Submission and Approval Sample Clauses
POPULAR SAMPLE Copied 1 times
Submission and Approval. The Contractor’s Submittals must comply with the Contract Documents. The Contractor shall review and approve all Submittals prior to submission. The Contract Documents shall specify when shop drawings or submittals require the seal of a specialty consultant. The Contractor shall submit copies of Submittals as required by the Contract Documents for the Work of the various trades. The Design Professional shall review, approve, or take other appropriate action with respect to shop drawings, samples, or other submissions of the Contractor, including, but not limited to, confirming conformance with the design concept of the Project and with the Contract Documents. The Design Professional shall respond to and return said items to the Contractor within fourteen calendar days from receipt provided that the Submittals are submitted by the Contractor in accordance with the required Submittal schedule. The Design Professional shall review and give comment or approval to Submittal schedule within fourteen calendar days from receipt. Large submittal documents may require longer review times, e.g., submittals with over fifty sheets of drawings. If, because of events beyond its reasonable control, the Design Professional is not able to meet the specified time period, then it is entitled to ask for additional time from the Owner. The Contractor shall make all corrections required by the Design Professional and furnish such corrected copies as may be needed. If the Contractor believes that any corrections required by the Design Professional constitute a change to the contract, the Contractor shall immediately notify the Design Professional and Owner and request instructions. By forwarding the approved Submittals to the Design Professional, the Contractor represents that the Contractor has determined and verified materials, field measurements, and field construction criteria related thereto, or will do so, and has checked and coordinated the information contained within such Submittals with the requirements of the Work and of the Contract Documents. The Design Professional’s approval of Submittals shall not relieve the Contractor from the responsibility for errors of any sort in Submittals or schedules. The Contractor shall perform no portion of the Work for which the Contract Documents require Submittals until the Design Professional has approved the respective Submittal. The Contractor shall maintain at the Site one copy of all approved Submittals.
Submission and Approval. The Design-Builder’s Submittals must comply with the Contract Documents. The Design-Builder shall review and approve all Submittals prior to submission. The Contract Documents shall specify when shop drawings or submittals require the seal of a specialty consultant. The Design-Builder shall submit copies of Submittals as required by the Contract Documents for the Work of the various trades. The Design-Builder shall perform no portion of the Work for which the Contract Documents require Submittals until the Design Professioanl has approved the respective Submittal. The Design-Builder shall maintain at the Site one copy of all approved Submittals.
Submission and Approval. Maintenance Contractor, within 240 Days after issuance by TxDOT of Maintenance NTP1, shall submit to TxDOT, for TxDOT’s review and approval, a Maintenance Transition Plan as described in Section 0208 of Exhibit 2.
Submission and Approval. Seller may, from time to time, submit a Credit File or Loan File to Arc for approval in accordance with the Arc Correspondent Seller's Guide. All submissions must be consistent for the loan types, programs and limitations as further defined in the applicable Arc Guide and/or this Agreement.
Submission and Approval. 4.1 Upon WEPCo’s confirmation of the New Project Request, WEPCo will (pursuant to Paragraph 4.1) produce outline proposals for New Projects, which develop and are consistent with the SDP where so requested. This is known as the Stage 1 Submission.
4.2 All Stage 1 Submissions will be produced within three (3) months (or such longer period up to a maximum of six (6) months where necessary) from the New Project Request. A Stage 1 Submission shall (as set out in Paragraph 4.2) be produced in accordance with the relevant Partnering Services Method Statement (to be incorporated into the SPA) and contain as a minimum (more expressly set out in Paragraphs 4.2.1 to 4.2.13):
4.2.1 a value for money assessment in respect of the New Project Request;
4.2.2 a concept design (to RIBA Stage 2) of the New Project;
4.2.3 a desktop study meeting the requirements of the Partnering Services Method Statements, site investigation studies and environmental impacts (as appropriate and as set out in Clause 4.2.3 more explicitly);
4.2.4 confirmation as to whether the New Project requires the transfer of properties by the Participant to WEPCo, to a Project Service Provider, or to a wholly owned Subsidiary of WEPCo;
4.2.5 the identity of the contractual structure and proposed corporate structure;
4.2.6 a schedule of all material amendments required to the New Project Specific Project Agreement and template Project Agreement for MIM Projects taking into account the Approval Criteria;
4.2.7 the identity of the Participant and/or other parties who will become Project Agreement Counterparties;
4.2.8 an explanation as to how the New Project fits into the service delivery strategy as set out in the latest SDP;
4.2.9 the effect (if any) on any employees of the Participant or relevant third party service providers;
4.2.10 a planning brief;
4.2.11 a maximum time period for submission of a Stage 2 Submission on the assumption that the New Tender Project achieves Stage 1 Approval;
4.2.12 the proposed Project Development Fee Estimate; and
4.2.13 a BIM Execution Plan.
4.3 The Stage 1 Submission must also be accompanied by a copy of the most recent WEPCo Performance Report and confirmation as to whether or not the Track Record Test has been passed at the date of submission of the Stage 1 Submission.
4.4 In developing a Stage 1 Submission, WEPCo shall (pursuant to Paragraph 4.3) liaise with the Participant and relevant end users as necessary to ensure the best available value for money is achieved t...
Submission and Approval. The Construction Manager shall submit no shop drawings which do not comply with the Contract Documents. The Construction Manager shall review all shop drawings prior to submission. He shall submit such reasonable number of shop drawings as shall be required by the Architect for the work of the various trades, and the Architect shall review and approve, making proper corrections. The Construction Manager shall make any proper corrections required by the Architect, file with him two corrected copies, and furnish such other copies as may be needed. The Architect's approval of such drawings or schedules shall not relieve the Construction Manager from responsibility for deviations from drawings or specifications nor shall it relieve him from the responsibility for errors of any sort in shop drawings or schedules.
Submission and Approval. Any scientific publication or presentation by either party with respect to the Product, including publications relating to clinical studies, will be approved by the other party prior to publication or presentation, such approval not to be unreasonably delayed or withheld. Due regard will be given to each party's legitimate interests, i.e., protection of confidential information, commercialization of the Product, etc. Any proposed publications which are to make public any findings, data or results of the studies relating to the Product will be provided to the other party at least thirty (30) days prior to submission for publication for the other party's approval, except that abstracts may be provided seven (7) days prior to submission for publication.
Submission and Approval. All documents and materials relating to the Facilities which are intended to be released by the Manager to the public shall be submitted to the City for review and approval prior to release to the public. Once information has been cleared for public release, it shall always be used in its originally cleared context and format. Information previously cleared for public release but containing new, modified or further developed information must be submitted again for public release following the steps outlined above.
Submission and Approval. Promptly following the execution and delivery of this Agreement, the Company shall use commercially reasonable efforts to submit to the holders of record of all of the voting shares of Common Stock issued and outstanding as of the date hereof for approval (the “280G Approval”) in a manner reasonably satisfactory to Parent, by such number of such holders of shares of Common Stock as is required by the terms of Section 280G(b)(5)(B) of the Code, any payments and/or benefits (with respect to which the prospective recipient has executed a waiver of such payments and/or benefits in a form reasonably satisfactory to Parent) that the Company has determined may separately or in the aggregate, constitute “parachute payments” (within the meaning of Section 280G of the Code and the Regulations). Prior to the Closing the Company shall deliver to Parent evidence of the results of such vote.
Submission and Approval. The Members agree that the development of the Property (such development being referred to hereinafter as the "Project") shall be based on an overall plan for development (a "Master Plan") approved from time to time by the Members or the Executive Committee pursuant to this Section 5.2. Any such plan, including modifications thereto, that is approved by the Members of the Executive Committee shall be termed the "Approved Master Plan." The initial Approved Master Plan is attached hereto as Exhibit A. Any Representative may from time to time submit revisions or modifications to the Approved Master Plan then in effect to the Executive Committee for its review and approval in accordance with Section 5.6 hereof; provided that no revisions or modifications shall be implemented unless approved in accordance with Section 5.6 hereof.