StadCo’s Right to Make Changes Sample Clauses

StadCo’s Right to Make Changes. StadCo may issue Field Change Orders without the Approval of the Authority. In all other instances, StadCo will be entitled to make Construction Contract Change Orders during the construction of the Project Improvements so long as StadCo pays all costs (including the cost of delays attributable thereto) associated therewith as and when such costs are incurred provided that StadCo may allocate Project Savings, as defined in Section 12.2, and Contingency to pay the same, subject to StadCo’s obligation to pay Cost Overruns; provided, however, StadCo shall obtain prior Approval of the Authority for any Construction Contract Change Order when such changes result in Cost Overruns or could result in the Project Improvements not meeting the Facility Standard. With respect to Construction Contract Change Orders that could result in a Cost Overrun, StadCo, at the time of the Approval of such Construction Contract Change Order, shall provide adequate evidence to the Authority of StadCo’s ability to pay the amounts due as a result thereof.
View SourceView Similar (9)
StadCo’s Right to Make Changes. StadCo may issue Field Change Orders without the Approval of the Authority. In all other instances, StadCo will be entitled to make Construction Contract Change Orders during the construction of the Project Improvements so long as StadCo pays all costs (including the cost of delays attributable thereto) associated therewith as and when such costs are incurred provided that StadCo may allocate Project Savings, and Contingency to pay the same, subject to StadCo’s obligation to pay Cost Overruns. With respect to Construction Contract Change Orders that could result in a Cost Overrun, StadCo shall provide adequate evidence to the Authority of StadCo’s ability to pay the amounts due as a result thereof.
View SourceView Similar (2)

Related to StadCo’s Right to Make Changes

  • Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.

  • HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.

  • Right to Make Agreement Each party warrants, with respect to itself, that neither the execution of this Agreement, nor the consummation of any transaction contemplated hereby, shall violate any provision of any law, or any judgment, writ, injunction, order or decree of any court or governmental authority having jurisdiction over it; nor result in or constitute a breach or default under any indenture, contract, other commitment or restriction to which it is a party or by which it is bound; nor require any consent, vote or approval which has not been given or taken, or at the time of the transaction involved shall not have been given or taken. Each party covenants that it has and will continue to have throughout the term of this Agreement and any extensions thereof, the full right to enter into this Agreement and perform its obligations hereunder.

  • Recognition of Company’s Rights I will not, at any time, without the Company’s prior written permission, either during or after my employment, disclose any Proprietary Information to anyone outside of the Company, or use or permit to be used any Proprietary Information for any purpose other than the performance of my duties as an employee of the Company. I will cooperate with the Company and use my best efforts to prevent the unauthorized disclosure of all Proprietary Information. I will deliver to the Company all copies of Proprietary Information in my possession or control upon the earlier of a request by the Company or termination of my employment.

  • Agency’s Right to Audit A. Grantee shall make available at reasonable times and upon reasonable notice, and for reasonable periods, work papers, reports, books, records, supporting documents kept current by Grantee pertaining to the Grant Agreement for purposes of inspecting, monitoring, auditing, or evaluating by System Agency and the State of Texas. Grantee shall ensure these same requirements are included in all subcontracts. B. In addition to any right of access arising by operation of law, Grantee and any of Grantee’s affiliate or subsidiary organizations, or Subcontractors shall permit the System Agency or any of its duly authorized representatives, as well as duly authorized federal, state or local authorities, unrestricted access to and the right to examine any site where business is conducted or services are performed, and all records, which includes but is not limited to financial, client and patient records, books, papers or documents related to this Grant Agreement. Grantee shall permit the System Agency or any of its duly authorized federal, state, or local authorities unrestricted access to and the right to examine all external contracts and or pricing models or methodologies related to the Grant Agreement. Grantee shall ensure these same requirements are included in all subcontracts. If the Grant Agreement includes federal funds, federal agencies that shall have a right of access to records as described in this section include: the federal agency providing the funds, the Comptroller General of the United States, the General Accounting Office, the Office of the Inspector General, and any of their authorized representatives. In addition, agencies of the State of Texas that shall have a right of access to records as described in this section include: the System Agency, HHS's contracted examiners, the State Auditor’s Office, the Office of the Texas Attorney General, and any successor agencies. Each of these entities may be a duly authorized authority. C. If deemed necessary by the System Agency or any duly authorized authority, for the purpose of oversight, including, but not limited to, reviews, inspections, audits and investigations, Grantee shall produce original documents related to this Grant Agreement. D. The System Agency and any duly authorized authority shall have the right to audit ▇▇▇▇▇▇▇▇ both before and after payment, and all documentation that substantiates the ▇▇▇▇▇▇▇▇ and payments related to the Grant Agreement, including those related to a Subcontractor. E. Grantee shall include the System Agency’s and any of its duly authorized representatives’, as well as duly authorized federal, state, or local authorities, unrestricted right of access to, and examination of, sites and information related to this Grant Agreement in any Subcontract it awards.