Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Landlord Improvements Prior to Tenant’s occupancy, Landlord shall complete the Landlord Improvements. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by the Anticipated Rent Commencement Date. (a) As of November 4, 2011, after consultation with Tenant, Landlord has provided Tenant with Landlord’s proposed plans and specifications (defined below in subpart (c))for the Landlord Improvements (such plans and specifications, as amended in accordance with the provisions of this Rider 101, are hereafter called “Plans and Specifications”). (b) The Plans and Specifications have been accepted by both Tenant and Landlord, the Plans and Specifications are incorporated herein by reference and made a part hereof for all purposes. (c) Landlord and Tenant acknowledge that the plans dated November 4, 2011, by Page ▇▇▇▇▇▇▇▇▇▇▇ Page, LLP have been approved by both parties and shall constitute the “Plans and Specifications.” (d) Promptly upon approval of the Plans and Specifications, Landlord has caused general contractors to bid for construction of the Landlord Improvements. All bids have been opened together, with Landlord selecting the general contractor with the lowest bid to construct the Landlord Improvements (the “General Contractor”), subject to the reasonable approval of Tenant. Landlord shall enter into a guaranteed maximum price construction contract with the General Contractor in the amount of its bid (the “Approved Bid”) and shall not modify such contract without Tenant’s consent, which shall not be unreasonably withheld, delayed or conditioned. Landlord and Tenant have reviewed the Plans and Specifications and the bids and have agreed upon the scope of work to be constructed at a cost of construction not to exceed the Landlord’s Contribution.
Landlord Work Prior to the execution of this First Amendment, Landlord and Tenant have approved (i) a detailed space plan for the construction of Landlord’s Work in the Premises, which space plan has been prepared by Studio O + A (“Final Approved Plan”) and (ii) a bid proposal for the construction of Landlord’s Work in the Premises, which bid proposal has been prepared by ▇▇ ▇▇▇▇ Construction and is dated June 2, 2011 (Rev-2) (“Bid Proposal”). The Final Approved Plan and Bid Proposal are approved by the parties as of the Effective Date, are attached hereto collectively, as Exhibit “D-1” and hereby replaces the original Approved Plan attached to the Lease as Exhibit “D-1”. Consequently, all references in the Work Letter to the “Approved Plan” shall mean and refer to the Final Approved Plan and Bid Proposal attached hereto as Exhibit “D-1”. Landlord agrees to construct the Landlord Work, pursuant to the terms and conditions set forth in the Work Letter and as depicted on the Approved Plan (as amended hereby). Landlord shall pay for the cost (including, the cost of obtaining all applicable building permits) of the design and construction of Landlord’s Work in an amount up to, but not exceeding, Two Hundred Twenty Two Thousand One Hundred Fifty and 00/100 Dollars ($222,150.00) plus any additional costs actually incurred by Landlord in excess of such $222,150.00 amount as a direct result of Landlord’s or Landlord’s contractor’s active negligence or willful misconduct or resulting from change order to the Approved Plans (as amended hereby) if such change order is initiated and executed by Landlord (the “Landlord’s Contribution”). Tenant shall pay for all costs in excess of the Landlord’s Contribution (“Over Allowance Amount”) which payment shall be made to Landlord in cash within thirty (30) days after Tenant’s receipt of invoice therefor from Landlord. Payment of the Over-Allowance Amount shall be in addition to Tenant’s obligation to pay to Landlord the cost of any Aggregate Extras as provided in Section 4 of the Work Letter.
Landlord’s Options Landlord shall have the option, exercisable by written notice delivered to Tenant within twenty (20) days after Landlord’s receipt of a Transfer Notice accompanied by the other information described in Section 12.1, to: (a) permit Tenant to Transfer the Premises; or (b) disapprove (provided, Landlord’s disapproval must be in accordance with Section 12.1 hereof) the Tenant’s Transfer of the Premises and to continue the Lease in full force and effect as to the entire Premises; or (c) in the event of (i) a proposed assignment of the Lease or (ii) a sublease of more than 50% of the Premises (taking into account all sublets in the aggregate) for all or substantially all of the balance of the Term, terminate the Lease as of the proposed effective date of the Transfer set forth in Tenant’s Transfer Notice (a “Recapture”); provided, however, that if Landlord shall notify Tenant of Landlord’s intention to Recapture the Premises, Tenant may elect to withdraw its Transfer Notice by written notice of such election delivered to Landlord within ten (10) business days of Tenant’s receipt of Landlord’s Recapture notice. If Landlord approves of the proposed Transfer pursuant to Section 12.1 above, Tenant may enter into the proposed Transfer with such proposed Transferee subject to the following conditions: (i) the Transfer shall be on the same terms set forth in the Transfer Notice; and (ii) no Transfer shall be valid and no Transferee shall take possession of the Premises until an executed counterpart of the assignment, sublease or other instrument effecting the Transfer (in the form approved by Landlord) has been delivered to Landlord pursuant to which the Transferee shall expressly assume all of Tenant’s obligations under this Lease applicable to that portion of the Premises then being transferred (provided that, for a subtenant, the rental obligations shall be governed by the terms of the applicable sublease). If Landlord exercises its option to terminate this Lease (or in the case of a partial sublet to release Tenant with respect to a portion of the Premises) as provided above, Tenant shall surrender possession of the Premises on the proposed effective date of the Transfer set forth in Tenant’s Transfer Notice, and thereafter neither Landlord nor Tenant shall have any further liability with respect thereto, except with respect to those matters that expressly survive the termination of the Lease.