The public involvement plan shall identify the location of the first stakeholder meeting and propose one (1) primary and one (1) alternate date and time; the date of the second stakeholder meeting will be dependent on the completion of the survey fieldwork. The Contracted Service Provider(s) shall ensure the availability of the proposed location for the primary and alternate times. The first stakeholder meeting shall be provided led by the Contracted Service Provider(s) who will provide information on the purpose and goals of the historic resource survey, the research design, the preliminary fieldwork methodology, the draft historic context, and the draft geographic survey scope. The first stakeholder meeting shall provide an opportunity for the stakeholders to express their views on the historic resources survey. The Contracted Service Provider(s) shall be prepared to collect information that the stakeholders might bring to the meeting, by means of scanning, copying, or photographing. The second stakeholder meeting shall be led by the Contracted Service Provider(s) who will provide information on the results of the historic resources survey report, including the historic context, fieldwork, and evaluations. The second stakeholder meeting shall provide an opportunity for the stakeholders to express their views on the historic resources survey. The Contracted Services Provider(s) shall submit the Task 1 draft deliverables - investigative study research design, draft fieldwork methodology and draft public involvement plan - in accordance Adobe PDF plus the native file formats used, such as Microsoft Word or Adobe InDesign, submitted via email to ▇▇▇-▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇▇ attention HIM-ESHPF Program Manager. The Contracted Services Provider(s) is/are responsible for quality assurance and quality control of the deliverables before they are submitted to the THC for review. Upon THC review and acceptance of the Task 1 deliverables, the Contracted Services Provider(s) shall develop a draft historic context report specific to the county, a draft countywide survey plan, a draft geographic survey scope recommendation, and a final public involvement plan. The Contracted Services Provider(s) shall consult with the Master Agreement THC during the development of the deliverable for this task. A historic context report shall be understood as a narrative that includes information based on cultural themes, specific chronological periods, and this SOW Agreementa defined geographic area. List clauses here It describes the broad patterns of community development, considering history, architecture, archeology, engineering, and culture, and identifies specific resource types (buildings, structures, sites, objects, and/or cross reference districts) that represent those patterns. Work will conform with National Park Service’s National Register Bulletin 39: Researching a Historic Property. Based on the appropriate historic context, including the identified Period(s) of Significance and Area(s) of Significance, the Contracted Service Provider(s) shall develop a draft countywide survey plan and develop a draft geographic survey scope recommending specific communities, locations, areas, and/or themes in which to conduct the initial phase of field investigations. The identified geographic scope shall be of reasonable scale that completion of a windshield-level field investigation by the Contracted Service Provider(s) is feasible before the end of the Contract period and within the Contract budget. The draft geographic survey scope shall also propose how future phases of field investigations covering the remainder of the county should be organized. After addressing any THC comments regarding the Task 1 deliverable of the draft public involvement plan, the Contracted Services Provider(s) shall submit the final public involvement plan. Adobe InDesign, submitted via email to ▇▇▇-▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇▇ attention HIM-ESHPF Program Manager. The Contracted Services Provider(s) is/are responsible for quality assurance and quality control of the deliverables before they are submitted to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given THC for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etcreview.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.

Scope of Work. The Contractor shall, in full satisfaction of the specific requirements of this SOW Agreement, provide the services set forth herein. These services shall be provided in accordance with the Master Agreement and this SOW Agreement. List clauses here and/or cross reference to the attachments included with this SOW, consistent with the items noticed in the SOW RFP section “Additional XXXXXXXXXX XXXXXXXXXXX Contractor shall provide a project manager to work as the primary point of contact with the State. As a part of its project management duties, the Contractor Project Manager will attend an agreed upon number of informational and status meetings and, when appropriate, call and lead such meetings. Such meetings may include the Project Management Team, the Contract Administrator, other consultants, elected officials, and other stakeholders as designated by the State. The Contractor Project Manager shall work directly with the State Project Manager to define, manage, and control the project scope, timeline, issue escalation and resolution processes. Contractor shall deliver written status reports on a weekly basis. Status information shall include, at a minimum: all planned tasks accomplished, planned tasks that are incomplete, or behind schedule in the previous week (with reasons given for those behind schedule); all tasks planned for the upcoming two weeks; an updated status of tasks (entered into the project plan and attached to the status report – e.g., percent completed, resources assigned to tasks, etc.); and the status of any corrective actions undertaken. The report will also contain items such as the current status of the project’s technical progress and contractual obligations; achievements to date; risk management activities; unresolved issues; requirements to resolve unresolved issues; action items; problems; installation and maintenance results; and significant changes to Contractor’s organization or method of operation, to the project management team, or to the deliverable schedule, where applicable. In addition, Contractor will create and routinely update the project plan, if any, to reflect changes in the nature and timing of project activities, all changes being subject to the State Project Manager’s approval. Project deliverables and activities will be subject to the State’s quality management process to be defined by the State prior to the project kick-off. Project Management/Business Analyst/Enterprise Architect DELETE SECTION OR REVISE AS NEEDED XXXXXXXXXXX Indicate State Resources and Central Point of Contact Indicate Key Contractor Staff and Contractor Project Manager Indicate Project Management Methodology, If Applicable XXXXXXX XXXXXXXX 1. The maximum amount payable under this SOW Agreement is $ . Payments of invoices shall be made in accordance with the payment provisions in the Master Agreement as further supplemented herein. 2. Contractor shall submit invoices to: INSERT STATE ADDRESS FOR INVOICING.