Settlement Proposal Sample Clauses

Settlement Proposal. After termination, Design-Builder shall submit a final termination settlement proposal to Department in the form and with the certification prescribed by Department. Design-Builder shall submit the proposal promptly, but no later than thirty (30) days from the effective date of termination unless Design-Builder has requested a time extension in writing within such 30-day period and Department has agreed in writing to allow such an extension.

Settlement Proposal. Within 90 days after receipt of a Notice of Termination for Convenience or Notice of Partial Termination for Convenience, DB Contractor shall submit a final termination settlement proposal to TxDOT in the form and with the certification prescribed by TxDOT. DB Contractor’s termination settlement proposal shall then be reviewed by TxDOT and acted upon, returned with comments, or rejected. If DB Contractor fails to submit the proposal within the time allowed, TxDOT may determine, on the basis of information available, the amount, if any, due DB Contractor because of the termination, shall pay DB Contractor the amount so determined and shall be bound by TxDOT’s determination.

Settlement Proposal. This Agreement represents Seller’s settlement proposal and is expressly subject to and contingent upon City approval. City shall not be bound to the terms and conditions herein unless and until this Agreement has been approved and executed by the appropriate City official(s) acting in their authorized capacity.

Settlement Proposal. After receipt of a Notice of Termination or Notice of Partial Termination for Convenience, Maintenance Contractor shall submit a final termination settlement proposal to TxDOT in the form and with the certification prescribed by TxDOT. Maintenance Contractor shall submit the proposal promptly, but no later than 90 Days from the effective date of termination unless Maintenance Contractor has requested a time extension in writing within such 90-Day period and TxDOT has agreed in writing to such extension. Maintenance Contractor’s termination settlement proposal shall then be reviewed by TxDOT and acted upon, returned with comments, or rejected. If Maintenance Contractor fails to submit the proposal within the time allowed, TxDOT may conclusively determine, on the basis of information available to it, the amount, if any, due Maintenance Contractor because of the termination and shall pay Maintenance Contractor the amount so determined.

Settlement Proposal. After termination under this Article 8, or for any other category of termination for which the Contract Documents expressly permit Design-Builder to recover under this Article 8, Design-Builder shall submit a final termination settlement proposal to Department in the form and with the certification prescribed by Department. Design-Builder shall submit the proposal promptly, but no later than ninety (90) days from the effective date of termination unless Design-Builder has requested a time extension in writing within such ninety (90)-day period and Department has agreed in writing to allow such an extension.

Settlement Proposal. Design-Builder shall submit a termination settlement proposal to VPRA in the form prescribed by VPRA no later than sixty (60) Days after the effective date of termination. Design-Builder may request a time extension in writing. An extension request must be received by VPRA within the sixty (60)-Day period in which Design-Builder was to have delivered the termination settlement proposal. VPRA will review Design-Builder’s termination settlement proposal and will accept it, return it with comments, or reject it. If Design-Builder fails to submit the proposal within the time allowed, VPRA may determine the amount, if any, due Design-Builder because of the termination consistent with Section 14.5.

Settlement Proposal. Each party shall present an overall settlement proposal to the arbitrator which shall encompass all issues to be resolved. The two proposals shall set the outer limits of the range within which the arbitrator can make a determination as to the appropriate settlement result. All costs of the arbitration process shall be borne by the party determined by the arbitrator to have lost the arbitration. In the event the arbitrator makes a determination which reflects a 50-50 settlement, Telecom and ▇▇▇▇▇▇ shall share equally the costs of the arbitration. In the event the arbitrator makes a determination which reflects a divided settlement, the arbitrator shall determine the proportion in which the parties shall share the costs of arbitration.

Settlement Proposal. Aclima will replenish its security deposit in the amount of $109,715.60 in the aggregate for the 3 leases as Port has applied all the security deposit under each of the 3 leases.

Settlement Proposal. After receipt of a Notice of Termination, Design/Builder shall submit a final termination settlement proposal to the Alamo RMA in the form and with the certification prescribed by the Alamo RMA. Design/Builder shall submit the proposal promptly, but no later than 90 Days from the effective date of termination unless Design/Builder has requested a time extension in writing within such 90-Day period and the Alamo RMA has agreed in writing to such extension. If Design/Builder fails to submit the proposal within the time allowed, the Alamo RMA may conclusively determine, on the basis of information available to it, the amount, if any, due Design/Builder because of the termination and shall pay Design/Builder the amount so determined. The provisions of Section 17 shall govern any termination of this Agreement as a result of an Event of Default.