CONTRACT FOR CONSTRUCTION AND SALE OF A DRILLSHIP (HULL NO.1865) BETWEEN DRILLSHIP KITHIRA OWNERS INC. AND SAMSUNG HEAVY INDUSTRIES CO., LTD.
EXHIBIT
10.4
CONTRACT
FOR
CONSTRUCTION
AND SALE
OF
A
DRILLSHIP
(HULL
NO.1865)
BETWEEN
DRILLSHIP
KITHIRA OWNERS INC.
AND
SAMSUNG
HEAVY INDUSTRIES CO., LTD.
INDEX
|
PAGE
|
|||
|
ARTICLE
I - DESCRIPTION AND CLASS
|
6
|
||
|
1.
|
Description:
|
6
|
|
|
2.
|
Dimensions
and Characteristics:
|
6
|
|
|
3.
|
The
Classification, Rules and Regulations:
|
7
|
|
|
4.
|
HSE
Analysis, studies and assessments
|
7
|
|
|
5.
|
Subcontracting
|
8
|
|
|
6.
|
Registration:
|
8
|
|
|
ARTICLE
II - CONTRACT PRICE AND TERMS OF PAYMENT
|
9
|
||
|
1.
|
Contract
Price:
|
9
|
|
|
2.
|
Adjustment
of Contract Price:
|
9
|
|
|
3.
|
Currency:
|
9
|
|
|
4.
|
Terms
of Payment:
|
9
|
|
|
5.
|
Method
of Payment:
|
11
|
|
|
6.
|
Notice
of Payment before Delivery:
|
12
|
|
|
7.
|
Expenses;
|
12
|
|
|
8.
|
Prepayment:
|
12
|
|
|
ARTICLE
III - ADJUSTMENT OF CONTRACT PRICE
|
13
|
||
|
1.
|
Delivery:
|
13
|
|
|
2.
|
Speed:
|
14
|
|
|
3.
|
Fuel
Consumption for the Diesel Generator Prime Drivers:
|
15
|
|
|
4.
|
Variable
Load Capacity:
|
15
|
|
|
5.
|
Effect
of Rescission:
|
16
|
|
|
ARTICLE
IV - APPROVAL OF PLANS AND DRAWINGS AND INSPECTION DURING
CONSTRUCTION
|
17
|
||
|
1.
|
Approval
of Plans and Drawings:
|
17
|
|
|
2.
|
Appointment
of BUYER'S Supervisor:
|
17
|
|
|
3.
|
Inspection
by the Supervisor:
|
17
|
|
|
4.
|
Facilities:
|
19
|
|
|
5.
|
Liability
of BUILDER:
|
19
|
|
|
6.
|
Responsibility
of BUYER:
|
20
|
|
|
7.
|
Delivery
and Construction Schedule:
|
20
|
|
|
ARTICLE
V - MODIFICATIONS, CHANGES AND EXTRAS
|
22
|
||
|
1.
|
How
Effected:
|
22
|
|
|
2.
|
Changes
in Rules of Classification Society, Regulations, etc.:
|
23
|
|
|
3.
|
Substitution
of Materials:
|
24
|
|
|
ARTICLE
VI - TRIALS AND ACCEPTANCE
|
25
|
||
2
|
1.
|
Notice:
|
25
|
|
|
2.
|
Weather
Condition:
|
25
|
|
|
3.
|
How
Conducted:
|
26
|
|
|
4.
|
Method
of Acceptance or Rejection
|
26
|
|
|
5.
|
Effect
of Acceptance:
|
27
|
|
|
6.
|
Disposition
of Surplus Consumable Stores:
|
28
|
|
|
ARTICLE
VII - DELIVERY
|
29
|
||
|
1.
|
Time
and Place:
|
29
|
|
|
2.
|
When
and How Effected:
|
29
|
|
|
3.
|
Documents
to be delivered to BUYER:
|
29
|
|
|
4.
|
Tender
of DRILLSHIP:
|
30
|
|
|
5.
|
Title
and Risk:
|
31
|
|
|
6.
|
Removal
of DRILLSHIP:
|
31
|
|
| ARTICLE VIII - DELAYS AND EXTENSION OF TIME FOR DELIVERY (FORCE MAJEURE) |
32
|
||
|
1.
|
Causes
of Delay (Force Majeure):
|
32
|
|
|
2.
|
Notice
of Delay:
|
33
|
|
|
3.
|
Definition
of Permissible Delay:
|
33
|
|
|
4.
|
Right
to Rescind for Excessive Delay:
|
33
|
|
|
ARTICLE
IX - WARRANTY OF QUALITY
|
35
|
||
|
1.
|
Guarantee:
|
35
|
|
|
2.
|
Notice
of Defects:
|
35
|
|
|
3.
|
Remedy
of Defects:
|
35
|
|
|
4.
|
Extent
of BUILDER'S Responsibility
|
37
|
|
|
ARTICLE
X - RESCISSION BY BUYER
|
38
|
||
|
1.
|
Notice:
|
38
|
|
|
2.
|
Refundment
by BUILDER:
|
38
|
|
|
3.
|
Discharge
of Obligations:
|
39
|
|
|
ARTICLE
XI - BUYER'S DEFAULT
|
40
|
||
|
1.
|
Definition
of Default:
|
40
|
|
|
2.
|
Effect
of Default on or before Delivery of DRILLSHIP:
|
40
|
|
|
3.
|
Disposal
of DRILLSHIP:
|
41
|
|
|
ARTICLE
XII - ARBITRATION
|
42
|
||
|
1.
|
Decision
by the Classification Society:
|
42
|
|
|
2.
|
Proceedings
of Arbitration in London UK.:
|
42
|
|
|
3.
|
Notice
of Award:
|
43
|
|
|
4.
|
Expenses:
|
43
|
|
|
5.
|
Entry
in Court:
|
43
|
|
|
6.
|
Alteration
of Delivery Date:
|
43
|
|
3
|
ARTICLE
XIII - SUCCESSOR AND ASSIGNS
|
45
|
||
|
ARTICLE
XIV - TAXES AND DUTIES
|
46
|
||
|
1.
|
Taxes
and Duties Incurred in Korea and/or China:
|
46
|
|
|
2.
|
Taxes
and Duties Incurred Outside Korea and/or China:
|
46
|
|
|
ARTICLE
XV - PATENTS, TRADEMARKS, COPYRIGHTS, ETC
|
47
|
||
|
1.
|
Patents:
|
47
|
|
|
2.
|
General
Plans, Specifications and Working Drawings:
|
47
|
|
|
ARTICLE
XVI - BUYER'S SUPPLIES
|
48
|
||
|
1.
|
Responsibility
of BUYER:
|
48
|
|
|
2.
|
Responsibility
of BUILDER:
|
49
|
|
|
3.
|
Title:
|
49
|
|
|
ARTICLE
XVII - INSURANCE
|
50
|
||
|
1.
|
Extent
of Insurance Coverage:
|
50
|
|
|
2.
|
Application
of the Recovered Amounts:
|
50
|
|
|
3.
|
Termination
of BUILDER'S Obligation to Insure:
|
51
|
|
|
ARTICLE
XVIII - NOTICE
|
52
|
||
|
1.
|
Address:
|
52
|
|
|
2.
|
Language:
|
52
|
|
|
3.
|
Effective
Date of Notice:
|
53
|
|
|
ARTICLE
XIX - EFFECTIVE DATE OF CONTRACT
|
54
|
||
|
ARTICLE
XX - INTERPRETATION
|
55
|
||
|
1.
|
Laws
Applicable:
|
55
|
|
|
2.
|
Discrepancies:
|
55
|
|
|
3.
|
Entire
Agreement:
|
55
|
|
|
4.
|
Amendments
and Supplements:
|
55
|
|
|
ARTICLE
XXI - CONFIDENTIALITY
|
56
|
||
|
EXHIBIT
"1"
|
VESSEL
SPECIFICATION
|
58
|
|
EXHIBIT
"2"
|
TOPSIDE
SPECIFICATION
|
59
|
|
EXHIBIT"3"
|
DELIVERY
AND CONSTRUCTION SCHEDULE
|
60
|
|
EXHIBIT
"4"
|
LETTER
OF REFUNDMENT GUARANTEE NO
|
61
|
|
EXHIBIT
"5"
|
PERFORMANCE
GUARANTEE
|
64
|
|
EXHIBIT
"6"
|
OPTIONAL
ITEMS
|
65
|
|
EXHIBIT"7"
|
FORM
OF DEMAND
|
.65
|
4
This
Contract, made and entered into on this 24th day of January 2008 by and between
DRILLSHIP KITHIRA OWNERS INC., a corporation incorporated and existing under the
laws of ▇▇▇▇▇▇▇▇ Islands having its registered office at Trust Company Complex,
Ajeltake Road, Ajeltake Island, Majuro, ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ (hereinafter
called the "BUYER"), on the one part and SAMSUNG HEAVY INDUSTRIES CO., LTD., a
corporation incorporated and existing under the laws of the Republic of Korea
and having its registered office at 34th Floor, Samsung Life Insurance ▇▇▇▇▇▇
▇▇▇▇▇ ▇▇▇▇-▇▇, ▇▇▇▇▇▇-▇▇▇▇, ▇▇▇▇▇▇-▇▇, ▇▇▇▇▇, ▇▇▇▇▇ 137-857 (hereinafter called
the "BUILDER"), on the other part.
WITNESSETH:
In
consideration of the mutual covenants herein contained, the BUILDER acknowledges
that the Contract is a turn key contract for the construction and sale of a
drillship constructed and tested out to be fully ready to drill and fully
functioning in accordance with and subject to the terms and conditions of this
Contract and Specifications and the BUILDER agrees as described in the
Specifications to design, construct, build, launch, equip, test and complete One
(1) Drillship composed of a hull part as described in the specification attached
hereto as Exhibit "1" of this Contract (hereinafter referred to as the "VESSEL")
and topside part as described in the specification attached hereto as Exhibit
"2" of this Contract (hereinafter referred to as "TOPSIDE") (the VESSEL and
TOPSIDE being hereinafter collectively referred to as the "DRILLSHIP") and in
accordance with the Delivery and Construction Schedule attached hereto as
Exhibit "3" (said Exhibits 1 through 3 (including all amendments, additions,
deletions and variations incorporated into the Specifications for HN. 1674 up to
the Effective Date of the Contract of HN.1837) being hereinafter collectively
called the "Specifications") which Specifications have been initialed by
representatives of the parties hereto for identification and which
Specifications hereby are each incorporated herein by reference hereto and made
an integral part of this Contract, at the BUILDER'S shipyard located in Geoje
Island, Korea (hereinafter referred to as the "Shipyard") and to deliver and
sell the same to the BUYER, and the BUYER hereby agrees to purchase and accept
delivery of the DRILLSHIP from the BUILDER, upon the terms and conditions
hereinafter set forth.
5
ARTICLE I
- DESCRIPTION AND CLASS
|
1.
|
Description:
|
The
DRILLSHIP, having the BUILDER'S Hull No. 1865, shall be designed, constructed,
built, launched, equipped, tested, completed and delivered in accordance with
the provisions of this Contract, and the Specifications as a subsequent
Drillship of HN. 1837. To the extent not defined in the Specifications, the
DRILLSHIP's construction is to meet the first-class international shipbuilding
and construction standards and practices, including without limitation such
standards and practices relating to BUILDER'S Quality Assurance
Programs,
|
2.
|
Dimensions
and Characteristics:
|
|
Length,
overall
|
Max.
228 meters
|
|
|
Length,
between perpendiculars
|
abt.
219.4 meters
|
|
|
Breadth,
moulded
|
abt.
42 meters
|
|
|
Depth,
moulded
|
abt.
19 meters
|
|
|
▇▇▇▇▇▇▇▇▇
draft, moulded
|
abt. 13
meters
|
Speed,
guaranteed: The trial speed shall not be less than 12.0 knots on the transit
draught of 8.5 meters and at total thruster motor output of 28,700
KW.
Guaranteed
Fuel Consumption, Diesel Generator Prime Drivers (in relation to each engine):
The fuel consumption shall be not more than the engine manufacturers' nominal
fuel consumption plus five percent (5) % with engine driven pumps at
manufacturer's shop trial, burning marine diesel having the lower calorific
value of 10,200 kCal/kg, at 85% MCR under the environment condition of ISO
3046/1-1986 specified in the Specifications.
Guaranteed
Variable Load Capacity: The variable load capacity of the DRILLSHIP will be not
less than 20,000 metric tons for drilling and survival conditions without
extended well test oil on board as specified in the Specifications.
The
details of the aforementioned particulars, as well as the definitions and the
methods of measurements and calculations shall be as indicated in the
Specifications.
6
|
3.
|
The
Classification, Rules and
Regulations:
|
The
DRILLSHIP, including its machinery, equipment and outfittings shall be
constructed and classified in accordance with the rules and regulations (the
editions and amendments thereto being in force) as of the signing date of the
Contract of HN.1837 and under special survey of American Bureau of Shipping
(hereinafter called the "Classification Society"), and shall be distinguished in
the register by the symbol of *A1 <D, "Drilling Unit", *AMS, *ACCU, *DPS-3,
NBLES, SH-DLA, *CDS.
Decisions
of the Classification Society as to compliance or non-compliance with the
classification rules and regulations shall be final and binding upon both
parties hereto. Details of its notation shall be in accordance with the
Specifications.
The
DRILLSHIP shall also comply with the rules, regulations and requirements of the
regulatory bodies as described and listed in the Specifications.
The
DRILLSHIP will be built and delivered (i) in accordance with the terms of this
Contract and the Specifications, (ii) in full compliance and certification to
and with the IMO MODU code with amendments, (iii) in full compliance with the
regulations, provisions, and requirements included in the Specifications, (iv)
in full compliance with the requirements of the Classification Society so as to
be classed with the Classification Society as a MODU, and (v) so that the
DRILLSHIP will be approved to operate in the United States Gulf of Mexico/the
Outer Continental Shelf of the United States, the waters outside West Africa,
Central Africa, South Africa, South America, South East Asia, UK, Australia,
South Atlantic and in the Mediterranean. The BUILDER will take all action
necessary, and remedy at its cost and expense, any deficiency that constitutes a
failure to comply with the above requirements.
All fees
and charges incidental to the Classification Society and in respect to
compliance with the above referred rules, regulations and requirements, as well
as all DRILLSHIP design fees and/or royalties (except any royalties for the
BUYER'S Supplies), shall be for account of the BUILDER,
|
4.
|
HSE
Analysis, studies and
assessments
|
7
The BUYER
shall perform HSE Analysis, studies and assessments such as HAZID's, Risk
Analysis, HAZOP's, Readability and Vulnerability analysis, Working Environment
assessment of the DRILLSHIP.
If the
finding of such HSE Analysis, studies and assessments demand changes to the
design, layout and construction of the DRILLSHIP to make the DRILLSHIP meet the
requirements of the Contract, then the BUILDER shall implement such changes in
accordance with the findings.
Should
the findings lead the BUYER to request changes to the Contract then a Variation
Order shall be in accordance with Article V.
The
BUILDER shall be responsible for obtaining the Classification Society's approval
of all required plans and drawings of the DRILLSHIP.
|
5.
|
Subcontracting
|
The
BUILDER may, at its sole discretion and responsibility, subcontract any portion
of the construction work of the DRILLSHIP, provided that the work is carried out
at a reputable yard in Korea or at the BUILDER'S wholly owned subsidiaries at
Ningbo and Rongcheng in China, where the aggregate value of the works or
services to be subcontracted equals or is below Five million five hundred
thousand United States Dollars (US$ 5,500,000) but if exceeding such value the
BUILDER shall obtain in writing the prior approval of the BUYER (whose approval
shall not be unreasonably withheld), but any subcontracting shall always be
subject to the condition that the BUILDER shall ensure that the rights of the
BUYER and the requirements in the Contract are satisfied and provided for in
such work. The BUILDER shall not be relieved from any of its obligations and
liabilities under the Contract and shall be responsible for all work, acts,
omissions and defaults of any subcontractors as fully as if they were the work,
acts, omissions or defaults of the BUILDER.
|
6.
|
Registration:
|
The
DRILLSHIP, at the time of its delivery and acceptance, shall be registered at
the port of registry by the BUYER under the Malta flag at the BUYER'S
expenses.
(End of
Article)
8
ARTICLE
II - CONTRACT PRICE AND TERMS OF PAYMENT
|
1.
|
Contract
Price:
|
The
Contract price of the DRILLSHIP, net receivable by the BUILDER and exclusive of
the BUYER'S Supplies (as defined in Paragraph 1 of Article XVI hereof) is Six
Hundred Sixty One Million United States Dollars (US$ 661,000,000) (hereinafter
referred to as the "Contract Price"). The Contract Price shall be subject to
upward or downward adjustment, if any, as hereinafter set forth in this
Contract.
|
2.
|
Adjustment
of Contract Price:
|
Increase
or decrease of the Contract Price, if any, due to adjustments thereof made in
accordance with the provisions of this Contract shall be adjusted by way of
addition to or subtraction from the Contract Price upon delivery of the
DRILLSHIP in the manner as hereinafter provided at article III.
The BUYER
has the right to exercise the purchase the option as per Exhibit "6" within 3
months after the date of the signing contract. Should the BUYER exercise one of
the options, the payment terms of the exercised option items shall be same with
that of the Contract, provided that the amount of the first installment shall be
paid at the same time of the second installment is due, and the BUILDER will
reissue a Refundment Guarantee covering full amount of the adjusted Contract
Price to replace the old Refundment Guarantee.
|
3.
|
Currency:
|
Any and
all payments by the BUYER to the BUILDER, or vice versa if any, which are due
under this Contract shall be made in United States Dollars.
|
4.
|
Terms
of Payment:
|
The
Contract Price shall be due and payable by the BUYER to the BUILDER in the
installments as follows:
|
|
(a)
|
First
Installment:
|
The First
Installment shall be paid as follows:
9
(i) Ten
Million United States Dollars (US$ 10,000,000) shall be due and payable to the
BUILDER by the BUYER following signing of this Contract, within five (5) banking
days after the receipt of the original Refund Guarantee as provided for in
clause 5(a) below of this Article II.
(ii) The
BUYER and the BUILDER agree that Thirty Nine Million Five Hundred Seventy Five
Thousand United States Dollars (7.5% less US$ 10,000,000, US$39,575,000), shall
be due and payable to the BUILDER by the BUYER on March 24, 3008.
(iii) The
BUYER and the BUILDER agree that Forty Nine Million Five Hundred Seventy Five
Thousand United States Dollars (7.5%, US$ 49,575,000) shall be paid on April 24,
2008
|
|
(b)
|
Second
Installment:
|
The
Second Installment amounting to Ninety Nine Million ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇
▇▇▇▇▇▇ ▇▇▇▇▇▇ Dollars (15%, US$ 99,150,000) shall be due and payable on
September 24, 2008.
|
|
(c)
|
Third
Installment:
|
The Third
Installment amounting to Ninety Nine Million ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇
▇▇▇▇▇▇ Dollars (15%, US$ 99,150,000) shall be due and payable within three (3)
banking days from the receipt of the BUILDER'S invoice and a telefax notice from
the BUILDER, countersigned by the classification surveyor, certifying that steel
cutting for the Drillship has commence but not earlier than 16 months after the
second installment.
|
|
(d)
|
Fourth
Installment:
|
The
Fourth Installment amounting to Ninety Nine Million ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇
▇▇▇▇▇▇ ▇▇▇▇▇▇ Dollars (15%, US$ 99,150,000) shall be due and payable within
three (3) banking days from the the receipt of the BUILDER'S invoice and a
telefax notice from the Builder, countersigned by the classification surveyor,
certifying that keel laying for the DRILLSHIP has commenced but not earlier than
4 months after the third installment.
|
|
(e)
|
Fifth
Installment:
|
10
The Fifth
Installment amounting to Two Hundred Sixty Four Million Four Hundred Thousand
United States Dollars (40%, US$ 264,400,000) plus or minus any adjustment of the
Contract Price under and pursuant to the provisions of this Contract, shall be
due and payable upon delivery of the DRILLSHIP or upon tender for delivery of
the DRILLSHIP referred to in Paragraph 4 of Article VII of this
Contract.
The BUYER
and the BUILDER agree that if the Contract is terminated by the BUYER prior to
March 24, 2008, the BUILDER shall have the right to take part of the First
Installment amounting to Ten Million United States Dollars (US$ 10,000,000) but
shall have no other rights whatsoever under this Contract. If the Contract is
terminated by the BUYER after March 24, 2008 the rights of the BUILDER shall
remain as referred to in Articles X and XI of this Contract.
|
5.
|
Method
of Payment:
|
|
|
(a)
|
First
Installment:
|
Within
the due date and provided that the BUYER has received the Refundment Guarantee
five (5) banking days in advance, the BUYER shall remit by telegraphic transfer
the first installment to the account to be specified in advance in writing by
the BUILDER.
|
|
(b)
|
Second,
Third and Fourth Installments:
|
Upon the
due date of the second, third and fourth installments, in accordance with
Article II, 4 (b), (c) and (d) as appropriate, the BUYER shall remit by
telegraphic transfer each of the respective installments to the account to be
specified in advance in writing by the BUILDER.
|
|
(c)
|
Fifth
Installment:
|
At least
three (3) banking days prior to the anticipated delivery date of the DRILLSHIP,
the BUYER shall remit by telegraphic transfer the fifth installment to the bank
specified in advance in writing by the BUILDER in the name of the BUYER'S bank with
instructions of the amount so remitted to be payable to the BUILDER against a
copy of PROTOCOL OF DELIVERY and ACCEPTANCE OF THE DRILLSHIP signed by the BUYER
and the BUILDER.
11
Simultaneously
with each of all such payment, the BUYER shall cause the BUYER'S BANK to
advise the BUILDER'S BANK of
the details of such payments by authenticated bank cable or
telefax.
No
payment due under this Contract shall be delayed, suspended or withheld by the
BUYER on account of any dispute or disagreement between the parties hereto. Any
claim that the BUYER may have against the BUILDER hereunder shall be settled and
liquidated separately from any payment by the BUYER to the BUILDER
hereunder.
|
6.
|
Notice
of Payment before Delivery:
|
With the
exception of the first installment, the BUILDER shall give the BUYER Ten (10)
banking days prior notice in writing or telefax or telex of the anticipated due
date and amount of each installment payable on or before delivery of the
DRILLSHIP.
|
7.
|
Expenses:
|
Expenses
and bank charges for remitting payments and any taxes, duties, expenses and fees
referred to in paragraph 2 of Article XIV of this Contract connected with such
payment shall be for account of the BUYER.
|
8.
|
Prepayment:
|
Prepayment
of any installment due on or before delivery of the DRILLSHIP shall be subject
to mutual agreement between the parties hereto.
(End of
Article)
12
ARTICLE
III - ADJUSTMENT OF CONTRACT PRICE
The
Contract Price shall be subject to adjustment, as hereinafter set forth, in the
event of the following contingencies (it being understood by both parties that
any reduction of the Contract Price is by way of liquidated damages and not by
way of penalty):
|
1.
|
Delivery:
|
|
|
(a)
|
No
adjustment shall be made and the Contract Price shall remain unchanged for
the first 30 days of delay in delivery of the DRILLSHIP beyond the
Delivery Date as defined in Article VII hereof (ending as of twelve
o'clock midnight of the 31st
day of delay).
|
|
|
(c)
|
If
the delivery of the DRILLSHIP is delayed more than 30 days after the
Delivery Date, then, in such event, beginning at twelve o'clock midnight
of the 31st
day after the Delivery Date, the Contract Price shall be reduced by the
sum of Hundred and twenty thousand United States Dollars (US$ 120,000) for
each full day for which thereafter delivery is
delayed.
|
However,
the total reduction in the Contract Price pursuant to this Paragraph (b) shall
not be more than as would be the case for a delay of 180 days counting from
midnight of the 31st day
after the Delivery Date at the above specified rate of reduction.
|
|
(c)
|
However,
if the delay in delivery of the DRILLSHIP should continue for a period of
210 days from the Delivery Date in Paragraph 1 of Article VII, then in
such event, and after such period has expired, the BUYER may, at its
option, rescind this Contract in accordance with the provisions of Article
X hereof.
|
The
BUILDER may, at any time after the expiration of the aforementioned 210 days of
delay in delivery, if the BUYER has not served notice of rescission as provided
in Article X hereof, demand in writing that the BUYER shall make an election, in
which case the BUYER shall, within Twenty (20) days after such demand is
received by the BUYER, notify the BUILDER of its intention either to rescind
this Contract or to consent to the acceptance of the DRILLSHIP at a specified
future date which date BUILDER represents to BUYER is the earliest date BUILDER
can deliver the DRILLSHIP to BUYER under this Contract, based on the
circumstances then known. If the BUYER shall not make an election within Twenty
(20) days as
13
provided
hereinabove, the BUYER shall be deemed to have accepted such extension of the
delivery date to the future delivery date indicated by the BUILDER and it being
understood by the parties hereto that if the DRILLSHIP is not delivered by such
specified date, the BUYER shall have the same right of rescission upon the same
terms and conditions as hereinabove provided.
|
|
(d)
|
If,
at the time of actual delivery the BUYER has entered into an unconditional
charter contract providing for the immediate deployment of the DRILLSHIP
to provide services in return for the payment of cash consideration upon
delivery of the DRILLSHIP (the "Delivery Contract"), and, should Delivery
occur before twelve o'clock midnight on the Delivery Date and the third
party accepts to take such early delivery under the Delivery Contract,
then in such event, the final installment of the Contract Price shall be
increased by the sum of Seventy five thousand United States Dollars (US$
75,000) for each full day of early delivery, beginning at the time of
actual delivery of the DRILLSHIP until twelve o'clock midnight on July 31,
2011, provided that the aggregate increases to the Contract Price for
early delivery of the DRILLSHIP shall not exceed Three million United
States Dollars (US$ 3,000,000) (the
"Bonus").
|
|
|
(e)
|
For
the purpose of this Article, the delivery of the DRILLSHIP shall be deemed
to be delayed when and if the DRILLSHIP, after taking into account all
postponements of the Delivery Date by reason of permissible delay as
defined in Article VIII and/or any other reason under this Contract, is
not delivered by the date upon which delivery is required under the terms
of this Contract.
|
|
2.
|
Speed:
|
|
|
(a)
|
The
Contract Price shall not be affected or changed by reason of the trial
speed (as determined according to the Specifications) being less than the
guaranteed speed, if such variation is not more than 0.5
knots.
|
|
|
(b)
|
However,
commencing with and including such deficiency of 0.5 knots in trial speed
below the guaranteed speed of the DRILLSHIP, the Contract Price shall be
reduced by Eighty thousand United States Dollars (US$ 80,000) for each 0.1
knot below the guaranteed speed.
|
|
|
(c)
|
If
the deficiency in the speed upon final sea trial is more than one (1) knot
below the guaranteed speed of the DRILLSHIP, then the BUYER may, at its
option, reject the
|
14
DRILLSHIP
and rescind this Contract in accordance with the provisions of Article X hereof,
or may accept the DRILLSHIP at a reduction in the Contract Price at a rate of
▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ Dollars (U$ 100,000) for each 0.1 knot below
11.5 knots.
|
3.
|
Fuel
Consumption for the Diesel Generator Prime
Drivers:
|
|
|
(a)
|
The
Contract Price shall not be affected or changed in case the actual fuel
consumption for each engine, as determined by the shop trial as specified
in the Specifications, is not more than one percent (1%) in excess of the
Guaranteed Fuel Consumption specified in Paragraph 2 of Article
I.
|
|
|
(b)
|
However,
in the event that the actual fuel consumption of any engine at the shop
trial is in excess of one percent (1%) of the Guaranteed Fuel Consumption,
the Contract Price shall be reduced by the sum of Forty thousand United
States Dollars (US$ 40,000) for each one percent (1%) per engine by which
the actual fuel consumption of any engine exceeds the Guaranteed Fuel
Consumption plus One percent (1%).
|
|
|
(c)
|
The
BUYER has an option to reject the DRILLSHIP and rescind the Contract in
accordance with the provisions of Paragraphs 1, 2 and 3 of Article X
-RESCISSION BY BUYER hereof in the event the actual fuel consumption of
any engine is more than five percent (5%) in excess of the Guaranteed Fuel
Consumption.
|
|
4.
|
Variable
Load Capacity:
|
|
|
(a)
|
In
the event that the actual Variable Load Capacity of the DRILLSHIP is more
than 500 metric tons below the Guaranteed Variable Deck Load Capacity of
the DRILLSHIP, then the Contract Price shall be reduced by Four thousand
United States Dollars (US$ 4,000) per each metric ton of the shortfall
below 19,500 metric tons.
|
|
|
(b)
|
In
the event that the actual Variable Load Capacity of the DRILLSHIP is more
than 1,500 metric tons below the Guaranteed Variable Load Capacity of the
DRILLSHIP, then the BUYER may at its option reject the DRILLSHIP and
rescind the Contract in accordance with the provisions of Paragraphs 1, 2
and 3 of Article X
|
15
-
RESCISSION BY BUYER hereof or accept the DRILLSHIP at a reduction in the
Contract Price of Four million United States Dollars (US$
4,000,000).
|
5.
|
Effect
of Rescission:
|
It is
expressly understood and agreed by the parties that in any case, if the BUYER
rescinds this Contract under this Article, the BUYER shall not be entitled to
any liquidated damages, or any other recourse unless by means of the provisions
of Article X hereof.
(End of
Article)
16
ARTICLE
IV - APPROVAL OF PLANS AND DRAWINGS AND INSPECTION DURING
CONSTRUCTION
|
1.
|
Approval
of Plans and Drawings:
|
All plans
and drawings of HN.1837 shall be deemed to be approved and applicable to the
Drillship without any distinct approval procedure.
|
2.
|
Appointment
of BUYER'S
Supervisor:
|
The BUYER
may send to and maintain at the Shipyard, at the BUYER'S own cost
and expense, one supervisor (herein called the "Supervisor") who shall be duly
authorized in writing by the BUYER, which authorization shall be described in a
separate letter to be sent to the BUILDER prior to the Supervisor's arrival, to
act on behalf of the BUYER in connection with the modifications of the
Specifications, adjustments of the Contract Price and Delivery Date in writing,
approval of the plans and drawings, attendance to the tests and inspections
relating to the DRILLSHIP, its machinery, equipment and outfittings, and any
other matters for which he is specifically authorized by the BUYER. The
Supervisor may appoint assistant(s) to attend at the Shipyard for the purposes
as aforesaid. In the event that assignment, novation or resale occurs under the
Article XIII and as a result, BUYER'S Supervisor
is changed during the construction of the DRILLSHIP, any and all matters
determined by mutual agreement between the BUYER'S Supervisor
and the BUILDER prior to the dispatch of a new Supervisor shall be accepted and
complied by the new Supervisor. In case two or more Supervisors are dispatched
to the Shipyard and authorized to perform the supervision, each of them will
form uniform opinions between them to keep the design and specifications so as
not to adversely affect the Contract Price and Delivery of the DRILLSHIP. In the
event of any additional costs attributable to dispatch of two or more
Supervisors due to resale, novation, charter or any other occurrence otherwise
resulting from the BUYER side, such costs shall be solely borne by the BUYER and
the BUYER shall reimburse and hold harmless the BUILDER from any such costs and
expenses.
|
3.
|
Inspection
by the Supervisor:
|
The
necessary inspections of the DRILLSHIP, its machinery, equipment and outfittings
shall be carried out by the Classification Society, other regulatory bodies
and/or the Supervisor throughout the entire period of construction in order to
ensure that the design,
17
construction,
building, launching, equipping, testing and completion of the DRILLSHIP is duly
performed in accordance with the Contract and the Specifications.
The
BUILDER shall give a written notice to the Supervisors reasonably in advance of
the date and place of tests and inspections for the convenience of their
attendance. Failure of the Supervisors to be present at such tests and
inspections after due notice to them as above provided, shall be deemed to be a
waiver of their right to be present. In such cases, the BUYER shall be obliged
to accept the results of such tests and inspections on the basis of the
BUILDER'S
certificate subject to acceptance by the Classification
Society.
Whether
or not the Supervisors have been present, the BUILDER shall promptly deliver to
the BUYER or the Supervisors a copy of the results of all tests and
inspections.
For tests
or inspections outside the Shipyard sufficient advance notice to allow for the
Supervisor to arrange transportation shall be given. This advance notice should
not be less than three (3) days for tests or inspection that require air travel
for attendance.
The
inspection schedule must be reasonable at all times in order to allow the
Supervisor to carry out their duties properly and inspections must be spread
over reasonable time, but in follow building schedule at the same
rate.
BUILDER
may request BUYER'S Supervisor
to attend the inspection and tests during public holidays and weekends and/or
Company holidays in order to keep BUILDER'S
construction schedule. BUYER'S Supervisor
shall fully cooperate with BUILDER and promptly attend such inspection/tests
including those for surface preparation and painting work, which are especially
vulnerable to weather condition and time interval. However, BUILDER shall keep
such inspection and tests to a minimum and only when the inspection and tests
affect BUILDER'S
construction schedule. The BUILDER'S prior
notice of such inspection/test schedule shall be informed to the BUYER'S Supervisor
one (1) day in advance as a minimum.
If any of
the BUYER'S
Supervisors discover any construction, material or workmanship which is
not deemed to conform to the requirements of this Contract and/or the
Specifications, the BUYER'S
Supervisors shall promptly give the BUILDER a notice in writing that such
alleged non-conformity exists. Upon receipt of such notice from the BUYER'S
Supervisor, the BUILDER shall correct such non-conformity, if the BUILDER
agrees to his view. Any disagreement shall be resolved in accordance with
Paragraph 1
18
of
Article XII and shall to the extent possible not prevent the progress of the
construction and the timely delivery of the DRILLSHIP.
If,
following such disagreement, the Classification Society or the arbitrator enters
a determination in favor of the BUYER, then in such case the BUILDER shall
immediately correct such non-conformity subject to Article VI 4. (b). If the
Classification Society or the arbitrator enters a determination in favor of the
BUILDER, then the time for delivery of the DRILLSHIP shall be extended for the
period of any actual delay in construction, if any, occasioned by such
proceedings (but not by any time by which the period is extended owing to the
BUILDER's
own default), and the BUYER shall pay the BUILDER interest at the rate of
five percent (5%) per annum on the outstanding Instalments of the Contract Price
for the said period of delay.
In
working hours during construction of the DRILLSHIP until delivery thereof, the
BUYER's
Supervisors shall, subject to the reasonable requirements of the
Shipyard's work program and safety control, be permitted free and ready access
to the DRILLSHIP, her machinery and equipment, and to any other place where work
on the DRILLSHIP is being done, or materials are being processed or stored in
connection with the construction of the DRILLSHIP, including the yards,
workshops, stores and offices of the BUILDER, and the premises of subcontractors
of the BUILDER, who are doing work or storing materials in connection with the
DRILLSHIP's construction.
|
4.
|
Facilities:
|
The
BUILDER shall furnish the Supervisor and his assistant(s) with adequate office
space and such other reasonable facilities according to the BUILDER'S practice
at or in the immediate vicinity of the Shipyard as may be necessary to enable
them to effectively carry out their duties. The BUYER shall pay for all such
facilities other than office space at the BUILDER'S normal
rate of charge.
|
5.
|
Liability
of BUILDER:
|
The
BUILDER agrees to fully protect, defend, indemnify and hold BUYER harmless from
and against all liabilities, obligations, claims or actions for personal injury
or death arising out of performance by BUILDER or BUYER of their obligations
hereunder prior to the acceptance by BUYER of the DRILLSHIP, and asserted by or
on behalf of,
(i) any
employee, agent, contractor, or subcontractor of
BUILDER, or
19
(ii) any
employee of any agent, contractor, or subcontractor of BUILDER, regardless of
the basis of such claims and even if such claims should arise out of the sole or
concurrent fault or negligence of BUYER, or any employee, agent, contractor or
subcontractor of BUYER.
Similarly,
the BUYER agrees to fully protect, defend, indemnify and hold BUILDER harmless
from and against all liabilities, obligations, claims or actions for personal
injury or death arising out of performance by BUILDER or BUYER of their
obligations hereunder prior to the acceptance by BUYER of the DRILLSHIP, and
asserted by or on behalf of,
|
(i)
|
any
employee, agent, contractor, or subcontractor of
BUYER,
|
or
|
|
(ii)
|
any
employee of any agent, contractor, or subcontractor of BUYER, regardless
of the basis of such claims and even if such claims should arise out of
the sole or concurrent fault or negligence of BUILDER, or any employee,
agent or subcontractor of BUILDER.
|
|
6.
|
Responsibility
of BUYER:
|
The BUYER
shall undertake and assure that the Supervisor shall carry out his duties
hereunder in accordance with the normal shipbuilding practice of the BUILDER,
which BUILDER represents and confirms is in all material respects in accordance
with normal shipbuilding practice and in such a way so as to avoid any
unnecessary increase in building cost, delay in the construction of the
DRILLSHIP, and/or any disturbance in the construction schedule of the
BUILDER.
The
BUILDER has the right to request the BUYER to replace the Supervisor who is
deemed unsuitable and unsatisfactory for the proper progress of the DRILLSHIP's
design, construction, building, launching, equipping, and completion. The BUYER
shall investigate the situation by sending its representative(s) to the Shipyard
if necessary, and if the BUYER considers that such BUILDER'S request is
justified, the BUYER shall effect such replacement as soon as conveniently
possible.
|
7.
|
Delivery
and Construction Schedule:
|
Attached
hereto as Exhibit "3" is a tentative Delivery and Construction Schedule, and
within one hundred and eighty (180) days after the date of this Contract,
BUILDER shall deliver or cause to be delivered to BUYER a final Delivery and
Construction
20
Schedule
(herein, as from time to time amended with notice to the BUYER, referred to as
the "Schedule"), prepared in reasonable detailed schedule and setting forth the
estimated time table for the design, construction, building, launching,
equipping, testing and completion of the DRILLSHIP, it being understood that the
Schedule may be used by BUYER for purposes of verifying and measuring the
progress being made under the terms of this Contract. In the event the actual
progress of the construction of the DRILLSHIP is lagging behind the Schedule,
the BUILDER shall issue a recovery plan to overcome such lagging so that the
planned Delivery Date shall not be affected.
During
the course of performance of this Contract the BUILDER shall submit to the BUYER
on a monthly basis;
|
a)
|
a
status report on the DRILLSHIP's construction as compared with the
Schedule;
|
|
b)
|
a
report setting out the actual progress in performance of this Contract
during the previous month as compared with the Schedule, including monthly
progress photographs illustrating the progress of the
construction;
|
|
c)
|
a
list of modifications or changes (if any) agreed during the previous
month;
|
|
d)
|
a
document register showing the status of document preparation and planned
and actual completion of documents.
|
(End of
Article)
21
ARTICLE V
- MODIFICATIONS, CHANGES AND EXTRAS
|
1.
|
How
Effected:
|
The
Specifications may be modified and/or changed by written agreement of the
parties, however, that any modifications and/or changes requested by the BUYER
or an accumulation of such modifications and/or changes will not adversely
affect the BUILDER'S planning
or program in relation to the BUILDER'S other
commitments and if the BUYER shall assent to adjustment of the Contract Price,
time for delivery of the DRILLSHIP, other terms and conditions of this Contract
and the Specifications occasioned by or resulting from such modifications and/or
changes. The BUILDER hereby agrees to exert its best efforts to accommodate such
reasonable request by the BUYER so that the said changes and/or modifications
may be made at a reasonable cost and within the shortest period of time that is
reasonably possible.
Any such
agreement for modifications and/or changes shall include an agreement as to the
increase or decrease, if any, in the Contract Price of the DRILLSHIP together
with an agreement as to any extension or reduction in the time of delivery, or
any other alterations in this Contract or the Specifications occasioned by such
modifications and/or changes.
The
aforementioned agreement to modify and/or change the Specifications may be
effected by an exchange of letters signed by the authorized representatives of
the parties hereto, or telefax confirmed in writing, manifesting such agreement.
Such letters and confirmed message exchanged by the parties hereto pursuant to
the foregoing shall constitute an amendment of the Specifications, and such
letters and message shall be incorporated into this Contract and made a part
hereof.
The
failure of the parties to agree on the increase or decrease in the Contract
Price, or extension or reduction in the time of delivery, if any, for any
modifications or changes requested by the BUYER shall not prevent the BUILDER
from performing any agreed work so as not to prevent the proper progress of the
DRILLSHIP's design, construction, building, launching, equipping, testing and
completion, but shall be dealt with in accordance with Article
XII.
22
The
BUILDER may make minor changes to the Specifications, if found necessary for
introduction of improved production methods or otherwise, provided that the
BUILDER shall first obtain the BUYER'S approval
that shall not be unreasonably withheld.
|
2.
|
Changes
in Rules of Classification Society, Regulations,
etc.:
|
If, after
the Effective Date of the Contract of HN.1837, any requirements as to
Classification Society, or as to the rules and regulations to which the
construction of the DRILLSHIP is required to conform, are altered or changed by
the Classification Society or regulatory bodies authorized to make such
alterations or changes, either of the parties hereto, upon receipt of
information thereof, shall transmit such information in full to the other party
in writing within fourteen (14) days after receipt of the said information and
thereafter the BUYER shall instruct the BUILDER in writing if such alterations
or changes shall be made in the DRILLSHIP or not, in the BUYER'S sole
discretion.
|
|
(a)
|
However,
if such alterations or changes are compulsory for the construction of
DRILLSHIP, the BUILDER shall incorporate such alterations or changes into
the construction of the DRILLSHIP, provided that the parties shall agree
on any increase or decrease in the Contract Price, extension or reduction
in time of delivery of the DRILLSHIP and other terms and conditions of
this Contract and the Specifications occasioned by or resulting from such
alterations or changes.
|
|
|
(b)
|
If
such alterations or changes are not compulsory for the construction of the
DRILLSHIP, but the BUYER desires to incorporate such alterations or
changes into the construction of the DRILLSHIP, then the BUYER shall
notify the BUILDER in writing of such intention within fourteen (14) days
after receipt of the said information. The BUILDER shall accept such
alterations or changes, provided that the parties shall agree on any
increase or decrease in the Contract Price, extension or reduction in time
of delivery of the DRILLSHIP and other terms and conditions of this
Contract and the Specifications occasioned by or resulting from such
alterations or changes.
|
Such
agreement of the BUYER shall be effected in the same manner as provided in
Paragraph 1 of this Article for modifications and/or changes of the
Specifications. The failure of the parties to agree on the increase or decrease
in the Contract Price, or extension or reduction in the time of delivery, if
any, for any modifications or changes requested by the BUYER shall not prevent
the BUILDER from performing any agreed work so as not to prevent the proper
progress of the DRILLSHIP's design, construction,
23
building,
launching, equipping, testing and completion, but shall be dealt with in
accordance with Article XII.
|
3.
|
Substitution
of Materials:
|
In the
event that any of the materials required by the Specifications or otherwise
under this Contract for the construction of the DRILLSHIP can not be procured in
time to effect timely delivery of the DRILLSHIP, or are in short supply, (other
than as the result of any neglect or omission on the part of the BUILDER) the
BUILDER may, provided the BUYER so agrees in writing, supply other materials and
equipment of the best available and like quality, capable of meeting the
requirements of the Classification Society and of the rules, regulations,
requirements and recommendations with which the construction of the DRILLSHIP
must comply. Any agreement as to such substitution of materials shall be
effected in the manner as provided in Paragraph 1 of this Article, and shall,
likewise, include decrease or increase in the Contract Price and other terms and
conditions of this Contract affected by such substitution.
(End of
Article)
24
ARTICLE
VI - TRIALS AND ACCEPTANCE
|
1.
|
Notice:
|
The sea
trial shall start when the DRILLSHIP is reasonably completed in all material
respects according to the Specifications, and otherwise any and all tests or
trials shall be performed and notified as per the scope of the subsequent
Drillship of HN.1837 in accordance with the Specifications.
The
BUILDER shall give the BUYER at least Thirty (30) days estimated prior notice
and seven (7) days confirming prior notice in writing or by telefax confirmed in
writing of the time and place of the sea trial of the DRILLSHIP, and the BUYER
shall promptly acknowledge receipt of such notice. The BUYER shall have its
representative and his assistant(s) on board the DRILLSHIP to witness such sea
trial.
Failure
in attendance of the BUYER'S
representative at the sea trial of the DRILLSHIP for any reason
whatsoever after due notice to the BUYER as above provided shall be deemed to be
a waiver by the BUYER of its right to have its representative on board the
DRILLSHIP at the sea trial, and the BUILDER may conduct the sea trial without
attendance of the BUYER'S
representative, and in such case the BUYER shall be obligated to accept
the DRILLSHIP on the basis of certificates of the Classification Society and a
certificate of the BUILDER stating that the DRILLSHIP, upon sea trial, is found
to conform to this Contract and the Specifications.
|
2.
|
Weather
Condition:
|
The sea
trial and any other tests and trials of the DRILLSHIP as per the Specifications
shall be carried out under the weather condition that is deemed favorable enough
by the judgment of both the BUYER and the BUILDER and as per the Specifications.
In the event of unfavorable weather on the date specified for the sea trial or
other tests and trials as per the Specifications, the same shall take place on
the first available day thereafter that the weather condition permits. It is
agreed that, if during the sea trial or other tests and trials of the DRILLSHIP
as per the Specifications, the weather should suddenly become so unfavorable
that orderly conduct of the test or trial can no longer be continued, the test
or trial shall be discontinued and postponed until the first favorable day next
following, unless the BUYER shall assent in writing to acceptance of
the
25
DRILLSHIP
on the basis of the tests and trials already made before such discontinuance has
occurred.
Any delay
of sea trial caused by such unfavorable weather condition shall operate to
postpone the Delivery Date by the period of the delay involved and such delay
shall be deemed as permissible delay in the delivery of the
DRILLSHIP.
|
3.
|
How
Conducted:
|
|
|
(a)
|
The
sea trial and any other tests and trials as per the Specifications shall
be conducted in the manner prescribed in the Specifications, and shall
prove full fulfillment of the performance requirements for the trial run
as set forth in the Specifications.
|
|
|
(b)
|
All
risk and expenses in connection with the sea trial and any other tests and
trials are to be for account of the BUILDER and the BUILDER shall provide,
at its own expense, fuel oil, lubes, stores and the necessary crew to
comply with conditions of safe
navigation.
|
|
|
(c)
|
Notwithstanding
above (b), the BUYER shall provide drilling crews at it's own expense
during tests and trials for drilling system. The crews shall perform the
tests and trials under the BUILDER's
responsibility and risk and familiarized themselves with the system
for the final take over of the
Drillship.
|
|
4.
|
Method
of Acceptance or Rejection.
|
|
|
(a)
|
Upon
completion of the sea trial, the BUILDER shall give the BUYER a notice by
telefax of completion of the trial run, as and if the BUILDER considers
that the results of trial run indicate conformity of the DRILLSHIP to this
Contract and the Specifications. The BUYER shall, within Five (5) days
after receipt of such notice from the BUILDER, notify the BUILDER by
telefax of its acceptance or rejection of the DRILLSHIP's conformity to
this Contract and Specifications.
|
|
|
(b)
|
However,
if the result of the sea trial is unacceptable, or if the DRILLSHIP, or
any part or equipment thereof, (except a defect in the BUYER'S
supplies not being the responsibility of the BUILDER) does not
conform to the requirements of this Contract and/or the Specifications, or
if the BUILDER is in agreement to
non-
|
26
conformity
as specified in the BUYER'S notice of
rejection, then, the BUILDER shall take necessary steps to correct such
non-conformity.
Upon
completion of correction of such non-conformity, and re-test or trial if
necessary, the BUILDER shall give the BUYER notice thereof by telefax confirmed
in writing.
The BUYER
shall, within Five (5) days after receipt of such notice from the BUILDER,
notify the BUILDER of its acceptance or rejection of the DRILLSHIP.
|
(c)
|
In
the event that the BUYER rejects the DRILLSHIP, the BUYER shall indicate
in detail in its notice of rejection in what respect the DRILLSHIP, or any
part or equipment thereof (except a defect in the BUYER'S
supplies not the responsibility of the BUILDER) does not conform to
this Contract and/or the
Specifications.
|
|
(d)
|
In
the event that the BUYER fails to notify the BUILDER by telefax confirmed
in writing of the acceptance of or the rejection together with the reason
therefore of the DRILLSHIP within the period as provided in the above
Sub-paragraph (a) or (b), the BUYER shall be deemed to have accepted the
trial results and/or the DRILLSHIP, as
appropriate.
|
|
(e)
|
Any
dispute between the BUILDER and the BUYER as to the conformity or
nonconformity of the DRILLSHIP to the requirements of this Contract
and/or the Specifications shall be submitted for final decision in
accordance with Article XII
hereof.
|
|
(f)
|
The
BUYER shall not be entitled to refuse acceptance of the DRILLSHIP by
reason of any minor or insubstantial non-conformity with this Contract and
the Specifications. For the purpose of this Sub-paragraph, a minor or
insubstantial nonconformity shall mean a non-conformity that does not
impair the safe or efficient operation of the DRILLSHIP and shall exclude
any non-conformities affecting compliance with the rules and regulations
of the Classification Society and other relevant Regulatory Bodies of the
DRILLSHIP as defined in the Specifications. The BUILDER shall remain
obliged to correct and/or remedy such minor or insubstantial
non-conformities as soon as reasonably possible following delivery of the
DRILLSHIP.
|
|
5.
|
Effect
of Acceptance:
|
27
Acceptance
of the DRILLSHIP as above provided shall be final and binding so far as
conformity of the DRILLSHIP to this Contract and the Specifications is concerned
and shall preclude the BUYER from refusing formal delivery of the DRILLSHIP as
hereinafter provided, if the BUILDER complies with all other procedural
requirements for delivery as provided in Article VII hereof. However, the
BUYER'S
acceptance of the DRILLSHIP shall not affect the BUYER'S rights
under Article IX hereof.
|
6
|
Disposition
of Surplus Consumable Stores:
|
Any fuel
oil furnished and paid for by the BUILDER for sea trial remaining on board
including in systems and pipes of the DRILLSHIP, at the time of acceptance of
the DRILLSHIP by the BUYER, shall be bought by the BUYER from the BUILDER at the
BUILDER'S
purchase price for such supply in Korea and payment by the BUYER thereof
shall be made at the time of delivery of the DRILLSHIP.
The
BUILDER shall pay the BUYER at the time of delivery of the DRILLSHIP an amount
for the consumed quantity during sea trial of any lubricating oil and greases
which were furnished and paid for by the BUYER, if any, at the BUYER'S purchase
price thereof.
(End of
Article)
28
ARTICLE
VII – DELIVERY
|
1.
|
Time
and Place:
|
The
DRILLSHIP shall be delivered by the BUILDER to the BUYER at the Shipyard on or
before July 31, 2011 (unless delays occur in the construction of the DRILLSHIP
or in any performance required under this Contract due to causes which under the
terms of this Contract permit postponement of the date of delivery, in which
event, the aforementioned date for delivery of the DRILLSHIP shall be changed
accordingly) or, such earlier date after completion of the DRILLSHIP according
to this Contract and the Specifications.
The
aforementioned date, or such earlier or later date to which the requirement of
delivery is advanced or postponed pursuant to this Contract, is herein called
the "Delivery Date".
|
2.
|
When
and How Effected:
|
Provided
that the BUILDER and the BUYER shall have fulfilled all of their obligations
stipulated under this Contract, the delivery of the DRILLSHIP shall be effected
forthwith by the concurrent delivery by each of the parties hereto to the other
of the PROTOCOL OF DELIVERY AND ACCEPTANCE, acknowledging delivery of the
DRILLSHIP by the BUILDER and acceptance thereof by the BUYER.
|
3.
|
Documents
to be delivered to BUYER:
|
Upon
delivery and acceptance of the DRILLSHIP, the BUILDER shall deliver to the BUYER
the following documents, which shall accompany the PROTOCOL OF DELIVERY AND
ACCEPTANCE.
|
|
(a)
|
PROTOCOL
OF TRIALS of the DRILLSHIP made pursuant to the
Specifications.
|
|
|
(b)
|
PROTOCOL
OF INVENTORY of the equipment of the DRILLSHIP, including spare parts and
the like, as specified in the
Specifications.
|
|
|
(c)
|
PROTOCOL
OF STORES OF CONSUMABLE NATURE referred to under paragraph 6 of Article VI
hereof.
|
29
|
|
(d)
|
ALL
CERTIFICATES including the BUILDER'S
CERTIFICATE required to be furnished upon delivery of the DRILLSHIP
pursuant to this Contract and the
Specifications.
|
It is
agreed that if, through no fault on the part of the BUILDER, the Classification
certificates and/or other certificates are not available at the time of delivery
of the DRILLSHIP, provisional certificates shall be accepted by the BUYER,
provided that the BUILDER shall furnish the BUYER with the formal certificates
as promptly as possible after such certificates have been issued.
Application
and certificate for statutory inspections for the registry of the DRILLSHIP
shall be arranged by the BUYER at its expense.
|
|
(e)
|
DECLARATION
OF WARRANTY of the BUILDER that the DRILLSHIP is delivered to the BUYER
free and clear of any liens, charges, claims, mortgages, or other
encumbrances upon the BUYER'S
title thereto, and in particular that the DRILLSHIP is absolutely
free of all burdens in the nature of imposts, taxes or charges imposed by
Korean Governmental Authorities or any other Authorities, as well as all
liabilities of the BUILDER to its subcontractors, employees and crew, and
of all the liabilities arising from the operation of the DRILLSHIP in
trial runs, or otherwise, prior to
delivery.
|
|
|
(f)
|
DRAWINGS
AND PLANS and any other technical documentation pertaining to the
DRILLSHIP as stipulated in the
Specifications
|
|
|
(g)
|
COMMERCIAL
INVOICE.
|
|
|
(h)
|
▇▇▇▇
of Sale to be notarized and
apostiled
|
|
|
(i)
|
Builder's
Resolution of Board of Directors to be notarized and
apostiled
|
|
|
(j)
|
Power
of Attorney to be notarized and
apostiled
|
|
|
(k)
|
Goodstanding
Certificate
|
|
|
(1)
|
Confirmation
by ABS to Malta Maritime Authority
|
|
|
(m)
|
Builder's
Certificate
|
|
4.
|
Tender
of DRILLSHIP:
|
If the
BUYER fails to take delivery of the DRILLSHIP after completion thereof according
to this Contract and the Specifications without any justifiable reason,
the
30
BUILDER
shall have the right to tender delivery of the DRILLSHIP after accomplishment of
all BUILDER'S obligations as provided herein.
|
5.
|
Title
and Risk:
|
Title to
and risk of loss of the DRILLSHIP shall pass to the BUYER only upon the delivery
and acceptance thereof having been completed as stated above; it being expressly
understood that, until such delivery is effected, title to and risk of damage to
or loss of the DRILLSHIP and her equipment shall be in the BUILDER.
|
6.
|
Removal
of DRILLSHIP:
|
The BUYER
shall take possession of the DRILLSHIP immediately upon delivery and acceptance
thereof and shall remove the DRILLSHIP from the premises of the Shipyard within
Three (3) days after delivery and acceptance thereof is effected.
If the
BUYER shall not remove the DRILLSHIP from the premises of the Shipyard within
the aforesaid Three (3) days, in such event, the BUYER shall pay to the BUILDER
the reasonable mooring charges of the DRILLSHIP.
(End of
Article)
31
ARTICLE
VIII - DELAYS AND EXTENSION OF TIME FOR DELIVERY (FORCE
MAJEURE)
|
1.
|
Causes
of Delay (Force Majeure):
|
If, at
any time either the construction or delivery of the DRILLSHIP or any performance
required hereunder as a prerequisite to the delivery thereof is delayed by any
of the following events; namely war, acts of state or government, blockade,
revolution, insurrections, mobilization, civil commotion, riots, strikes,
sabotage, lockouts, Acts of God or the public enemy, plague or other epidemics,
quarantines, prolonged failure of electric current, freight embargoes, or
defects in major forgings or castings, if any, or shortage of materials,
machinery or equipment in inability to obtain delivery or delays in delivery of
materials, machinery or equipment other than resulting from any act, omission or
improvidence of the BUILDER or its agents, employees or Subcontractors, provided
that at the time of ordering the same could reasonably be expected by the
BUILDER to be delivered in time, or defects in materials, machinery or equipment
which could not have been detected by the BUILDER using reasonable
care, or earthquakes, tidal waves, typhoons, hurricanes, prolonged or
unusually severe weather conditions or delay in the construction of the
BUILDER'S other new-building projects in the same dry-dock due to any such
causes as described in this Article which in turn delay the keel laying and
eventual delivery of the DRILLSHIP in view of the Shipyard's overall building
program or the BUILDER'S performance under this Contract, or by destruction of
the premises or works of the BUILDER or its sub-contractors, or of the
DRILLSHIP, or any part thereof, by fire, landslides, flood, lightning,
explosion, or other causes beyond the control of the BUILDER, or its
sub-contractors, as the case may be, or for any other causes which, under terms
of this Contract, authorize and permit extension of the time for delivery of the
DRILLSHIP, then, in the event of delays due to the happening of any of the
aforementioned contingencies, the Delivery Date of the DRILLSHIP under this
Contract shall be extended for a period of time which shall not exceed the total
accumulated time of all such delays.
The
BUILDER'S entitlement to extension of the Delivery Date due to any of the
aforesaid events shall, however, always be subject to the delay, or any part of
the delay, not being caused by the BUILDER'S error, neglect, act or omission or
that of its agents, employees or Subcontactors, and that the BUILDER having
taken all reasonable steps to mitigate the effect of the event upon the Delivery
Date.
32
|
2.
|
Notice
of Delay:
|
Within
Ten (10) days after the date of occurrence of any cause of delay, on account of
which the BUILDER claims that it is entitled under this Contract to a
postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing
or by telefax confirmed in writing of the date when such cause of delay
occurred. Likewise, within Ten (10) days after the date of ending of such cause
of delay, the BUILDER shall notify the BUYER in writing or by telefax confirmed
in writing of the date when such cause of delay ended.
The
BUILDER shall also notify promptly the BUYER of the period, by which in their
opinion the Delivery Date is postponed by reason of such cause of delay. If the
BUILDER does not give the timely advice as above, the BUILDER shall lose the
right to claim such delays as permissible delay.
Failure
of the BUYER to acknowledge to the BUILDER's claim for postponement of the
Delivery Date within Ten (10) days after receipt by the BUYER of such notice of
claim shall be deemed to be a waiver by the BUYER of its right to object to such
postponement of the Delivery Date.
|
3.
|
Definition
of Permissible Delay:
|
Delays on
account of such causes as specified in Paragraph 1 of this Article and any other
delay of a nature which under the terms of this Contract permits postponement of
the Delivery Date shall be understood to be permissible delays and are to be
distinguished from unauthorized delays on account of which the Contract Price is
subject to adjustment as provided for in Article III hereof.
|
4.
|
Right
to Rescind for Excessive
Delay:
|
If the
total accumulated time of all delays claimed by the BUILDER on account of the
causes specified in Paragraph 1 of this Article, excluding other delays of the
nature which under the terms of this Contract permit postponement of the
Delivery Date, amounts to Two Hundred and Ten (210) days or more, then, in such
event, the BUYER may rescind this Contract in accordance with the provisions of
Article X hereof.
The
BUILDER may, at any time after the accumulated time of the aforementioned delays
justifying rescission by the BUYER, demand in writing that the BUYER
shall
33
make an
election, in which case the BUYER shall, within Fourteen (14) working days after
such demand is received by the BUYER either notify the BUILDER of its intention
to rescind this Contract, or consent to a postponement of the Delivery Date to
an agreed specific future date, which date BUILDER represents to BUYER is the
earliest date BUILDER can deliver the DRILLSHIP to BUYER, based on the
circumstances then known, it being understood by the parties hereto that if the
DRILLSHIP is not delivered by such future date, the BUYER shall have the same
right of rescission upon the same terms and conditions as hereinabove
provided.
(End of
Article)
34
ARTICLE
IX - WARRANTY OF QUALITY
|
1.
|
Guarantee:
|
The
BUILDER, for the period of Twelve (12) months after delivery of the DRILLSHIP
(hereinafter called "Guarantee Period"), guarantees the DRILLSHIP and her
engines, including all parts and equipment manufactured, furnished or installed
by the BUILDER or its subcontractors under this Contract, and including the
machinery, equipment and appurtenances thereof (including the installation work
performed or required to be performed by BUILDER under this Contract for the
BUYER supplied or furnished equipment), under the Contract but excluding any
item which is supplied or designated by the BUYER or by any other bodies on
behalf of the BUYER, against all defects discovered within the Guarantee Period
which are due to defective material, design and/or poor workmanship or negligent
or other improper acts or omissions on the part of the BUILDER or its
subcontractors (hereinafter called the "Defect" or "Defects") and are not a
result of accident, ordinary wear and tear, misuse, mismanagement, negligent or
other improper acts or omissions or neglect on the part of the BUYER, its
employee or agents.
|
2.
|
Notice
of Defects:
|
The BUYER
shall notify the BUILDER in writing, or by telefax confirmed in writing, of any
Defect for which claim is made under this guarantee, as promptly as possible
after discovery thereof. The BUYER'S written notice shall describe the nature,
cause and extent of the Defects.
The
BUILDER shall have no obligation for any Defect discovered prior to the expiry
date of the Guarantee Period, unless notice of such Defect is received by the
BUILDER not later than Fourteen (14) working days after the expiry of the
Guarantee Period.
|
3.
|
Remedy
of Defects:
|
|
(a)
|
The
BUILDER shall remedy, at its expense, any Defect against which the
DRILLSHIP is guaranteed under this Article, by making all necessary
repairs or replacements at the
Shipyard.
|
35
|
(b)
|
However,
if it is impracticable to bring the DRILLSHIP to the Shipyard, the BUYER
may cause the necessary repairs or replacements to be made elsewhere which
is deemed suitable for the purpose, provided that, in such event, the
BUILDER may forward or supply replacement parts or materials to the
nearest airport or port from the DRILLSHIP, unless forwarding or supplying
thereof would impair or delay the operation or working schedule of the
DRILLSHIP. In the event that the BUYER proposes to cause the necessary
repairs or replacements for the DRILLSHIP to be made at any other shipyard
or works than the Shipyard, the BUYER shall first, but in all events as
soon as possible, give the BUILDER notice in writing or by telefax
confirmed in writing of the time and place when and where such repairs
will be made, and if the DRILLSHIP is not thereby delayed, or her
operation or working schedule is not thereby impaired, the BUILDER shall
have the right to verify by its own representative(s) the nature, cause
and extent of the Defects complained of. The BUILDER shall, in such case,
promptly advise the BUYER by telefax or telex after such examination has
been completed, of its acceptance or rejection of the Defects as ones that
are covered by the guarantee herein provided. Upon the BUILDER's
acceptance of the Defects as justifying remedy under this Article, or upon
award of the arbitration so determining, the BUILDER shall compensate the
BUYER for such repairs or replacements a sum
equal to the necessary and
reasonable cost of making the same
repairs or replacements in a competent shipyard at a reasonable
location, at the prices prevailing at the time of such repairs or
replacements are made. The reimbursement of the cost incurred in relation
to guarantee works shall be paid after the repairs or replacements are
made but if not made or the costs incurred for each such repair or
replacement is below US$ 100,000, such costs shall be paid at the
expiration of the guarantee
period.
|
|
(c)
|
The
BUILDER guarantees repairs or replacements to the DRILLSHIP made under the
guarantee in paragraph 1 of this Article for a further period of Twelve
(12) months from the date of completion of such repair or replacement. In
any case, the maximum guarantee period shall not exceed Eighteen (18)
months.
|
|
(d)
|
In
any case, the DRILLSHIP shall be taken, at the BUYER'S cost and
responsibility, to the place elected, ready in all respects for such
repairs or replacement.
|
|
(e)
|
Any
dispute under this Article shall be referred to arbitration in accordance
with the provisions of Article XII
hereof.
|
36
|
4.
|
Extent
of BUILDER'S Responsibility
|
|
(a)
|
The
BUILDER shall have no responsibility or liability for any other defect
whatsoever in the DRILLSHIP than the Defects specified in Paragraph 1 of
this Article, Nor the BUILDER shall in any circumstance be responsible or
liable for any consequential or special loss, damage or expense including
but not limited to loss of time, loss of profit of earning or demurrage
directly or indirectly occasioned to the BUYER by reason of the Defects
specified in Paragraph 1 of this Article or due to repairs or other works
done to the DRILLSHIP to remedy such
Defects.
|
|
(b)
|
The
BUILDER shall not be responsible for any defect in any part of the
DRILLSHIP which may, subsequently to delivery of the DRILLSHIP, have been
replaced or repaired in any way by any other contractor, or for any defect
which have been caused or aggravated by omission or improper use and
maintenance of the DRILLSHIP on the part of the BUYER, its servants or
agents or by ordinary wear and tear or by any other reason beyond control
of the BUILDER.
|
|
(c)
|
The
guarantee contained as hereinabove in this Article replaces and excludes
any other liability, guarantee, warranty and/or condition imposed or
implied by the law, customary, statutory or otherwise, by reason of the
construction and sale of the DRILLSHIP by the BUILDER for and to the
BUYER.
|
(End of
Article)
37
ARTICLE X
- RESCISSION BY BUYER
|
1.
|
Notice:
|
The
payments made by the BUYER prior to delivery of the DRILLSHIP shall be in the
nature of advances to the BUILDER, and in the event that the DRILLSHIP is
rejected by the BUYER or the Contract is rescinded by the BUYER in accordance
with the terms of this Contract under and pursuant to any of the provisions of
this Contract specifically permitting the BUYER to do so, then the BUYER shall
notify the BUILDER in writing or by telefax confirmed in writing, and such
rescission shall be effective as of the date when notice thereof is received by
the BUILDER.
|
2.
|
Refundment
by BUILDER:
|
In case
the BUILDER receives the notice stipulated in Paragraph 1 of this Article, the
BUILDER shall promptly refund to the BUYER the full amount of all sums paid by
the BUYER to the BUILDER on account of the DRILLSHIP, together with the interest
thereon, unless the BUILDER proceeds to the arbitration under the provisions of
Article XII hereof. The BUILDER shall also return any BUYER'S Supplies, or if
such cannot be returned, the BUILDER shall pay to the BUYER an amount equal to
the BUYER's costs for such equipment.
In the
event of such rescission by the BUYER, the BUILDER shall pay the BUYER interest
at the rate of six percent (6%) per annum on the amount required herein to be
refunded to the BUYER, computed from the respective dates on which such sums
were paid by the BUYER to the BUILDER to the date of remittance by transfer of
such refund to the BUYER by the BUILDER, provided, however, that if the said
rescission by the BUYER is made under the provisions of Paragraph 4 of Article
VIII hereof, then in such event the BUILDER shall pay the BUYER interest at the
rate of four and a half percent (4.5%) per annum on the sums
refundable.
As
security for refund of installments prior to delivery of the DRILLSHIP, the
BUILDER shall furnish to BUYER, prior to the due date of the first installment,
with an irrevocable letter of guarantee covering the amount of such pre-delivery
installments and issued by KEXIM, KDB, or a bank acceptable to the BUYER in
favour of the BUYER. Such letter of guarantee shall have substantially the same
form and substance as Exhibit "4" annexed hereto.
38
|
3.
|
Discharge
of Obligations:
|
Upon such
refund by the BUILDER to the BUYER, all obligations, duties and liabilities of
each of the parties hereto to the other under this Contract shall be forthwith
completely discharged, without prejudice, however, to any claims either party
may have resulting from the other party's breach of any of its obligations under
this Contract.
(End of
Article)
39
ARTICLE
XI - BUYER'S DEFAULT
|
1.
|
Definition
of Default:
|
The BUYER
shall be deemed to be in default of its performance of obligations under this
Contract in the following cases:
|
(a)
|
If
the first installment is not paid in full by the BUYER within the due date
specified in Article II. 4 (a) after the receipt of original Refundment
Guarantee or if any of the second, third or fourth installment is not paid
in full by the BUYER to the BUILDER within Three (3) banking days in New
York after such installment becomes due and payable as provided in Article
II hereof; or
|
|
(b)
|
If
a performance guarantee by Cardiff Marine Inc. is not presented to the
BUILDER within 5 banking days from the Effective Date of this
Contract.
|
|
(c)
|
If
the fifth installment, after adjustment pursuant to the relevant
provisions of this Contract, is not paid in full by the BUYER to the
BUILDER concurrently with the delivery of the DRILLSHIP as provided in
Article II hereof; or
|
|
(d)
|
If
the BUYER, when the DRILLSHIP is duly tendered for delivery by the BUILDER
in accordance with the provisions of this Contract, fails to accept the
DRILLSHIP within Five (5) days from the tendered date without any specific
and valid ground thereof under this
Contract.
|
|
2.
|
Effect
of Default on or before Delivery of
DRILLSHIP:
|
|
(a)
|
Should
the BUYER make default in payment of any installment of the Contract Price
on or before delivery of the DRILLSHIP, the BUYER shall pay the
installment(s) in default plus accrued interest thereon at the rate of six
percent (6%) per annum computed from the due date of such installment
provided in Paragraph 4 of Article II hereof up to the date when the
BUILDER receives the payment, and, for the purpose of Paragraph 1 of
Article VII hereof, the Delivery Date of the DRILLSHIP shall be
automatically extended by a period of continuance of such default by the
BUYER.
|
In any
event of default by the BUYER, the BUYER shall also pay all charges
and
40
expenses
incurred to the BUILDER in direct consequence of such
default.
|
(b)
|
If
any default by the BUYER continues for a period of Fifteen (15) days, the
BUILDER may, at its option, rescind this Contract by giving notice of such
effect to the BUYER by telefax confirmed in
writing.
|
Upon
dispatch by the BUILDER of such notice of rescission, this Contract shall be
forthwith rescinded and terminated. In the event of such rescission of this
Contract, the BUILDER shall be entitled to retain any installment or
installments already paid by the BUYER to the BUILDER on account of this
Contract and the BUYER'S Supplies already delivered to the Shipyard, if
any.
|
3.
|
Disposal
of DRILLSHIP:
|
|
(a)
|
In
the event that this Contract is rescinded by the BUILDER under the
provisions of Paragraph 2(b) of this Article, the BUILDER may, at its sole
discretion, either complete the DRILLSHIP and sell the same, or sell the
DRILLSHIP in its incomplete state, free of any right or claim
of the BUYER. Such sale of the DRILLSHIP by the BUILDER shall be either by
public auction or private contract at the BUILDER'S sole discretion and on
such terms and conditions as the BUILDER shall deem
fit.
|
|
(b)
|
In
the event of such sale of the DRILLSHIP, the amount of the sale received
by the BUILDER shall be applied firstly to all expenses attending such
sale or otherwise incurred to the BUILDER as a result of the BUYER'S
default, secondly to the payment of all costs and expenses of construction
of the DRILLSHIP incurred to the BUILDER less BUYER'S Supplies and the
installments already paid by the BUYER, and then to the compensation to
the BUILDER for a reasonable cost due to rescission of this Contract, and
finally to the repayment to the BUYER if any balance is
obtained.
|
|
(c)
|
If
the proceeds of sale are insufficient to pay such total costs and loss of
profit as aforesaid, the BUYER shall promptly pay the deficiency to the
BUILDER upon request.
|
(End of
Article)
41
ARTICLE
XII - ARBITRATION
|
1.
|
Decision
by the Classification
Society:
|
If any
dispute arises between the parties hereto in regard to the design and/or
construction of the DRILL SHIP, its machinery and equipment, and/or in respect
of the materials and/or workmanship thereof and/or thereon, and/or in respect of
interpretations of this Contract or the Specifications, the parties may by
mutual agreement refer the dispute to the Classification Society or to such
other expert as may be mutually agreed between the parties hereto, and whose
decision shall be final, conclusive and binding upon the parties
hereto.
|
2.
|
Proceedings
of Arbitration in London UK,:
|
In the
event that the parties hereto do not agree to settle a dispute according to
Paragraph 1 of this Article and/or in the event of any other dispute of any kind
whatsoever between the parties and relating to this Contract, including any
dispute regarding its validity and existence, or its rescission or any
stipulation herein, such dispute shall be submitted to arbitration in
London.
If the
dispute or difference does not exceed the sum of Five Hundred Thousand United
States Dollars (US$ 500,000) the arbitration shall be conducted in accordance
with the London Maritime Arbitrators Association's Small Claims Procedure
current at the time when the arbitration proceedings are
commenced.
For
disputes of value above Five Hundred Thousand United States Dollars (US$
500,000) each party shall appoint an arbitrator and in the event that they
cannot agree, the two arbitrators so appointed shall appoint an
Umpire.
If the
two arbitrators are unable to agree upon an Umpire within Twenty (20) days after
appointment of the second arbitrator, either of the said two arbitrators may
apply to the President for the time being of the London Maritime Arbitrators
Association to appoint the Umpire, and the two arbitrators and the Umpire shall
constitute the Arbitration Board.
Such
arbitration shall be in accordance with and subject to the provisions of the
British Arbitration ▇▇▇ ▇▇▇▇, or any statutory modification or re-enactment
thereof for the time
42
being in
force.
Either
party may demand arbitration of any such dispute by giving notice to the other
party. Any demand for arbitration by either of the parties hereto shall state
the name of the arbitrator appointed by such party and shall also state
specifically the question or questions as to which such party is demanding
arbitration.
Within
Fourteen (14) days after receipt of notice of such demand for arbitration, the
other party shall in turn appoint a second arbitrator and give notice in writing
of such appointment to the party demanding arbitration. If a party fails to
appoint an arbitrator as aforementioned within Fourteen (14) days following
receipt of notice of demand for arbitration by the other party, the party
failing to appoint an arbitrator shall be deemed to have accepted and appointed,
as its own arbitrator, the arbitrator appointed by the party demanding
arbitration and the arbitration shall proceed before this sole arbitrator who
alone in such event shall constitute the Arbitration Board.
The award
of the Arbitration Board shall be final and binding on both
parties.
|
3.
|
Notice
of Award:
|
The award
decision shall immediately be communicated to the BUYER and the BUILDER by
facsimile and confirmed in writing.
|
4.
|
Expenses:
|
The
Arbitration Board shall determine which party shall bear the expenses of the
arbitration or the portion of such expenses that each party shall
bear.
|
5.
|
Entry
in Court:
|
In case
of failure by either party to respect the award of the arbitration, the judgment
may be entered in any proper court having jurisdiction
thereof.
|
6.
|
Alteration
of Delivery Date:
|
In the
event of reference to arbitration of any dispute arising out of matters
occurring prior to delivery of the DRILLSHIP, the award may include any
adjustment of the Delivery Date that the Arbitration Board may deem
appropriate.
43
(End of
Article)
44
ARTICLE
XIII - SUCCESSOR AND ASSIGNS
The
BUILDER agrees that, prior to delivery of the DRILLSHIP, this Contract may, with
the prior written approval of the BUILDER, which the BUILDER shall not
unreasonably withhold, be transferred to and the title thereof may be taken by
another company.
In the
event of any assignment or novation pursuant to the terms of this Contract, the
assignee shall succeed to all of the rights and obligations of the assignor
under this Contract and the assignor shall remain responsible for the
fulfillment of this Contract.
In the
event of the assignment or novation from the BUYER to any other individual or
company pursuant to this provision, the BUILDER shall be entitled to request
issuance of a Performance Guarantee from the BUYER having identical form and
contents as Exhibit "5" annexed hereto.
In the
event of any resale, assignment or novation of the Contract, any and all matters
determined by mutual agreement between the BUYER and the BUILDER prior to the
resale, assignment or novation of the Contract shall be accepted and complied by
the New BUYER (i.e., assignee). If the New BUYER or its Supervisor makes
unreasonable requests that may have a significant impact on the delivery
schedule of the DRILLSHIP and/or costs of construction (including, without
limitation to, request for substantial change of ship type or excessive revision
of design specification, etc.), the BUILDER shall be entitled to withhold its
consent to the resale, assignment or novation of the Contract but in such
situation the BUILDER may grant at its option consent to such resale, assignment
or novation if the New BUYER will bear any and all direct and indirect costs
attributable to such requests and changes resulting
therefrom.
(End of
Article)
45
ARTICLE
XIV - TAXES AND DUTIES
|
1.
|
Taxes
and Duties Incurred in Korea and /or
China:
|
The
BUILDER shall bear and pay all taxes, duties, stamps and fees incurred in Korea
and/or China in connection with execution and/or performance of this Contract as
the BUILDER, except for any taxes and duties imposed in Korea and/or China upon
the BUYER'S Supplies.
|
2.
|
Taxes
and Duties Incurred Outside Korea and or
China:
|
The BUYER
shall bear and pay all taxes, duties, stamps and fees incurred outside Korea
and/or China in connection with execution and/or performance of this Contract as
the BUYER, except for taxes and duties imposed upon those items to be procured
by the BUILDER for construction.
(End of
Article)
46
ARTICLE
XV - PATENTS, TRADEMARKS, COPYRIGHTS, ETC.
|
1.
|
Patents:
|
BUILDER
agrees to defend, indemnify and hold BUYER harmless from any liability or claims
of infringement of patent rights, utility model rights, trade ▇▇▇▇ rights or
copyrights, or any other intellectual property rights of any third party
relating to the construction and supply of the DRILLSHIP.
With
regard to the performance of the current Contract, notwithstanding anything to
the contrary herein, BUYER shall defend, indemnify and hold BUILDER harmless
from any liability or claims of infringement of patent rights, utility model
rights, trade ▇▇▇▇ rights or copyrights, or any other intellectual property
rights of any third party related to (i) process supplied by BUYER, (ii) BUYER'S
Supplies and (iii) any construction, operation or use of the drilling
system.
Except as
otherwise provided for in this Contract, nothing contained herein shall be
construed as transferring any rights in any patent, trademarks or copyrights
utilized in the performance of this Contract.
|
2.
|
General
Plans, Specifications and Working
Drawings:
|
The
BUILDER retains all rights with respect to the Specifications, and plans and
working drawings, technical descriptions, calculations, test results and other
data, information and documents concerning the design and construction of the
DRILLSHIP, and the BUYER undertakes therefore not to disclose the same or
divulge any information contained therein to any third parties, without the
prior written consent of the BUILDER, such consent not to be unreasonably
withheld, except where it is necessary for usual operation, repair and
maintenance of the DRILLSHIP.
(End of
Article)
47
ARTICLE
XVI - BUYER'S SUPPLIES
|
1.
|
Responsibility
of BUYER:
|
|
(a)
|
The
BUYER shall, at its own risk, cost and expense, supply and deliver to the
BUILDER all of the items to be furnished by the BUYER as specified in the
Specifications (herein called the BUYER'S Supplies) at warehouse or other
storage of the Shipyard in the complete, proper condition ready for
installation in or on the DRILLSHIP, in accordance with the time schedule
designated and advised by the BUILDER to the
BUYER.
|
|
(b)
|
In
order to facilitate installation by the BUILDER of the BUYER's Supplies in
or on
the DRILLSHIP, the BUYER shall furnish
the BUILDER with necessary
specifications, plans, drawings, instruction
books, manuals, test reports and
certificates required by the rules and regulations of the Specifications.
If so requested by the BUILDER, the BUYER, without any charge to the
BUILDER, shall cause the representatives of the manufacturers of the
BUYER'S Supplies to advise the BUILDER in installation thereof in or on
the DRILLSHIP.
|
|
(c)
|
Any
and all of the BUYER'S Supplies shall be subject to the BUILDER'S
reasonable right of rejection, as and if they are found to be unsuitable
or in improper condition for
installation.
|
|
(d)
|
A
delivery Schedule of the BUYER'S Supplies, if any of such have effect on
the BUILDER'S construction of the DRILLSHIP, shall be finalized and
settled within one hundred and eighty (180) calendar days from the date of
the Contract signing. Should the BUYER fail to deliver any of the BUYER's
Supplies within the time designated, the Delivery Date shall be
automatically extended for a period that actually caused the delay in the
delivery of the DRILLSHIP.
|
|
(e)
|
If
delay in delivery of any of the BUYER'S Supplies, having effect on the
BUILDER'S construction of the DRILLSHIP, exceeds thirty (30) days, then,
the BUILDER shall be entitled to proceed with construction of the
DRILLSHIP without installation thereof in or on the DRILLSHIP as
hereinabove provided, and the BUYER shall accept and take delivery of the
DRILLSHIP so constructed, unless such delay is caused by Force Majeure in
which case the provision Paragraph l(d) of this Article shall
apply.
|
48
|
2.
|
Responsibility
of BUILDER:
|
The
BUILDER shall be responsible for storing and handling with reasonable care of
the BUYER'S Supplies after delivery thereof at the Shipyard, and shall, at its
own cost and expense, install them in or on the DRILLSHIP, unless otherwise
provided herein or agreed by the parties hereto, provided, always, that the
BUILDER shall not be responsible for quality, efficiency and/or performance of
any of the BUYER'S Supplies.
It will
be the BUILDER'S responsibility to the BUYER to: (i) if applicable, assemble the
BUYER'S Supplies; (ii) test the BUYER'S Supplies as necessary or appropriate;
(iii) install the BUYER'S Supplies on the DRILLSHIP, in modules, as required, or
otherwise as required, and to integrate the BUYER'S Supplies into the overall
designed system of the DRILLSHIP. In no event will BUILDER charge any additional
cost for any of the above. The BUILDER will perform above works under guidance
of BUYER and the Vendors representative when required. Any rework involved due
to no fault of the BUILDER shall be to BUYER'S cost and
responsibility.
|
3.
|
Title:
|
Title to
the BUYER'S Supplies shall at all times remain with the BUYER during the
Contract; however, the BUILDER shall have the risk of loss of or damage to such
BUYER'S Supplies from the time set out in subparagraph l(a) of this Article
until delivery of the DRILLSHIP.
(End of
Article)
49
ARTICLE
XVII - INSURANCE
|
1.
|
Extent
of Insurance Coverage:
|
From the
time of the keel-laying until delivery of the DRILLSHIP, the BUILDER shall, at
its own cost and expense fully insure the DRILLSHIP and all machinery, materials
and equipment delivered to the Shipyard for the DRILLSHIP, including BUYER'S
Supplies, built into or installed in or upon the DRILLSHIP against all risks
under the "Institute Clauses for Builder's Risks" with first class insurance
company or underwriters in Korea. From the time of the first arrival of the
BUYER's Supplies in Korea until delivery of the DRILLSHIP, the BUILDER shall
keep the BUYER's Supplies fully insured with the aforementioned insurance
companies or underwriters to cover BUILDER's Risk.
The
BUILDER shall promptly furnish the BUILDER with certified copies in the English
language of the insurance policies taken out.
|
2.
|
Application
of the Recovered Amounts:
|
In the
event that the DRILLSHIP shall be damaged from any insured cause at any time
before delivery of the DRILLSHIP, and in the further event that such damage
shall not constitute an actual or constructive total loss of the DRILLSHIP, the
amount received in respect of the insurance shall be applied by the BUILDER in
repair of such damage, satisfactory to the Classification Society and its
requirements, and the BUYER shall accept the DRILLSHIP under this Contract if
completed in accordance with this Contract and the Specifications, however,
subject to the extension of delivery time under Article VIII hereof (except in
case of negligence of the BUILDER),
Should
the DRILLSHIP from any cause become an actual or constructive total loss, the
BUILDER shall by the mutual agreement between the parties hereto,
either:
|
(a)
|
Proceed
in accordance with the terms of this Contract, in which case the amount
received in respect of the insurance shall be applied to the construction
and repair of damage of the DRILLSHIP, provided the parties hereto shall
have first agreed thereto in writing and to such reasonable extension of
delivery time as may be necessary for the completion of such
reconstruction and repair; or
|
50
|
(b)
|
Refund
promptly to the BUYER the full amount of all sums paid by the BUYER to the
BUILDER as installments in advance of delivery of the DRILLSHIP, and
deliver to the BUYER all BUYER's Supplies (or the insurance proceeds paid
with respect thereto), in which case this Contract shall be deemed to be
automatically terminated and shall be deemed rescinded for purposes of
Article X hereof and all rights, duties, liabilities and obligations of
each of the parties to the other shall forthwith cease and
terminate.
|
If the
parties fail to reach such agreement within Sixty (60) days after the DRILLSHIP
is determined to be an actual or constructive total loss, the provisions of
sub-paragraph 2 (b) as above shall apply.
|
3.
|
Termination
of BUILDER's Obligation to
Insure:
|
The
BUILDER shall be under no obligation to insure the DRILLSHIP hereunder after
delivery thereof and acceptance by the BUYER.
(End of
Article)
51
ARTICLE
XVIII - NOTICE
|
1.
|
Address:
|
Any and
all notices and communications in connection with this Contract shall be
addressed as follows:
To the
BUYER:
Drillship
Kithira Owners Inc. c/o Cardiff Marine Inc.
▇▇
▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇,
▇▇-▇▇▇ ▇▇
▇▇▇▇▇▇▇▇▇▇▇,
▇▇▇▇▇▇
Fax
no.(▇▇▇)▇▇▇ ▇▇▇▇▇▇▇
E-mail:
▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇ for the attention of ▇▇. ▇▇▇▇▇▇▇▇▇
▇▇▇▇▇▇▇▇▇
▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇
for the attention of ▇▇. ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇
To the
BUILDER:
Samsung
Heavy Industries Co., Ltd.
34th Floor,
Samsung Life Insurance ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇-▇▇,
▇▇▇▇▇▇-▇▇▇▇,
▇▇▇▇▇▇-▇▇, ▇▇▇▇▇, ▇▇▇▇▇ 137-857
Seoul,
Korea 135-080
Facsimile
No.: (▇▇▇) ▇ ▇▇▇▇ ▇▇▇▇
Telphone
No.: (▇▇▇) ▇ ▇▇▇▇ ▇▇▇▇
E-mail:
▇▇▇▇▇▇▇▇.▇▇▇@▇▇▇▇▇▇▇.▇▇▇
or
preferably to its Geoje Yard:
Samsung
Heavy Industries Co., Ltd.
530,
Jangpyeong-ri, Sinhvun-up,
Geoje,
Kyeongsangnam-do,
656-717,
Korea
Facsimile
No.: (▇▇▇ ▇▇ ▇▇▇ ▇▇▇▇)
|
2.
|
Language:
|
Any and
all notices and communications in connection with this Contract shall be written
in the English language.
52
|
3.
|
Effective
Date of Notice:
|
The
notice in connection with this Contract shall become effective from the date
when such notice is received by the BUYER or by the BUILDER except otherwise
described in the Contract.
(End of
Article)
53
ARTICLE
XIX - EFFECTIVE DATE OF CONTRACT
This
Contract shall become effective upon signing by the parties
hereto.
(End of
Article)
54
ARTICLE
XX - INTERPRETATION
|
1.
|
Laws
Applicable:
|
The
parties hereto agree that the validity and the interpretation of this Contract
and of each Article and part thereof shall be governed by the laws of
England.
|
2.
|
Discrepancies:
|
All
general language or requirements embodied in the Specifications are intended to
amplify, explain and implement the requirements of this Contract, However, in
the event that any language or requirements so embodied permit an interpretation
inconsistent with any provision of this Contract, then, in each and every such
event, the applicable provisions of this Contract shall prevail and govern. In
the event of conflict between the Specifications and Plans, the Specifications
shall prevail and govern.
|
3.
|
Entire
Agreement:
|
This
Contract contains the entire agreement and understanding between the parties
hereto and supersedes all prior negotiations, representations, undertakings and
agreements on any subject matter of this Contract.
|
4.
|
Amendments
and Supplements:
|
Any
supplement, memorandum of understanding or amendment, whatsoever form it may be
relating to this Contract, to be made and signed among parties hereof after
signing this Contract, shall be the integral part of this Contract and shall be
predominant over the respective corresponding Article and/or Paragraph of this
Contract.
(End of
Article)
55
ARTICLE
XXI - CONFIDENTIALITY
BUILDER
and BUYER agree that the terms and conditions of this Contract shall remain
confidential and neither party shall disclose any such terms and conditions of
this Contract to any third party without first obtaining the prior written
consent of the other, provided however, that either party shall be entitled to
disclose any or all of the terms and conditions of the Contract to the extent it
is necessary to do so to implement, effectuate and comply with the terms of the
Contract or to otherwise exercise any right or discharge any obligation that
party may have pursuant to this Contract or any laws, rules and
regulations.
(End of
Article)
56
IN
WITNESS WHEREOF, the parties hereto have caused this Contract to be duly
executed on the day and year first above written.
|
BUYER:
|
BUILDER:
|
|
|
For and
on behalf of the BUYER:
|
For and
on behalf of the BUILDER:
|
|
|
DRILLSHIP
KITHIRA OWNERS INC.
|
SAMSUNG
HEAVY INDUSTRIES CO., LTD
|
|
|
/s/
▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇
|
/s/ ▇. ▇.
▇▇▇
|
|
|
By: Mr.
▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇
|
By: ▇▇.
▇.▇. ▇▇▇
|
|
|
Title:
Authorized Signatory
|
Title:
President & CEO
|
|
|
WITNESSED
BY
|
WITNESSED
BY
|
|
|
/s/
▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇
|
/s/ ▇ ▇
▇▇▇
|
|
|
By: ▇▇.
▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇
|
By: ▇.▇.
▇▇▇
|
|
|
Title:
General Manager of Cardiff Marine Inc.
|
Title:
Chief Marketing
Officer
|
57
EXHIBIT
"1" VESSEL SPECIFICATION
The
Vessel Specification of this Contract for HN.1865 shall be identical to the
Vessel Specification (Doc. No. SP07146.FS02 of September 14th, 2007) and
Manufacturer List (Doc. No. SP07146.ML02 of September 14th 2007) of the Contract
for HN.1837. Any modification of the Vessel Specification requested during the
design and/or construction of HN.1837, shall be applied.
58
EXHIBIT
"2" TOPSIDE SPECIFICATION
The
Topside Specification of this Contract for HN.1865 shall be identical to the
Topside Specification (Doc. No. SP07146.FS01 of September 14th, 2007) of the
Contract for HN. 1837.
59
EXHIBIT
"3" DELIVERY AND CONSTRUCTION SCHEDULE
INSERT IMAGE scheduletable2.jpg
60
EXHIBIT
"4" LETTER OF REFUNDMENT GUARANTEE NO.
Gentlemen:
We hereby
open our irrevocable letter of guarantee No. in favor of Drillship Kithira
Owners Inc.(hereinafter called the "BUYER") for account of ▇▇▇▇▇▇▇ ▇▇▇▇▇
▇▇▇▇▇▇▇▇▇▇, ▇▇▇▇▇, ▇▇▇▇▇ as follows in consideration of the Drillship contract
dated 24th January 2008 (hereinafter called the "Contract") made by and among
the BUYER and Samsung Heavy Industries Co., Ltd. (hereinafter called the
"BUILDER") for the construction of one (1) Drillship composed of hull part and
topside part, having BUILDER'S Hull No. 1865(hereinafter called the
"DRILLSHIP").
If in
connection with the terms of the Contract the BUYER shall become entitled to
a refund of the advance
payment(s) made to the BUILDER prior to the delivery of the DRILLSHIP, we hereby
irrevocably guarantee as primary obligor and not merely as surety the repayment
of the same to the BUYER immediately on demand USD 10,000,000 (United States
Dollars Ten Million only) together with interest thereon at the rate of six
percent (6%) per annum from the date following the date of receipt by the
BUILDER to the date of remittance by telegraphic transfer of such
refund.
The
amount of this guarantee will be automatically increased, not more than five (5)
times, upon BUILDER'S receipt of the respective installment: each time by the
amount of instalment of USD 39,575,000, USD 49,575,000, USD 99,150,000 and
USD 99,150,000 and USD 99,150,000 respectively, plus interest thereon as
provided in the Contract, but in any eventuality the amount of this guarantee
shall not exceed the total sum of USD 396,600,000 (Say United States Dollars
Three Hundred Ninety Six Million Six Hundred Thousand only) plus interest
thereon at the rate of six per cent (6%) per annum from the date following the
date of BUILDER'S receipt of each installment to the date of remittance by
telegraphic transfer of the refund.
In case
any refund is made to you by the BUILDER or by us under this guarantee, our
liability hereunder shall be automatically reduced by the amount of such
refund.
In the
event of cancellation of the Contract being based on delays due to force majeure
or other causes beyond the control of the BUILDER, as required by Article X of
the Contract, interest
61
shall be
paid at the rate of Four and a half percent (4.5%) per annum from the date of
following the date of Builder's receipt of each installment to the date of
remittance by telegraphic transfer of the refund.
This
letter of guarantee is available against our receipt of signed statement
certifying that BUYER'S demand for refund has been made in conformity with
Article X of the Contract and the BUILDER has failed to make the refund within
Thirty (30) days after your demand to the BUILDER. Refund shall be made to you
by telegraphic transfer in United States Dollars in freely transferable funds
and free and clear of and without deduction for and on account of any set off,
counterclaim or present or future tax, levy, impost, duty, charge, fee or other
withholding of any nature whatsoever imposed and by whomsoever on yourselves. In
the event we are required by law to make any deduction or withholding from any
payment to be made by it pursuant to this letter of guarantee, we will pay to
you whatever additional amount (after taking into account any additional taxes
on, or deductions or withholdings from, or restrictions or conditions on, that
additional amount) is necessary to ensure that, after making the deduction or
withholding, you receive a net sum equal to the sum which you would have
received had no deduction or withholding been made.
This
letter of guarantee shall expire and become null and void upon receipt by the
BUYER of the sum guaranteed hereby or upon acceptance by the BUYER of delivery
of the DRILLSHIP in accordance with the terms of the Contract and, in either
case, this letter of guarantee shall be returned to us. This guarantee is valid
from the date of this letter of guarantee until delivery or in the event of
delayed delivery until such time as the DRILLSHIP is delivered by the BUILDER to
the BUYER in accordance with the terms of the Contract.
Notwithstanding
the provisions hereinabove, in case we receive notification from you or the
BUILDER confirmed by the Arbitration Board stating that your claim to cancel the
Contract or your claim for refundment thereunder has been disputed and referred
to Arbitration in accordance with the provisions of the Contract, the period of
validity of this guarantee shall be extended until Sixty (60) days after the
final award shall be rendered in the Arbitration and a copy thereof acknowledged
by the Arbitration Board. In such case, this guarantee shall not be available
unless and until such acknowledged copy of the final award in the Arbitration
justifying your claim is presented to us.
This
guarantee shall not be affected by any extension of time or concession granted
by the BUYER to the BUILDER or any delay or failure of the BUYER in enforcing
its rights under the Contract.
62
The BUYER
shall have the right to assign this guarantee and all of its benefits to any
assignee to whom the Contract is assigned.
This
guarantee shall be governed by the laws of England and the undersigned hereby
submits to the non-exclusive jurisdiction of the courts of England. If we
receive written or telefaxed notice from you or the BUILDER that there exists an
arbitration between you and BUILDER or that you have made a formal demand of us
under this Letter of Guarantee we shall within thirty (30) days of receipt of
such notice irrevocably appoint an agent for service of process in respect of
any proceedings in England and notify you of such appointment and undertake
that, throughout the terms of this Letter of Guarantee, we will retain such
agent in England for such purposes. If we fail to make such appointment and/or
give such notification within thirty (30) day period we hereby appoint and be
deemed to have appointed the London branch of our bank currently at 1st Floor,
▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇-▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇
▇▇▇▇▇▇▇.
Any
notice or demand under this Letter of Guarantee required to be given by
yourselves to us shall be
addressed
to us as follows:
Address:
▇▇-▇, ▇▇▇▇▇-▇▇▇▇, ▇▇▇▇▇▇▇▇▇▇▇▇-▇▇, ▇▇▇▇▇ ▇▇▇-▇▇▇ ▇▇▇▇▇
Tel:▇▇▇-▇-▇▇▇▇-▇▇▇▇
Fax:▇▇▇-▇-▇▇▇▇-▇▇▇▇
|
Very
truly yours,
|
|
|
The
Export-Import Bank of Korea
|
63
EXHIBIT
"5" PERFORMANCE GUARANTEE
Messrs.
Samsung
Heavy Industries Co., Ltd.
34th Floor,
Samsung Life Insurance ▇▇▇▇▇▇ ▇▇▇▇▇
▇▇▇▇-▇▇,
▇▇▇▇▇▇-▇▇▇▇, ▇▇▇▇▇▇-▇▇,
▇▇▇▇▇,
▇▇▇▇▇▇▇▇ of Korea 137-857
In
consideration of the shipbuilding contract dated 24th January 2008 (hereinafter
called the "Contract") by us to (hereinafter called the "BUYER"), for the
construction of one (1) Drillship having your Hull No. 1865(hereinafter called
the "Drillship") providing among other things for payment of the Contract Price
amounting to United States Dollars Six Hundred Sixty One Million (US$
661,000,000);
We, the
undersigned, hereby irrevocably and unconditionally guarantee to you, your
successors, and assigns the due and faithful performance by the BUYER of its all
liabilities and responsibilities under the Contract and any supplement,
amendment, change or modification hereafter made thereto, including but not
limited to, due and prompt payment of the Contract Price by the BUYER to you,
your successors, and assigns under the Contract and any supplement, amendment,
change or modification as aforesaid (hereby expressly waiving notice of any such
supplement, amendment, change or modification as may be agreed to by the BUYER
and confirming that this guarantee shall be fully applicable to the Contract as
so supplemented, amended, changed or modified).
This
Performance Guarantee shall be governed by the laws of
England.
GUARANTOR
: CARDIFF MARINE INC.
BY:
TITLE:
WITNESS
:
64
EXHIBIT
"6" OPTIONAL ITEMS
|
No
|
Items
|
Amount
|
|
1.1
|
Dual
Drilling (Aux Rig):
a) Travelling
block
b)
Retractable dolly
c) Elevated
backup tong
d)
Drawworks
e) Drill
line & Reel
f) Deadline
Anchor
g)
Top drive
h)
Mud standpipes manifold/Standpipes/Hoses
i) Cement
standpipe manifold/Standpipe/Hose
|
US$
15,752,130
|
|
1.2
|
False
rotary table in Aux well centre
|
US$
865,740
|
|
2
|
Personnel
elevator in the ▇▇▇▇▇▇▇
|
US$
987,120
|
|
3
|
Additional
3,000 ft of Riser [designed for 10,000 ft of water depth
operation]
|
US$
15,000,000
|
|
4
|
Upgrade
Drilling Equipment suitable for 12,000 ft of water depth operation: Both
parties agree that this Option shall be based on Hull No. 1837/1838 for
Hull system and SAIPEM 12K for Topsides
|
US$
37,400,000
|
|
5
|
In
addition to Option 4, further upgrade main rig with 1,250 Ton Hoisting
capacity:
|
US$
9,400,000
|
|
6
|
Supply
of additional 3,000 ft of riser [designed for 12,000 ft of water depth
operation]:
|
US$
19,500,000
|
|
7
|
Supply
of additional 2,000 ft of riser over 10,000 ft [designed for 12,000 ft of
water depth operation]:
|
To
be
informed
|
1.
Details for the above optional items (1.1, 1.2, 2 & 3) are included in the
Drillship Specification (Doc. No. SP07146, FS01 of September 14th
2007)
2.
Details for the above optional items (4 & 5) are included in the Drillship
Drilling System Specification (Section 9.3 of Doc. No. SP07146.FS01 of January
16th 2008) attached herewith.
3.
In case of the Buyer's declaration of Option No. 4 & 5, all tests or trials
shall be performed and notified as per the Specifications.
65
EXHIBIT
"7" FORM OF DEMAND
To: [Insert name and address of Refund
Guarantor]
Attention:
[•]
Dear
Sirs
ADVANCE
PAYMENT REFUND GUARANTEE
REFUND
GUARANTEE no.
We refer
to your Advance Payment Refund Guarantee number [•] dated [•] (the "Refund
Guarantee").
Terms
defined in the Refund Guarantee shall have the same meanings when used
herein.
The
BUILDER has failed to fulfill the terms and conditions of the Contract in the
following respects:
[...........................................]
As a
result of such failure, an amount of USD[•] (United States Dollars [•]),
together with interest
thereon at a rate of [........................] [.....................] per
annum calculated from
[date] until the date of payment by you, is due from you to
us.
Please
make payment of the above amount to us without any deduction or withholding and
promptly upon receipt by you of this written demand to the following
account:
[Insert
account details]
Yours
faithfully
For and
on behalf of [Insert name of
BUYER]
____________________
Name:
Designation:
Authorised Signatory
66