Selection of Architect/Construction Documents Sample Clauses

The Selection of Architect/Construction Documents clause defines the process and criteria for choosing the architect responsible for a construction project and outlines the requirements for preparing and approving construction documents. Typically, this clause specifies who has authority to select the architect, the qualifications required, and the steps for submitting, reviewing, and finalizing design documents such as plans and specifications. Its core function is to ensure that the design phase is managed by qualified professionals and that all construction documents meet agreed standards, thereby reducing the risk of misunderstandings or disputes during the building process.
Selection of Architect/Construction Documents. Landlord consents to Tenant retaining Integrated Design, PA (the “Architect”) to prepare the “Construction Documents,” as that term is defined in this Section 3.1 for the Tenant Improvements, together with the consulting engineers selected by the Architect and reasonably approved by Landlord. Tenant is not obligated to retain Integrated Design, PA and may retain another Architect or Architects from time to time, provided, however, that any such other Architects shall be subject to Landlord’s reasonable approval. The plans and drawings to be prepared by Architect hereunder shall be known collectively as the “Construction Documents.” All Construction Documents shall reasonably comply with the drawing format and specifications as reasonably determined by Landlord, and shall be subject to Landlord’s and Tenant’s approval. Landlord may hire an architectural firm to conduct a peer review, and the fees associated with this peer review shall be paid from the Landlord’s Project Oversight Fee and shall not result in an additional charge to Tenant. Landlord has no obligation to approve any Tenant Change or any Tenant Improvements not shown on the plans previously approved by Landlord and Tenant or reasonably inferable therefrom if, in Landlord’s reasonable judgment, such Tenant Improvements (i) would materially increase the cost of performing any other work in the Building, not including the Tenant Improvements, unless in each case Tenant agrees to pay such costs based on Landlord’s Change Estimate Notice (as defined below), (ii) are incompatible with the design, quality, equipment or systems of the Building or otherwise require a change to the existing Building systems or structure, each in a manner that would not otherwise be required in connection with the improvements contemplated by the Fit Plan (as defined below), (iii) is not consistent with the existing quality and nature of the Building, or (iv) otherwise do not comply with the provisions of the Lease.
View SourceView Similar (27)

Related to Selection of Architect/Construction Documents

  • Selection of Architect/Construction Drawings Tenant shall retain -------------------------------------------- Gensler as the architect/space planner (the "Architect") to prepare the "Construction Drawings", as that term is defined in this Section 3.1. Tenant shall retain Landlord's engineering consultants (the "Engineers") to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base, Shell and Core work. The fees changed by the Engineers shall be comparable to the fees charged by comparable engineers performing comparable work in the Comparable Buildings. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the "Construction Drawings." All Construction Drawings shall comply with Landlord's drawing format and specifications. Landlord's review of the Construction Drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord's review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Construction Drawings are reviewed by Landlord or its space planner, architect, engineers and consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlord's space planner, architect, engineers, and consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in the Construction Drawings, and Tenant's waiver and indemnity set forth in Section 10.1 of this Lease shall specifically apply to the Construction Drawings. Furthermore, Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.

  • Construction Documents Phase Bidding or Negotiation Phase:

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.