SHIPBUILDING CONTRACT FOR CONSTRUCTION OF ONE 48,500 CBM LEG/LPG CARRIER (HULL NO. H2854) BETWEEN NAVIGATOR POLARIS L.L.C. as the BUYER and JIANGNAN SHIPYARD (GROUP) CO., LTD. and CHINA SHIPBUILDING TRADING CO., LTD. Collectively as the SELLER

Exhibit 10.1

SHIPBUILDING CONTRACT

FOR

CONSTRUCTION OF ONE 48,500 CBM LEG/LPG CARRIER

(HULL NO. H2854)

BETWEEN

NAVIGATOR POLARIS L.L.C.

as the BUYER

and

JIANGNAN SHIPYARD (GROUP) CO., LTD.

and

CHINA SHIPBUILDING TRADING CO., LTD.

Collectively as the SELLER

CONTENTS

1 / 82

2 / 82

3 / 82

SHIPBUILDING CONTRACT

FOR

CONSTRUCTION OF ONE 48,500 CBM LEG/LPG CARRIER

(HULL NO. H2854)

This SHIPBUILDING CONTRACT, entered into this 23^rd day of August, 2024 (hereinafter called the “CONTRACT”) by and between NAVIGATOR POLARIS L.L.C., a limited liability company organized and existing under the laws of ▇▇▇▇▇▇▇▇ Islands, having its registered office at Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, ▇▇▇▇▇▇▇▇ Islands, MH 96960 (hereinafter called the “BUYER”) on one part;

and

CHINA SHIPBUILDING TRADING CO., LTD., a corporation organized and existing under the Laws of the People’s Republic of China, having its registered office at ▇▇(▇▇) ▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇ ▇▇▇, ▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇ ▇▇▇▇▇▇’▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ (hereinafter called “CSTC”), and JIANGNAN SHIPYARD (GROUP) CO., LTD., a corporation organized and existing under the Laws of the People’s Republic of China, having its registered office at ▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇., ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, the People’s Republic of China (hereinafter called the “BUILDER”) on the other part, jointly and severally. CSTC and the BUILDER are hereinafter collectively called the “SELLER”.

WITNESSETH

In consideration of the mutual covenants contained herein, the SELLER agrees to design, build, launch, equip, test, complete and to sell and deliver to the BUYER after completion of successful trials one (1) 48,500 CBM LEG/LPG as more fully described in Article I hereof, to be registered under the flag of Denmark and the BUYER agrees to purchase and take delivery of the aforesaid VESSEL from the SELLER and to pay for the same in accordance with the terms and conditions hereinafter set forth.

4 / 82

ARTICLE I DESCRIPTION AND CLASS

1. DESCRIPTION

The VESSEL is a 48,500 CBM LEG/LPG CARRIER, at designed draft moulded of 9.80 meters (hereinafter called the “VESSEL”) of the class described below. The VESSEL shall have the BUILDER’s Hull No. H2854 and shall be designed, constructed, equipped, tested and completed in accordance with the provisions of this CONTRACT and as per the following “Specifications”:

attached hereto and signed by the BUYER and the BUILDER (hereinafter collectively called the “Specifications”), making an integral part hereof.

2. CLASS AND RULES

The VESSEL, including its machinery and equipment, shall be constructed in accordance with the rules and regulations issued and having become effective and compulsorily applicable to the VESSEL up to and on the signing date of this CONTRACT of American Bureau of Shipping (hereinafter called the “Classification Society”) and shall be distinguished in the record by the symbol of

X Al, (E), Liquefied Gas Carrier with independent tanks (description: “Ship type 2G and Min. cargo temperature -104°C, Max. vapour pressure 0.25 bar G, Max. specific gravity 0.69)”, SH, SFA (40, WWT), SHCM, CPS, UWILD, NBLES, CR, ENVIRO, IHM, TCM, BWE, BWT, DFD-Ethane, Ammonia Fuel Ready Level lC and 2D (S) X AMS, X ACCU, RELIQ and shall also comply with the rules and regulations as fully described in the Specifications.

The requirements of the authorities as fully described in the Specifications including that of the Classification Society are to include any additional rules or circulars thereof issued and become effective and compulsorily applicable to the VESSEL up to and on the signing date of this CONTRACT.

The SELLER shall arrange with the Classification Society to assign a representative or representatives (hereinafter called the “Classification Surveyor”) to the BUILDER’s shipyard for supervision of the construction of the VESSEL.

5 / 82

All fees and charges incidental to the Classification Society and those related to compliance with the rules, regulations and requirements of this CONTRACT as described in the Specifications issued, effective and compulsorily applicable to the VESSEL up to the signing date of this CONTRACT as well as royalties, if any, payable on account of the construction of the VESSEL shall be for the account of the SELLER, except as otherwise provided and agreed herein. The key plans, materials and workmanship entering into the construction of the VESSEL shall at all times be subject to inspections and tests in accordance with the rules and regulations of the Classification Society.

Decisions of the Classification Society as to compliance or noncompliance with classification rules and regulations as well as any other rules, regulations and circulars applicable to the VESSEL under this CONTRACT shall be final and binding upon the parties hereto.

The SELLER shall take necessary action to remedy at its cost and expense any defect or deficiency that constitutes a failure of the VESSEL to comply with the rules, regulations and requirements of this CONTRACT as described in the Specifications issued, effective and compulsorily applicable to the VESSEL up to the signing date of this CONTRACT

The PARTIES agree to provide copies of technical exchanges regarding the VESSEL with the Classification Society upon the other party’s reasonable request.

3. PRINCIPAL PARTICULARS AND DIMENSIONS OF THE VESSEL

The VESSEL shall be equipped, in accordance with the Specifications, with MAN 6G50ME-C9.5-GIE_HPSCR type Main Engine.

6 / 82

4. GUARANTEED SPEED

The service speed at design draught and NCR of main engine with 15% sea margin and including PTO (1800kWm) shall not be less than 16.0 knots

The service speed shall be guaranteed on even keel and with clean hull under the calm weather (no wind, no wave, and no current) and deep sea condition

5. GUARANTEED FUEL CONSUMPTION

The SELLER guarantees that the specific fuel consumption of main engine at NCR & Tier II mode shall be 171.3 g/kWh fuel oil at fuel oil mode and total heat rate of7,314 kJ/kWh at gas mode, based on diesel oil with a lower calorific value of 42,700 kJ/kg, fuel gas with lower calorific value of 47,500 kJ/kg and under ISO standard reference conditions.

The fuel oil consumption and total heat rate shall be subject to a tolerance of +5% and measured at shop test bed

6. GUARANTEED DEADWEIGHT

The deadweight shall not be less than 35,200 metric tons at the moulded ▇▇▇▇▇▇▇▇▇ draught on even keel in sea water with the specific gravity of 1.025.

The guaranteed deadweight shall be adjusted for all alterations by the Buyer’s request if any according to the provisions of this Specification

The actual deadweight of the VESSEL expressed in metric tons shall be based on calculations made by the BUILDER, approved by the Classification Society and checked by the BUYER, and all measurements necessary for such calculations shall be performed in the presence of the BUYER’s Supervisor

Should there be any dispute between the BUILDER and the BUYER in such calculations and/or measurements, the decision of the Classification Surveyor shall be final and binding on the parties.

7. GUARANTEED CARGO TANK CAPACITY

The SELLER guarantees that the VESSEL is to have a total cargo tank capacity of not less than 48,500 cubic meters with ambient temperature of20 degrees Celsius (100% geometric, including tank domes and Ethane Fuel tank).

7 / 82

Subject to the provisions of this ARTICLE, the SELLER may, at its sole discretion and responsibility, subcontract any portion of the construction work of the VESSEL to experienced and qualified subcontractors, but the final assembly into the VESSEL of any such work subcontracted shall be at the BUILDER’s shipyard.

No later than eleven (11) months from the date of this CONTRACT, the SELLER and the BUYER shall agree which (if any) major part(s) of the VESSEL shall be constructed by the BUILDER at the BUILDER’s shipyard, and which major part(s) shall be built by a subcontractor(s). The SELLER shall use reasonable endeavours to arrange to build any major part of the VESSEL at the BUILDER’s shipyard.

Unless otherwise agreed by the SELLER and BUYER in writing and notwithstanding any other provision of this ARTICLE, the SELLER shall not subcontract the design of the VESSEL and/or any cargo tank, without the prior written approval of the BUYER, such approval shall not be unreasonably withheld or delayed.

When seeking the BUYER’s approval under this ARTICLE, within SELLER’s capacities, the SELLER agrees to assist the BUYER, reasonably in advance, in obtaining reasonable information allowing the BUYER to evaluate the performance of such proposed subcontractor.

The BUYER will act in good faith in giving or withholding its consent to any proposed subcontractor under this ARTICLE and will use reasonable endeavours to give or refuse consent (as the case may be) within seven (7) days following SELLER’s request for approval.

The SELLER shall in all events remain directly responsible in full for the performance of its obligations as set out here in respect of all subcontracted work.

9. REGISTRATION

The VESSEL shall be registered by the BUYER at its own cost and expenses under the laws of Denmark at the time of delivery and acceptance thereof

The BUILDER agree to provide reasonable assistance to the BUYER in relation to the BUYER’ s efforts to register the VESSEL in the selected jurisdiction.

8 / 82

ARTICLE II CONTRACT PRICE & TERMS OF PAYMENT

1. CONTRACT PRICE

The purchase price of the VESSEL is United States Dollars One Hundred and Two Million and Nine Hundred Thousand only (US$ 102,900,000.00), net receivable by the SELLER (hereinafter called the “Contract Price”), which is exclusive of the cost for the BUYER Supplied Items as provided in Article V hereof, and shall be subject to upward or downward adjustment, if any, as hereinafter set forth in this CONTRACT. All costs and expenses incurred in supplying all the relevant plans and/or drawings to the BUYER as required pursuant to the Specifications shall be for SELLER’s account.

2. CURRENCY

Any and all payments by the BUYER to the SELLER under this CONTRACT shall be made in United States Dollars.

3. TERMS OF PAYMENT

The Contract Price shall be paid by the BUYER to the SELLER in instalments as follows:

(a) 1^st Instalment:

The sum of United States Dollars Ten Million Two Hundred and Ninety Thousand only (US$ 10,290,000.00), representing Ten percent (10%) of the Contract Price, shall become due and payable and be paid by the BUYER within Five (5) Banking Days after its receipt of the Refund Guarantee as described in Paragraph 7 of this Article.

(b) 2^nd Instalment:

The sum of United States Dollars Ten Million Two Hundred and Ninety Thousand only (US$ 10,290,000.00), representing Ten percent (10%) of the Contract Price, shall become due and payable and be paid by the BUYER within Five (5) Banking Days upon 180 days after the signing date of this CONTRACT.

9 / 82

(c) 3^rd Instalment:

The sum of United States Dollars Ten Million Two Hundred and Ninety Thousand only (US$ 10,290,000.00), representing Ten percent (10%) of the Contract Price, shall become due and payable and be paid by the BUYER within Five (5) Banking Days after receipt by the BUYER of a notice from the BUILDER attaching a stage certificate confirmed by the Classification Society, certifying the cutting of the first steel plate of the VESSEL. The SELLER shall notify with an email notice to the BUYER stating that the first steel plate has been cut and demand for payment of this instalment, along with an invoice issued by the SELLER, but not earlier than 1st July, 2025.

(d) 4^th Instalment:

The sum of United States Dollars Ten Million Two Hundred and Ninety Thousand only (US$ 10,290,000.00), representing Ten percent (10%) of the Contract Price, shall become due and payable and be paid by the BUYER within Five (5) Banking Days after keel-laying of the first section of the VESSEL. The SELLER shall notify with an email notice to the BUYER stating that the said keel-laying has been carried out and demand for payment of this instalment with an invoice by the SELLER but not earlier than 1^st February, 2026

(e) 5^th Instalment:

The sum of United States Dollars Ten Million Two Hundred and Ninety Thousand only (US$ 10,290,000.00), representing Ten percent (10%) of the Contract Price, shall become due and payable and be paid by the BUYER within Five (5) Banking Days after launching of the VESSEL. The SELLER shall notify with an email notice to the BUYER and confirmed by the Classification Society, stating that the launching of the VESSEL has been carried out and demand for payment of this instalment with an invoice by the SELLER, but not earlier than 1^st June, 2026

(f) 6^th Instalment:

The sum of United States Dollars Fifty One Million Four Hundred and Fifty Thousand only (US$ 51,450,000.00), representing Fifty percent (50%) of the Contract Price, plus any increase or minus any decrease due to modifications and/or adjustments of the Contract Price in accordance with the provisions of relevant Articles hereof, shall become due and payable and be paid by the BUYER to the SELLER concurrently with Delivery of the VESSEL. The SELLER shall send to the BUYER an email demand or this instalment Ten (10) days prior to the scheduled date of delivery of the VESSEL.

10 / 82

4. METHOD OF PAYMENT

(a) 1s^t Instalment:

The BUYER shall remit the amount of this instalment in accordance with Article II, Paragraph 3(a) by telegraphic transfer to BANK OF CHINA SHANGHAI BRANCH, ▇▇.▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ (▇.▇) ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ (having SWIFT Code ▇▇▇▇▇▇▇▇▇▇▇) as receiving bank nominated by the SELLER for credit to the account of JIANGNAN SHIPYARD (GROUP) CO., LTD (account No. 444259237023),or through any other receiving bank to be nominated by the SELLER from time to time and such nomination shall be notified to the BUYER at least Ten (10) Days prior to the due date for payment.

(b) 2^nd Instalment:

The BUYER shall remit the amount of this instalment in accordance with Article II, Paragraph 3(b) by telegraphic transfer to BANK OF CHINA SHANGHAI BRANCH, ▇▇.▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ (▇.▇) ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ (having SWIFT Code ▇▇▇▇▇▇▇▇▇▇▇) as receiving bank nominated by the SELLER for credit to the account of JIANGNAN SHIPYARD (GROUP) CO., LTD (account No. 444259237023) or through any other receiving bank to be nominated by the SELLER from time to time and such nomination shall be notified to the BUYER at least Ten (10) Days prior to the due date for payment.

(c) 3^rdInstalment:

The BUYER shall remit the amount of this instalment in accordance with Article II, Paragraph 3(c) by telegraphic transfer to BANK OF CHINA SHANGHAI BRANCH, ▇▇.▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ (▇.▇) ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ (having SWIFT Code ▇▇▇▇▇▇▇▇▇▇▇) as receiving bank nominated by the SELLER for credit to the account of JIANGNAN SHIPYARD (GROUP) CO., LTD (account No. 444259237023), or through any other receiving bank to be nominated by the SELLER from time to time and such nomination shall be notified to the BUYER at least Ten (10) Days prior to the due date for payment.

11 / 82

(d) 4^th Instalment:

The BUYER shall remit the amount of this instalment in accordance with Article II, Paragraph 3(d) by telegraphic transfer to BANK OF CHINA SHANGHAI BRANCH, ▇▇.▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ (▇.▇) ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ (having SWIFT Code ▇▇▇▇▇▇▇▇▇▇▇) as receiving bank nominated by the SELLER for credit to the account of JIANGNAN SHIPYARD (GROUP) CO., LTD (account No. 444259237023), or through any other receiving bank to be nominated by the SELLER from time to time and such nomination shall be notified to the BUYER at least Ten (10) Days prior to the due date for payment.

(e) 5^th Instalment:

The BUYER shall remit the amount of this instalment in accordance with Article II, Paragraph 3(e) by telegraphic transfer to BANK OF CHINA SHANGHAI BRANCH, ▇▇.▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ (▇.▇) ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ (having SWIFT Code ▇▇▇▇▇▇▇▇▇▇▇) as receiving bank nominated by the SELLER for credit to the account of JIANGNAN SHIPYARD (GROUP) CO., LTD (account No. 444259237023), or through any other receiving bank to be nominated by the SELLER from time to time and such nomination shall be notified to the BUYER at least Ten (10) Days prior to the due date for payment.

(f) 6^th Instalment:

The BUYER shall, at least Three (3) Banking Days prior to the scheduled date of delivery of the VESSEL, through the BUYER’s bank make an irrevocable cash deposit in the name of the BUYER with the Bank of China or other bank to be nominated by the SELLER with at least Ten (10) days notice prior to the scheduled date of delivery of the VESSEL, for a period of Twenty(20) days and covering the amount of this instalment (as adjusted in accordance with the provisions of this CONTRACT), with an irrevocable instruction that the said amount shall be released to the SELLER against presentation by the SELLER to the said the Bank of China, of a copy of the Protocol of Delivery and Acceptance signed by the BUYER’s authorized representative, and the SELLER. Interest, if any, accrued from such deposit, shall be for the benefit of the BUYER.

If the delivery of the VESSEL is not effected on or before the expiry of the aforesaid Twenty (20) days deposit period, the BUYER shall have the right to withdraw the said deposit plus accrued interest upon the expiry date. However, when the newly scheduled delivery date is notified to the BUYER by the SELLER, the BUYER shall make the cash deposit in accordance with the same terms and conditions as set out above.

Expenses and bank charges for remitting payment incurred by the BUYER’s bank shall be for the BUYER’s account and the expenses and bank charges of the SELLER’s bank shall be for the SELLER’s account.

12 / 82

Expenses and bank charges for receiving and/or cancelling the Refund Guarantee charged by the BUYER’s bank shall be for the BUYER’s account and the expenses and bank charges for issuing and/or cancelling the Refund Guarantee charged by the SELLER’s bank shall be for the SELLER’s account.

5. PREPAYMENT

The BUYER shall have the right to make prepayment of any and all instalments before delivery of the VESSEL, by giving to the SELLER at least thirty (30) days prior written notice, without any price adjustment of the VESSEL for such prepayment.

6. SECURITY FOR PAYMENT OF INSTALMENTS BEFORE DELIVERY

The BUYER shall, within Five(5) Banking Days after signing of this CONTRACT, deliver to the SELLER an irrevocable and unconditional Letter of Guarantee (the “PAYMENT GUARANTEE”) in the form annexed hereto as Exhibit “B” in favour of the SELLER issued by NAVIGATOR HOLDINGS LTD. (hereinafter called the “Payment Guarantor”) acceptable to the SELLER’s bank and the SELLER. The PAYMENT GUARANTEE shall secure the BUYER’s obligation for the payment of all 2^nd, 3^rd ,4^th and 5^th instalments of the Contract Price.

If the Payment Guarantor should merge with, or transfer the whole or substantially the whole of its assets to another entity (the “Successor”), then [unless the Successor automatically succeeds to all of the obligations of the Payment Guarantor under the PAYMENT GUARANTEE, the Payment Guarantor shall provide with Seller adequate prior notice in advance together with supporting documents of such transfer reasonably required by the Seller for its internal compliance purposes, and shall procure the Successor to issue a new PAYMENT GUARANTEE on the terms set out in Exhibit B, and the Parent Guarantor shall thereafter be discharged from liability under its PAYMENT GUARANTEE

7. REFUNDS

13 / 82

If the expiry date of the Refund Guarantees becomes earlier than the Release Date (which is the Delivery Date plus the excessive delay period stipulated in Article VIII), the expiry date of the Refund Guarantees shall be extended by at least such period corresponding to the extension in the time for delivery of the VESSEL as aforesaid.

14 / 82

ARTICLE III ADJUSTMENT OF THE CONTRACT PRICE

The Contract Price of the VESSEL shall be subject to adjustments as hereinafter set forth. It is hereby understood by both parties that any reduction of the Contract Price is by way of liquidated damages and not by way of penalty

1. DELIVERY

Unless the parties hereto agree otherwise, the total reduction in the Contract Price shall be deducted from the 6^th Instalment of the Contract Price and in any event (including the event that the BUYER consents to take the VESSEL at the later delivery date after the expiration of Two Hundred and Twenty Five (225) days of delay in delivery as described in Paragraph l(c) of this Article or after the expiration of Two Hundred and Seventy (270) days of delay in delivery as described in Paragraph 3 of Article VIII) shall not be more than the sum of United States Dollars Five Million Forty Thousand (US$ 5,040,000.00) being the maximum, as above One Hundred and Eighty (180) days of delay in delivery from the forty-Sixth (46^th) day after the Delivery Date at the above specified rate of reduction. Other than the liquidated damages permitted under this Paragraph 1(b) and in any event subject to the limitation of the aforesaid maximum amount, claims of the BUYER on account of the delay in delivery of the VESSEL arising out of any nature whatsoever or caused by whatever reason shall be and are hereby expressly and irrevocably waived and given up by the BUYER whether under this CONTRACT or under the laws of England.

15 / 82

For the purpose of determining the liquidated damages to the BUYER (according to the provisions of Paragraph 1(b) of this Article) and the BUYER’s right to cancel or rescind this CONTRACT (according to the provisions of Paragraph l(c) of this Article),the newly planned delivery date declared by the SELLER shall not be in any way treated or taken as having substituted the Delivery Date as defined in Article VII.

2. INSUFFICIENT SPEED

16 / 82

In case of deficiency,

3. EXCESSIVE FUEL CONSUMPTION

17 / 82

4. INSUFFICIENT CARGO TANK CAPACITY

18 / 82

5. EFFECT OF RESCISSION OR CANCELLATION

It is expressly understood and agreed by the parties hereto that in any case as stated herein, if the BUYER cancels or rescinds this CONTRACT pursuant to any provision under this Article or under the laws of England, the BUYER, save its rights and remedy set out in Article X hereof, shall not be entitled to any liquidated damage or compensation whether described above or , otherwise available under any applicable laws (including the laws of England). Any other rights or remedies whether under this CONTRACT or under any applicable laws are hereby expressly waived and given up by the BUYER.

The above liquidated damages shall be the BUYER’s sole and exclusive remedy for any excessive delay in the delivery of the VESSEL and any deficiency/insufficiency/excess in the guaranteed technical performance parameters as set out in this Article and shall be in lieu of all damages, which the BUYER may suffer by reason of such delay and deficiency/insufficiency/excess as set out in this Article. Save as expressly provided in this Article III hereinabove, it being further understood and agreed that SELLER shall not be responsible or liable to BUYER or any third party for any other damages, losses, expenses of any nature whatsoever (including but not limited to loss of use of the VESSEL, loss of charter costs, loss of time, loss of production, loss of profit or earnings, financing costs, loss of other contracts, etc.), occasioned by and/or in connection with such delay and deficiency/insufficiency/excess as set out in this Article.

19 / 82

ARTICLE IV SUPERVISION AND INSPECTION

1. APPOINTMENT OF THE BUYER’S SUPERVISOR

The BUYER shall send in good time to and maintain at the BUILDER’s shipyard, at the BUYER’s own cost, expense and risk, one or more representative(s) who shall be duly authorised in writing by the BUYER (such representative(s) being hereinafter collectively and individually called the “Supervisor”) to communicate with the BUILDER and to supervise the construction by the BUILDER of the VESSEL, her engines and accessories, to approve plans and drawings, attend tests and inspections related to the VESSEL, its machinery, equipment, outfitting and any other matters for which they are authorized by the BUYER.

The SELLER hereby agrees to arrange the invitation letter(s) for the Supervisor to apply for visas to enter China provided that the Supervisor meets with the rules, regulations and laws of the People’s Republic of China. The BUYER undertakes to give the SELLER reasonable notice for the application of visa. The SELLER agree to provide the BUYER with necessary assistance within Seller’s capacity and upon reasonable request by the BUYER to facilitate the arrangement of visas, work permits, residence permits and any other P.R.C government consents or licenses necessary to allow the Supervisor to exercise their rights and perform their duties at the BUILDER’s shipyard.

2. COMMENTS TO PLANS AND DRAWINGS

The Parties hereto shall, within Thirty (30) days after s1gmng of this CONTRACT, mutually agree a list of all the plans and drawings, which are to be sent to the BUYER for which the BUYER’s approval or comment is required in accordance with the Specifications (herein below called the “LIST”) and a schedule for dispatching the plans and drawings to the BUYER for BUYER’s reference (the “Dispatch Schedule”). The LIST shall be in English. Before arrival of the Supervisor at the BUILDER’s shipyard, the plans and drawings specified in the LIST shall be sent to the BUYER in a controlled manner, and the BUYER shall, within Fourteen (14) days after receipt thereof, return such plans and drawings submitted by the SELLER with comments, if any, and in accordance with the Dispatch Schedule. Notwithstanding the above, the BUYER shall nevertheless waive its right to comment on the plans and drawings if such plans and drawings have been previously applied to build other vessels with the same specification as that of the VESSEL.

20 / 82

Concurrently with the arrival of the Supervisor at the BUILDER’s shipyard, the BUYER shall notify the BUILDER in writing, stating the authority which the said Supervisor shall have, and can, on behalf of the BUYER, give comments, as the case may be, which of the plans and drawings specified in the LIST but not yet been sent to the BUYER, nevertheless in line with the Supervisor’s authority. The Supervisor shall, within seven (7) days after receipt thereof, return those plans and drawings with comments, if any,

Unless notification is given to the BUILDER by the Supervisor or the BUYER of the comments to any plans and drawings within the above designated period of time for each case, the said plans and drawings shall be regarded as approved by the BUYER and shall be implemented for construction by the BUILDER, except where the BUYER has requested in writing an extension of the deadline to submit its comments and the SELLER has consent such extension in writing and in such instance, the BUYER shall have a further seven (7) days from the date of such request to submit any comments to the SELLER.

Notwithstanding the time limits referred to in this Article, the parties agree to respond to each other as quickly as possible and to use reasonable endeavours to expedite the approval process.

3. SUPERVISION AND INSPECTION BY THE SUPERVISOR

The necessary inspection of the VESSEL, its machinery, equipment and outfittings shall be carried out by the Classification Society, and/or inspection team of the BUILDER throughout the entire period of design, construction, launching, equipping and testing of the VESSEL in order to ensure that the construction of the VESSEL is duly performed in accordance with the CONTRACT and Specifications.

The Supervisor shall have, at all times during the construction of the VESSEL, the right to attend tests according to the mutually agreed test list and free and ready access to inspect the VESSEL, her engines, accessories and materials at the BUILDER’s shipyard, its subcontractors or any other place where work is done or materials are stored, processed or tested in connection with the VESSEL. In the event that the Supervisor discovers any construction or material or workmanship which does not or will not conform to the requirements of this CONTRACT and the Specifications, the Supervisor shall forthwith give the BUILDER a notice in writing as to such nonconformity, upon receipt of which the BUILDER shall correct such nonconformity if the BUILDER agrees with the BUYER(if not, a official reply will be provided by Builder). In any circumstances, the BUILDER shall be entitled to proceed with the construction of the VESSEL even if there

21 / 82

exists a discrepancy in the opinion between the BUYER and the SELLER, without however prejudice to the SELLER’s obligations under this CONTRACT or prejudice to the BUYER’s right for submitting the issue for determination by the Classification Society or arbitration in accordance with the provisions hereof However, the BUYER undertakes and assures the SELLER that the Supervisor shall carry out their inspections in accordance with the agreed test list, the SELLER’s working schedule and usual shipbuilding practice and shall not cause any increase in building costs and delays in the construction of the VESSEL,. Once an inspection and/or a test has been witnessed and approved by the Supervisor the same inspection and test should not have to be repeated, provided it has been carried out in compliance with the requirements of the Classification Society and Specifications.

The BUILDER agrees to furnish free of charge the Supervisor with transportation between shipyard and ▇▇▇▇▇’s residence in Pudong area of Shanghai, office space, working lunch, washing facilities and other reasonable facilities according to the BUILDER’s practice at or in the immediate vicinity of the BUILDER’s shipyard, suitably sized and with air-conditioning and to include tables, desks, chairs and filing cabinets. But the fees for the international communication like telephone, telefax, but excluding high speed internet, etc. shall be borne by the BUYER. The office space should be supplied with, as a minimum, dedicated internet access for WAN communication. This should have a minimum capacity of 30Mbps synchronous connection. At all times, during the construction of the VESSEL until delivery thereof, the Supervisor shall be given free and ready access to the VESSEL, her engines and accessories, and to any other place where the work is being done, or the materials are being processed or stored, in connection with the construction of the VESSEL, including the yards, workshops, stores of the BUILDER, and the premises of subcontractors of the BUILDER, who are doing work, or storing materials in connection with the VESSEL’s construction. The travel expenses for the said access to SELLER’s subcontractors outside of (Shanghai city) shall be for the BUYER’s account. The transportation in any nature whatsoever shall be provided to the Supervisor by the BUYER.

The BUYER undertakes to maintain a sufficient number of Supervisor personnel at the BUILDER’s shipyard throughout the period of construction of the VESSEL so as to meet the BUILDER’s reasonable requirements for inspection, survey and attending tests and/or trials. The SELLER agrees to try to arrange for the inspection by the supervisor during the working hours of the Seller. However, such inspection may be arranged beyond the seller’s normal working hours, including weekend and/ or holidays if this considered necessary by the seller in order to meet the seller’s construction schedule, on the condition that the seller will inform the supervisor at least one (1) day in advance of such inspection. The

22 / 82

BUILDER shall notify the Supervisor reasonably in advance of the date and place of all tests and inspections of or relating to the VESSEL, its machinery and equipment. If the location of any such tests, trials and inspections of the VESSEL is the BUILDER’s shipyard, the BUILDER shall give at least twenty-four (24) hours’ prior notice, and if the location is away from the BUILDER’s shipyard, the BUILDER shall give at least three (3) days’ prior notice to the BUYER (unless the location is outside China, in which case the BUILDER shall give at least Fourteen (14) days’ prior written notice to the BUYER provided that in exceptional circumstances and in the event of visa issuance delays the notice period may be modified by mutual agreement) of the commencement of such tests, trials and inspections. The SELLER agrees to use best endeavours to hold any and all tests and/or trials during the daytime on Work Days in China.

Should the Supervisor fail to conduct any inspection or attend any test (after notice by the BUILDER of the same in accordance with this Article) due to any reason whatsoever, the BUILDER shall be entitled to carry out the construction and/or test without inspection and/or attendance of the Supervisor and such work so carried out shall be treated as approved by the Supervisor, provided that nothing herein shall affect the BUILDER’S obligation to design, construct, build, launch, equip, test, complete and deliver the VESSEL in accordance with the provisions of the Specifications,

It is hereby agreed that any third parties (such as major vendors of the BUYER’s suppliers) providing necessary services on the VESSEL in connection with the items and/or equipment as purchased by the BUYER for the VESSEL shall, subject to the SELLER’s prior written consent (such consent not to be unreasonably withheld), be permitted free and ready access to the VESSEL, her machinery and equipment or the premises which are necessarily relevant to the aforesaid services, provided such access shall in no event cause adverse influence on the construction of the VESSEL

The decision, approval or advice of the Supervisor shall be deemed to have been given by the BUYER and once given shall not be withdrawn, revoked or modified except with consent of the BUILDER. However, if the Supervisor fails to submit to the BUILDER without delay any such demand concerning alterations with respect to the building, arrangement or outfit of the VESSEL, her engines or accessories, or any other items or matters in connection herewith, which the Supervisor has examined or inspected or attended at the tests thereof under this CONTRACT or the Specifications, the Supervisor shall be deemed to have approved the same and shall be precluded from making any demand for alterations or other complaints with respect thereto at a later date.

23 / 82

4. LIABILITY OF THE SELLER

The Supervisor engaged by the BUYER under this CONTRACT shall at all times be deemed to be in the employ of the BUYER. The SELLER shall be under no liability whatsoever to the BUYER, or to the Supervisor or the BUYER’s employees or agents for personal injuries, including death, during the time when they, or any of them, are on the VESSEL, or within the premises of either the SELLER or its subcontractors, or are otherwise engaged in and about the construction of the VESSEL, unless, however, such personal injuries, including death, were caused by gross negligence or wilful misconduct of the SELLER, or of any of the SELLER’s employees or agents or subcontractors of the SELLER. Nor shall the SELLER be under any liability whatsoever to the BUYER for damage to, or loss or destruction of property in China of the BUYER or of the Supervisor or of the BUYER’s employees or agents, unless such damage, loss or destruction was caused by gross negligence or wilful misconduct of the SELLER, or of any of the employees, or agents or subcontractors of the SELLER.

The Supervisor, or the BUYER’s employee or agents, shall not be liable for damage to property of the SELLER or death or injuries caused to the SELLER’s employees, contractors or agents, unless caused by the BUYER’S or the BUYER’s Supervisor’s, employee’s or agent’s gross negligence or wilful misconduct.

5. SALARIES AND EXPENSES

All salaries and expenses of the Supervisor, or any other employees employed by the BUYER under this Article, shall be for the BUYER’s account.

6. REPLACEMENT OF SUPERVISOR

The SELLER has the right to request the BUYER in writing to replace any Supervisor who is deemed by the SELLER (acting reasonably) to be unsuitable and unsatisfactory for the proper progress of the VESSEL’s construction together with reasons. The BUYER shall investigate the situation by sending its representative to the BUILDER’s shipyard, if necessary, and if the BUYER considers that such SELLER’s request is justified, the BUYER shall effect the replacement as soon as conveniently arrangeable.

24 / 82

ARTICLE V MODIFICATION, CHANGES AND EXTRAS

1. HOW EFFECTED

The Specifications and plans in accordance with which the VESSEL is constructed, may be modified and/or changed at any time hereafter by written agreement of the parties hereto, provided that such modifications and/or changes or an accumulation thereof will not, in the BUILDER’s reasonable judgment, adversely affect the BUILDER’s other commitments or result in a breach of the Classification Society’s or the intended flag’s rules and regulations, and provided further that the BUYER shall assent to adjustment of the Contract Price, time of delivery of the VESSEL and other terms of this CONTRACT, if any, as hereinafter provided. Subject to the above, the SELLER hereby agrees to exert their best endeavours to accommodate such reasonable requests by the BUYER so that the said changes and/or modifications may be made at a reasonable cost and within the shortest period of time which is reasonable and possible. Any such agreement for modifications and/or changes shall include an agreement as to the increase or decrease, if any, in the Contract Price of the VESSEL together with an agreement as to any extension or reduction in the time of delivery, or any other alterations in this CONTRACT, or the Specifications occasioned by such modifications and/or changes. The aforementioned agreement to modify and/or to change the Specifications and/or plans may be effected by an exchange of duly authenticated letters, or email, manifesting such agreement. The letters and/or emails exchanged by the parties hereto pursuant to the foregoing shall constitute an amendment of the Specifications under which the VESSEL shall be built, and such letters and emails shall be deemed to be incorporated into this CONTRACT and the Specifications by reference and made a part hereof provided that any modification related to extra cost and delivery time adjustment shall be subject to the BUYER’s agreement in writing (be it in electronic or manuscript form). Upon consummation of the agreement to modify and/or to change the Specifications, the SELLER shall alter the construction of the VESSEL in accordance therewith, including any additions to, or deductions from, the work to be performed in connection with such construction. If, due to whatever reasons, the parties hereto shall fail to agree on the adjustment of the Contract Price or extension of time of delivery or modification of any terms of this CONTRACT which are necessitated by such modifications and/or changes, then the SELLER shall have no obligation to comply with the BUYER’s request for any modification and/or changes.

The failure of the parties to agree on the increase or decrease in the Contract Price, or extension or reduction in the time of delivery or modification of any terms of this CONTRACT which are necessitated by such modifications and/or changes, if any, for any modifications or changes requested by the BUYER shall not prevent the BUILDER from continuing the VESSEL’s construction as per the existing terms and conditions of this CONTRACT and existing Specifications

25 / 82

2. CHANGES IN RULES AND REGULATIONS, ETC.

Agreement as to such alterations or changes under this Paragraph shall be made in the same manner as provided above for modifications and/or changes of the Specifications and/or plans.

26 / 82

3. SUBSTITUTION OF MATERIALS AND/OR EQUIPMENT

In the event that any of the materials and/or equipment required by the Specifications under this CONTRACT for the construction of the VESSEL cannot be procured in time to effect delivery of the VESSEL, the SELLER may, provided the SELLER shall provide adequate evidence acceptable to the BUYER and the BUYER so agrees in writing, supply other materials and/or equipment of the equivalent or superior quality, capable of meeting the requirements of the Specifications, the Classification Society and of the rules, regulations, requirements and recommendations with which the construction of the VESSEL must comply.

27 / 82

4. BUYER SUPPLIED ITEMS

The BUYER shall, at its own risk, cost and expense, supply and deliver to the SELLER at its shipyard the items as specified in the Specifications which the BUYER shall supply on the BUYER’s account (the “BUYER Supplied Items”) by the time or times designated by the SELLER together with Seller’s notice

Should the BUYER fail to deliver to the BUILDER such BUYER Supplied Items together with relevant documents, drawings and other information within the time Specified, the delivery of the VESSEL shall automatically be extended for a period of such delay.) In such event, the BUYER shall pay to the SELLER all reasonably incurred losses and damages sustained by the SELLER due to such delay in the delivery of the BUYER Supplied Items and such payment shall be made upon delivery of the VESSEL.

Furthermore, if the delay in delivery of the BUYER Supplied Items should exceed Fifteen (15) days, the SELLER shall be entitled to proceed with construction of the VESSEL without installation of such items in or onto the VESSEL, without prejudice to the SELLER’s right hereinabove provided, and the BUYER shall accept the VESSEL so completed,

The BUILDER shall be responsible for storing and handling of the BUYER Supplied Items as specified in the Specifications after delivery to the BUILDER, at a warehouse or other storage at the BUILDER’s shipyard or in the immediate vicinity of the builder’s shipyard, and shall install them on board the VESSEL at the BUILDER’s expenses. The SELLER Agrees to provide assistance to the BUYER within Seller’s capacity for customs clearance for the import of the BUYER’s Supplied Items into China.

Upon arrival of such shipment of the BUYER Supplied Items, both parties shall undertake a joint unpacking inspection. If any damages are found to be not suitable for installation, the BUILDER shall be entitled to refuse to take the BUYER Supplied Items into its custody.

The SELLER shall not be responsible for the quality, performance or efficiency of the BUYER Supplied Items and is under no obligation with respect to the guarantee of such BUYER Supplied Items against any defects caused by defective quality, performance or efficiency thereof. The SELLER shall have the risk or loss and damage caused by improper storage and handling to such BUYER’s Supplied Items from time of delivery to SELLER until delivery of the VESSEL.

28 / 82

In order to facilitate the installation by the BUILDER of the BUYER’s Supplied Items in or on the VESSEL, the BUYER shall furnish the BUILDER with the necessary specifications, plans, drawings, instruction books manual, test reports and certificates required by the rules and regulations of the Specifications. If so requested by the BUILDER, the BUYER shall, without any charge to the BUILDER, cause the representatives of the manufacturers of the BUYER’s Supplied Items to, within the time requested by the BUILDER, assist the BUILDER in installation thereof in or on the VESSEL and/or to carry out installation thereof by themselves or to assist the BUILDER to make necessary adjustments or commissioning.

In the event of rescission of the Contract by the BUYER provided that those rescissions of the Contract are not made as per clauses of Article VIII & Article XII clauses of the Contract which are due to faults of the Seller, the SELLER will return all BUYER Supplied Items. In the event such return would be impossible or impractical, the SELLER shall compensate the BUYER the BUYER’s cost of such BUYER Supplied Items as evidenced by invoice or other documentary evidence acceptable to the SELLER.

29 / 82

ARTICLE VI TRIALS

1. NOTICE

The BUYER shall receive from the SELLER at least Fifteen (15) days approximate notice in advance and Seven (7) days definite notice in advance by telefax or email of the time and place of the VESSEL’s sea trial as described in the Specifications (hereinafter referred to as the “Trial Run”) and the BUYER shall promptly acknowledge receipt of such notice. The Supervisor shall be entitled to be on board the VESSEL to witness such Trial Run, and to check upon the performance of the VESSEL during the same. Failure of the Supervisor to be present after receipt of due notice as provided above, shall be deemed as that the BUYER has waived its right to have its Supervisor on board the VESSEL during the Trial Run, and the BUILDER may conduct such Trial Run without the Supervisor being present. In such case, the BUYER shall be obliged to accept the VESSEL on the basis of a certificate of the BUILDER certifying that the VESSEL, after Trial Run subject to minor alterations and corrections as provided in this Article, if any, is found to conform to the CONTRACT and Specifications. The SELLER hereby agrees to assist to arrange the invitation letter for the Supervisor to apply visa to enter China. However, should the nationalities and other personal particulars of the Supervisor be not acceptable to the SELLER in accordance with the relevant rules, regulations and/or laws of the People’s Republic of China then prevailing, then the BUYER shall effect replacement of all or any of them immediately. Otherwise, the Delivery Date as stipulated in Article VII hereof shall be extended by the delays so caused by the BUYER. In the event of unfavorable weather on the date specified for the Trial Run, the same shall take place on the first available day thereafter that the weather conditions permit. The parties hereto recognize that the weather conditions in Chinese waters in which the Trial Run is to take place are such that great changes in weather may arise momentarily and without warning and, therefore, it is agreed that if during the Trial Run of the VESSEL, the weather should suddenly become unfavorable, as would have precluded the continuance of the Trial Run, the Trial Run of the VESSEL shall be discontinued and postponed until the first favorable day next following, unless the BUYER shall assent by telefax or email of its acceptance of the VESSEL on the basis of the Trial Run made prior to such sudden change in weather conditions.

Inspections and/or tests of any part of the VESSEL, including its equipment has been witnessed during the Trial Run and proved to conform to the requirements of this CONTRACT and Specifications shall not be repeated during the re-Trial Run(s).

30 / 82

Any delay to the Trail Run as a result of unfavorable weather or sea conditions shall operate to extend the Delivery Date by the period of delay. Such extension of the Delivery Date shall be regarded as mutually agreed change of Delivery Date and shall be distinguished from the Permissible Delays and non-Permissible Delays which will entitle the BUYER to cancel and/or rescind this CONTRACT.

2. HOW CONDUCTED

The course of Trial Run shall be determined by the BUILDER and shall be conducted within the trial basin equipped with speed measuring facilities.

3. TRIAL LOAD DRAFT

In addition to the supplies provided by the BUYER in accordance with sub-paragraph (b) of the preceding Paragraph 2 hereof, the BUILDER shall provide the VESSEL with the required quantity of fresh water and other stores necessary for the conduct of the Trial Run. The necessary ballast (fresh and sea water and such other ballast as may be required) to bring the VESSEL to the trial load draft as specified in the Specifications, shall be for the BUILDER’s account.

31 / 82

4. METHOD OF ACCEPTANCE OR REJECTION

Any dispute arising among the parties hereto as to the result of any Trial, any further tests or trials or any issues not addressed during any Trial, as the case may be, of the VESSEL shall be solved by reference to arbitration as provided in Article XIII hereof.

5. DISPOSITION OF SURPLUS CONSUMABLE STORES

Should any amount of fuel oil, fresh water, or other unbroached consumable stores furnished by the BUILDER for the Trials or repeat Trials remain on board the VESSEL at the time of acceptance thereof by the BUYER, the BUYER agrees to buy the same from the SELLER at the original invoiced purchase price (or other documented price) incurred by the BUILDER at the port of delivery thereof, and payment by the BUYER shall be effected as provided in Article II 3 (f) and 4 (f) of this CONTRACT.

32 / 82

The BUYER shall supply lubricating oil and hydraulic oil for the purpose of the Trial Run or re-Trial Run(s) at its own expenses and the SELLER will reimburse for the amount of lubricating oil and hydraulic oil actually consumed for the said Trial Run or re-Trial Run(s) at the original purchase price incurred by the BUYER and payment by the SELLER shall be effected as provided in Article II 3(f) and 4(f) of this CONTRACT.

6. EFFECT OF ACCEPTANCE

The BUYER’s acceptance of the VESSEL, in accordance with the provisions set out above, shall be final and binding so far as conformity of the VESSEL to this CONTRACT and the Specifications is concerned, and shall preclude the BUYER from refusing formal delivery by the SELLER of the VESSEL, as hereinafter provided, if the SELLER complies with all other procedural requirements for delivery as hereinafter set forth.

If, at the time of delivery of the VESSEL, there are deficiencies in the VESSEL, such deficiencies should be resolved in such way that if the deficiencies are of minor importance, and do not in any way affect the safety or the operation of the VESSEL, its crew, passengers or cargo, the SELLER shall be nevertheless entitled to tender the VESSEL for delivery and the BUYER shall be nevertheless obliged to take delivery of the VESSEL, provided that:

33 / 82

ARTICLE VII DELIVERY

1. TIME AND PLACE

The VESSEL shall be delivered safely afloat by the SELLER to the BUYER at the BUILDER’s shipyard, on or before March 31, 2027, Provided that, in the event of delays in the construction of the VESSEL or any performance required under this CONTRACT due to causes which under the terms of the CONTRACT and/or the applicable law permit extension or postponement of the time for delivery, the aforementioned time for delivery of the Vessel shall be extended accordingly.

The aforementioned date or such later date to which delivery is extended or postponed pursuant to the terms of this CONTRACT (the “Delivery Date”).

The BUYER shall have no obligation to take delivery of the VESSEL more than ninety (90) days prior to the Delivery Date.

2. WHEN AND HOW EFFECTED

Provided that the BUYER and the SELLER shall each have fulfilled all of their respective obligations as stipulated in this CONTRACT, delivery of the VESSEL shall be effected forthwith, and concurrently each of the parties hereto shall deliver, one to the other, of the Protocol of Delivery and Acceptance, acknowledging delivery of the VESSEL by the SELLER and acceptance thereof by the BUYER. The Protocol of Delivery and Acceptance shall be prepared in triplicate and signed by each of the parties hereto.

3. DOCUMENTS TO BE DELIVERED TO THE BUYER

Upon Delivery and acceptance of the VESSEL by the BUYER, the SELLER shall deliver to the BUYER the following documents (subject to the provision contained in Article V.2 hereof) which shall accompany the Protocol of Delivery and Acceptance

34 / 82

35 / 82

Such other documents as the BUYER may reasonably require, and which the SELLER within its capability can reasonably provide and for which the BUYER gives reasonable notice to the SELLER, for the purpose of obtaining financing and/or for registration of the VESSEL, as applicable.

4. TITLE AND RISK

Title to and risk of the VESSEL shall pass to the BUYER only upon delivery thereof. As stated above, it being expressly understood that, until such delivery is effected, title to and risk of damage to or loss of the VESSEL, and her equipment, shall remain at all times with the SELLER and are at the entire risk of the SELLER.

5. REMOVAL OF VESSEL

The BUYER shall take possession of the VESSEL immediately upon delivery and acceptance thereof, and shall remove the VESSEL from the premises of the BUILDER within Seven (7) days after delivery and acceptance thereof is effected. If the BUYER shall not remove the VESSEL from the premises of the BUILDER within the aforesaid Seven (7) days, then, in such event, without prejudice to the SELLER’s right to require the BUYER to remove the VESSEL immediately at any time thereafter, the BUYER shall pay to the SELLER the reasonable mooring charge of the VESSEL.

The SELLER agrees to provide necessary assistance (such as documentation, if available, as may be required by authorities) for the VESSEL to be removed as aforesaid

6. TENDER OF THE VESSEL

If the BUYER fails to take delivery of the VESSEL after completion in accordance with this CONTRACT and the Specifications without justified reason, the SELLER shall have the right to tender the VESSEL for delivery.

36 / 82

7. Cargo GAS TRIAL

The SELLER shall pay all costs and charges of its own representative(s) and of the Classification Society and shall arrange at their expense for the cargo handling system supplier to send at least one representative to the gas trial.

The BUYER shall at its own cost and expense provide suitable product in sufficient and satisfactory quantity and quality as well as utilities and consumables for operation.

Should the Gas Plant not be in conformity with the Specifications, the SELLER shall carry out remedial work to extent necessary to bring the Gas Plant into compliance with Specifications. After the remedial works are completed the BUYER shall arrange to re-run the gas trial to the extent which will be necessary to demonstrate that the rectified part of the Gas Plant is then in conformity with this Contract and the Specifications and the proper functioning of the Gas Plant as a whole is secured.

37 / 82

All direct costs and expenses of remedying the non-conformity and of re-running the gas trial (including provision of suitable product, utilities and consumables) shall be for the account of the SELLER.

8. Fuel GAS TRIAL

38 / 82

The BUYER shall at its own cost and expense provide suitable product in sufficient and satisfactory quantity and quality as well as utilities and consumables for operation.

Should the fuel gas plant not be in conformity with the Specifications, the SELLER shall carry out at the port remedial work to the extent necessary to bring the plant into compliance with Specifications. The BUILDER shall pay all costs relating to the remedial work, including but not limited to additional product and time spent by the supplier and the Classification Society. After the remedial works are completed the BUYER shall arrange, at the SELLER’s cost to re-run the fuel gas trial to the extent which will be necessary to demonstrate that the rectified part of the fuel gas plant is then in conformity with this Contract and the Specifications and the proper functioning of the fuel gas plant.

For avoidance of doubt, for Paragraphs 7 and 8 of this ARTICLE, the Cargo gas trial and Fuel gas trial should be, if practically possible, carried out at the same time.

39 / 82

ARTICLE VIII DELAYS & EXTENSION OF TIME FOR DELIVERY

1. CAUSE OF DELAY

If, at any time before actual delivery , either the construction of the VESSEL or any performance required hereunder as a prerequisite of delivery of the VESSEL is delayed due to war, blockade, revolution, insurrection, mobilization, civil commotions, riots, ,strikes sabotage, lockouts, local temperature higher than 35 degree centigrade or lower than minus 10 degree centigrade, Acts of God or the public enemy, terrorism, plague or other epidemics/pandemic quarantines, prolonged failure or restriction of electric cmTent from an outside source, freight embargoes, if any, earthquakes, tidal waves, typhoons, hurricanes, storms or other causes beyond the control of the SELLER or of its subcontractors or its key equipment suppliers (i.e. gas handling system, gas supply system, main engine, propeller, or similar.), as the case may be, or by force majeure of any description, whether of the nature indicated by the foregoing or not, or by destruction of the SELLER or works of the SELLER or its subcontractors or its key equipment suppliers (i.e. gas handling system, gas supply system, main engine, propeller, or similar.), or of the VESSEL or any part thereof, by fire, flood, or other causes beyond the control of the SELLER or its subcontractors or its key equipment suppliers (i.e. gas handling system, gas supply system, main engine, propeller, or similar,) as the case may be, , or due to the bankruptcy of the key equipment and/or material suppliers (i.e. gas handling system, gas supply system, main engine, propeller, or similar.) or due to the delay caused by acts of God in the supply of parts essential to the construction of the VESSEL; or due to any other cause, whether or not of similar description, beyond the reasonable control of the SELLER and its subcontractors, then, in the event of delay due to the happening of any of the aforementioned contingencies, the SELLER shall not be liable for such delay and the time for delivery of the VESSEL under this CONTRACT shall be extended without any reduction in the Contract Price for a period of time which shall not exceed the total accumulated time of all such delays, subject nevertheless to the BUYER’s right of cancellation under Paragraph 3 of this Article and subject however to all relevant provisions of this CONTRACT which authorize and permit extension of the time of delivery of the VESSEL. The SELLER agrees to use reasonable endeavors to mitigate the effect of any delay in the construction of the VESSEL.

40 / 82

2. NOTICE OF DELAY

Within Seven (7) days from the date of commencement of any event on account of which the SELLER claims that it is entitled under this Article to an extension of the time for delivery of the VESSEL, the SELLER shall advise the BUYER by email of the date such event commenced, the nature and cause (such notice “Initial Notice”) .

Likewise, within Seven (7) days after such event ends, the SELLER shall advise the BUYER by email, of the date such event ended, and also shall specify the maximum period of the time by which the date for delivery of the VESSEL is extended by reason of such event. Failure of the BUYER to object to the SELLER’s notification of any claim for extension of the Delivery Date within Ten

(10) days after receipt by the BUYER of such notification, shall be deemed to be a waiver by the BUYER of its right to object to such extension. If the SELLER fails give the Initial Notice within the time limits stipulated above, the SELLER shall be deemed to have waived its right to claim any extension of the Delivery Date for such delay.

3. RIGHT TO CANCEL FOR EXCESSIVE DELAY

If the total accumulated time of all delays on account of the causes specified in Paragraph 1 of the Article aggregate to Two Hundred and Twenty-Five (225) days or more, or if the total accumulated time of all delays on account of the causes specified in Paragraph 1 of the Article and non-Permissible Delays as described in Paragraph 1 of Article III aggregate to Two Hundred and Seventy (270) days or more, in any circumstances, excluding delays due to arbitration as provided for in Article XIII hereof or due to default in performance by the BUYER, or due to delays in delivery of the BUYER Supplied Items, and excluding delays due to causes which, under Article V, VI, XI and XII and any other provisions hereof, permit extension or postponement of the time for delivery of the VESSEL, then in such event, the BUYER may in accordance with the provisions set out herein cancel or rescind this CONTRACT by serving upon the SELLER emailed notice of cancellation or recession and the provisions of Article X of this CONTRACT shall apply.

4. DEFINITION OF PERMISSIBLE DELAYS

Delays on account of such causes as provided for in Paragraph 1 of this Article excluding any other extensions or postponement of a nature which under the terms of this CONTRACT and/or applicable laws permit extension or postponement of the Delivery Date or delays due to reasons attributable to the BUYER, shall be understood to be (and are herein referred to as) Permissible Delays, and are to be distinguished from non-Permissible Delays on account of which the Contract

41 / 82

Price of the VESSEL is subject to adjustment as provided for in Article III hereof. Notwithstanding any other stipulations of this CONTRACT, the parties hereby agree that a default in performance of, or any breach of this CONTRACT by, or reasons attributable to, the BUYER or the events described under this CONTRACT permit extension of the Delivery Date shall entitle the SELLER to extend the Delivery Date. Such extension of the Delivery Date shall be regarded as mutually agreed change of Delivery Date and shall be distinguished from the Permissible Delays and non-Permissible Delays which will entitle the BUYER to cancel or rescind this CONTRACT.

42 / 82

ARTICLE IX WARRANTY OF QUALITY

1. GUARANTEE OF MATERIAL AND WORKMANSHIP

The SELLER, for a period of twelve (12) months following Delivery to the BUYER of the VESSEL, guarantees the VESSEL, her hull and machinery and all parts and equipment thereof that are designed (except to the extent that such design is proposed and/or developed by the BUYER or its agents or employees) manufactured or furnished or sourced or supplied by the SELLER and/or its sub-contractors under this CONTRACT including material, equipment (however excluding any parts for the VESSEL which have been supplied by or on behalf of the BUYER(unless caused by faulty installation or handling by the SELLER and/or its subcontractors) against all defects which are due to defective materials or equipment, and/or poor workmanship on the part of the SELLER, provided that a notice thereof is duly given to the SELLER as provided under Paragraph 2 of this Article; and the liability of the SELLER shall be limited to those set forth in Paragraph 3(a) of this Article and subject to all such exclusion of the SELLER’s liabilities as described in Paragraph 4 of this Article..

In addition, upon ▇▇▇▇▇’s request, the SELLER agree to assist the BUYER to obtain the benefit of all guarantees of greater than twelve months’ duration which the SELLER has itself been given by its subcontractors and suppliers, if any.

In the event any defects of part and equipment are repaired, replaced or remedied by the BUILDER during warranty period, the period of guarantee for such item or items shall be extended for another six (6) months period after repairing replacement or remedy, but in any case such extended guarantee period shall not exceed eighteen (18) months from the delivery of the VESSEL.

2. NOTICE OF DEFECTS

The BUYER shall notify the SELLER by email of any defects for which a claim is made under this guarantee as promptly as possible after discovery thereof. The BUYER’s written notice shall describe the nature and the extent of the defect. The SELLER shall have no obligation for any defects discovered prior to the expiry date of the said Twelve (12) months period, unless notice of such defects is received by the SELLER no later than ten (10) days after such expiry date.

43 / 82

3. REMEDY OF DEFECTS

44 / 82

4. EXTENT OF SELLER’S RESPONSIBILITY

The SELLER shall have no responsibility or liability for any other defects whatsoever in the VESSEL other than the defects specified in Paragraph 1 of this Article.

The SELLER shall be liable to the BUYER for defects and damages caused by any of the defects specified in Paragraph 1 of this Article provided that such liability of the SELLER shall be limited to damage occasioned within the guarantee period specified in Paragraph 1 above

The SELLER shall not be obligated to repair, or to be liable for any losses and/or damages to the VESSEL, or to any part of the equipment thereof, due to ordinary wear and tear, nor shall there be any SELLER’s liability hereunder for defects in the VESSEL other than those specified in Paragraph 1 of this Article, or any part of the equipment thereof, caused by fire or accidents at sea or elsewhere, or mismanagement, accidents, negligence, or willful neglect, on the part of the BUYER, its employees or agents including the VESSEL’s officers, crew and passengers, or any persons on or doing work on the VESSEL other than the SELLER, its employees, agents or subcontractors. Likewise, the SELLER shall not be liable for defects in the VESSEL, or the equipment or any part thereof, due to repairs or replacement which were made by those other than the SELLER and/or their subcontractors or alteration or addition by the BUYER not previously approved by the SELLER.

Upon delivery of the VESSEL to the BUYER, in accordance with the terms of the CONTRACT, the SELLER shall thereby and thereupon be released of all responsibility and liability whatsoever and howsoever arising under or by virtue of this CONTRACT and/or any applicable laws (save in respect of those obligations to the BUYER expressly provided for in this Article IX) including without limitation, any responsibility or liability for defective workmanship, materials or equipment, design or in respect of any other defects whatsoever and any loss or damage resulting from any act, omission or default of the SELLER. In any circumstances whatsoever, whether under or in connection with this CONTRACT or any applicable laws, the SELLER’s liability shall be limited to the repairs and replacement as set forth in Paragraph 1 of this Article, excluding any other responsibility, obligation and/or liability such as but not limited to those for (i) consequential loss or special loss; or (ii) any damages, losses, costs and/or expenses arising from any cause whatsoever (including but not limited to

45 / 82

the loss of management fees, pilot charges or costs, fuel or lubrication oils consumed, damage to the VESSEL or any part thereof or any third party caused by the defects specified in Paragraph 1 of this Article etc.) regardless of whether the aforesaid damages, losses, costs and/or expenses are directly or indirectly occasioned to the BUYER by reason of the defects specified in Paragraph 1 of this Article; (iii) loss of time, loss of use, loss of hire, loss of profit or earnings or demurrage arising from any cause whatsoever

The guarantee provided in this Article and the obligations and the liabilities of the SELLER hereunder are exclusive and in lieu of and the BUYER hereby waives all other remedies, warranties, conditions, guarantees or liabilities, express or implied, arising by any applicable law (i.e. laws of England) or out of the CONTRACT or otherwise (including without limitation any obligations of the SELLER with respect to fitness, merchantability and consequential damages) or whether or not occasioned by the SELLER’s negligence. This guarantee shall not be extended, altered or varied except by a written instrument signed by the duly authorized representatives of the SELLER, and the BUYER.

46 / 82

ARTICLE X CANCELLATION, REJECTION AND RESCISSION BY THE BUYER

For the avoidance of doubt, the events and/or occurrences which entitle the BUYER to cancel or rescind the CONTRACT shall be limited to those occurrences or events specified in this CONTRACT which specifically permits the BUYER to do so. No other event or circumstance shall give rise to any right to the BUYER for rescission or cancellation of the CONTRACT whether under this CONTRACT or any applicable laws.

The occurrences or events which specifically permits the BUYER to rescind or cancel or terminate the Contract are as follows:

(a) either Builder or CSTC is dissolved, liquidated or ceases to be registered as a company in its place of incorporation, or ceases to carry on its business as a whole, or declares its intention that such event will take place, except due to group internal restructuring, requirement of IPO and/or restructuring for financing purpose; or

(b) the BUYER becomes entitled to rescind the Contract, for (i) excessive delay in delivery of the VESSEL (Article III.1 (c)); or (ii) excessive deficiency of the speed of the VESSEL (Article III.2 (c)); or (iii) excessive fuel consumption of any one of the Engines (Article III.3 (c)); or (iv) excessive deficiency of the cargo tank capacity of the VESSEL (Article III.4(c); or (V) as per Article XXI.

47 / 82

by the SELLER, and the BUYER shall not be entitled to demand repayment from the Refund Guarantor under its guarantee, until the Final Award or judgment on appeal therefrom, which shall be in favour of the BUYER, declaring the BUYER’s cancellation or rescission justified, is made and delivered to the SELLER. In the event of the SELLER is obligated to make refundment, the SELLER shall pay the BUYER interest in United States Dollars at the [rate of Five percent (5%),] if the cancellation or rescission of the CONTRACT is exercised by the BUYER in accordance with the provision of Article 111.l(c), 2(c), 3(c) or 4(c) hereof, on the amount required herein to be refunded to the BUYER computed from the respective dates when such sums were received by Bank of China or any such other bank account as nominated by the SELLER pursuant to Article II.4(b), 4(c), 4(d) or 4(e) from the BUYER to the date of remittance by telegraphic transfer of such refund to the BUYER by the SELLER, provided, however, that if the said cancellation or rescission by the BUYER is made under the provisions of Paragraph 3 of Article VIII or this CONTRACT terminates under Paragraph 2(b) of Article XII, then in such event the SELLER shall not be required to pay any interest.

48 / 82

ARTICLE XI BUYER’S DEFAULT

1. DEFINITION OF DEFAULT

The BUYER shall be deemed in default of its obligation under the CONTRACT if any of the following events occurs:

49 / 82

2. NOTICE OF BUYER DEFAULT

If the BUYER is in default of payment or in performance of its obligations as provided hereinabove, the SELLER shall notify the BUYER to that effect by telefax or email after the date of occurrence of the default as per Paragraph 1 of this Article and the BUYER shall forthwith acknowledge by email to the SELLER that such notification has been received. In case the BUYER does not give the aforesaid email acknowledgment to the SELLER within Three (3) calendar days it shall be deemed that such notification has been duly received by the BUYER.

3. INTEREST AND CHARGE ON BUYER’S DEFAULT

4. DEFAULT BEFORE DELIVERY OF THE VESSEL

50 / 82

5. SALE OF THE VESSEL

51 / 82

52 / 82

ARTICLE XII INSURANCE

1. EXTENT OF INSURANCE COVERAGE

From the time of keel-laying of the first section of the VESSEL until the same is completed, delivered to and accepted by the BUYER, the SELLER shall, at its own cost and expense, keep the VESSEL and all machinery, materials, equipment, appurtenances and outfit and supplies delivered to the BUILDER for the VESSEL or built into, or installed in or upon the VESSEL, including the BUYER Supplied Items, fully insured with first class Chinese insurance companies for BUILDER’s RISK. A copy of the BUILDER’s insurance policy shall be sent to the BUYER on request from the BUYER.

The amount of such insurance coverage shall, up to the date of delivery of the VESSEL, be in an amount at least equal to, but not limited to, the aggregate of the payments made by the BUYER to the SELLER including the value of a maximum amount of US$ 300,000.00 of the BUYER Supplied Items. The policy referred to hereinabove shall be taken out in the name of the SELLER and all losses under such policy shall be payable to the SELLER.

2. APPLICATION OF RECOVERED AMOUNT

In the event the VESSEL shall be damaged by any insured cause whatsoever prior to acceptance and delivery thereof by the BUYER and the SELLER and in the further event that such damage shall not constitute an actual or a constructive total loss of the VESSEL, the SELLER shall apply the amount recovered under the insurance policy referred to in Paragraph 1 of this Article to the repair of such damage satisfactory to the Classification Society and other institutions or authorities as described in the Specifications without additional expenses to the BUYER, and the BUYER shall accept the VESSEL under this CONTRACT if completed in accordance with this CONTRACT and Specifications and not make any claim for any damage, consequential loss or depreciation.

53 / 82

However, in the event that the VESSEL is determined to be an actual or constructive total loss, the SELLER shall either:

Within Thirty (30) days after receiving email notice of any damage to the VESSEL constituting an actual or a constructive total loss, the BUYER shall notify the SELLER by email of its agreement or disagreement under Paragraph 2(b) of this Article. In the event the BUYER fails to so notify the SELLER, then such failure shall be construed as a disagreement on the part of the BUYER. This CONTRACT shall be deemed as canceled or rescinded and Paragraph 2 (b) (ii) of this Article shall apply.

3. TERMINATION OF THE SELLER’S OBLIGATION TO INSURE

The SELLER’s obligation to insure the VESSEL hereunder shall cease and terminate forthwith upon delivery thereof to and acceptance by the BUYER.

54 / 82

ARTICLE XIII DISPUTES AND ARBITRATION

1. PROCEEDINGS

This CONTRACT shall be governed by and construed in accordance with English law and any dispute arising out of or in connection with this CONTRACT shall be referred to arbitration in London in accordance with the Arbitration Act 1996 or any statutory modification or reenactment thereof save to the extent necessary to give effect to the provisions of this Article.

The seat of the arbitration shall be England, even where the hearing takes place outside England.

The arbitration shall be conducted in accordance with the London Maritime Arbitrators Association (LMAA) Terms current at the time when the arbitration proceedings are commenced.

The reference shall be to three arbitrators, one to be appointed by each party and the third, subject to the provisions of the LMAA Terms, by the two so appointed. A party wishing to refer a dispute to arbitration shall appoint its arbitrator and send notice of such appointment in writing to the other party requiring the other party to appoint its own arbitrator within 28 calendar days of that notice and stating that it will appoint its arbitrator as sole arbitrator unless the other party appoints its own arbitrator and gives notice that it has done so within the 28 days specified. If the other party does not appoint its own arbitrator and give notice that it has done so within the 28 days specified in the notice, the party referring a dispute to arbitration may, without the requirement of any further prior notice to the other party, appoint its arbitrator as sole arbitrator and shall advise the other party accordingly. The award of a sole arbitrator shall be binding on both parties as if the arbitrator had been appointed by agreement.

Nothing herein shall prevent the parties agreeing in writing to vary these provisions to provide for the appointment of a sole arbitrator.

In cases where neither the claim nor any counterclaim exceeds the sum of US$I00,000 (or such other sum as the parties may agree) the arbitration shall be conducted in accordance with the LMAA Small Claims Procedure current at the time when the arbitration proceedings are commenced.

55 / 82

In cases where the claim or any counterclaim exceeds the sum agreed for the LMAA Small Claims Procedure and neither the claim nor the counterclaim exceeds the sum of US$400,000 (or such other sum as the parties may agree) the parties may further agree that the arbitration shall be conducted in accordance with the LMAA Intermediate Claims Procedure current at the time when the arbitration proceedings and commenced. Where the reference is to three arbitrators the procedure for making appointments shall be in accordance with the procedure for full arbitration stated above.

2. ALTERNATIVE ARBITRATION BY AGREEMENT

Notwithstanding the preceding provisions of this Article, it is recognized that in the event of any dispute or difference of opinion arising in regard to the construction of the VESSEL, her machinery and equipment, or concerning the quality of materials or workmanship thereof or thereon, such dispute may be referred to the Classification Society upon mutual agreement of the parties hereto. In such case, the opinion of the Classification Society shall be final and binding on the parties hereto.

3. NOTICE OF AWARD

Notice of any award shall immediately be given by email to the SELLER and the BUYER.

4. EXPENSES

The arbitrator(s) or the Classification Society, as applicable, shall determine which party shall bear the expenses of the arbitration or the proportion of such expenses which each party shall bear.

5. AWARD OF ARBITRATION

Award of arbitration, shall be final and binding upon the parties concerned. Any right of appeal available under the laws of England is hereby expressly precluded and excluded by the parties hereto.

56 / 82

6. ENTRY IN COURT

Judgment on any award may be entered in any court of competent jurisdiction.

7. ALTERATION OF DELIVERY TIME

In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the SELLER shall not be entitled to extend the Delivery Date as defined in Article VII hereof and the BUYER shall not be entitled to postpone its acceptance of the VESSEL on the Delivery Date. However, if the construction of the VESSEL is affected by any arbitration, the SELLER shall then be permitted to extend the Delivery Date as defined in Article VII and the decision or the award shall include a finding as to what extent the SELLER shall be permitted to extend the Delivery Date.

57 / 82

ARTICLE XIV RIGHT OF ASSIGNMENT

Neither of the parties hereto shall assign this CONTRACT to any other individual, firm, company or corporation unless prior written consent of the other party is given in writing (such consent not to be unreasonably withheld or delayed).

Notwithstanding the foregoing, the BUYER may:

(i) novate its rights and obligations under this Contract to any fully guaranteed affiliate of the Buyer upon condition that the Corporate Guarantor guarantees in accordance with the format in Exhibit B the obligations of such affiliate in a manner reasonably satisfactory to the SELLER (in which event the parties to this Contract shall execute a novation agreement in a form reasonably mutually agreed to by the parties), or

(ii) assign the benefit, but not the obligations, of this Contract to a financial bank or financial institution involved in the provision of financing to the BUYER (in which event the SELLER shall execute an acknowledgement to the financiers upon receipt of a notice of assignment in a form reasonably acceptable to the SELLER)

In case novation or assignment takes place, the SELLER shall not, by virtue of the novation or assignment, have any additional obligations and/or risks other than those existing prior to the date when such novation or assignment becomes effective.

58 / 82

ARTICLE XV TAXES AND DUTIES

1. TAXES

All costs for taxes including, but not limited to, stamp duties, dues, and levies, if any, incurred in connection with this CONTRACT in the People’s Republic of China shall be borne by the SELLER. Any taxes and/or duties imposed upon those items or services procured by the SELLER in the People’s Republic of China or elsewhere for the construction of the VESSEL shall be borne by the SELLER.

The BUYER shall be responsible for the personal income tax for any person it employs, including Supervisor or other BUYER’s staff, agent and representatives who work at the BUILDER’s shipyard and premise.

All taxes, duties, stamps, dues, levies and fees of whatsoever nature incurred or imposed in China in respect of the BUYER Supplied Items, if any, shall be borne by the BUYER.

2. DUTIES

The BUYER shall bear and pay all taxes, duties, stamps and fees incurred outside China in connection with execution and/or performance of this CONTRACT by the BUYER, except for taxes, duties, stamps, dues, levies and fees imposed upon those items which are to be procured by the SELLER for the construction of the VESSEL in accordance with the terms of this CONTRACT and the Specifications. The Seller shall within its capability provide the assistance to Buyer in relating to the taxes of Buyer’s Supply items where reasonable possible for the procedure.

Any tax or duty other than those described hereinabove, if any, shall be borne by the BUYER.

59 / 82

ARTICLE XVI PATENTS, TRADEMARKS AND COPYRIGHTS

The machinery and equipment of the VESSEL may bear the patent number, trademarks or trade names of the manufacturers. The SELLER shall defend and save harmless the BUYER from patent liability or claims of patent infringement of any nature or kind, including costs and expenses for, or on account of any patented or patentable invention made or used in the performance of this CONTRACT and also including cost and expense of litigation, if any.

Nothing contained herein shall be construed as transferring any patent or trademark rights or copyright with respect to equipment, the Specifications, plans, drawings, technical descriptions, calculations, tests results and other data, and information and documents concerning the design and construction of the VESSEL covered by this CONTRACT, and all such rights are hereby expressly reserved to the true and lawful owners thereof.

The parties undertake, until the delivery of the vessel, not to disclose the same or divulge any Confidential Information without the prior written consent of the other party, except where such disclosure is:

60 / 82

Provided that the BUILDER and the BUYER, when making such disclosure, shall require the third party receiving such Confidential Information to keep such information confidential on the same terms as provided in this Article.

For the purposes of this Article, “Confidential Information” means any data, specifications, drawings, reports or other documents or information supplied or made available by one party to the other in connection with the design and construction of the Vessel , except information: (a) which was developed by and in possession of either party prior to first receipt from the other party; and/or (b) which at the date hereof or hereafter becomes, through no wrongful act or failure to act on the part of either party, published information generally known on a non-confidential basis; and/or (c) which is hereafter furnished to the either party by a third party as a matter of right without restrictions on disclosure; and/or (d) which is already a public knowledge in the market.

The SELLER’s indemnity hereunder does not extend to equipment or parts supplied by the BUYER to the BUILDER if any.

The SELLER retains all rights with respect to the Specifications, and plans and working drawings, technical descriptions, calculations, test results and other data, information and documents, with BUYER’s Comments incorporated, concerning the design and construction of the VESSEL and the BUYER undertakes therefore not to disclose the same or divulge any information contained therein to any third parties, without the prior written consent of the SELLER, except where it is necessary for usual operation, repair and maintenance, sale or charter of the VESSEL.

Nothing in this ARTICLE shall prevent the SELLER from disclosing any specifications, drawings, or designs relating to the VESSEL, including those developed by the PARTIES during this CONTRACT, to other customers or potential customers (except where such information includes the intellectual property of the BUYER).

The BUYER shall forthwith notify the SELLER of any claims for any intellectual property or industrial proprietary rights (including without limitation patents, trademarks, copyrights, utility models, registered designs and models and/or knowhow) related infringement upon it becoming aware of such claims.

61 / 82

The SELLER shall have full control and decision over any discussion, mediation, settlement and/or legal proceedings (i.e., litigation or arbitration) in respect of and/or in connection with such claims. The Seller agrees to provide the Buyer with a copy of the settlement in relating to such claims before signing of the settlement, if any.

the SELLER shall in no event be liable to the BUYER for (i) consequential loss or special loss; or (ii) any damages, losses, costs and/or expenses arising from any cause whatsoever regardless of whether the aforesaid damages, losses, costs and/or expenses are directly or indirectly occasioned to the BUYER by reason of any claims for any intellectual property or industrial proprietary rights (including without limitation patents, trademarks, copyrights, utility models, registered designs and models and/or knowhow) related infringement; (iii) loss of time, loss of use, loss of hire, loss of profit or earnings or demurrage arising from any cause whatsoever.

62 / 82

ARTICLE XVII NOTICE

Any and all notices and communications in connection with this CONTRACT shall be addressed as follows:

To CSTC: CHINA SHIPBUILDING TRADING CO., LTD.

To the BUILDER: JIANGNAN SHIPYARD (GROUP) Co., LTD.

Any notices and communications sent by CSTC or the BUILDER alone to the BUYER shall be deemed as having being sent by both CSTC and the BUILDER.

Any change of address shall be communicated in writing by registered mail or email by the party making such change to the other party and in the event of failure to give such notice of change, communications addressed to the party at their last known address shall be deemed sufficient.

Any and all notices, requests, demands, instructions, advice and communications in connection with this CONTRACT shall be deemed to be given at, and shall become effective from, the time when the same is delivered to the address of the party to be served, provided, however, that registered airmail shall be deemed to be delivered Ten (10) days after the date of dispatch, express courier service shall be deemed to be delivered Five (5) days after the date of dispatch, and email transmission shall be deemed as delivered upon the subject email has been moved to the “Sent” box on the sending computer.

63 / 82

Any and all notices, communications, Specifications and drawings in connection with this CONTRACT shall be written in the English language and each party hereto shall have no obligation to translate them into any other language.

64 / 82

ARTICLE XVIII EFFECTIVE DATE OF CONTRACT

This CONTRACT shall become effective upon being signed by both parties.

65 / 82

ARTICLE XIX INTERPRETATION

1. LAW APPLICABLE

The parties hereto agree that the validity and interpretation of this CONTRACT and of each Article and part hereof, , shall be governed by and interpreted in accordance with the laws of England.

2. DISCREPANCIES

All general language or requirements embodied in the Specifications are intended to amplify, explain and implement the requirements of this CONTRACT. However, in the event that any language or requirements so embodied in the Specifications permit an interpretation inconsistent with any provision of this CONTRACT, then in each and every such event the applicable provisions of this CONTRACT shall govern. The Specifications and plans are also intended to explain each other, and anything shown on the plans and not stipulated in the Specifications or stipulated in the Specifications and not shown on the plans, shall be deemed and considered as if embodied in both. In the event of conflict between the Specifications and plans, the Specifications shall govern.

However, with regard to such inconsistency or contradiction between this CONTRACT and the Specifications as may later occur by any change or changes in the Specifications agreed upon by and among the parties hereto after execution of this CONTRACT, then such change or changes shall govern.

3. DEFINITIONS

“Affiliate” shall mean any other entity directly or indirectly controlling or controlled by or under direct or indirect common control with such specified party. For the purposes of this definition, “control” (including, with correlative meanings, “controlling”, “controlled by”, and “under common control with”) means the power to direct or cause the direction of the management and policies of such entity, directly or indirectly, whether through the ownership of voting securities, by contract or otherwise and, it being understood and agreed that with respect to a corporation, limited liability company or partnership, control shall mean direct or indirect ownership of at least 50% of the voting stock, or limited liability company interest, general partnership interest or voting interest in any such corporation, limited liability company or partnership.

66 / 82

“Banking Day(s)” are days on which banks are open both in Beijing, P.R. China, and New York City, U.S.A.

“Business Day(s)” are days on which the working day(s) in P. R. China and London, England are others than Saturday, Sunday and Public Holiday.

In absence of stipulation of“Banking Day(s)” or “Business Day(s)”, the “Day(s)” or “day(s)” shall be taken as “calendar day(s)”.

“Final Award” means a published arbitration award in respect of any disputes arising out of or in connection with this CONTRACT where any right of appeal available in respect of such arbitration award under the applicable law is waived/excluded or is not exercised by the BUYER and the SELLER within the time limit under such applicable law and in case of such arbitration award is appealed, the final judgement from any court of competent jurisdiction on such award upon appeal by either the BUYER or the SELLER where any right of appeal available in respect of such judgement under the applicable law is waived/excluded or is not exercised by the BUYER and the SELLER within the time limit under such applicable law.

4. ENTIRE AGREEMENT

This CONTRACT sets forth the entire understanding of the parties with respect to the subject matter discussed herein. It supersedes all prior discussions, negotiations and agreements, (including but not limited to the Letter of Intent/Option Agreement) whether oral or written, expressed or implied.

67 / 82

ARTICLE XX ANTI-BRIBERY AND CORRUPTION

The PARTIES agree that in connection with the performance of this CONTRACT, they shall each:

Each Party represents and warrants that neither it nor any member of its organization has committed any breach of applicable anti-corruption legislation and will not commit a breach of applicable anti-corruption legislation during this CONTRACT. Each Party shall immediately notify the other ifit receives or becomes aware of any matter that is prohibited by this ARTICLE.

The PARTIES shall, within its capabilities, require its subcontractors to comply with the requirements of this ARTICLE.

68 / 82

ARTICLE XXI TRADE AND COMPLIANCE

Notwithstanding any other Article in this CONTRACT:

(a) Each Party warrants, represents and undertakes to the other Party that at the date of entering into this CONTRACT and continuing until the delivery and acceptance of the VESSEL: (i) neither it nor any of its directors, officers or employees are listed on the Specially Designated Nationals and Blocked Persons List maintained by the U.S. Department of the Treasury’s Office of Foreign Asset Control, the Consolidated Financial Sanctions List maintained by the European Commission, the Consolidated List of Financial Sanctions Targets in the U.K. maintained by HM Treasury of the U.K., and sanction lists maintained by Ministry of Foreign Affairs of the People’s Republic of China which may prohibit or restrict either Party’s entry into this CONTRACT and/or construction and delivery of the Vessel (the “Sanctions”), and(ii) it is not owned and/or controlled by an entity listed on any Sanctions (for the purposes of this Article, ‘owned’ means where any parties, directly or indirectly, owns a 50% or greater interest in any entity, individually or in the aggregate, without need to prove any form of joint arrangement between said parties or that the shares are held jointly); and (iii) its entry into and performance of this CONTRACT is not prohibited or restricted by, and does not expose the other Party, the VESSEL or the other Party’s directors, officers or employees or the sale and purchase of the VESSEL under this CONTRACT to the aforesaid Sanctions; and

(b) During the performance of this CONTRACT, a Party shall notify the other Party in writing immediately if such Party is aware that there is a breach of the aforesaid Paragraph 1 and in such event, both Parties shall provide and share with each other without delay any and all necessary information in relation to the Sanctions.

Both Parties shall then discuss and consider in good faith within ninety (90) days after the date of aforesaid notice or such longer period as may be mutually agreed in writing by both Parties (the “Discussion Period”) the acceptable and lawful ways and options, including but not limited to (the “Acceptable Solution”):

69 / 82

and the Parties shall make their reasonable efforts to achieve the Acceptable Solution.

During the Discussion Period that both Parties are discussing and considering the Acceptable Solution, the Delivery Date shall be extended for a period of the Discussion Period and if and to the extent that there arises any non-performance or suspension of performance by either Party of any or all its obligations under this CONTRACT due to such Party (including such Party’s bank, subcontractor and/or supplier’s) compliance with the Sanctions, such non-performance or suspension of performance shall not constitute a breach of this CONTRACT. For the avoidance of doubt and without prejudice to each Party’s other rights and remedies, neither Party shall have right to rescind or cancel this CONTRACT during the Discussion Period.

If the Parties identify an Acceptable Solution within the Discussion Period, the Parties shall closely and diligently work together to immediately implement the Acceptable Solution within sixty (60) days after the end of the Discussion Period or such longer period as may be mutually agreed in writing by both Parties for the purpose of implementing the Acceptable Solution (the “Extended Period”). The Delivery Date shall be further extended for a further period of the Extended Period or until completion of the Acceptable Solution (whichever is earlier)•.

If the Parties fail to identify an Acceptable Solution within the Discussion Period or fail to implement the Acceptable Solution within the Extended Period, to the extent permitted by the Sanctions and applicable laws:

i) if the SELLER is the party that is in breach of Paragraph 1, the BUYER shall have the right to terminate this CONTRACT within fifteen (15) days after the expiry of the Discussion Period or the Extended Period (as the case may be). In this case, the provisions of Articles X.2 and X.3 shall apply but the SELLER shall refund to the BUYER all instalments paid by the BUYER without interest and, upon the SELLER’s aforesaid refund of the instalments, all obligations, duties and liabilities of the one Party towards the other Party and all rights, benefits and claims against one Party by/of the other Party under or in connection with this CONTRACT and/or any applicable laws shall be forthwith completely discharged.

70 / 82

ii) if the BUYER is the party that is in breach of Paragraph 1, the SELLER shall have the right to terminate this CONTRACT within fifteen (15) days after the expiry of the Discussion Period or the Extended Period (as the case may be), and upon such termination, the SELLER shall be entitled to all rights as provided in the provisions of Articles XI.4 and XI.5 (including without limitation, the rights to retain the instalment(s) paid by the BUYER on account of this CONTRACT and to sell or otherwise dispose the VESSEL and any part ofit and the BUYER’s Supplied Items as it deems fit)

However, should no Party elect to terminate this CONTRACT within the fifteen (15) days period after the expiry of the Discussion Period, then the Parties shall be regarded as having elected to continue to perform this CONTRACT and, in such event, the Delivery Date as provided in Article VII shall be automatically extended for a period of the Discussion Period, plus the Extended Period, plus fifteen (15) days and the relevant terms of this CONTRACT shall be correspondingly adjusted in consequence of such extension.

For the avoidance of any doubt, save for Sanctions caused by or applicable to either Party as set out above, no other sanction of whatsoever nature or any similar measures/restrictions onto either Party shall give rise to any right to the other Party for termination of the Contract or any claims for loss or damage, whether under this Contract or any applicable laws.

(c) Notwithstanding anything in this Article to the contrary, the BUYER and/or the SELLER shall not be required to do anything which constitutes a violation of the national, international and supranational laws and regulations to which either of them is subject.

71 / 82

In WITNESS WHEREOF, the parties hereto have caused this CONTRACT to be duly signed on the day and year first above written.

72 / 82

Exhibit “A”: IRREVOCABLE LETTER OF GUARANTEE

(Refund Guarantee)

Dear Sirs,

Irrevocable Letter of Guarantee No.[***]

At the request of JIANGNAN SHIPYARD (GROUP) CO., LTD. and in consideration of your agreeing to pay JIANGNAN SHIPYARD (GROUP) CO., LTD and CHINA SHIPBUILDING TRADING CO., LTD.. (hereinafter collectively called the “SELLER”) the instalments before delivery of the VESSEL under the contract concluded by and amongst you, and the SELLER dated[***] for the construction of one (I) 48,500 CBM LEG/LPG CARRIER to be designated as Hull No.H2854 hereinafter called “the CONTRACT”), for good and valuable consideration, receipt and sufficiency acknowledged, we, [***], do as primary obligor hereby irrevocably guarantee repayment to you by the SELLER of an amount up to but not exceeding a total amount of US$ 51,450,000.00 say United States Dollars Fifty One Million Four Hundred and Fifty Thousand Only representing the aggregate of the

73 / 82

Should the SELLER fail to make such repayment, we shall pay you the amount the SELLER ought to pay with no interest if cancellation of the CONTRACT is exercised by you for the delay caused by the Permissible Delays in accordance with the provisions of Article VIII.3 or total loss in accordance with the provisions of Article XII.2(b), or together with an interest at the rate of Five percent (5%) per annum if the cancellation of the CONTRACT is exercised by you in accordance with the provisions of Article III l(c), 2(c), 3(c) or 4(c) of the CONTRACT within Thirty (30) Business Days after our receipt of the relevant written demand from you for repayment.

However, if within twenty-five (25) business days after your written demand, the SELLER or you notify us in writing that there is a dispute between you and the SELLER in relation to:

(1) whether the SELLER shall be liable to repay the instalment paid by you; and

(2) consequently, whether you shall have the right to demand payment from us,

and that such dispute is submitted either by the SELLER or by you for arbitration in accordance with Article XIII of the CONTRACT, we shall be entitled to withhold and defer payment until the Final Award is published or a settlement agreement entered into between you and the SELLER. We shall not be obligated to make any payment to you unless the Final Award orders the SELLER to make repayment or the settlement agreement so provides. If the SELLER fails to honour the Final Award or settlement agreement then we shall refund to you to the extent the Final Award orders or settlement agreement requires but not exceeding the aggregate amount of this guarantee plus the interest described above. We shall make payment within Twenty-Five (25) Business Days after the date of receipt by us of your further written demand accompanied by (i) a copy of the Final Award or settlement agreement and (ii) your written statement that SELLER has not within Thirty (30) days of its date complied with the Final Award or Settlement agreement

74 / 82

“Final Award” means a published arbitration award in respect of any disputes arising out of or in connection with the CONTRACT where any right of appeal available in respect of such arbitration award under the applicable law is waived/excluded or is not exercised by the BUYER and the SELLER within the time limit under such applicable law and in case of such arbitration award is appealed, the final judgement from any court of competent jurisdiction on such award upon appeal by either the BUYER or the SELLER where any right of appeal available in respect of such judgement under the applicable law is waived/excluded or is not exercised by the BUYER and the SELLER within the time limit under such applicable law.

All payments to be made by us hereunder shall be made by telegraphic transfer in United States Dollars; and be paid without set off or counterclaim; or deduction or withholding for any present or future taxes or restrictions in [the People’s Republic of China] or other similar charges. If we shall be required by law to make any such deduction from any payment, the sum payable shall be increased as may be necessary so that, after making all required deductions (including, without limitation, deductions applicable to additional sums payable under this provision), you receive an amount equal to the sum you would have received where no deductions have been made

This Letter of Guarantee shall become effective from the time of the actual receipt of the l^st instalment by the SELLER from you and the amount effective under this Letter of Guarantee shall correspond to the payment of the instalment(s) actually made by you under the CONTRACT prior to the delivery of the VESSEL. However, the available amount under this Letter of Guarantee shall in no event exceed the above-mentioned total aggregate amount of the instalment(s) actually paid to the SELLER, together with interest calculated, as described above without interest or, at Five percent (5%) per annum, as the case may be for the period commencing from the date of receipt by the SELLER of the respective instalment to the date of repayments thereof.

All demands, claims and notices in connection with this Letter of Guarantee shall be validly given if sent to us by AUTHENTICATED SWIFT (SWIFTCODE. [***]) to be sent through[***].

75 / 82

This Letter of Guarantee shall remain in force until the VESSEL has been delivered to and accepted by you (which shall be conclusively evidenced by presentation to us of an copy of fully signed protocol of delivery and acceptance of the VESSEL) or refund has been made by the SELLER or ourselves, or until March 31st, 2028, whichever occurs the earliest, Upon expiry of this Letter of Guarantee for the aforesaid reasons, this Letter of Guarantee shall automatically become null and void, regardless of whether returned to us for cancellation or not, and any demand received after expiry shall be ineffective. However, if on or prior to this date, an arbitration has been commenced between you and the SELLER pursuant to Article XIII of the Contract, then this Letter of Guarantee shall remain in full force and effect until the date falling 45 days after the date of the final arbitration award or settlement agreement.

For the avoidance of doubt, our liability under this Guarantee shall not be affected, discharged, impaired or diminished by any novation, amendment, supplement or variation, of the CONTRACT, the irregularity, illegality, unenforceability or invalidity in whole or in part of the CONTRACT or any other guarantee, surety or security for the obligations of the SELLER thereunder; any delay in enforcing your rights of under the CONTRACT or otherwise or waiver, time or indulgence granted to the SELLER; any insolvency, bankruptcy, liquidation or re-organisation of either party constituting the SELLER; the dissolution of either party constituting the SELLER (or its otherwise ceasing to exist) or by any other matter or thing which, but for this paragraph, might have operated to affect our liability hereunder.

This letter of Guarantee is governed by the lays of England. Any and all disputes in connection with this letter of Guarantee shall be submitted to arbitration in London, England in according with the Arbitration Act 1996 and the rules of the London Maritime Arbitrator’s Association.

For [the Refund Guarantor]

76 / 82

Exhibit “B”:IRREVOCABLE LETTER OF GUARANTEE FOR THE SECOND, THIRD, FOURTH AND FIFTH INSTALMENTS

From:[***)

Date: [***]

56(▇▇) ▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇ ▇▇▇, Beijing

100044, the People’s Republic of China

and

JIANGNAN SHIPYARD (GROUP) CO., LTD.

▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇., ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, the People’s Republic of China

Dear Sirs,

77 / 82

In the event that the BUYER fails to punctually. pay the Instalments guaranteed hereunder or the BUYER fails to pay any interest thereon, and any such default continues for a period of fifteen (15) days, then, upon receipt by us of your first written demand, we shall immediately pay to you or your assignee the unpaid 2nd installment, or the 3rd installment, or the 4th installment or the 5th instalment together with the interest as specified in paragraph. (3) hereof, without requesting you to take any or further action, procedure or step against the BUYER or with respect to any other security which you may hold.

78 / 82

79 / 82

(a) All the 2nd and the 3rd and 4th and 5th instalments guaranteed hereunder in the total amount of United States Dollars Forty-One Million One Hundred and Sixty Thousand only (US$ 41,160,000.00); and

(b) Interest at the rate of five percent (5%) per annum on the Instalment for a period of sixty (60) days in the amount of United States Dollars One Hundred and Thirty Thousand Six Hundred and Sixty Seven only (US$343,000.00).

Very Truly Yours,

By:[***)

80 / 82