TERM; POSSESSION The Term shall commence on the Commencement Date and ---------------- shall expire, if not sooner terminated pursuant to the provisions of this Lease, on the Expiration Date. On the Commencement Date, the Premises and Equipment Space are accepted by Tenant in "as is" condition and configuration (subject to the completion of the Landlord Work). By taking possession of the Premises and Equipment Space, Tenant agrees that the Premises and Equipment Space are in good order and satisfactory condition, and that there are no representations or warranties by Landlord regarding the condition of the Premises, Equipment Space or the Building except as may be expressly set forth herein. If Landlord is delayed in delivering possession of the Premises and Equipment Space or any other space, Landlord shall use reasonable efforts to obtain possession of the space, but no such delay shall nullify this Lease or give rise to any claim for damages on the part of Tenant. If Tenant takes possession of the Premises or Equipment Space before the Commencement Date, such possession shall be subject to the terms and conditions of this Lease except that, prior to the Rent Commencement Date, Tenant will not be required to pay Rent hereunder. Notwithstanding the foregoing, if the Commencement Date does not occur by the date that is one hundred fifty (150) days following the mutual execution and delivery of this Lease (the "Outside Delivery Date"), Tenant, as its sole remedy, may terminate this Lease by giving Landlord written notice of termination after the Outside Delivery Date. In such event, and subject to the provisions set forth below in this Article 3, this Lease shall be deemed null and void and of no further force and effect and Landlord shall promptly refund any prepaid Rent and Security Deposit previously advanced by Tenant under this Lease and the parties hereto shall have no further responsibilities or obligations to each other with respect to this Lease. Landlord and Tenant acknowledge and agree that the Outside Delivery Date shall be postponed by the number of days the Commencement Date is delayed due to events of Force Majeure (as defined herein). Notwithstanding the foregoing to the contrary, if Tenant exercises its right to terminate this Lease as set forth above but Landlord delivers the Premises to Tenant in the condition required by this Lease within thirty (30) days after the date of Tenant's delivery of Tenant's termination notice, this Lease shall continue in full force and effect the same as if Tenant had not delivered its termination notice, and Tenant's termination notice will be null and void. Tenant's right to terminate as described herein shall be null and void as of the Commencement Date.
Peaceful Possession The Authority hereby warrants that:
a) The Project Site has been acquired through the due process of law and belongs to and is vested with the Authority and that the Authority has full powers to hold, dispose of and deal with the same consistent, inter alia, with the provisions of this Agreement.
b) In the event the Developer is obstructed by any Person claiming any right, title or interest in or over the Project Site or any part thereof, or in the event of any enforcement action including any attachment, distrait, appointment of receiver or liquidator being initiated by any Person claiming to have any interest in/charge or the Project Site or any part thereof, the Authority shall, if called upon by the Developer, defend such claims and proceedings and also keep the Developer indemnified against any consequential loss or damages which the Developer may suffer, on account of any such right, title, interest or charge.
Quiet Possession Upon Tenant paying the rent reserved hereunder and observing and performing all of the covenants, conditions and provisions on Tenant's part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire term hereof, subject to all the provisions of this Lease.
VACANT POSSESSION The Purchaser after the payment of the TPP shall at his own costs and expenses take possession of the Property without any obligation on the part of the Assignee/Bank to give vacant possession and the Purchaser is PROHIBITED from entering upon the Property or take possession of the Property prior to the settlement of the balance purchase price and/or late payment interest (if any).
Documents, Records and Funds in Possession of the Master Servicer to be Held for the Trustee. The Master Servicer shall account fully to the Trustee for any funds it receives or otherwise collects as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, the Collection Account, Distribution Account, or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment, or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.