Performance Bank Guarantee 4.2.1 The Performance Bank Guarantee furnished by Power Producer to GUVNL shall be for guaranteeing the commissioining / commercial operation of the project up to the Contracted Capacity within SCOD. 4.2.2 If the Power Producer fails to commission the project on or before Scheduled Commercial Operation Date, GUVNL shall have the right to encash the Performance Bank Guarantee without prejudice to the other rights of the Power Producer under this Agreement as per Article 3.3. 4.2.3 GUVNL shall release the Performance Bank Guarantee upon successful commissioning of full contracted capacity after adjusting Liquidated Damages (if any) as per Article 3.3.
Availability of Performance Order If, and to the extent that, a breach of this contract has been caused by a Relevant Force Majeure Event, the Non-affected Party shall not be entitled to a Performance Order except to secure performance by the Affected Party of its obligations under this Clause 17.
Suspension of Performance Disbursement Into Court If at any time, there shall exist any dispute between the Company and the Investor(s) with respect to holding or disposition of any portion of the Escrow Funds or any other obligations of Escrow Agent hereunder, or if at any time Escrow Agent is unable to determine, to Escrow Agent's sole satisfaction, the proper disposition of any portion of the Escrow Funds or Escrow Agent's proper actions with respect to its obligations hereunder, or if the parties have not within thirty (30) days of the furnishing by Escrow Agent of a notice of resignation pursuant to Section 9 hereof, appointed a successor Escrow Agent to act hereunder, then Escrow Agent may, in its sole discretion, take either or both of the following actions: a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of Escrow Agent or until a successor Escrow Agent shall be appointed (as the case may be); provided however, Escrow Agent shall continue to invest the Escrow Funds in accordance with Section 8 hereof; and/or b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to Escrow Agent, for instructions with respect to such dispute or uncertainty, and to the extent required by law, pay into such court, for holding and disposition in accordance with the instructions of such court, all funds held by it in the Escrow Funds, after deduction and payment to Escrow Agent of all fees and expenses (including court costs and attorneys' fees) payable to, incurred by, or expected to be incurred by Escrow Agent in connection with performance of its duties and the exercise of its rights hereunder. c. Escrow Agent shall have no liability to the Company, the Investor(s), or any person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of funds held in the Escrow Funds or any delay in with respect to any other action required or requested of Escrow Agent.
Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified. (ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement. (iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.
Guaranty of Performance Each Guarantor also guaranties the full, prompt and unconditional performance of all obligations and agreements of every kind owed or hereafter to be owed by the Borrower to the Agent or the Lenders under the Credit Agreement and the other Loan Documents to which the Borrower is a party. Every provision for the benefit of the Agent or the Lenders contained in this Guaranty shall apply to the guaranty of performance given in this paragraph.