ASHFORD PRIME MUTUAL EXCLUSIVITY AGREEMENT

Exhibit 10.6

EXECUTION VERSION

ASHFORD PRIME

THIS ASHFORD PRIME MUTUAL EXCLUSIVITY AGREEMENT (this “Agreement”) is entered as of the 19th day of November, 2013 (the “Effective Date”) by and among ASHFORD HOSPITALITY PRIME LIMITED PARTNERSHIP, a Delaware limited partnership (the “Partnership”), ASHFORD HOSPITALITY PRIME, INC., a Maryland corporation (the “REIT”), and REMINGTON LODGING & HOSPITALITY, LLC, a Delaware limited liability company (“Manager”), and is consented and agreed to by ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ as a Remington Affiliate.

THE PARTIES HERETO ENTER THIS AGREEMENT on the basis of the following facts, understandings and intentions:

A. Prior to the date hereof, the Remington Parties have been actively engaged in various aspects of acquisition, development, renovation, management and operation of Hotel Properties.

B. The Remington Parties plan to continue to engage in various aspects of acquisition, development, project management, renovation, management and operation of Hotel Properties.

C. The REIT has undertaken, or will concurrently with it becoming a publicly traded company, undertake to acquire, develop, invest in, or purchase Hotel Properties that meet the REIT’s Initial Investment Guidelines.

D. The REIT Parties desire to benefit from the hotel development, project management and property management experience of the Remington Parties and have agreed to engage Manager in connection with certain investment opportunities (subject to an Independent Director Election); provided, the Remington Parties agree to grant the REIT Parties a first right of refusal with respect to any Remington Transaction that any of the Remington Parties source or identify, meeting the Initial Investment Guidelines of the REIT Parties.

NOW, THEREFORE, IN CONSIDERATION of the mutual covenants and promises of the parties hereto, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:

1. Definitions. All terms used in this Agreement but not defined herein shall have the meanings as set forth on Exhibit A attached hereto and incorporated herein for all purposes (applicable to both the singular and plural forms of the terms defined).

2. Term of Agreement. This Agreement shall commence as of the Effective Date and shall terminate ten (10) years thereafter (the “Initial Term”), unless earlier terminated in whole or in part (with respect to the Remington Exclusivity Rights or the REIT Exclusivity Rights, or both, as applicable), due to (a) an Event of Default under this Agreement and the non-defaulting party elects to terminate this Agreement, (b) the occurrence of a Remington Termination Event, (c) the occurrence of a REIT Termination Event, or (d) termination of the Master Management Agreement with respect to all of the Hotel Properties covered thereby

-1-

pursuant to an Event of Default (as defined therein) applicable to all of the Hotel Properties then covered by the Master Management Agreement as set forth in Section 19.02 thereof and the non-defaulting party thereunder elects in writing to terminate this Agreement (the events in subparagraphs (a) through (d) herein each called, a “Termination Event”). Notwithstanding the foregoing, the Initial Term shall automatically be extended at the expiration of the Initial Term (with respect to the Remington Exclusivity Rights or the REIT Exclusivity Rights, or both, as applicable), on the same terms and conditions contained herein, for each of three (3) successive periods of seven (7) Fiscal Years each and one final period of four (4) years; provided, however, that at the time of the expiration of the Initial Term or extension term, as applicable, a Termination Event with respect to the entirety of this Agreement does not then exist. The Initial Term as extended by any extension terms, if any, shall herein be called the “Term.” Upon the occurrence of a Termination Event (except where such Termination Event is due to an Event of Default by any of the Remington Parties under this Agreement), the Remington Parties shall be entitled to receive the Reimbursement Amount payable under this Agreement. Subject to Section 8(b) below, upon termination of the entirety of this Agreement, the Remington Parties and the REIT Parties shall have no further obligations to one another pursuant to this Agreement, except for any indemnification obligations contained herein, which shall survive such termination. Any termination of this Agreement in whole or in part shall not terminate any existing management and/or development agreements or any other agreements executed between the parties hereto that are then continuing and in full force and effect.

3. Early Termination Events.

(a) Remington Termination Event. Upon the occurrence of any of the following events, the Remington Parties acting through Manager may, at their election exercised in their sole and absolute discretion and upon written notice to the REIT Parties, terminate the REIT Exclusivity Rights:

(i)

▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ (1) is removed as chief executive officer or chairman of the board of directors of the REIT, (2) is not re-appointed as chief executive officer or chairman of the board of directors of the REIT, or (3) resigns as chief executive officer or chairman of the board of directors of the REIT;

(ii)

The termination of the Advisory Agreement for any reason pursuant to its terms and ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ is no longer serving as the chief executive officer and chairman of the board of directors of the REIT; or

(iii)

If the REIT Parties terminate the Remington Exclusivity Rights based upon a REIT Termination Event.

Upon the REIT Parties’ receipt of written notice of termination of the REIT Exclusivity Rights from the Remington Parties, the REIT Exclusivity Rights set forth in this Agreement shall terminate; however, all other terms and provisions of this Agreement shall remain in full force and effect, including the Remington Exclusivity Rights, until this Agreement expires or is otherwise terminated as permitted under this Agreement.

-2-

(b) REIT Termination Event. Upon the occurrence of any of the following events, the REIT Parties may, at their election exercised in their sole and absolute discretion and upon written notice to the Remington Parties, terminate the Remington Exclusivity Rights:

(i)

The Manager fails to qualify as an “eligible independent contractor” as defined in Section 856(d)(9) of the Internal Revenue Code, which results in a termination of the Master Management Agreement;

(ii)

Any one of the Remington Parties ceases to be controlled by ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇. and/or ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ and/or their respective family partnership or trusts, the sole members of which are at all times lineal descendants of ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇. or ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ (including step children) and spouses of any of the foregoing, with “control” meaning (a) the possession, directly or indirectly, of a majority of the capital stock and voting power of such Remington Parties, or (b) the power to direct or cause the direction of the management and policies of the Remington Parties in the capacity of chief executive officer, president, chairman, or other similar capacity where either is actively engaged and/or involved in providing such direction or control and spend substantial time managing the Remington Parties;

(iii)

If there is a Change In Control of the REIT and the REIT terminates the Master Management Agreement with respect to all Hotels and Non-Managed Hotels covered thereby, provided that the REIT first pays to the Manager the greater of (A) the product of (1) 65% of the aggregate Base Management Fees and Incentive Fees budgeted in the Annual Operating Budgets applicable to the Hotels for the full current Fiscal Year in which such termination is to occur (but in no event less than the Base Management Fees and Incentive Fees for the preceding full Fiscal Year) by (2) nine (9), or (B) the product of (1) 65% of the Project Management Fees and Market Service Fees estimated to be payable to Manager with respect to the Non-Managed Hotels pursuant to Capital Improvement Budgets for the full current Fiscal Year in which such termination is to occur (but in no event less than the aggregate Project Management Fees and Market Services Fees paid to Manager for the preceding Fiscal Year) and (2) nine (9);

(iv)

If the Remington Parties terminate the REIT Exclusivity Rights by reason of a Remington Termination Event; or

(v)

The termination of the Advisory Agreement pursuant to its terms and ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ is no longer serving as the chief executive officer and chairman of the board of directors of the REIT.

Upon the Remington Parties’ receipt of written notice of termination of the Remington Exclusivity Rights from the REIT Parties, the Remington Exclusivity Rights set forth in this Agreement shall terminate; however, all other terms and provisions of this Agreement shall remain in full force and effect, including the REIT Exclusivity Rights, until this Agreement expires or is otherwise terminated as permitted under this Agreement.

-3-

4. REIT Exclusivity Rights.

(a) Remington Transaction. If any of the Remington Affiliates identifies an opportunity to develop and construct, acquire all or a portion of, or invest in, a Hotel Property that meets the Initial Investment Guidelines of the REIT (herein each called, a “Remington Transaction”), the Remington Parties on behalf of themselves and their Affiliates, hereby grant to the REIT Parties the first right of refusal to purchase and assume such Remington Transaction and agree not to pursue any such opportunity (except as provided in this Section 4) and acknowledge that each such opportunity will belong to the REIT Parties (the “REIT Exclusivity Rights”). The REIT Exclusivity Rights shall not apply to any Excluded Remington Transactions or any investment in a Hotel Property that does not meet the initial Investment Guidelines of the REIT. For the avoidance of doubt, the REIT Exclusivity Rights shall be, with respect to opportunities that satisfy the REIT’s initial Investment Guidelines, superior to any exclusivity rights or right of first refusal of the Ashford Trust pursuant to the Ashford Trust Mutual Exclusivity Agreement (the “Ashford Trust Exclusivity Rights”).

If the REIT materially modifies its Initial Investment Guidelines without the written consent of Manager (on behalf of the Remington Parties), which such consent may be withheld in its sole and absolute discretion and may further be subject to the consent of the Ashford Trust Parties, the Remington Parties will have no obligation to present or offer a Remington Transaction to the REIT Parties at any time thereafter, regardless of any subsequent modifications by the REIT to its Investment Guidelines. For purposes hereof, a “material” modification of the REIT’s initial Investment Guidelines shall mean any modification of the Initial Investment Guidelines which cause the REIT’s Investment Guidelines to be competitive with Ashford Trust’s Investment Guidelines. Instead, the Remington Parties, subject to the superior rights of the Ashford Trust Parties or any other Person with which any of the Remington Parties may have a right of first offer agreement or similar agreement, shall use their reasonable discretion to determine how to allocate such Remington Transaction. The REIT Parties acknowledge the terms and conditions of the Ashford Trust Mutual Exclusivity Agreement, and further acknowledge that if the REIT materially modifies its Initial Investment Guidelines without the consent of Manager (on behalf of the Remington Parties), the Ashford Trust Parties, unless otherwise waived, will have superior rights to Remington Transactions pursuant to the terms of the Ashford Trust Mutual Exclusivity Agreement. Further, the REIT Parties acknowledge that if the REIT materially modifies its Initial Investment Guidelines without the written consent of Manager, that the REIT Parties will not be entitled to preferential treatment with respect to Remington Transactions. Notwithstanding the foregoing, if the REIT materially modifies its Initial Investment Guidelines without the consent of Manager, the Remington Exclusivity Rights provided herein shall remain in full force and effect.

(b) Remington Notice. In connection with each Remington Transaction, the Remington Parties on behalf of the Remington Affiliates shall deliver to the REIT Parties, with a copy to the Independent Directors, a written notice (the “Remington Notice”) in reasonable detail sufficient to describe the material terms of the Remington Transaction, including without limitation, as applicable, a description of the nature of the transaction (acquisition, development, or other investment), description and location of the asset, name of franchisor, inspection period, timing for closing, ▇▇▇▇▇▇▇ money requirements, closing costs, an accounting of the Reimbursement Amount in reasonable detail, and to the extent available and in the possession of the Remington

-4-

Parties, copies of any letters of intent, purchase and sale agreements, or development agreements, as applicable (the “REIT Transaction Documents”). Such Remington Notice shall be delivered to the REIT Parties (with a copy to the Independent Directors), as soon as reasonably practical after the opportunity of the Remington Transaction is identified for any of the Remington Affiliates.

(c) REIT ROFR. The REIT Parties shall have the right, through any of the REIT Affiliates, to accept or decline such Remington Transaction (the “REIT ROFR”) by giving written notice (the “REIT ROFR Notice”) to the Remington Parties at any time on or before ten (10) business days from its receipt of a Remington Notice (the “REIT ROFR Period”).

(d) Acceptance of Remington Transaction. Any acceptance of the Remington Transaction by the REIT Parties shall be in accordance with the following terms and conditions:

(i)

Upon delivery of a REIT ROFR Notice accepting the Remington Transaction, the REIT Parties (through any of the REIT Affiliates) shall assume (and the applicable Remington Affiliate shall assign) any applicable REIT Transaction Documents containing materially the same terms and conditions as set forth in the Remington Notice within ten (10) business days of the receipt by the Remington Parties of the REIT ROFR Notice;

(ii)

The REIT Parties (through any of the REIT Affiliates) shall pay the Reimbursement Amount to the applicable Remington Affiliate;

(iii)

The REIT Parties (through any of the REIT Affiliates) shall pursue the Remington Transaction in accordance with the applicable REIT Transaction Documents with commercially reasonable diligence; and

(iv)

If the Remington Transaction involves the management and operation of a Hotel Property, and/or the construction, development, project management or the performance of Project Related Services relating to a Hotel Property, the applicable REIT Affiliate assuming the Remington Transaction shall engage Manager, and Manager agrees to accept such engagement, to perform such services and execute the applicable documents as described in Section 5(b) below, provided Independent Director Disapproval has not been received.

(e) Rejection or Lapse of REIT ROFR; Failure to Close. If the REIT Parties fail to deliver a REIT ROFR Notice within the REIT ROFR Period or by REIT ROFR Notice reject or decline to purchase and assume the Remington Transaction, or the applicable REIT Affiliate fails to timely prepare and execute the proper REIT Transaction Documents with respect to the Remington Transaction, then the REIT ROFR shall lapse. The REIT Parties acknowledge that pursuant to the terms of the Ashford Trust Mutual Exclusivity Agreement, if the REIT ROFR lapses, the Ashford Trust Parties may exercise their rights to assume or acquire the Remington Transaction. Further, the applicable Remington Affiliate shall be entitled, subject to the Ashford Trust Exclusivity Rights, to proceed with the Remington Transaction described in the Remington Notice on materially the same terms and conditions as outlined therein within the time period established therein and in accordance with the underlying REIT Transaction Documents, subject

-5-

to reasonable extensions of the closing date. If the terms and conditions of the Remington Transaction materially change, then the Remington Parties hereby grant (on behalf of themselves and the applicable Remington Affiliate) to the REIT Parties the exclusive first right of refusal to purchase and assume the rights and obligations of the applicable Remington Affiliate with respect to such Remington Transaction on the changed terms and conditions and in connection therewith shall deliver to the REIT Parties a new Remington Notice (subject to the same time requirements for review and exercise as set forth in this Agreement).

(f) Additional Information. During the REIT ROFR Period with respect to each Remington Transaction and the related Hotel Property, the Remington Parties shall deliver to the REIT Parties upon the written request of the REIT Parties, from time to time and to the extent available, (i) any and all documents, correspondence and reports, including, without limitation, due diligence information (including, property condition reports, surveys, environmental reports), information and documents bearing on contracts, litigation and such other matters, and title and lien information; (ii) any notices of non-compliance with applicable laws bearing on such Hotel Property; (iii) quarterly financial information with respect to such Hotel Property showing hotel revenues and hotel operating expenses; and (iv) such other information relating to the Hotel Property or the Remington Transaction as reasonably requested by the REIT Parties.

(g) No Additional Fees. Reimbursement to the Remington Parties of the Reimbursement Amount shall be the sole payment to the applicable Remington Affiliate with regard to a Remington Transaction. The Remington Parties shall not receive any finder’s fee, brokerage fee, development fee, or other commissions or compensation with regard to any Remington Transaction.

5. Remington Exclusivity Rights.

(a) REIT Transaction; REIT Notice. If any of the REIT Parties or their Affiliates subsidiaries acquires or invests in (i) a Hotel Property or (ii) a Property for the purposes of development or construction of a Hotel Property, and such REIT Parties or their Affiliates have the right and/or control the right to direct the management of and/or development and construction of and/or capital improvements to or refurbishment of, or the provision of project management or other services, such as purchasing, interior design, freight management, or construction management for such Hotel Property or hotel improvements (herein each called, a “REIT Transaction”), the REIT Parties hereby agree (on behalf of themselves and the applicable REIT Affiliate) to engage Manager or an Affiliate of Manager (so long as such Affiliate constitutes an Eligible Independent Contractor and there has not been an Independent Director Disapproval), to provide, and Manager agrees to then provide or cause such Affiliate to provide, any such management, development and construction, capital improvement, refurbishment, and/or project management or other such services in connection with such REIT Transaction (the “Remington Exclusivity Rights”) and in connection therewith shall deliver to the Remington Parties, a written notice (the “REIT Notice”) which describes such REIT Transaction and the services to be provided by Manager, including, the description and location of the asset, name of the franchisor, and the development, construction or improvement timeline. The REIT Parties may engage a third party and not Manager or an Affiliate of Manager to provide any or all of the foregoing services in connection with the REIT Transaction if the REIT Transaction has received Independent Director Disapproval.

-6-

(b) Remington Transaction Documents.

(i)

Master Management Agreement. In the event that a REIT Transaction (for which Manager has been engaged) relates to the management and operation of a Hotel Property, the terms and conditions of the management, operation and any construction, renovations, improvements, refurbishments, or other services, such as purchasing, interior design, freight management, or construction management, to be undertaken with respect to such Hotel Property during the term of such management and operation, including the amount of any management, incentive, project or other service fees shall be either pursuant to the terms and conditions of the Master Management Agreement (and the Master Management Agreement shall be amended accordingly to include such Hotel Property), or pursuant to a management agreement with Manager or a subsidiary of Manager substantially in form of the Master Management Agreement.

(ii)

Development Agreement. In the event that a REIT Transaction relates to the development and construction of a Hotel Property, then the terms and conditions of any such development and construction, including the project oversight and developer management fees, shall be pursuant to the terms set forth in that certain form of Development Agreement attached hereto as Exhibit B.

6. Excepted Transactions. Notwithstanding anything contained in this Agreement to the contrary, the REIT Parties’ rights under Section 4 do not extend to the Excluded Remington Transactions and the Remington Parties’ rights under Section 4(d)(iv) or Section 5 do not extend to the Excluded REIT Transactions. Each party hereto agrees to give written notice to the other party of any Excluded REIT Transaction or Excluded Remington Transaction, as applicable, describing said transaction with reasonable detail.

7. Indemnity.

(a) Remington Parties’ Indemnity. Except as set forth in Section 7(b) below, the Remington Parties shall indemnify and hold the REIT Affiliates and Ashford Hospitality Advisors LLC, the REIT’s advisor, (and each of their respective agents, principals, shareholders, partners, members, officers, directors, attorneys and employees) harmless from and against all liabilities, losses, claims, damages, costs and expenses (including, but not limited to, reasonable attorneys’ fees and expenses) that may be incurred by or asserted against any such party and that arise from (i) the fraud, willful misconduct or gross negligence of any of the Remington Affiliates (other than any REIT Affiliate), (ii) the breach by the Remington Affiliates of any provision of this Agreement, or (iii) the breach by the Remington Affiliates of any Remington Transaction Documents first occurring prior to the date of the assumption of same by any of the REIT Affiliates. The REIT Parties shall promptly provide the Remington Parties with written notice of any claim or suit brought against any of them by a third party which might result in such indemnification.

(b) REIT Parties’ Indemnity. Except as set forth in Section 7(a) herein above, the REIT Parties shall indemnify and hold the Remington Affiliates (and their respective agents, principals, shareholders, partners, members, officers, directors, attorneys and employees)

-7-

harmless from and against all liabilities, losses, claims, damages, costs and expenses (including, but not limited to, reasonable attorneys’ fees and expenses) that may be incurred by or asserted against any such party and that arise from (i) the fraud, willful misconduct or gross negligence of the REIT Affiliates (other than any Remington Affiliate), or (ii) the breach by the REIT Affiliates of any provision of this Agreement (other than any Remington Affiliate). The Remington Parties shall promptly provide the REIT Parties with written notice of any claim or suit brought against any of them by a third party which might result in such indemnification.

(c) Indemnification Procedure. Any party obligated to indemnify the other party under this Agreement (the “Indemnifying Party”) shall have the right, by written notice to the indemnified party, to assume the defense of any claim with respect to which the indemnified party is entitled to indemnification hereunder. If the Indemnifying Party gives such written notice, (i) such defense shall be conducted by counsel selected by the Indemnifying Party and approved by the indemnified party, such approval not to be unreasonably withheld or delayed (provided, however, that the indemnified party’s approval shall not be required with respect to counsel designated by the Indemnifying Party’s insurer); (ii) so long as the Indemnifying Party is conducting such defense with reasonable diligence, the Indemnifying Party shall have the right to control said defense and shall not be required to pay the fees or disbursements of any counsel engaged by the indemnified party for services rendered after the Indemnifying Party has given the written notice provided for above to the indemnified party, except if there is a conflict of interest between the parties with respect to such claim or defense; and (iii) the Indemnifying Party shall have the right, without the consent of the indemnified party, to settle such claim, provided that such settlement involves only the payment of money, the Indemnifying Party pays all amounts due in connection with or by reason of such settlement and, as part thereof, the indemnified party is unconditionally released from all liability in respect of such claim. The indemnified party shall have the right to participate in the defense of such claim being defended by the Indemnifying Party at the expense of the indemnified party, but the Indemnifying Party shall have the right to control such defense (other than in the event of a conflict of interest between the parties with respect to such claim or defense). In no event shall (i) the indemnified party settle any claim without the consent of the Indemnifying Party so long as the Indemnifying Party is conducting the defense thereof in accordance with this Agreement; or (ii) if a claim is covered by the Indemnifying Party’s liability insurance, take or omit to take any action which would cause the insurer not to defend such claim or to disclaim liability in respect thereof.

8. Events of Default; Consequences; Remedies.

(a) Events of Default. The following shall constitute events of default (each an “Event of Default”):

(i)

The filing of a voluntary petition in bankruptcy or insolvency or a petition for reorganization under any bankruptcy law by any of the Remington Parties or the REIT Parties;

(ii)

The consent to any involuntary petition in bankruptcy or the failure to vacate, within ninety (90) days from the date of entry thereof, any order approving an involuntary petition by any of the Remington Parties or the REIT Parties;

-8-

(iii)

The entering of an order, judgment or decree by any court of competent jurisdiction, on the application of a creditor, adjudicating any of the Remington Parties or the REIT Parties as bankrupt or insolvent, or approving a petition seeking reorganization or appointing a receiver, trustee, or liquidator of all or a substantial part of such party’s assets, and such order, judgment or decree continues unstayed and in effect for any period of ninety (90) days or more;

(iv)

The appointment of a receiver for all or any substantial portion of the property of any of the Remington Parties or the REIT Parties;

(v)

The failure of any of the REIT Parties to make any payment required to be made in accordance with the terms of this Agreement within thirty (30) days after receipt of written notice from the Remington Parties specifying said default with reasonable specificity as to when such payment is due and payable; or

(vi)

The failure of any of the Remington Parties or the REIT Parties to perform, keep or fulfill any of the other covenants, undertakings, obligations or conditions set forth in this Agreement, and the continuance of such default for a period of thirty (30) days after written notice of said failure; provided, however, if such default cannot be cured within such thirty (30) day period and the Remington Parties or the REIT Parties, as the case may be, commences to cure such default within such thirty (30) day period and thereafter diligently and expeditiously proceeds to cure the same, such thirty (30) day period shall be extended so long as it shall require the Remington Parties or the REIT Parties, as the case may be, in the exercise of due diligence to cure such default, it being agreed that no such extension shall be for a period in excess of one hundred twenty (120) days.

(b) Consequence of Default. Upon the occurrence of any Event of Default, the non-defaulting party may, at its election, give the defaulting party written notice of intention to terminate this Agreement (after the expiration of any applicable grace or cure period provided in Section 8(a) above), and upon the expiration of thirty (30) days from the date of such notice, this Agreement shall terminate and the non-defaulting party shall be entitled to pursue any and all rights and remedies available, at law or in equity, to the non-defaulting party under this Agreement (including any indemnity obligations which shall survive this Agreement) or under applicable law.

9. Non-Solicitation. Upon the occurrence of a Termination Event, and for a period of two years from the date of such termination, the REIT (or any of its Affiliates) shall not solicit for employment, employ or otherwise retain (directly or indirectly) any employee of the Manager (or any of its Affiliates) without the prior written consent of Manager, which consent may be granted, withheld or conditioned in Manager’s sole and absolute discretion.

10. Miscellaneous.

(a) Notices. All notices and other communications required or permitted hereunder shall be in writing, shall be deemed duly given upon actual receipt and shall be delivered (i) in person, (ii) by registered or certified mail (air mail if addressed to an address outside of the

-9-

country in which mailed), postage prepaid, return receipt requested, or (iii) by facsimile or other generally accepted means of electronic transmission (provided that a copy of any notice delivered pursuant to this clause (iii) shall also be sent pursuant to clause (ii), addressed as follows (or to such other addresses as may be specified by like notice to the other parties):


To the Remington Parties:		Remington Lodging & Hospitality, LLC ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇
		▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: ▇▇. ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇

with a copy to:		Remington Lodging & Hospitality, LLC
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇
		▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: Legal Department

To the REIT Parties:		Ashford Hospitality Prime, Inc. Ashford Hospitality Prime Limited Partnership c/o Ashford Hospitality Advisors LLC
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇
		▇▇▇▇▇ ▇▇▇▇
		▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: President

with a copy to:		Ashford Hospitality Prime, Inc.
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇
		▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: Legal Department

with a copy to:		Ashford Hospitality Prime, Inc.
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇
		▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: Independent Directors

(b) Amendments. No amendment, modification or supplement to this Agreement shall be binding on any of the parties hereto unless it is in writing and signed by the parties in interest at the time of the modification, and further provided any such modification is approved by a majority of the Independent Directors.

(c) Successors and Assigns. Neither this Agreement nor any rights or obligations hereunder shall be assignable by a party to this Agreement without the prior, express written consent of each of the other parties; provided, however, Manager shall have the right, without such consent, to assign its interest in this Agreement to any Manager Affiliate, provided such Manager Affiliate qualifies as an Eligible Independent Contractor as of the date of such transfer.

-10-

This Agreement and all of the provisions hereof shall be binding upon and inure to the benefit of the parties to this Agreement and their respective successors and permitted assigns.

(d) No Third-Party Beneficiaries. This Agreement is solely for the benefit of the parties to this Agreement and should not be deemed to confer upon third parties any remedy, claim, liability, reimbursement, claims or action or other right in excess of those existing without reference to this Agreement.

(e) Titles and Headings. Titles and headings to paragraphs and sections in this Agreement are inserted for the convenience of reference only and are not intended to be a part of or to affect the meaning or interpretation of this Agreement.

(f) Maximum Legal Enforceability; Time of Essence. Any provision of this Agreement that is prohibited or unenforceable in any jurisdiction shall, as to such jurisdiction, be ineffective to the extent of such prohibition or unenforceability without invalidating the remaining provisions hereof. Any such prohibition or unenforceability in any jurisdiction shall not invalidate or render unenforceable such provision in any other jurisdiction. Without prejudice to any rights or remedies otherwise available to any party to this Agreement, each party hereto acknowledges that damages would not be an adequate remedy for any breach of the provisions of this Agreement and agrees that the obligations of the parties hereunder shall be specifically enforceable. Time shall be of the essence as to each and every provision of this Agreement.

(g) Further Assurances. The parties to this Agreement will execute and deliver or cause the execution and delivery of such further instruments and documents and will take such other actions as any other party to the Agreement may reasonably request in order to effectuate the purpose of this Agreement and to carry out the terms hereof.

(h) Complete Agreement; Construction. This Agreement, and the other agreements and documents referred to herein, shall constitute the entire agreement between the parties with respect to the subject matter thereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter.

(i) Governing Law. This Agreement and its interpretation, validity and performance shall be governed by the laws of the State of Texas, without regard to its conflicts of interest principles. In the event any court of law of appropriate judicial authority shall hold or declare that the law of another jurisdiction is applicable, this Agreement shall remain enforceable under the laws of the appropriate jurisdiction.

[Signature Pages to Follow]

-11-

IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be duly executed as of the day and year first written above.


PARTNERSHIP:

ASHFORD HOSPITALITY PRIME LIMITED
PARTNERSHIP, a Delaware limited partnership

By:	Ashford Prime OP General Partner
LLC, a Delaware limited liability company, its general partner

	By:	/s/ ▇▇▇▇▇ ▇. ▇▇▇▇▇▇
	▇▇▇▇▇ ▇. ▇▇▇▇▇▇
	Vice President


REIT:

ASHFORD HOSPITALITY PRIME, INC., a
Maryland corporation

By:		/s/ ▇▇▇▇▇ ▇▇▇▇▇▇
		▇▇▇▇▇ ▇▇▇▇▇▇
		Chief Operating Officer and General Counsel


MANAGER:

REMINGTON LODGING & HOSPITALITY, LLC, a Delaware limited liability company

By:		/s/ ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇
		▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇
		Chief Executive Officer

[Signature page to Mutual Exclusivity Agreement]

CONSENTED AND AGREED

TO THIS 19TH DAY OF

NOVEMBER, 2013

/s/ ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇

▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇

[Signature page to Mutual Exclusivity Agreement]

EXHIBIT A

DEFINITIONS

“ADR” shall mean average daily rate and is calculated by dividing total number of rooms sold in a given period.

“Advisor” shall mean Ashford Hospitality Advisors LLC, a Delaware limited liability company, or any permitted successor or assign under the terms of the Advisory Agreement.

“Advisory Agreement” shall mean that certain Advisory Agreement dated November 19, 2013, by and among the REIT, the Partnership, and the Advisor, as may be amended, modified or supplemented.

“Affiliate” means with respect to a person, any person directly or indirectly controlling, controlled by or under common control with such person. The term “person” means and includes any natural person, corporation, partnership, association, limited liability company or any other legal entity.

“Annual Operating Budget” shall have the meaning given such term in the Master Management Agreement.

“Ashford Trust” shall mean Ashford Hospitality Trust, Inc., a Maryland corporation.

“Ashford Trust Exclusivity Rights” shall have the meaning as set forth in Section 4(a).

“Ashford Trust’s Investment Guidelines” shall mean all segments of the hospitality industry (including direct, joint venture and debt investments in hotels, condo-hotels, time-shares and all other hospitality related assets), with RevPAR criteria less than two (2) times the then current U.S. average RevPAR.

“Ashford Trust Mutual Exclusivity Agreement” shall mean that certain Mutual Exclusivity Agreement dated as of August 29, 2003, by and among Ashford Trust OP, Ashford Trust, Remington Hotel Corporation, Manager, ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇., and ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇, as may be amended or modified.

“Ashford Trust OP” shall mean Ashford Hospitality Limited Partnership, a Delaware limited partnership.

“Ashford Trust Parties” shall collectively mean Ashford Trust and Ashford Trust OP.

“Base Management Fee” shall have the meaning given such term in the Master Management Agreement.

“Capital Improvement Budget” shall have the meaning given such term in the Master Management Agreement.

“Change of Control” will be deemed to have taken place upon the occurrence of any of the following events:

(i) any “person” (as defined in Section 3(a)(9) of the Securities Exchange Act of 1934, as amended (the “Exchange Act”), and as modified in Section 13(d) and 14(d) of the Exchange Act) other than (A) the REIT or any of its subsidiaries, (B) any employee benefit plan of the REIT or any of its subsidiaries, (C) any Remington Affiliate, (D) a company owned, directly or indirectly, by stockholders of the REIT in substantially the same proportions as their ownership of the REIT, or (E) an underwriter temporarily holding securities pursuant to an offering of such securities, becomes the “beneficial owner” (as defined in Rule 13d-3 of the Exchange Act), directly or indirectly, of securities of the REIT representing 35% or more of the shares of voting stock of the REIT then outstanding; or

(ii) the consummation of any merger, reorganization, business combination or consolidation of the REIT or one of its subsidiaries with or into any other company, other than a merger, reorganization, business combination or consolidation which would result in the holders of the voting securities of the REIT outstanding immediately prior thereto holding securities which represent immediately after such merger, reorganization, business combination or consolidation more than 50% of the combined voting power of the voting securities of the REIT or the surviving company or the parent of such surviving company; or

(iii) the consummation of the sale or disposition by the REIT of all or substantially all of the REIT’s assets, other than a sale or disposition if the holders of the voting securities of the REIT outstanding immediately prior thereto hold securities immediately thereafter which represent more than 50% of the combined voting power of the voting securities of the acquiror, or parent of the acquiror, of such assets; or the stockholders of the REIT approve a plan of complete liquidation or dissolution of the REIT.

“Effective Date” shall have meaning given such term in the preamble of the Agreement.

“Eligible Independent Contractor” shall have the same meaning given such term in the Master Management Agreement.

“Event of Default” shall have the meaning as set forth in Section 8.

“Excluded REIT Transactions” shall mean a REIT Transaction with respect to which there has been an Independent Director Election.

“Excluded Remington Transactions” shall mean the following excluded transactions of the Remington Affiliates:

(a) Existing hotel investments made by one or more of the Remington Affiliates with any of their Existing Investors;

(b) Existing bona fide arm’s length third party management arrangements (or arrangements for other services such as project management) with parties other than the REIT Affiliates pursuant to which one or more of the Remington Affiliates provide customary hotel management and hotel construction management, project management and other services; and

(c) Like-kind exchanges under Section 1031 of the Internal Revenue Code of 1986, as amended, made by any of the Existing Investors pursuant to contractual obligations existing as of the date of this Agreement provided that Manager provides ten (10) days prior notice to the REIT of said transaction.

(d) Any Hotel Property investment that does not satisfy the initial Investment Guidelines of the REIT Parties.

“Existing Investors” shall mean the existing joint venture partners, investors or property owners of the Remington Affiliates as listed on Exhibit C attached hereto.

“Fiscal Year” shall mean the twelve (12) month calendar year ending December 31, except that the first Fiscal Year and last Fiscal Year of the term of this Agreement may not be full calendar years.

“Hotel” shall have the meaning given such term in the Master Management Agreement.

“Hotel Property” means any Property that is used in whole or in part for hotel purposes, including, without limitation, any motels, motor inns, or hotels and the like (full service, select service, extended stay or otherwise), whether in fee or leasehold, together with any improvements and fixtures now or hereafter located thereon, all rights, privileges and easements appurtenant thereto, and all tangible and intangible personal property used in connection therewith.

“Incentive Fee” shall have the meaning given such terms in the Master Management Agreement.

“Indemnifying Party” shall have the meaning as set forth in Section 7(c).

“Independent Director Disapproval” shall mean either of the following:

1) The Independent Directors upon a unanimous vote, have at any time elected not to engage Manager; or

2) A majority of the Independent Directors have elected not to engage Manager based upon a determination in their reasonable business judgment that either:

A) Special circumstances exist such that it would be in the best interest of the REIT not to engage Manager with respect to a particular Hotel Property; or

B) Based on the prior performance of Manager, another manager or developer could perform the management, development or other duties in question materially better than Manager for a particular Hotel Property.

“Independent Director Election” shall mean a choice by the Independent Directors to exercise their Independent Director Disapproval rights.

“Independent Directors” shall mean those directors of the REIT who are “independent” within the meaning of the rules of the New York Stock Exchange as in effect on the date hereof.

“Initial Term” shall have the meaning as set forth in Section 2.

“Initial Investment Guidelines” shall mean the Investment Guidelines of the REIT Parties as set forth in the Advisory Agreement as of the date hereof.

“Investment Guidelines” shall have the same meaning herein as given such term in the Advisory Agreement.

“Manager” means Remington Lodging and Hospitality, LLC, a Delaware limited liability company.

“Manager Affiliate” shall have the meaning given such term in the Master Management Agreement.

“Market Service Fees” shall have the meaning given such term in the Master Management Agreement.

“Master Management Agreement” means that certain Ashford Prime Hotel Master Management Agreement of even date herewith executed between Manager as the manager and Tenant (or its designees), as the owner in interest of the Hotel Properties subject of such agreement, a copy of which is attached hereto as Exhibit D, or any other management agreement with Manager, or a subsidiary of Manager, substantially in the form of the Master Management Agreement.

“Non-Managed Hotel” shall have the meaning given such term in the Master Management Agreement.

“Partnership” means Ashford Hospitality Prime Limited Partnership, a Delaware limited partnership.

“Person” shall mean any individual, corporation, partnership, limited liability company, joint venture, association, trust, unincorporated organization or other entity.

“Project Management Fee” shall have the meaning given such term in the Master Management Agreement.

“Project Related Services” shall have the meaning given such term in the Master Management Agreement.

“Property” means any real property or any interest therein.

“Reimbursement Amount” shall mean the total of all actual out of pocket and third party costs and expenses paid by and to be reimbursed to the Remington Affiliates that were necessary and/or appropriate in connection with the Remington Transaction, including all ▇▇▇▇▇▇▇ money deposits. The Reimbursement Amount shall be calculated by the Remington Parties and set forth in a certificate delivered to the REIT Parties and certified as true and correct by the Remington Parties. The Reimbursement Amount shall not include any finder’s fee, brokerage fee, development fee, or other compensation paid to the Remington Affiliates.

“REIT” means Ashford Hospitality Prime, Inc., a Maryland corporation.

“REIT Affiliate” shall mean the REIT Parties and their Affiliates.

“REIT Exclusivity Rights” shall have the meaning as set forth in Section 4(a).

“REIT ROFR” shall have the meaning as described in Section 4(c).

“REIT ROFR Notice” shall have the meaning as described in Section 4(c).

“REIT ROFR Period” shall have the meaning as described in Section 4(c).

“REIT Parties” shall mean the REIT and the Partnership.

“REIT Termination Event” shall mean the events described in Section 3(b).

“REIT Transaction” shall have the meaning as set forth in Section 5(a).

“REIT Transaction Documents” shall have the meaning as set forth in Section 4(b).

“Remington Affiliate” shall mean the Remington Parties and their Affiliates.

“Remington Exclusivity Rights” shall have the meaning as set forth in Section 5(a).

“Remington Notice” shall have the meaning as set forth in Section 4(b).

“Remington Parties” shall mean Remington Holdings, LP and Manager.

“Remington Termination Event” shall mean the events described in Section 3(a).

“Remington Transaction” shall have the meaning as set forth in Section 4(a).

“Remington Transaction Documents” shall have the meaning as set forth in Section 5(b).

“RevPAR” shall mean revenue per available room and is calculated by multiplying ADR by the average daily occupancy.

“Tenant” shall mean Ashford Prime TRS Corporation, a Delaware corporation.

“Term” shall have the meaning as set forth in Section 2.

“Termination Event” shall have the meaning as set forth in Section 2.

EXHIBIT B

DEVELOPMENT AGREEMENT

THIS DEVELOPMENT AGREEMENT (the “Agreement”) dated as of , 20 (the “Effective Date”), by and between ASHFORD HOSPITALITY PRIME LIMITED PARTNERSHIP, a Delaware limited partnership (“Owner”) and [REMINGTON LODGING & HOSPITALITY LLC, a Delaware limited liability company or other Affiliate] (“Developer”).

R E C I T A L S:

A. Owner owns that certain tract or parcel of land situated in County, , as more particularly described on Exhibit “A” attached hereto and made a part hereof for all purposes (the “Land”).

B. Owner desires to engage Developer to develop an approximate room hotel and to furnish and perform the functions and services hereinafter prescribed, and Developer desires to accept such engagement, all for the term and subject to the covenants, agreements, and stipulations hereinafter set forth.

A G R E E M E N T S:

NOW, THEREFORE, in consideration of the premises and the mutual covenants herein contained, the parties hereto agree as follows:

1. Definitions. As used in this Agreement, the following terms shall have the following respective meanings:

1.1. Affiliate. The term “Affiliate” shall mean with respect to any entity, any firm, corporation, partnership, association, trust or other entity which, directly or indirectly, controls, is controlled by, or is under common control with, the subject entity, or any family member or trust for the benefit of a family member of a person having control of such entity. For purposes hereof, the term “control” shall mean the possession, directly or indirectly, of the power to direct or cause the direction of the management and policies of any such person or entity, whether through the ownership of voting securities, by contract, or otherwise.

1.2. Agreement. The term “Agreement” shall mean this Development Agreement.

1.3. Ashford Prime TRS. The term “Ashford Prime TRS” shall mean Ashford Prime TRS Corporation, a Delaware corporation.

1.4. Commencement Date. The term “Commencement Date” shall mean the date on which Developer certifies to Owner in writing that construction has commenced for the development of the Project by the primary contractor after (i) the issuance of the building permit and other permits necessary for the commencement of construction issued under applicable Legal Requirements, (ii) the execution and delivery of the Construction Loan Documents, if applicable, (iii) the approval of the proposed platting, if applicable, for the Land under applicable Legal Requirements, and (iv) the approval of the applicable site plan for the Project under applicable Legal Requirements.

1.5. Completion Date. The term “Completion Date” shall mean the first day by which (i) the Project Architect has certified that the construction, equipping and furnishing of the Project has been substantially completed in accordance with the Plans and Specifications, (ii) the applicable governmental authorities have issued all necessary certificates of occupancy and other consents and approvals in respect of or necessary for the operation of the Project as an operating Hotel, (iii) the Franchisor has authorized the opening of the Hotel and the operation thereof under the terms of the Franchise Agreement, and (iv) the Project is opened to the public for business as [a] [an] Hotel.

1.6. Conceptual Plan Phase. The term “Conceptual Plan Phase” shall have the meaning given such term in Section 2.2 hereof.

1.7. [Construction Loan Agreement. The term “Construction Loan Agreement” shall mean that certain loan agreement part of the Construction Loan Documents.] [IF APPLICABLE]

1.8. [Construction Loan Documents. The term “Construction Loan Documents” shall mean each and every document or instrument executed in connection with or as security for the construction loan for the Project.] [IF APPLICABLE]

1.9. Design Phase. The term “Design Phase” shall have the meaning given such term in Section 2.2 hereof.

1.10. Developer. The term “Developer” shall have the meaning attributed to it in the preamble to this Agreement.

1.11. Developer Default. The term “Developer Default” shall have the meaning attributed to it in Section 3.3.1.

1.12. Developer’s Fee. The term “Developer’s Fee” shall have the meaning attributed to it in Section 5.1.

1.13. Development Budget. The term “Development Budget” shall mean the development budget for the Project approved by Owner and Lender, if applicable, in the form attached hereto as Exhibit “B” and made a part hereof for all purposes, to be proposed by Developer pursuant to Section 2.2 hereof, and as updated and revised, from time to time, with Owner’s approval.

1.14. Development Plan. The term “Development Plan” shall mean the plan for the development and construction of an approximate room hotel and all related amenities, parking areas and other improvements, to be approved by Owner pursuant to Section 2.2 below.

1.15. Force Majeure. The term “Force Majeure” shall mean any act of God (including adverse weather conditions); act of the state or federal government in its sovereign or contractual capacity; war; civil disturbance, riot or mob violence; terrorism; earthquake; flood; fire or other casualty; epidemic; quarantine restrictions; labor strikes or lockout; freight embargo; materials

shortages or unusual unavailability of specified materials, or similar causes beyond the reasonable control of Developer.

1.16. Franchisor. The term “Franchisor” shall mean .

1.17. Franchise Agreement. The term “Franchise Agreement” shall mean the contract entered into between Owner and Franchisor pertaining to the name and operating procedures, systems and standards for the Hotel.

1.18. Franchisor Requirements. The term “Franchisor Requirements” shall mean the conditions, guidelines and requirements of Franchisor applicable to the Project and the operation of the Hotel for the issuance of the Franchise Agreement by Franchisor.

1.19. Hotel. The term “Hotel” shall mean the proposed improvements to be constructed on the Land comprised of an approximate -story Hotel with not less than guest [rooms][suites] to be operated under the Franchise Agreement and to be constructed in accordance with the Plans and Specifications.

1.20. Land. The term “Land” shall have the meaning attributed to it in the first recital hereof.

1.21. Legal Requirements. The term “Legal Requirements” shall mean all laws, statutes, ordinances, orders, rules, regulations, permits, licenses, authorizations, directions and requirements of all governments and governmental authorities, which now or hereafter may be applicable to the Project and the operation of the Hotel.

1.22. Lender. The term “Lender” shall mean .

1.23. Management Agreement. The term “Management Agreement” shall mean that certain Hotel Master Management Agreement between Ashford TRS, an affiliate of Owner and Manager, an affiliate of Developer.

1.24. Manager. The term “Manager” shall mean Remington Lodging & Hospitality, LLC, a Delaware limited liability company.

1.25. Objection Notice. The term “Objection Notice” shall have the meaning given such term in Section 2.2. hereof.

1.26. Outside Completion Date. The term “Outside Completion Date” shall [have the meaning as set forth in the Construction Loan Agreement entered into or to be entered into between Lender and Owner][mean ].

1.27. Owner. The term “Owner” shall have the meaning attributed to it in the preamble to this Agreement.

1.28. Owner Delays. The term “Owner Delays” shall mean delays caused by actions or inactions of Owner with respect to any review, approval, funding, and other requirements and rights of Owner under this Agreement.

1.29. Owner Default. The term “Owner Default” shall have the meaning attributed to it in Section 3.2.2.

1.30. Person. The term “Person” shall mean an individual, partnership, corporation, trust, unincorporated association, or other entity or association.

1.31. Plans and Specifications. The term “Plans and Specifications” shall mean the architectural plans and specifications for the Project prepared by the Project Architect and approved by Owner and Lender.

1.32. Project. The term “Project” shall mean the Hotel, together with other related improvements, to be constructed on the Land.

1.33. Project Architect. The term “Project Architect” shall mean [ ] [the architect recommended by Developer and approved by Owner].

1.34. State. The term “State” shall mean .

2. Engagement of Developer.

2.1. Engagement. Owner hereby engages the services of Developer, as Owner’s developer for the Project, with the powers and duties of arranging, supervising, coordinating, and carrying out the development of the Project, and Developer undertakes and accepts such engagement, subject to the terms and provisions of this Agreement.

2.2. Development Plan. During the first days after the Effective Date (the “Conceptual Plan Phase”), Developer shall work with Owner and Franchisor to develop a conceptual Development Plan for the Project which shall include (i) a schematic representation of the Hotel and proposed improvements (with exterior elevation), (ii) a preliminary Development Budget, (iii) recommended contractors, (iv) recommended architects, (v) listing of major construction materials, (vi) listing of recommended interior selections, and (vii) other matters, all of sufficient scope to establish a basis for performance of the development on the Project. Upon Owner’s and Franchisor’s, as applicable, approval of the Conceptual Development Plan, Manager shall then engage, on behalf of Owner, the Project Architect to prepare plans and specifications for completion within days after the expiration of the Conceptual Plan Phase and engagement of the Project Architect (the “Design Phase”). During the Design Phase, Manager shall supervise and direct, on behalf of Owner, the completion of the Plans and Specifications for Owner’s review and approval. Manager shall consult with and coordinate the preparation of the Plans and Specifications with the Franchisor at 50%, 75% and 100% completion. A preliminary Development Budget has been prepared by Developer and delivered to Owner. Consistent with the terms set forth in the preliminary Development Budget, Developer shall further refine and provide more detail during the Design Phase with the intent that upon conclusion of all Plans and Specifications for the intended and approved Development Plan, Developer shall submit a complete Development Budget to Owner for Owner’s approval. Upon receipt thereof, with appropriate supporting information including trade costs breakdowns, construction schedules and other items reasonably requested by Owner after all appropriate bidding has concluded, Owner shall reasonably cooperate with Developer in developing the final and approved Development Budget. The Development Budget and the Development Plan shall

not be deemed accepted by Owner in the absence of its express written approval. Not later than thirty (30) days after receipt by Owner of the proposed Development Budget and the Development Plan (or such longer period as Owner may reasonably request on notice to Developer), Owner may deliver a notice (an “Objection Notice”) to Developer stating that Owner objects to any information contained in or omitted from such proposed Development Budget and Development Plan, and setting forth the nature of such objections with reasonable specificity. Failure of Owner to timely deliver an Objection Notice shall be deemed a rejection of the Developer’s proposed Development Budget in its entirety. Upon receipt of any Objection Notice, the Developer shall, after consultation with Owner, modify the proposed Development Budget and the Development Plan, taking into account Owner’s objections, and shall resubmit the same to Owner for Owner’s approval within fifteen (15) days thereafter (or such additional time as may be reasonably required with the reasonable approval of Owner), and Owner may deliver further Objection Notices (if any) within fifteen (15) days thereafter (in which event, the resubmission and review process described above in this sentence shall continue until the proposed Development Budget and Development Plan in question is accepted and consented to by Owner).

Notwithstanding anything to the contrary set forth herein, Owner shall have the right at any time subsequent to the acceptance and consent with respect to any Development Budget or the Development Plan, on notice to Developer, to revise such Development Budget and Development Plan or to request that Developer prepare for Owner’s reasonable approval a revised Development Budget or Development Plan, taking into account such circumstances as Owner deems reasonably appropriate; provided, however, the revision of a Development Budget or Development Plan shall not be deemed a revocation of the Developer’s authority with respect to such actions as the Developer may have already taken (including, without limitation, construction contracts, architectural agreements, professional services contracts, and other contracts executed in connection with the authority granted herein) prior to receipt of such revision notice in implementing a previously approved Development Budget or Development Plan.

2.3. Delegation of Authority. The development of the Project shall be under the supervision and control of Developer who, except as otherwise specifically provided herein, shall be responsible for the completion of the Project prior to the Outside Completion Date, subject to Force Majeure and/or Owner Delays, materially in accordance with the Plans and Specifications, [the Construction Loan Documents,] applicable Legal Requirements, and the Franchisor Requirements. Accordingly, subject to the terms of this Agreement, the Plans and Specifications, the Development Plan and the Development Budget, Developer shall have the authority to:

(a) Negotiate, execute and effect the administration of, in the name of and on behalf of Owner, any agreements for architectural, engineering, testing, and/or professional or skilled consultant’s services, and any agreements for the construction of any and all improvements, including, but not limited to, the furnishing of any supplies, materials, machinery or equipment therefor, and any amendments of the foregoing.

(b) Consult with architects, engineers, and others referred to in Section 2.2(a) above so that the design and Plans and Specifications for the Hotel will be prepared, developed and finalized to the reasonable satisfaction of Owner.

(c) Secure or cause the appropriate parties engaged by the Owner to secure all required permits, licenses, and approvals from applicable authorities in connection with: (i) the demolition of any existing structure on the Land; (ii) the construction, completion and occupancy of the Hotel; and (iii) the development and operation of the Hotel, regardless of when and from what source they are to be obtained.

(d) Cause the appropriate parties engaged by the Developer to prepare a project time construction schedule for reasonable approval by Owner and effect coordination and integration of the various services required for the construction and completion of the Hotel in conformity with such schedules, subject to delay due to Force Majeure and Owner Delays.

(e) Recommend the Project general contractor for approval by Owner (not to be unreasonably withheld) and then select other professional consultants and engineers necessary to complete the development of the Project and supervise the negotiation and execution of all construction and professional service contracts and any revisions, amendments or supplements thereto.

(f) If required by Owner [or Lender], require the Project general contractor to provide at its expense a payment bond and a performance bond, each in an amount equal to 100% of the respective contracts issued by a financially responsible surety company licensed by the State in which the Project is located, insuring to Owner’s [and Lender’s] reasonable satisfaction that the services called for in the Project general contractor’s contract will be completed and fully paid.

(g) Advise and assist Owner in the preparation of the Development Plan and Development Budget and make revisions to same as necessary, subject to the approval of Owner, and to keep Owner advised of changes in cost estimates included in the Development Budget from time to time so as to provide Owner at all times with current information as to Project costs.

(h) Cooperate with and assist with the Project general contractor in the preparation of: (i) bid documents and procedures; (ii) the selection of lists of bidders; and (iii) in the negotiations, finalization and award of all major subcontracts and material purchase orders.

(i) Provide supervision over the performance of the Project general contractor of its services in an effort to expedite completion of the Hotel in accordance with approved Plans and Specifications and contract documents, the Development Budget, the Construction Loan Documents and the critical path progress schedule prepared by the Project general contractor under the supervision of Developer.

(j) Establish a procedure for the review and processing of applications by the Project general contractor and subcontractors of progress and final payments [in compliance with the Construction Loan Documents].

(k) Inspect the progress of the course of construction of the Hotel, including verification, through the Project Architect, of the materials and labor being furnished to and on such construction, and in addition, verify based on such inspection that construction is being carried out in accordance with the Plans and Specifications, the Construction Loan Documents, Legal Requirements and the Franchisor Requirements.

(l) Manage and consult with and direct all persons or firms engaged for the responsibility of designing the Project.

(m) Except as otherwise provided in the Management Agreement, at Owner’s expense, obtain and maintain insurance coverage for the Project, Owner (and any of its partners if deemed necessary by Owner), at all times until construction of the Hotel is fully completed, such policies to be in compliance with the insurance requirements set forth in Exhibit C attached hereto and made a part hereof for all purposes and [with the Construction Loan Documents].

(n) Provide administration of all contracts and the enforcement thereof and of all appropriate records.

(o) Use reasonable commercial efforts to accomplish the timely completion of the development of the Hotel subject to Force Majeure and Owner Delays.

(p) Secure such cross easements, reciprocal operating agreements, cross use agreements, and other similar access agreements between the Hotel and adjoining landowners and appropriate parties as are necessary to develop and operate the Hotel.

(q) Provide as a liaison between Owner and any federal, state, county or local government boards, statutory bodies or other agencies having jurisdiction over the Land of the development of the Hotel in order to provide a relationship between the Owner and such parties, and to permit the development of the Hotel to proceed in a cost efficient and expeditious manner.

(r) Maintain all office and accounting facilities and equipment necessary for Developer to carry out the foregoing functions, and in connection with accounting functions, if Owner so directs, receive and disburse loan proceeds and other funds for and on behalf of the Owner and subject to Owner’s approval.

(s) Prepare and furnish to Owner monthly budget updates, progress reports and other reports reasonably required by Owner and provide necessary and appropriate computer and related services in the performance of the above functions.

(t) Arrange for and supervise the preparation of, and deliver to Owner and Lender promptly when available, all documentation relevant to the Project, in proposed and final forms, including, without limitation, surveys, title reports, site plans,

engineering and environmental reports, soil reports, Plans and Specifications, construction contracts, consultants’ contracts, construction schedules and trade breakdowns, and purchase orders and contracts.

2.4. Project Related Services. Developer and Owner agree that the duties of Developer hereunder shall not extend to providing any of the services defined as “Project Related Services” in the Management Agreement, unless and until it has been determined that the Market Service Fees (as defined in the Management Agreement) with respect to such Project Related Services has been determined in accordance with the terms and procedures set forth in Section 8.02(G), (H) and (I) of the Management Agreement, the terms and provisions of which are incorporated herein by this reference.

2.5. Approvals by Owner. Developer covenants and agrees that in addition to any Owner approval requirements otherwise set forth herein, Developer shall obtain the prior written approval by Owner for each of the following:

(a) Plans and Specifications for the Project and any material changes thereto;

(b) Any material deviation from the approved Plans and Specifications, as same may have been amended or modified;

(c) Approval of the Development Pans and the Development Budget (if not heretofore approved in writing by Owner) and any material changes thereto;

(d) The making of, or the agreement to incur, expenditures in connection with the development of the Project which cause total expenditures for the development of the Project to exceed the total construction costs for the entire Project as set forth in the then approved Development Budget [or any variance exceeding % of any major line item in the Development Budget];

(e) Approval of the General Contractor (including the applicable construction contract or any material amendments or modifications thereto or any change order thereunder which would cause total expenditures for the development of the Project to exceed the total construction cost for the entire Project as set forth in the then approval Development Budget or would cause a variance in any major line item in the Development Budget of %); and

(f) Approval of the Project Architect and all major professional consultants and engineers engaged for the implementation of the Development Budget (including applicable contracts for the engagement of such professionals or material amendments or modifications thereto).

2.6. Emergencies. Notwithstanding Section 2.5 to the contrary, in any emergency affecting the safety of persons or property, which is likely to result in a substantial construction work stoppage or a substantial delay of the Completion Date, Developer shall be authorized to act in a manner intended to mitigate or prevent threatened damage, injury or loss, and shall be entitled to make expenditures in connection therewith. However, Developer shall authorize only such acts and shall make only such expenditures reasonably required to stabilize the emergency.

In addition, Developer shall authorize such acts and make such expenditures only after Developer has made a reasonable attempt (if circumstances permit) to inform Owner of (a) the cause of such emergency, (b) the prepared course of action in connection therewith, and (c) the likely amount of such expenditures.

2.7. Cooperation by Owner. Owner agrees to cooperate with Developer as may be requested by Developer in furtherance of the development and construction of the Project as specified in this Agreement and to execute such documents as shall be submitted to it with a favorable recommendation by Developer, provided that the same shall be consistent with and in implementation of the matters approved by Owner as required hereunder.

2.8. Performance of Duties; Guaranty of Completion. Developer accepts as aforesaid the engagement under this Agreement and agrees to act with reasonable prudence and diligence in the performance of its duties and responsibilities hereunder and in good faith and in the best interest of Owner. Subject to the continuing obligation of Owner to provide funds necessary for the development of the Project, Developer hereby covenants and agrees, subject to Force Majeure and Owner Delays, to cause the commencement of the construction of the Project and thereafter cause the prosecution of same with diligence and continuity to completion on or before the Outside Completion Date, all in a good and workmanlike manner and (i) in accordance with the then approved Development Budget, (ii) in substantial accordance with the Plans and Specifications (as same may be changed pursuant to Section 2.5(a) and (b) hereof, (iii) all Legal Requirements in all material respects, (iv) the Construction Loan Documents, and (v) the Franchisor Requirements, free and clear of any liens or claims of liens for materials supplied or worked performed in connection therewith, except for permitted liens and encumbrances [pursuant to the terms of the Construction Loan Documents].

3. Term, Default, Termination and Remedies.

3.1. Term. Unless earlier terminated pursuant to the provisions hereof, this Agreement shall be for a term commencing as of the Commencement Date and terminating upon a date thirty (30) days following the Completion Date. Termination hereof shall not relieve either Owner or Developer of obligations to each other that accrue on or before such termination nor the continuing and surviving obligation of Owner to pay, to the extent required hereunder, the Developer’s Fee or reimburse Developer for overages pursuant to Section 5 hereof.

3.2. Default.

3.2.1. Developer Default. Each of the following shall constitute a “Developer Default”:

(a) The filing of a voluntary petition in bankruptcy or insolvency or a petition for reorganization under any bankruptcy law by Developer;

(b) The consent to any involuntary petition in bankruptcy or the failure to vacate, within ninety (90) days from the date of entry thereof, any order approving an involuntary petition by Developer;

(c) The entering of an order, judgment or decree by any court of competent jurisdiction, on the application of a creditor, adjudicating Developer as bankrupt or an insolvent, or approving a petition seeking reorganization or appointing a receiver, trustee, or liquidator of all or a substantial part of Developer assets, and such order, judgment or decree continues unstayed and in effect for any period of ninety (90) days or more;

(d) The appointment of a receiver for all or any substantial portion of the property of Developer;

(e) The failure of Developer to make any payment in accordance with the terms of this Agreement within ten (10) days after receipt of written notice specifying said default from Owner, that such payment is due and payable; and

(f) The failure of Developer to perform, keep or fulfill any of the other covenants, undertakings, obligations or conditions set forth in this Agreement, and the continuance of such failure for a period of thirty (30) days after written notice of such failure; provided, however, if such default cannot be cured within such thirty (30) day period and Developer shall have commenced to cure such default within such thirty (30) day period and thereafter diligently, continuously and expeditiously proceeds to cure the same, such thirty (30) day period shall be extended so long as it shall require Developer to cure such default.

3.2.2. Owner Default. Each of the following shall constitute an “Owner Default” if (but only if) and to the extent the failure in question is not attributable to the action or breach by the Developer or any Affiliate of Developer:

(a) The failure of Owner to make any payment in accordance with the terms of this Agreement within ten (10) days after receipt of written notice specifying said default from Developer, that such payment is due and payable; or

(b) The failure of Owner to perform, keep or fulfill any of the other covenants, undertakings, obligations or conditions set forth in this Agreement to be performed, kept or fulfilled by it, and the continuance of such failure for a period of thirty (30) days after written notice of such failure from Developer; provided, however, if such default cannot be cured within such thirty (30) day period and Owner shall have commenced to cure such default within such thirty (30) day period and thereafter diligently, continuously and expeditiously proceeds to cure the same, such thirty (30) day period shall be extended so long as it shall require Owner to cure such default.

3.3. Consequence of Default.

3.3.1. Developer Default. Upon the occurrence of any Developer Default, Owner may, at its option, give Developer written notice of termination of this Agreement (after the expiration of any applicable grace or cure period provided above), and upon the expiration of fifteen (15) days from the date of such written notice, this Agreement shall terminate.

3.3.2. Owner Default. Upon the occurrence of any Owner Default, Developer may give Owner written notice of its intention to terminate this Agreement (after the expiration of any applicable grace or cure period provided above), and upon the expiration of fifteen (15) days from the date of such written notice, this Agreement shall terminate.

3.4. Other Remedies Cumulative. In the event of the occurrence of either a Developer Default or Owner Default hereunder, the aggrieved party (Developer or Owner, as the case may be) shall, in addition to its rights and remedies hereunder and at law or in equity, have the right to recover from the party in default damages suffered and all reasonable costs and expenses incurred by the aggrieved party in enforcing its rights and remedies hereunder, including reasonable attorneys’ fees. The termination of this Agreement by either Developer or Owner by reason of default by the other party, as aforesaid, shall not relieve either party of any of its obligations theretofore accrued under this Agreement prior to the effective date of such termination.

3.5. Duties Flowing From Termination. Upon termination of this Agreement, Owner shall:

(a) Indemnify and hold Developer harmless from and against any and all claims, obligations and liabilities by reason of anything done or required to be done after the effective date of such termination under any contract entered into by Owner in connection with or relating to the development of the Project; and

(b) Pay for the cost of all services (including, without limitation, the Development Fee earned through the date of such termination), materials, and supplies, if any, which may have been ordered or incurred by Developer as a result of its obligations arising under this Agreement but which may not have been charged to or paid by Developer and reimbursed under this Agreement at the time of termination, if such services, materials, and supplies have been ordered or incurred in accordance with the provisions of this Agreement; provided, however, that in the event of a termination of this Agreement as a result of a Developer Default, Owner shall have the right to offset against any amounts due to Developer under this Section 3.5 any amounts to which Owner is entitled hereunder, under Section 3.4 or otherwise.

Upon such termination, Developer shall execute and deliver to Owner such documents of transfer and assignment as may be required to vest in Owner all of Developer’s rights, if any, under any and all contracts referenced in Section 3.5(a) above, and Developer shall cooperate in good faith to effect an orderly transition of its duties to Owner (or a new development manager), and use reasonable efforts to minimize costs and delays associated with such transition.

4. Insurance and Indemnity.

4.1. Insurance.

(a) Developer, on behalf of Owner shall purchase and maintain in effect “all-risk” builder’s risk property insurance upon all work and materials to be an integral part

of the Hotel which are situated at the construction site of the Hotel and/or Project, during inland transit and while in storage elsewhere, in an amount, subject to such deductibles and otherwise in form and substance as shall be agreed upon by Developer and Owner, and as otherwise required by the Construction Loan Documents. Such insurance shall include the interests of Developer, Owner (including its partners), Manager, Lender, the contractor and sub-contractors involved in the construction of the Project, and shall contain the insurer’s waiver of subrogation rights against Developer.

(b) Developer, on behalf of Owner, shall purchase and maintain or cause the contractor to purchase and maintain comprehensive liability and property damage insurance against claims for personal and bodily injury or death and property damage occurring upon, in or about the construction site of the Hotel and upon, in or about the adjoining streets and passageways thereof, or otherwise, arising under the contracts for the construction of the Project and/or this Agreement, such public liability insurance to include Developer, Owner Manager and Lender as an additional insureds and be in form and substance satisfactory to Owner and as otherwise required under the Construction Loan Documents.

(c) Developer, on behalf of Owner and at Owner’s cost, shall purchase and maintain such other insurance, in such forms and amounts, as shall be required under the Construction Loan Documents or as Owner may otherwise require. Developer shall provide to Owner and Lender (i) certified copies of policies of all insurance provided for in this Section 4.1 prior to the commencement of construction of the Project, and thirty (30) days or other minimum periods under the applicable law of the State prior to the expiration date of all such policies, certified copies of renewal policies. All such policies shall provide that the same may not be cancelled or materially modified without at least thirty (30) days prior written notice to all insureds.

(d) Developer shall provide Owner with evidence that the general contractor, all major subcontractors, the Project Architect and other consultants, designers and engineers have obtained liability insurance and errors and omissions insurance coverage in a nature and to an extent customarily obtained by said entities in the metropolitan area of the city in which the Project of located, and as may be required by the Construction Loan Documents.

(e) Developer shall provide evidence to Owner of workmen’s compensation insurance with employer liability insurance covering all persons employed by Developer, the general contractor and consultants hired by Developer in connection with the Project, at the statutory limits as provided by the laws of the State in which the workmen are employed, and require general contract to require that all major subcontractors maintain the statutory minimum.

(f) Promptly after the Completion Date, Developer shall coordinate with Manager the transfer of all policies of insurance and benefits related thereto to the extent required under the terms of the Management Agreement.

(g) All insurance required hereunder shall be issued by companies satisfactory to Owner qualified or licensed, as the case may be, to issue insurance in the State and otherwise in compliance with the Construction Loan Documents.

4.2. Indemnities.

(a) Notwithstanding anything herein contained to the contrary, Developer shall indemnify and save Owner harmless in respect of any action, cause of action, suit, debt, loss, cost, expense (including, without limitation, reasonable attorneys’ fees), claim or demand whatsoever, at law or in equity (collectively, “Damages”), arising by way of any breach during term of this Agreement by Developer, its employees, servants, agents or subcontractors, of any of the provisions of this Agreement or by reason of the grossly negligent or willful misconduct of the Developer, its employees, servants, agents or subcontractors, which indemnity shall continue notwithstanding the termination of this Agreement with respect to any act or occurrence preceding such termination.

(b) Owner agrees to indemnify and save Developer completely harmless in respect of any Damages in connection with the performance by Developer of any and all of its obligations in accordance with this Agreement, including, without limitation, any damage or injury whatsoever to any employees or other Person or property arising out of the use, administration, or control of the Project or any other asset of Owner relating to the Project during the term of this Agreement, which indemnity shall continue notwithstanding the termination of this Agreement with respect to any act or occurrence preceding such termination; provided, however, in no event shall the indemnity provided under this Subsection 4.2(b) extend to any action, cause of action, suit, debt, cost, expense, claim or demand (i) against which Owner is indemnified under Section 4.2(a) above, or (ii) which is covered by insurance pursuant to Section 4.1 hereof.

5. Compensation of Developer.

5.1. Fees. For services performed hereunder, Developer shall be paid as its compensation a fee of four percent (4%) of the total Project costs (both hard and soft costs) associated with the development of the Project pursuant to the Development Budget payable on the first business day of each month in arrears based upon the prior calendar month’s total expenditures under the Development Budget (“Developer’s Fee”).

Notwithstanding the foregoing, (i) Developer shall not be entitled to receive any portion of the Developer’s Fee not yet payable at the time this Agreement is terminated by Owner due to a Developer Default, (ii) any of the Developer’s Fee that would otherwise be due in a month in which construction of the Project has been suspended by reason of a Developer Default, shall be postponed by the number of months for which construction is suspended, and (iii) Developer’s right to receive the Developer’s Fee is subject to the provisions of Section 3.3.1.

5.2. Reimbursement. In addition to the foregoing, Owner shall reimburse Developer for all third party, out of pocket costs and expenses, such as, but without limitation, (a) costs of reproductions of Plans and Specifications, (b) accountants fees and attorneys’ fees, fees paid to computer services for preparation of critical path method studies and other work, and similar

charges, (c) fees paid to design consultants and other outside consultants, (d) all costs of an on-site project office and of office supplies, rent, repair and maintenance of office machines and postage incurred for or in connection with the Project office, and (e) long distance air travel and similar expenses incurred during the Conceptual Plan Phase, the Design Phase and implementation, administration and completion of the Development Plan; provided that such costs are incurred with the scope of the authority granted to Developer hereunder and consistent with the Development Budget or as otherwise approved in writing by Owner.

6. Miscellaneous.

6.1. Governing Law; Venue. Developer and Owner agree that all disputes relating to the performance and/or interpretation of any term or provision of this Agreement shall be governed by the laws of the State of Texas. The parties hereto agree that venue for any action in connection herewith may be in Dallas County, Texas. Each party hereto consents to the jurisdiction of any local, state or federal court situated in Dallas, Texas, and waive any objection which they may have pertaining to improper venue or forum non conviens to the conduct of any proceeding in any such court.

6.2. No Waiver of Breach, etc. No failure by Developer or Owner to insist upon the strict performance of any covenant, agreement, term or condition of this Agreement, or to exercise any right or remedy consequent upon a breach thereof, shall constitute a waiver of any such breach or any subsequent breach of such covenant, agreement, term or condition. No waiver of any breach shall affect or alter this Agreement, but each and every covenant, agreement, term and condition of this Agreement shall continue in full force and effect with respect to any other then existing or subsequent breach thereof.

6.3. Severability of Provisions. If any term or provision of this Agreement or the application thereof to any person or circumstances shall, to any extent, be invalid or unenforceable, the remainder of this Agreement and the application of such term of provision to persons or circumstances other than those as to which it is held invalid or unenforceable, as the case may be, shall not be effected thereof, and each term and provision of this Agreement shall be valid and enforceable to the fullest extent permitted by law.

6.4. Notices. All notices, requests, approvals, demands, and other communications required or permitted to be given under this Agreement shall be in writing and shall be deemed given and received three (3) days after being deposited in the United States mail as registered or certified matter, postage prepaid, return receipt requested, or deemed given and received one (1) day after being delivered by any reputable overnight air courier service, addressed as follows:


If to Developer:		Remington Lodging & Hospitality LLC ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: ▇▇▇▇▇ ▇▇▇▇▇▇▇

If to Owner:		Ashford Hospitality Prime Limited Partnership ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: General Counsel

or at such other address as the party to whom the notice is sent shall have designated in accordance with the provisions of this Section 6.4.

6.5. Entire Agreement. This Agreement constitutes the entire agreement between the parties hereto with respect to the subject matter hereof.

6.6. Counterparts. This Agreement may be executed in several counterparts, each of which shall be an original, but all of which shall constitute but one and the same instrument.

6.7. Changes, Waivers, etc. Neither this Agreement nor any term or provision hereof may be changed, waived, discharged or terminated orally, but only by an instrument in writing signed by the party against which the enforcement of the change, waiver, discharge or termination is sought.

6.8. Captions. The captions to the Articles and Sections of this Agreement are for convenience of reference only and in no way define, limit or describe the scope or intent of this Agreement or in any part hereof, nor in any way affect this Agreement or any part hereof.

6.9. No Partnership or Joint Venture. Nothing contained in this Agreement shall constitute or be construed to be or create a partnership, joint venture or similar relationship between Owner and Developer.

6.10. No Assignment. Developer may not assign this Agreement of any of its rights hereunder, and may not delegate or sub-contract any of its duties hereunder; except that Developer may delegate some or all of the duties hereunder to any Affiliate, provided such Affiliate is controlled by ▇▇▇▇▇ ▇▇▇▇▇▇▇ and/or ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇., but no such delegation shall relieve Developer from liability for the performance of all obligations to be performed by it hereunder, and Developer shall remain responsible and liable for such obligations, and for any breach thereof by any such delegate.

IN WITNESS WHEREOF, the parties have executed this Agreement on the day and year first above written.


OWNER:

ASHFORD HOSPITALITY PRIME LIMITED PARTNERSHIP, a Delaware limited partnership

By:		Ashford Prime OP General Partner LLC, a
		Delaware limited liability company, its general partner

		By:
		Name:
		Title:

DEVELOPER:

[REMINGTON AFFILIATE]

List of Exhibits

Exhibit A – Legal Description

Exhibit B – Development Budget

Exhibit C – Insurance Requirements

Exhibit A

Legal Description

Exhibit B

Development Budget

Exhibit C

Insurance Requirements

EXHIBIT C

EXISTING INVESTORS

None

EXHIBIT D

MASTER MANAGEMENT AGREEMENT

EXECUTION VERSION

ASHFORD PRIME HOTEL MASTER MANAGEMENT AGREEMENT

by and between

ASHFORD PRIME TRS CORPORATION,

a Delaware corporation

and

REMINGTON LODGING & HOSPITALITY, LLC

a Delaware limited liability company

TABLE OF CONTENTS


ARTICLE I DEFINITION OF TERMS		7

1.01	Definition of Terms	7

ARTICLE II TERM OF AGREEMENT		17

2.01	Term	17

2.02	Actions to be Taken upon Termination	18

2.03	Early Termination Rights; Liquidated Damages	19

ARTICLE III PREMISES		23

ARTICLE IV APPOINTMENT OF MANAGER		23

4.01	Appointment	23

4.02	Delegation of Authority	24

4.03	Contracts, Equipment Leases and Other Agreements	24

4.04	Alcoholic Beverage/Liquor Licensing Requirements	24

ARTICLE V REPRESENTATIONS AND WARRANTIES		24

5.01	Lessee Representations	24

5.02	Manager Representations	25

ARTICLE VI OPERATION		26

6.01	Name of Premises; Standard of Operation	26

6.02	Use of Premises	27

6.03	Group Services	28

6.04	Right to Inspect	28

ARTICLE VII WORKING CAPITAL AND INVENTORIES		29

7.01	Working Capital and Inventories	29

7.02	Fixed Asset Supplies	29


ARTICLE VIII MAINTENANCE, REPLACEMENT AND CHANGES		30

8.01	Routine and Non-Routine Repairs and Maintenance	30

8.02	Capital Improvement Reserve	30

ARTICLE IX EMPLOYEES		35

9.01	Employee Hiring	35

9.02	Costs; Benefit Plans	35

9.03	Manager’s Employees	37

9.04	Special Projects - Corporate Employees	37

9.05	Termination	38

9.06	Employee Use of Hotel	39

9.07	Non-Solicitation	39

ARTICLE X BUDGET, STANDARDS AND CONTRACTS		39

10.01	Annual Operating Budget	39

10.02	Budget Approval	39

10.03	Operation Pending Approval	40

10.04	Budget Meetings	40

ARTICLE XI OPERATING DISTRIBUTIONS		41

11.01	Management Fee	41

11.02	Accounting and Interim Payment	41

ARTICLE XII INSURANCE		42

12.01	Insurance	42

12.02	Replacement Cost	43

12.03	Increase in Limits	43

12.04	Blanket Policy	44

12.05	Costs and Expenses	44


12.06	Policies and Endorsements	44

12.07	Termination	44

ARTICLE XIII TAXES AND DEBT SERVICE		45

13.01	Taxes	45

13.02	Debt Service; Ground Lease Payments	45

ARTICLE XIV BANK ACCOUNTS		45

ARTICLE XV ACCOUNTING SYSTEM		47

15.01	Books and Records	47

15.02	Monthly Financial Statements	47

15.03	Annual Financial Statements	47

ARTICLE XVI PAYMENT BY LESSEE		48

16.01	Payment of Base Management Fee	48

16.02	Distributions	48

16.03	Payment Option	48

ARTICLE XVII RELATIONSHIP AND AUTHORITY		49

ARTICLE XVIII DAMAGE, CONDEMNATION AND FORCE MAJEURE		50

18.01	Damage and Repair	50

18.02	Condemnation	50

18.03	Force Majeure	51

18.04	Liquidated Damages if Casualty	51

18.05	No Liquidated Damages if Condemnation or Force Majeure	51

ARTICLE XIX DEFAULT AND TERMINATION		52

19.01	Events of Default	52

19.02	Consequence of Default	52

ARTICLE XX WAIVER AND INVALIDITY		53


20.01	Waiver	53

20.02	Partial Invalidity	53

ARTICLE XXI ASSIGNMENT		53

ARTICLE XXII NOTICES		54

ARTICLE XXIII SUBORDINATION; NON-DISTURBANCE		55

23.01	Subordination	55

23.02	Non-Disturbance Agreement	55

ARTICLE XXIV PROPRIETARY MARKS; INTELLECTUAL PROPERTY		56

24.01	Proprietary Marks	56

24.02	Computer Software and Equipment	56

24.03	Intellectual Property	56

24.04	Books and Records	57

ARTICLE XXV INDEMNIFICATION		57

25.01	Manager Indemnity	57

25.02	Lessee Indemnity	57

25.03	Indemnification Procedure	58

25.04	Survival	58

25.05	No Successor Liability	58

ARTICLE XXVI NEW HOTELS AND NON-MANAGED HOTELS		59

ARTICLE XXVII GOVERNING; LAW VENUE		59

ARTICLE XXVIII MISCELLANEOUS		60

28.01	Rights to Make Agreement	60

28.02	Agency	60

28.03	Failure to Perform	60

28.04	Headings	60


28.05	Attorneys’ Fees and Costs	60

28.06	Entire Agreement	60

28.07	Consents	61

28.08	Eligible Independent Contractor	61

28.09	Environmental Matters	62

28.10	Equity and Debt Offerings	62

28.11	Estoppel Certificates	63

28.12	Confidentiality	63

28.13	Modification	63

28.14	Counterparts	63

ASHFORD PRIME HOTEL MASTER MANAGEMENT AGREEMENT

THIS ASHFORD PRIME HOTEL MASTER MANAGEMENT AGREEMENT is made and entered into on this day of , 2013, by and between ASHFORD PRIME TRS CORPORATION, a Delaware corporation (hereinafter referred to as “Lessee”), REMINGTON LODGING & HOSPITALITY, LLC, a Delaware limited liability company (hereinafter referred to as “Manager”), and for the limited purposes of Article VIII herein, the Landlords (defined below).

R E C I T A L S:

1. Lessee desires to retain Manager to manage and operate each Hotel (as defined below), and Manager is willing to perform such services for the account of Lessee, all as more particularly set forth in this Agreement.

A G R E E M E N T S:

NOW, THEREFORE, in consideration of the premises and the mutual covenants herein contained, the parties hereto agree as follows:

ARTICLE I

DEFINITION OF TERMS

1.01 Definition of Terms. The following terms when used in this Agreement shall have the meanings indicated below.

“Accounting Period” shall mean a calendar month.

“Addendum” shall have the meaning as set forth in Article XXVI.

“Agreement” shall mean this Master Management Agreement, and all amendments, modifications, supplements, consolidations, extensions and revisions to this Master Management Agreement approved by Lessee and Manager in accordance with the provisions hereof.

“AHP” means Ashford Hospitality Prime, Inc., a Maryland corporation.

“Annual Operating Budget” shall have the meaning as set forth in Section 10.01.

“AOB Objection Notice” shall have the meaning as set forth in Section 10.02.

“Applicable Standards” shall mean standards of operation for the Premises which are (a) in accordance with the requirements of the applicable Franchise Agreement, this Agreement and all CCRs affecting the Premises and of which true and complete copies have been made available by Lessee to Manager, (b) in accordance with applicable Legal Requirements, (c) in accordance with the terms and conditions of any Hotel Mortgage or Ground

Lease to the extent not otherwise inconsistent with the terms of this Agreement (to the extent Lessee has made available to Manager true and complete copies of the applicable loan documents relating to any such Hotel Mortgage and/or the Ground Leases), (d) in accordance with the Leases (to the extent Lessee has made available to Manager a true and complete copy thereof), (e) in accordance with the requirements of any carrier having insurance on the Hotel or any part thereof (to the extent Manager has been given written notice of such requirements or policies and/or has coordinated same on behalf of Lessee), and (f) in accordance with the requirements of Section 856(d)(9)(D) of the Code for qualifying each Hotel as a Qualified Lodging Facility.

“Approval Requirement” shall have the meaning as set forth in Section 8.02I.

“Base Management Fee” shall have the meaning as set forth in Section 11.01A.

“Benefit Plans” shall have the meaning as set forth in Section 9.02.

“Black-Scholes Amount” shall have the meaning as set forth in Section 16.03B.

“Black-Scholes Model” shall have the meaning as set forth in Section 16.03B.

“Business Day” shall mean any day excluding (i) Saturday, (ii) Sunday, (iii) any day which is a legal holiday under the laws of the States of New York, Maryland or Texas, and (iv) any day on which banking institutions located in such states are generally not open for the conduct of regular business.

“Budgeted HP” shall mean the House Profit as set forth in the Annual Operating Budget for the applicable Fiscal Year, as approved by Lessee and Manager pursuant to Article X hereof.

“CCRs” shall mean those certain restrictive covenants encumbering the Premises recorded in the real property records of the county where such premises are located, as described in the owner policies of title insurance relating to such premises, a copy of which are acknowledged received by the Manager.

“Capital Improvement Budget” shall have the meaning as set forth in Section 8.02E.

“Cash Management Agreements” shall mean agreements, if any, entered into by Lessee, Landlord and a Holder for the collection and disbursement of any Gross Revenues, Deductions, Management Fees or excess Working Capital with respect to the applicable Premises, which constitute a part of the loan documents executed and delivered in connection with any Hotel Mortgage by Landlord.

“Capital Improvement Reserve” shall have the meaning as set forth in Section 8.02A.

“CIB Objection Notice” shall have the meaning as set forth in Section 8.02E.

“CPI” means the Consumer Price Index, published for all Urban Consumers for the U.S. City Average for All Items, 1982-84=100 issued by the Bureau of Labor Statistics of the United States Department of Labor, as published in the Wall Street Journal.

“Code” shall mean the Internal Revenue Code of 1986, as amended.

“Commencement Date” shall have the meaning as set forth in Section 2.01.

“Competitive Set” shall mean, for each Hotel, the hotels situated in the same market segment as such Hotel as noted on Schedule 1 to the applicable Addendum for such Hotel, which competitive set shall include such Hotel. The Competitive Set may be changed from time to time by mutual agreement of Lessee and Manager to reasonably and accurately reflect a set within the market of such Hotel that is comparable in rate quality and in operation to such Hotel and directly competitive with such Hotel.

“Contract(s)” shall have the meaning as set forth in Section 4.03.

“Debt Service” shall mean actual scheduled payments of principal and interest, including accrued and cumulative interest, payable by a Landlord with respect to any Hotel Mortgage.

“Deductions” shall mean the following matters:

Employee Costs and Expenses (including, Employee Claims but excluding Excluded Employee Claims);

Administrative and general expenses and the cost of advertising and business promotion, heat, light, power, communications (i.e., telephone, fax, cable service and internet) and other utilities and routine repairs, maintenance and minor alterations pertaining to the Premises;

The cost of replacing, maintaining or replenishing Inventories and Fixed Asset Supplies consumed in the operation of the Premises;

A reasonable reserve for uncollectible accounts receivable as reasonably determined by Manager and approved by Lessee (such approval not to be unreasonably withheld);

All costs and fees of independent accountants, attorneys or other third parties who perform services related to the Hotel or the operation thereof, including, without limitation, an allocation of costs of Manager’s in-house corporate counsel who performs legal services directly for the benefit of the Hotels to be allocated on a fair and equitable cost basis as reasonably determined by Manager and approved by Lessee (such approval not to be unreasonably withheld);

The cost and expense of non-routine technical consultants and operational experts for specialized services in connection with the Premises, including, without limitation, an

allocation of costs of Manager’s corporate staff who may perform special services directly related to the Hotels such as sales and marketing, revenue management, training, property tax services, federal, state and/or local tax services, recruiting, and similar functions or services as set forth in Section 9.04, to be allocated on a fair and equitable cost basis as reasonably determined by Manager and approved by Lessee (such approval not to be unreasonably withheld);

Insurance costs and expenses as provided in Article XII;

Real estate and personal property taxes levied or assessed against the Premises by duly authorized taxing authorities and such other taxes, if any, payable by or assessed against Manager or the Premises related to the operation and/or ownership of the Premises;

Franchise fees, royalties, license fees, or compensation or consideration paid or payable to the Franchisor (as hereinafter defined), or any successor Franchisor, pursuant to a Franchise Agreement (as hereinafter defined);

10.

The Premises’ allocable share of the actual costs and expenses incurred by Manager in providing Group Services as provided in Section 6.03 hereof;

11.

The Management Fee;

12.

Rental payments made under equipment leases; and

13.

Other expenses incurred in connection with the maintenance or operation of the Premises not expressly set forth above and authorized pursuant to this Agreement.

Deductions shall not include: (a) depreciation and amortization, (b) Debt Service, (c) Ground Lease Payments, or (d) payments allocated or made to the Capital Improvement Reserve.

“Designated Fees” shall have the meaning as set forth in Section 16.03.

“Effective Date” shall mean the date this Agreement is fully executed and delivered.

“Eligible Independent Contractor” shall have the meaning as set forth in Section 28.08.

“Emergency Expenses” shall mean any expenses, regardless of amount, which, in Manager’s reasonable judgment, are immediately necessary to protect the physical integrity or lawful operation of the Hotel or the health or safety of its occupants.

“Employee Claims” shall mean any claims (including all fines, judgments, penalties, costs, litigation and/or arbitration expenses, attorneys’ fees and expenses, and costs of settlement with respect to any such claim) made by or in respect of an employee or potential hire

of Manager against Manager and/or Lessee which are based on a violation or alleged violation of the Employment Laws or alleged contractual obligations.

“Employee Costs and Expenses” shall have the meaning as set forth in Section 9.03.

“Employee Related Termination Costs” shall have the meaning as set forth in Section 9.05.

“Employment Laws” shall mean all applicable federal, state and local laws (including, without limitation, any statutes, regulations, ordinances or common laws) regarding the employment, hiring or discharge of persons.

“Event(s) of Default” shall have the meaning set forth in Article XIX.

“Excluded Employee Claims” shall mean any Employee Claims (a) to the extent attributable to a substantial violation by Manager of Employment Laws, or (b) which do not arise from an isolated act of an individual employee but rather is the direct result of corporate policies of Manager which either encourage or fail to discourage the conduct from which such Employee Claim arises.

“Executive Employees” shall mean each member of the senior executive or Premises level staff and each department head of the Hotel.

“Expiration Date” shall have the meaning as set forth in Section 2.01.

“FF&E” shall have the meaning as set forth in Section 8.01.

“Fixed Asset Supplies” shall mean supply items included within “Property and Equipment” under the Uniform System of Accounts, including linen, china, glassware, silver, uniforms, and similar items.

“Force Majeure” shall mean any act of God (including adverse weather conditions); act of the state or federal government in its sovereign or contractual capacity; war; civil disturbance, riot or mob violence; terrorism; earthquake, flood, fire or other casualty; epidemic; quarantine restriction; labor strikes or lock out; freight embargo; civil disturbance; or similar causes beyond the reasonable control of Manager.

“Franchisor” shall mean the franchisors and any successor franchisors selected by Lessee (subject to the terms of the Leases) identified on Exhibit “C” to the applicable Addendum for the Hotel.

“Franchise Agreement” shall mean any license agreements between a Franchisor and Lessee and/or Landlord, as applicable, as such license agreements are amended from time to time, and any other contract hereafter entered into between Lessee and/or Landlord, as applicable, and such Franchisor pertaining to the name and operating procedures, systems and standards, as described on Exhibit “C” to the applicable Addendum for the Hotel.

“full replacement cost” shall have the meaning as set forth in Section 12.02.

“GAAP” shall mean generally accepted accounting principles consistently applied as recognized by the accounting industry and standards within the United States.

“General Manager” or “General Managers” shall have the meanings as set forth in Section 9.07.

“Gross Operating Profit” shall mean the actual gross operating profit of the Premises determined generally in accordance with the Uniform System of Accounts, consistently applied and consistent with the determination thereof in the Annual Operating Budget.

“Gross Operating Profit Margin” shall mean for any applicable Fiscal Year, the quotient expressed as a percentage, (i) the numerator of which is the Gross Operating Profit, and (ii) the denominator of which is Gross Revenues.

“Gross Revenues” shall mean all revenues and receipts of every kind received from operating the Premises and all departments and parts thereof, including but not limited to, income from both cash and credit transactions, income from the rental of rooms, stores, offices, banquet rooms, conference rooms, exhibits or sale space of every kind, license, lease and concession fees and rentals (not including gross receipts of licensees, lessees and concessionaires), vending machines, health club membership fees, food and beverage sales, wholesale and retail sales of merchandise, service charges, and proceeds, if any, from business interruption or other loss of income insurance; provided, however, Gross Revenues shall not include (a) gratuities to the Premises’ employees, (b) federal, state or municipal excise, sales or use taxes or similar impositions collected directly from customers, patrons or guests or included as part of the sales prices of any goods or services paid over to federal, state or municipal governments, (c) property insurance or condemnation proceeds (excluding proceeds from business interruption or other loss of income coverage), (d) proceeds from the sale or refinance of assets other than sales in the ordinary course of business, (e) funds furnished by the Lessee, (f) judgments and awards other than for lost business, (g) the amount of all credits, rebates or refunds (which shall be deductions from Gross Revenues) to customers, patrons or guests, (h) receipts of licensees, concessionaires, and tenants, (i) payments received at any of the Hotels for hotel accommodations, goods or services to be provided at other hotels, although arranged by, for or on behalf of Manager; (j) the value of complimentary rooms, food and beverages, (k) interest income, (l) lease security deposits, and (m) items constituting “allowances” under the Uniform System of Accounts.

“Ground Lease Payments” shall mean payments due under any Ground Lease and payable by Landlord thereunder.

“Ground Lease” shall mean any ground lease agreements relating to the Hotel, executed by Landlord with any third party landlords.

“Group Services” shall have the meaning as set forth in Section 6.03.

“Holder” shall mean the holder of any Hotel Mortgage and the indebtedness secured thereby, and such holder’s successors and assigns.

“Hotel” shall mean the hotel or motel property leased by Lessee and managed by Manager pursuant to an Addendum.

“Hotel Mortgage” shall mean, collectively, any mortgage or deed of trust hereafter from time to time, encumbering all or any portion of the Premises (or the leasehold interest therein), together with all other instruments evidencing or securing payment of the indebtedness secured by such mortgage or deed of trust and all amendments, modifications, supplements, extensions and revisions of such mortgage, deed of trust, and other instruments.

“Hotel’s REVPAR Yield Penetration” shall mean, for a Hotel for any applicable Fiscal Year, (i) such Hotel’s actual occupancy rate multiplied by the actual average daily rate, divided by (ii) the Competitive Set’s occupancy rate multiplied by the Competitive Set’s average daily rate for the same Fiscal Period. The determination of the Competitive Set’s occupancy and rate shall be made by reference to the ▇▇▇▇▇ Travel Research reports or its successor or comparable market research reports prepared by another nationally recognized hospitality firm reasonably acceptable to Lessee and Manager.

“House Profit” shall mean the actual house profit of the Premises determined generally in accordance with the Uniform System of Accounts, consistently applied and consistent with the determination thereof in the Annual Operating Budget.

“HP Test” shall have the meaning as set forth in Section 11.01B.

“Incentive Fee” shall have the meaning as set forth in Section 11.01B.

“Indemnifying Party” shall have the meaning as set forth in Section 25.03.

“Independent Directors” shall mean those directors of AHP who are “independent” within the meaning of the rules of the New York Stock Exchange or such other national securities exchange or interdealer quotation system on which AHP’s common stock is then principally traded.

“Intellectual Property” shall have the meaning as set forth in Section 24.03.

“Inventories” shall mean “Inventories” as defined in the Uniform System of Accounts, such as provisions in storerooms, refrigerators, pantries and kitchens, beverages in wine cellars and bars, other merchandise intended for sale, fuel, mechanical supplies, stationery, and other supplies and similar items.

“issuing party” shall have the meaning as set forth in Section 28.10.

“Key Employees” shall have the meaning as set forth in Section 9.07.

“Landlords” shall mean the landlords under the Leases.

“Leases” shall mean any lease agreements as amended, modified, supplemented, and extended from time to time, executed by Lessee as tenant and the Landlords, as described on Exhibit “B” attached to an Addendum.

“Legal Requirements” shall mean all laws, statutes, ordinances, orders, rules, regulations, permits, licenses, authorizations, directions and requirements of all governments and governmental authorities, which now or hereafter may be applicable to the Premises and the operation of the Hotels.

“Lessee” shall have the meaning as set forth in the introductory paragraph of this Agreement; provided, if Lessee is not the “lessee” under the Lease for the Hotel or a Non-Managed Hotel, the term “Lessee” with respect to the Hotel or Non-Managed Hotel shall mean the “lessee” under the Lease, as designated in the applicable Addendum for the Hotel or Project Management Addendum for the Non-Managed Hotel.

“Management Fee” shall collectively mean the Base Management Fee, the Incentive Fee, the Project Management Fee, the Market Service Fee, and any other fees payable to Manager pursuant to the terms of this Agreement.

“Manager” shall have the meaning as set forth in the introductory paragraph of this Agreement.

“Manager Affiliate Entity” shall have the meaning as set forth in Article XXI.

“Market Service Fees” shall have the meaning as set forth in Section 8.02(G).

“Mutual Exclusivity Agreement” shall mean that certain Mutual Exclusivity Agreement dated the date hereof among the Partnership, AHP, Manager and ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇.

“Necessary Expenses” shall mean any expenses, regardless of amount, which are necessary for the continued operation of the Hotel in accordance with Legal Requirements and the Applicable Standards and which are not within the reasonable control of Manager (including, but not limited to those for taxes, utility charges, approved leases and contracts, licensing and permits).

“Net Operating Income” shall be equal to Gross Operating Profit less (i) all amounts to be paid or credited to the Capital Improvement Reserve, and (ii) Rental Payments to the extent that such rental payments are not properly chargeable as an operating expense.

“Non-Disturbance Agreement” means an agreement, in recordable form in the jurisdiction in which a Hotel is located, executed and delivered by the Holder of a Hotel

Mortgage or a Landlord, as applicable, (which agreement shall by its terms be binding upon all assignees of such lender or landlord and upon any individual or entity that acquires title to or possession of a Hotel (referred to as a “Subsequent Owner”), for the benefit of Manager, pursuant to which, in the event such holder (or its assignee) or landlord (or its assignee) or any Subsequent Owner comes into possession of or acquires title to a Hotel, such holder (and its assignee) or landlord (or its assignee) and all Subsequent Owners shall (x) recognize Manager’s rights under this Agreement, and (y) shall not name Manager as a party in any foreclosure action or proceeding, and (z) shall not disturb Manager in its right to continue to manage the Hotels pursuant to this Agreement; provided, however, that at such time, (i) this Agreement has not expired or otherwise been earlier terminated in accordance with its terms, and (ii) there are no outstanding Events of Default by Manager, and (iii) no material event has occurred and no material condition exists which, after notice or the passage of time or both, would entitle Lessee to terminate this Agreement.

“non-issuing party” shall have the meaning as set forth in Section 28.10.

“Non-Managed Hotel” shall mean any hotel or motel property leased by Lessee from an Affiliate of the Partnership for which a Project Management Addendum has been executed and delivered by the parties thereto, and that is not a Hotel managed by Manager pursuant to an Addendum.

“Notice” shall have the meaning as set forth in Article XXII.

“Operating Account” shall have the meaning as set forth in Article XIV.

“Partnership” means Ashford Hospitality Prime Limited Partnership, a Delaware limited partnership.

“Payment Option Request” shall have the meaning as set forth in Section 16.03.

“Performance Cure Period” shall have the meaning as set forth in Section 2.03(b)(i)(2).

“Performance Failure” shall have the meaning as set forth in Section 2.03(b)(i)(1).

“Performance Test” shall have the meaning as defined in Section 2.03(b)(i).

“Predecessor Manager” shall have the meaning as set forth in Section 25.05.

“Premises” shall mean, as to each Hotel, the Lessee’s leasehold interest in such Hotel and Site pursuant to the terms and conditions of the applicable Lease.

“Prime Rate” shall have the meaning as set forth in Section 28.03.

“Project Management Fee” shall have the meaning as set forth in Section 8.02G.

“Project Management Addendum” shall have the meaning as set forth in Article XXVI.

“Project Related Services” shall have the meaning as set forth in Section 8.02G.

“Property Service Account” shall have the meaning as set forth in Section 13.02.

“Proprietary Marks” shall have the meaning as set forth in Section 24.01.

“Prospectus” shall have the meaning as set forth in Section 28.10.

“Qualified Lodging Facility” shall mean a “qualified lodging facility” as defined in Section 856(d)(9)(D) of the Code and means a “Lodging Facility” (defined below), unless wagering activities are conducted at or in connection with such facility by any person who is engaged in the business of accepting ▇▇▇▇▇▇ and who is legally authorized to engage in such business at or in connection with such facility. A “Lodging Facility” is a hotel, motel or other establishment more than one-half of the dwelling units in which are used on a transient basis, and includes customary amenities and facilities operated as part of, or associated with, the lodging facility so long as such amenities and facilities are customary for other properties of a comparable size and class owned by other owners unrelated to AHP.

“Reasonable Working Capital” shall have the meaning as set forth in Section 16.02.

“Related Person” shall have the meaning as set forth in Section 28.08(e).

“Rental Payments” shall mean rental payments made under equipment leases permitted pursuant to the terms of this Agreement.

“REVPAR” shall mean the revenue per available room, determined by taking the actual occupancy rate of the applicable hotel and multiplying such rate by the actual average daily rate of such hotel.

“Sale” shall mean any sale, assignment, transfer or other disposition, for value or otherwise, voluntary or involuntary of Landlord’s title (whether fee or leasehold) in the Hotel, or of a controlling interest therein, other than a collateral assignment intended to provide security for a loan, and shall include any such disposition through the disposition of the ownership interests in the entity that holds such title and any lease or sublease of the Hotel.

“Site” shall mean, as to a Hotel, those certain tracts or parcels of land described in “Exhibit B-1” attached to the applicable Addendum.

“Software” shall have the meaning as set forth in Section 24.02.

“Strike Price” shall have the meaning as set forth in Section 16.03.

“Subject Hotel” shall have the meaning set forth in Section 2.03(b)(i).

“Targeted REVPAR Yield Penetration” shall mean, as to a Hotel, 80%.

“Term” shall mean, as to the Hotel, the contractual duration of this Agreement for the Hotel, as defined in Section 2.01.

“Termination” shall mean the expiration or sooner cessation of this Agreement as to a Hotel.

“Termination Date” shall have the meaning as set forth in Section 2.01.

“Uniform System of Accounts” shall mean the Uniform System of Accounts for the Lodging Industry, 9th Revised Edition, as may be modified from time to time by the International Association of Hospitality Accountants.

“Unrelated Person” shall have the meaning as set forth in Section 28.08(e).

“Working Capital” shall mean the amounts by which current assets exceed current liabilities as defined by the Uniform System of Accounts which are reasonably necessary for the day-to-day operation of the Premises’ business, including, without limitation, the excess of change and ▇▇▇▇▇ cash funds, operating bank accounts, receivables, prepaid expenses and funds required to maintain Inventories, over the amount of accounts payable and accrued current liabilities.

ARTICLE II

TERM OF AGREEMENT

2.01 Term. The term (“Term”) of this Agreement shall commence for each Hotel or Non-Managed Hotel, as the case may be, on the “Commencement Date” as noted on Exhibit “A” of the Addendum for such Hotel or the Project Management Addendum for such Non-Managed Hotel, and, unless sooner terminated as herein provided, shall continue until the “Termination Date.” For purposes of this Agreement, the “Termination Date” for each Hotel or Non-Managed Hotel shall be the earlier to occur of (i) the Expiration Date applicable to such Hotel or Non-Managed Hotel, (ii) termination at the option of Lessee in connection with the bona fide Sale of the Hotel or Non-Managed Hotel by Landlord or Lessee to an unaffiliated third party as provided in and subject to the terms of Section 2.03(a) hereof, (iii) termination at the option of Lessee after the Performance Test has not been satisfied pursuant to and subject to the terms and conditions of Section 2.03(b) below, (iv) termination at the option of Lessee for convenience pursuant to and subject to the terms and conditions of Section 2.03(c) below, or (v) termination by either Lessee or Manager pursuant to Article XVIII hereof in connection with a condemnation, casualty or Force Majeure, subject to the terms thereof. The “Expiration Date” with respect to a Hotel or Non-Managed Hotel shall mean the 10^th anniversary of the Commencement Date applicable to such Hotel or Non-Managed Hotel, provided that such initial 10-year term may thereafter be renewed by Manager, at its option, on the same terms and conditions contained herein, for three (3) successive periods of seven (7) Fiscal Years each, and thereafter, for a final period of four (4) Fiscal Years; and provided further, that at the time of

exercise of any such option to renew, an Event of Default by Manager does not then exist beyond any applicable grace or cure period. If at any time of the exercise of any renewal period, Manager is then in default under this Agreement, then the exercise of the renewal option will be conditional on timely cure of such default, and if such default is not timely cured, then Lessee may terminate this Agreement regardless of the exercise of such renewal period and without the payment of any fee or liquidated damages. If Manager desires to exercise any such option to renew, it shall give Lessee Notice to that effect not less than ninety (90) days prior to the expiration of the then current Term. Notwithstanding the expiration or earlier termination of the Term, Lessee and Manager agree that the obligations of Lessee to pay, remit, reimburse and to otherwise indemnify Manager for any and all expenses and fees incurred or accrued by Manager pursuant to the provisions of this Agreement prior to the expiration or earlier termination of the Term (or actually incurred by Manager after the termination) shall survive Termination, provided such expenses and fees have been incurred consistent with the then current terms of this Agreement and the applicable Annual Operating Budget or Capital Improvement Budget, including, without limitation but only to the extent so consistent, all costs, expenses and liabilities arising from the termination of the Premises’ employees such as accrued vacation and sick leave, severance pay and other accrued benefits, employer liabilities pursuant to the Consolidated Omnibus Budget Reconciliation Act and employer liabilities pursuant to the Worker Adjustment and Retraining Notification Act. In addition, subject to Section 19.02 below and the foregoing sentence, upon Termination of this Agreement as to a Hotel or Non-Managed Hotel, Lessee and Manager shall have no further obligations to one another pursuant to this Agreement with respect to such Hotel or Non-Managed Hotel, except that Section 2.02, obligations to make payments under Section 2.03 or Section 9.05, Section 9.07, the last sentence of Section 15.01, obligations to make payments of termination fees pursuant to Article XVIII, Article XXIV, Article XXV, Article XXVII and Section 28.12 shall survive Termination.

2.02 Actions to be Taken upon Termination. Upon a Termination of this Agreement as to a Hotel, the following shall be applicable:

Manager shall, within forty-five (45) days after Termination of this Agreement as to a Hotel, prepare and deliver to Lessee a final accounting statement with respect to the Hotel, in form and substance consistent with the statements provided pursuant to Section 15.02, along with a statement of any sums due from Lessee to Manager pursuant hereto, dated as of the date of Termination. Within thirty (30) days after the receipt by Lessee of such final accounting statement, the parties will make whatever cash adjustments are necessary pursuant to such final statement. The cost of preparing such final accounting statement shall be a Deduction. Manager and Lessee acknowledge that there may be certain adjustments for which the necessary information will not be available at the time of such final accounting, and the parties agree to readjust such amounts and make the necessary cash adjustments when such information becomes available.

As of the date of the final accounting referred to in subsection A above, Manager shall release and transfer to Lessee any of Lessee’s funds which are held or controlled by Manager with respect to the Hotel, with the exception of funds to

be held in escrow pursuant to Section 9.05 and Section 12.07. During the period between the date of Termination and the date of such final accounting, Manager shall pay (or reserve against) all Deductions which accrued (but were not paid) prior to the date of Termination, using for such purpose any Gross Revenues which accrued prior to the date of Termination.

Manager shall make available to Lessee such books and records respecting the Hotel (including those from prior years, subject to Manager’s reasonable records retention policies) as will be needed by Lessee to prepare the accounting statements, in accordance with the Uniform System of Accounts, for the Hotel for the year in which the Termination occurs and for any subsequent year. Such books and records shall not include: (i) employee records which must remain confidential pursuant to either Legal Requirements or confidentiality agreements, or (ii) any Intellectual Property.

Manager shall (to the extent permitted by Legal Requirements) assign to Lessee, or to any other manager employed by Lessee to operate and manage the Hotel, all operating licenses for the Hotel which have been issued in Manager’s name; provided that if Manager has expended any of its own funds in the acquisition of any of such licenses, Lessee shall reimburse Manager therefor if it has not done so already.

Lessee agrees that hotel reservations and any and all contracts made in connection with hotel convention, banquet or other group services made by Manager in the ordinary and normal course of business consistent with this Agreement, for dates subsequent to the date of Termination and at rates prevailing for such reservations at the time they were made, shall be honored and remain in effect after Termination of this Agreement.

Manager shall cooperate with the new operator of the Hotel as to effect a smooth transition and shall peacefully vacate and surrender the Hotel to Lessee.

Manager and Lessee agree to use best efforts to resolve any disputes amicably and promptly under this Section 2.02 to effect a smooth transition of the Hotel to Lessee and/or Lessee’s new manager.

2.03 Early Termination Rights; Liquidated Damages.

(a) Termination Upon Sale. Upon Notice to Manager, Lessee shall have the option to terminate this Agreement with respect to one, more or all of the Hotels or Non-Managed Hotels effective as of the closing of the Sale of such Hotels or Non-Managed Hotels to a third party. Such Notice shall be given at least forty-five (45) days’ in advance (unless otherwise required by Legal Requirements, in which case Lessee shall provide such additional notice in order to comply with such Legal Requirements) and shall inform Manager of the identity of the contract purchaser. Manager, at its election, may offer to provide management services to such contract purchaser after the closing of the sale. Lessee shall, in connection with such Sale, by a separate document reasonably

acceptable to Lessee and Manager, indemnify and save Manager harmless against any and all losses, costs, damages, liabilities and court costs, claims and expenses, including, without limitation, reasonable attorneys’ fees arising or resulting from the failure of Lessee or such prospective purchaser to provide any of the services contracted for in connection with the business booked for such hotels to, and including, the date of such Termination, in accordance with the terms of this Agreement, including without limitation, any and all business so booked as to which facilities and/or services are to be furnished subsequent to the date of Termination, provided that any settlement by Manager of any such claims shall be subject to the prior written approval of Lessee which shall not be unreasonably withheld, conditioned or delayed. In addition, the following terms shall apply in connection with the sale of any Hotel:

(i) If this Agreement is terminated pursuant to Section 2.03(a) with respect to a Hotel prior to the first anniversary of the Commencement Date applicable to such Hotel, then Lessee shall pay to Manager on such termination, a termination fee as liquidated damages and not as a penalty (provided that an Event of Default by Manager is not then existing beyond any cure or grace periods set forth in this Agreement) in an amount equal to the estimated Base Management Fee and Incentive Fee that was estimated to be paid to Manager with respect to such Hotel pursuant to the Annual Operating Budget for the remaining Accounting Periods until the first anniversary of the Commencement Date for such Hotel (irrespective of the Management Fees paid to Manager prior to the date of the Termination with respect to such Hotel). If this Agreement is terminated pursuant to Section 2.03(a) with respect to a Hotel after the first anniversary of the Commencement Date applicable to such Hotel, then no termination fees shall be payable by Lessee for such Hotel.

(b) Termination Due to Failure to Satisfy Performance Test.

(i) Performance Test. Lessee shall have the right to terminate this Agreement with respect to any Hotel (for the purposes of this Section 2.03(b)(i) called “Subject Hotel”), subject to the payment of a termination fee as set forth in subsection (ii) below, in the event of the occurrence of the following (collectively herein called, the “Performance Test”):

(1) If for any Fiscal Year (a) a Subject Hotel’s Gross Operating Profit Margin for such Fiscal Year is less than seventy-five percent (75%) of the average Gross Operating Profit Margin of comparable hotels in similar markets and geographic locations to the applicable Hotel as reasonably determined by Lessee and Manager, and (b) such Subject Hotel’s REVPAR Yield Penetration is less than the Targeted REVPAR Yield Penetration for such Fiscal Year (herein (a) and (b) collectively called “Performance Failure”); then

(2) Manager shall have a period of two (2) years, commencing with the next ensuing Fiscal Year (the “Performance Cure Period”), to

cure the Performance Failure after Manager’s receipt of Notice from Lessee of such Performance Failure and Lessee’s intent to terminate this Agreement with respect to the Subject Hotel if the Performance Failure is not cured within such Performance Cure Period; and

(3) If after the first full Fiscal Year during the Performance Cure Period, the Performance Failure remains uncured, then upon written Notice to Manager by Lessee, Manager shall engage a consultant reasonably acceptable to Manager and Lessee (with significant experience in the hotel lodging industry) to make a written determination (within forty-five (45) days of such Notice) as to whether another management company (with comparable breadth of knowledge and experience as any of the hotel management companies owned and/or controlled by ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇. and/or ▇▇▇▇▇ ▇▇▇▇▇▇▇, including with respect to number and type of hotels managed in similar markets and geographical areas) could manage the Subject Hotel in a materially more efficient manner. If such consultant determination is in the negative, then Manager will be deemed not to be in default under the Performance Test. If such consultant determination is in the affirmative, then Manager agrees to engage such consultant (such cost and expense to be shared by Lessee and Manager equally) to assist Manager during the second Fiscal Year of the Performance Cure Period with the cure of the Performance Failure; and

(4) If after the end of the Performance Cure Period, the Performance Failure remains uncured and the consultant again makes a written determination that another management company (with comparable breadth of knowledge and experience as any of the hotel management companies owned and/or controlled by ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇. and/or ▇▇▇▇▇ ▇▇▇▇▇▇▇, including with respect to number and type of hotels managed in similar markets and geographical areas) could manage the Subject Hotel in a materially more efficient manner, then Lessee may, at its election, terminate this Agreement upon forty-five (45) days’ prior Notice to Manager.

(ii) Termination Fees. If Lessee elects to terminate this Agreement with respect to a Subject Hotel for failure to satisfy the Performance Test, Lessee shall pay to Manager as liquidated damages but not as a penalty, a termination fee (provided that there does not then exist an Event of Default by Manager under this Agreement beyond any applicable cure periods) in the amount equal to 60% of the product obtained by multiplying (A) 65% of the aggregate Base Management Fees and Incentive Fees budgeted in the Annual Operating Budget applicable to the Subject Hotel for the full current Fiscal Year in which such termination is to occur (but in no event less than the Base Management Fees and Incentive Fees for the preceding full Fiscal Year) by (B) nine (9).

(iii) Finance Reports. Determinations of the performance of the Subject Hotel shall be in accordance with the audited annual financial statements delivered by Lessee’s accountant pursuant to Section 15.03 hereof.

(iv) Extension of Performance Cure Period. Notwithstanding the foregoing, if at any time during the Performance Cure Period (a) Lessee is in material default under any of its obligations under this Agreement, or (b) Lessee has terminated, terminates or causes a termination of the Franchise Agreement (other than defaults due to Manager) and does not obtain a new franchise agreement with a comparable franchisor, or (c) the operation of the Hotel or the use of the Hotel’s facilities are materially disrupted by casualty, condemnation, or events of Force Majeure that are beyond the reasonable control of Manager, or by major repairs to or major refurbishment of the Hotel, then, for such period, the Performance Cure Period shall be extended.

(v) Renewal Period. If at the time of Manager’s exercise of a renewal period with respect to any Hotel, such hotel is a Subject Hotel within a Performance Cure Period, the exercise of such renewal period shall be conditional upon timely cure of the Performance Failure, and if such Performance Failure is not timely cured, then, notwithstanding the foregoing provisions, Lessee may elect to terminate this Agreement with respect to such Subject Hotel pursuant to the terms of this Section 2.03(b) without payment of any termination fee.

(c) Termination For Convenience. Lessee may terminate this Agreement with respect to a particular Hotel or Non-Managed Hotel for convenience (except if due to a Sale of a Hotel or Non-Managed Hotel, whereupon Section 2.03(a) shall govern) upon ninety (90) days Notice to Manager, and shall pay to Manager as liquidated damages but not as a penalty, a termination fee (provided that there does not then exist an Event of Default by Manager under this Agreement beyond any applicable cure or grace periods) in an amount equal to (i) with respect to a Hotel, the product of (A) 65% of the aggregate Base Management Fees and Incentive Fees budgeted in the Annual Operating Budget applicable to the Hotel for the full current Fiscal Year in which such termination is to occur (but in no event less than the Base Management Fees and Incentive Fees for the preceding full Fiscal Year) by (B) nine (9), and (ii) with respect to a Non-Managed Hotel, the product of (A) 65% of the aggregate Project Management Fees and Market Service Fees estimated for the Non-Managed Hotel for the full current Fiscal Year in which such termination is to occur (but in no event less than the Project Management Fees and Market Service Fees for the preceding full Fiscal Year) by (B) nine (9).

(d) Payment of Liquidated Damages. WITH RESPECT TO ANY TERMINATION FEES PAYABLE IN CONNECTION WITH ANY EARLY TERMINATION RIGHT SET FORTH IN THIS SECTION 2.03, OR IN SECTION 18.04 BELOW, LESSEE RECOGNIZES AND AGREES THAT, IF THIS AGREEMENT IS TERMINATED WITH RESPECT TO ANY OF THE HOTELS FOR THE REASONS SPECIFIED IN THIS SECTION 2.03 OR IN SECTION 18.04 BELOW, THEREBY ENTITLING MANAGER TO RECEIVE THE TERMINATION

FEES AS SET FORTH IN THIS SECTION 2.03 OR IN SECTION 18.04 BELOW, MANAGER WOULD SUFFER AN ECONOMIC LOSS BY VIRTUE OF THE RESULTING LOSS OF MANAGEMENT FEES WHICH WOULD OTHERWISE HAVE BEEN EARNED UNDER THIS AGREEMENT. BECAUSE SUCH FEES VARY IN AMOUNT DEPENDING ON THE TOTAL GROSS REVENUES EARNED AT THE HOTELS AND ACCORDINGLY WOULD BE EXTREMELY DIFFICULT AND IMPRACTICAL TO ASCERTAIN WITH CERTAINTY, THE PARTIES AGREE THAT THE TERMINATION FEES PROVIDED IN THIS SECTION 2.03 AND IN SECTION 18.04 BELOW CONSTITUTE A REASONABLE ESTIMATE OF LIQUIDATED DAMAGES TO MANAGER FOR PURPOSES OF ANY AND ALL LEGAL REQUIREMENTS, AND IT IS AGREED THAT MANAGER SHALL NOT BE ENTITLED TO MAINTAIN A CAUSE OF ACTION AGAINST LESSEE, EXCEPT AS SPECIFICALLY PROVIDED HEREIN, FOR ACTUAL DAMAGES IN EXCESS OF THE TERMINATION FEES IN ANY CONTEXT WHERE THE TERMINATION FEES ARE PROVIDED BY THIS AGREEMENT, AND RECEIPT OF SUCH FEES (TOGETHER WITH ALL OTHER AMOUNTS DUE AND PAYABLE BY LESSEE TO MANAGER WITH RESPECT TO EVENTS OCCURRING PRIOR TO TERMINATION OF THIS AGREEMENT WITH RESPECT TO THE APPLICABLE HOTELS OR AS OTHERWISE PROVIDED HEREIN) SHALL BE MANAGER’S SOLE REMEDY FOR DAMAGES AGAINST LESSEE IN ANY SUCH CASE. The foregoing shall in no way affect any other sums due Manager under this Article II or otherwise hereunder, including, without limitation, the Management Fees earned during the Term, or any other rights or remedies, at law or in equity of Manager under this Agreement or under Legal Requirements, including any indemnity obligations of Lessee to Manager under this Agreement.

ARTICLE III

PREMISES

Manager shall be responsible, at the sole cost and expense of Lessee, for keeping and maintaining the Premises fully equipped in accordance with plans, specifications, construction safety and fire safety standards, and designs pursuant to applicable Legal Requirements, the standards and requirements of a Franchisor pursuant to any applicable Franchise Agreement, any applicable Hotel Mortgage, the Leases and the Capital Improvement Budgets approved pursuant to the terms hereof, subject in all respects to performance by Lessee of its obligations pursuant to this Agreement.

ARTICLE IV

APPOINTMENT OF MANAGER

4.01 Appointment. Lessee hereby appoints Manager as its sole, exclusive and continuing operator and manager to supervise and direct, for and at the expense of Lessee, the management and operation of the Premises under the terms and conditions hereinafter set forth. In exercising its duties hereunder, Manager shall act as agent and for the account of Lessee. Manager hereby accepts said appointment and agrees to manage the Premises during the Term of this Agreement under the terms and conditions hereinafter set forth.

4.02 Delegation of Authority. The operation of the Premises shall be under the exclusive supervision and control of Manager who, except as otherwise specifically provided in this Agreement, shall be responsible for the proper and efficient management and operation of the Premises in accordance with this Agreement, the Leases, the Franchise Agreements, the Capital Improvement Budget and the Annual Operating Budget. Subject to the terms of such agreements and budgets, the Manager shall have discretion and control in all matters relating to the management and operation of the Premises, including, without limitation, charges for rooms and commercial space, the determination of credit policies (including entering into agreements with credit card organizations), food and beverage service and policies, employment policies, procurement of inventories, supplies and services, promotion, advertising, publicity and marketing, and, generally, all activities necessary for the operation of the Premises. Manager shall also be responsible for the receipt, holding and disbursement of funds and maintenance of bank accounts in compliance with the Cash Management Agreements, if applicable.

4.03 Contracts, Equipment Leases and Other Agreements. Manager is hereby authorized to grant concessions, lease commercial space and enter into any other contract, equipment lease, agreement or arrangement pertaining to or otherwise reasonably necessary for the normal operation of the Premises (such concession, lease, equipment lease, contract, agreement or arrangement hereinafter being referred to individually as a “Contract” and collectively as “Contracts”) on behalf of Lessee, as may be necessary or advisable and reasonably prudent business judgment in connection with the operation of the Premises and consistent with the Annual Operating Budget, and subject to any restrictions imposed by the Franchise Agreements, Leases or any Hotel Mortgage, and subject to the Lessee’s prior written approval of: (i) any Contract which provides for a term exceeding one (1) year (unless such Contract is thirty day cancellable with cost, premium or penalty equal to or less than $25,000.00) or (ii) any tenant space lease, license or concession concerning any portion of the public space in or on the Premises for stores, office space, restaurant space, or lobby space. Lessee’s approval of any Contract shall not be unreasonably withheld, delayed or conditioned. Unless otherwise agreed, all Contracts for the Premises shall be entered into in Lessee’s name. Manager shall make available to Lessee, its agents, and employees, at the Premises during business hours, executed counterparts or certified true copies of all Contracts it enters into pursuant to this Section 4.03.

4.04 Alcoholic Beverage/Liquor Licensing Requirements. With respect to any licenses and permits held by Lessee or any of its subsidiaries for the sale of any liquor and alcoholic beverages at any of the Premises, Manager agrees, as part of its management duties and services under this Agreement, to fully cooperate with any applicable liquor and/or alcoholic beverage authority and to assist Lessee with any documentation and other requests of such authority to the extent necessary to comply with any licensing and/or permitting requirements applicable to the Premises.

ARTICLE V

REPRESENTATIONS AND WARRANTIES

5.01 Lessee Representations. Upon execution of an Addendum or a Project Management Addendum, the Lessee identified in the Addendum or Project Management

Addendum, in order to induce Manager to enter into this Agreement, will be deemed to hereby represent and warrant to Manager as of the date of such Addendum as follows:

5.01.1. The execution of this Agreement is permitted by the organizational documents of Lessee and this Agreement has been duly authorized, executed and delivered on behalf of Lessee and constitutes the legal, valid and binding obligation of Lessee enforceable in accordance with the terms hereof;

5.01.2. There is no claim, litigation, proceeding or governmental investigation pending, or, to the best knowledge and belief of Lessee, threatened, against or relating to Lessee, the properties or businesses of Lessee or the transactions contemplated by this Agreement which does, or may reasonably be expected to, materially or adversely affect the ability of Lessee to enter into this Agreement or to carry out its obligations hereunder, and, to the best knowledge and belief of Lessee, there is no basis for any such claim, litigation, proceeding or governmental investigation except as has been fully disclosed in writing by Lessee to Manager;

5.01.3. Neither the consummation of the transactions contemplated by this Agreement on the part of Lessee to be performed, nor the fulfillment of the terms, conditions and provisions of this Agreement, conflicts with or will result in the breach of any of the terms, conditions or provisions of, or constitute a default under, any agreement, indenture, instrument or undertaking to which Lessee is a party or by which it is bound;

5.01.4. No approval of any third party (including any Landlord or the Holder of any Hotel Mortgage in effect as of the date of this Agreement) is required for Lessee’s execution, delivery and performance of this Agreement that has not been obtained prior to the execution hereof;

5.01.5. Lessee holds all required governmental approvals required (if applicable) to be held by it to lease the Hotel or Non-Managed Hotel; and

5.01.6. As of the date of this Agreement there are no defaults under any of the Leases.

5.02 Manager Representations. Upon execution of an Addendum or Project Management Addendum, Manager, in order to induce Lessee to enter into this Agreement, will be deemed to hereby represent and warrant to Lessee as of the date of such Addendum or Project Management Addendum as follows:

5.02.1. The execution of this Agreement is permitted by the organizational documents of Manager and this Agreement has been duly authorized, executed and delivered on behalf of Manager and constitutes a legal, valid and binding obligation of Manager enforceable in accordance with the terms hereof;

5.02.2. There is no claim, litigation, proceeding or governmental investigation pending, or, to the best knowledge and belief of Manager, threatened, against or relating

to Manager, the properties or business of Manager or the transactions contemplated by this Agreement which does, or may reasonably be expected to, materially or adversely affect the ability of Manager to enter into this Agreement or to carry out its obligations hereunder, and, to the best knowledge and belief of Manager, there is no basis for any such claim, litigation, proceeding or governmental investigation, except as has been fully disclosed in writing by Manager to Lessee;

5.02.3. Neither the consummation of the transactions contemplated by this Agreement on the part of Manager to be performed, nor the fulfillment of the terms, conditions and provisions of this Agreement, conflicts with or will result in the breach of any of the terms, conditions or provisions of, or constitute a default under, any agreement, indenture, instrument or undertaking to which Manager is a party or by which it is bound;

5.02.4. No approval of any third party is required for Manager’s execution, delivery and performance of this Agreement that has not been obtained prior to the execution and delivery hereof;

5.02.5. Manager holds all required governmental approvals required to be held by it to perform its obligations under this Agreement; and

5.02.6. Manager qualifies as an Eligible Independent Contractor, and during the Term of this Agreement, agrees to continue to qualify as an Eligible Independent Contractor.

ARTICLE VI

OPERATION

6.01 Name of Premises; Standard of Operation. During the Term of this Agreement, the Premises shall be known and operated by Manager as a hotel licensed with the applicable Franchisor as noted on Exhibit C to each Addendum, with additional identification as may be necessary to provide local identification, provided Manager and/or Lessee have obtained and are successful in continuously maintaining the right to so operate the Premises, which Manager agrees to use its reasonable best efforts to do. Manager agrees to manage the Premises, for the account of Lessee, and so far as is legally possible, in accordance with the Annual Operating Budget and Applicable Standards subject to Force Majeure. In the event of termination of a Franchise Agreement for one or more of the Premises, Manager shall operate such Premises under such other franchise agreement, if any, as Lessee enters into or obtains as franchisee. If the name of a Franchisor’s hotel system is changed, Lessee shall have the right to change the name of the applicable Hotel to conform thereto.

Notwithstanding the foregoing or any other provision in this Agreement to the contrary, Manager’s obligation with respect to operating and managing the Hotel in accordance with any Hotel Mortgage, Ground Leases, the Leases and the CCRs shall be limited to the extent (i) true and complete copies thereof have been made available to Manager by Lessee reasonably sufficient in advance to allow Manager to manage the Hotel in compliance with such documents, and (ii) the provisions thereof and/or compliance with such provisions by Manager (a) are

applicable to the day-to-day management, maintenance and routine repair and replacement of the Hotel, the FF&E or any portion thereof, (b) do not require contribution of funds from Manager, (c) do not materially increase Manager’s obligations hereunder or materially decrease Manager’s rights or benefits hereunder, (d) do not limit or restrict, or attempt to limit or restrict any corporate activity or transaction with respect to Manager or any Manager Affiliate Entity or any other activity, transfer, transaction, property or other matter involving Manager or the Manager Affiliate Entities other than at the Site of the Hotel and (e) are otherwise within the scope of Manager’s duties under this Agreement. Lessee acknowledges and agrees, without limiting the foregoing, that any failure of (i) Lessee to comply with the provisions of any Hotel Mortgage, Ground Leases, the Leases and the CCRs or Legal Requirements or (ii) Manager to comply with the provisions of any such agreements or Legal Requirements arising out of, in the case of both (i) and (ii), (A) the condition of the Hotel, and/or the failure of the Hotel to comply with the provisions of such agreements, prior to the Commencement Date, (B) construction activities at the Hotel prior to the Commencement Date, (C) inherent limitations in the design and/or construction of, location of the Hotel and/or parking at the Hotel prior to the Commencement Date, (D) failure of Lessee to provide funds, from operations or otherwise, sufficient to allow timely compliance with the provisions of the Applicable Standards or the Leases, the Ground Leases, any Hotel Mortgage and/or the CCRs through reasonable and customary business practices, and/or (E) Lessee’s failure to approve any matter reasonably requested by Manager in Manager’s good faith business judgment as necessary or appropriate to achieve compliance with such items, shall not be deemed a breach by Manager of its obligations under this Agreement. Manager and Lessee agree, that Manager may from time to time, so long as Manager is in compliance with the Franchise Agreements and Legal Requirements, provide collateral marketing materials in the rooms of the Hotel which advertise other hotels or programs of Manager or its Affiliates (including, through a dedicated television channel in the rooms of the Hotel), at the sole cost and expense of Manager, provided such other hotels or programs being marketed by Manager are not competing directly in the same market with the Hotel where the marketing materials and information are being placed by Manager.

6.02 Use of Premises. Manager shall use the Premises solely for the operation of the Hotel in accordance with the Applicable Standards and for all activities in connection therewith which are customary and usual to such an operation. Subject to the terms of this Agreement, Manager shall comply with and abide by all applicable Legal Requirements, and the requirements of any insurance companies covering any of the risks against which the Premises are insured, any Hotel Mortgage, the Ground Leases, the Leases, and the Franchise Agreements. If there are insufficient funds in the Operating Account to make any expenditure required to remedy non-compliance with such Legal Requirements or with the requirements of any Hotel Mortgage, the Ground Leases, the Leases, or the Franchise Agreements or applicable insurance, Manager shall promptly notify Lessee of such non-compliance and estimated cost of curing such non-compliance. If Lessee fails to make funds available for the expenditure so requested by Manager within thirty (30) days, Lessee agrees to indemnify and hold Manager harmless from and against any and all costs, expenses and other liabilities incurred by Manager resulting from such non-compliance (which such indemnity shall survive any termination of this Agreement). In no event shall Manager be required to make available or distribute, as applicable, sexually explicit materials or items of any kind, whether through retail stores or gift shops located at the Hotel or through “pay for view” programming in the guest rooms of the Hotel.

6.03 Group Services. Manager may cause to be furnished to the Premises certain services (“Group Services”) which are furnished generally on a central or regional basis to other hotels managed by Manager or any Manager Affiliate Entity and which benefit each hotel managed by Manager including, by way of example and not by way of limitation, (i) marketing, advertising and promotion; (ii) centralized accounting payroll processing, ADP management, management and administration of accounts payable, accounts receivable and cash management accounting and MIS support services; (iii) the preparation and maintenance of the general ledger and journal entries, internal audit, budgeting and financial statement preparation, (iv) recruiting, training, career development and relocation in accordance with Manager’s or any Manager Affiliate Entities’ relocation plan; (v) employee benefits administration; (vi) engineering and risk management; (vii) information technology; (viii) legal support (such as license and permit coordination, filing and completion, standardized contracts, negotiation and preparation, and similar legal services benefiting the Hotel); (ix) purchasing arising out of ordinary hotel operations not otherwise contemplated in Section 8.02G hereof; (x) internal audit services; (xi) reservation systems; and (xii) such other additional services as are or may be, from time to time, furnished for the benefit of Manager’s or any Manager Affiliate Entities’ hotels or in substitution for services now performed at Manager’s individual hotels which may be more efficiently performed on a group basis. Group Services shall include Manager’s costs relating to the establishment of an office(s) and the placement of Manager’s personnel at international locations as may be reasonably required to oversee the performance of its services and duties hereunder for international assets. International office expenses, overhead, international personnel costs and benefits, travel and other costs directly related to Manager’s personnel (other than property level personnel who are employed at a Hotel and whose Employee Costs and Expenses constitute Deductions) who oversee the operations of international assets shall be allocated pro-rata to international Hotels based on room count and/or revenues in a fair and equitable manner reasonably determined by Manager. Manager shall assure that the costs and expenses incurred in providing Group Services to the Premises shall have been allocated to the Premises on a pro-rata basis consistent with the method of allocation to all of Manager’s (and any Manager Affiliate Entities’) hotels receiving the same services, shall be incurred at a cost consistent with the Annual Operating Budget and shall constitute Deductions. All Group Services provided by Manager shall be at the actual costs (without ▇▇▇▇ up for fee or profit to Manager or any Manager Affiliate Entity, but including salary and employee benefit costs and costs of equipment used in performing such services and overhead costs) of Group Services for the benefit of all of Manager’s hotels receiving the same services, and shall be of a quality comparable to which Manager could obtain from other providers for similar services.

6.04 Right to Inspect. Lessee, the beneficial owners of Lessee, the Landlords (to the extent permitted under such Leases), any Holder under any Hotel Mortgage (to the extent permitted under such Hotel Mortgage), and their respective agents, shall have access to the Premises at any and all reasonable times for any purpose. Manager will be available to consult with and advise such parties, at their reasonable request, concerning all policies and procedures affecting all phases of the conduct of business at the Hotel.

ARTICLE VII

WORKING CAPITAL AND INVENTORIES

7.01 Working Capital and Inventories. The Lessee shall cause funds to be deposited in one or more operating accounts established by Manager, in amounts sufficient to operate the Premises in accordance with the Annual Operating Budget, including the establishment and maintenance of positive Working Capital and Inventories as reasonably determined by Manager. All Working Capital and Inventories are and shall remain the property of Lessee. In the event Lessee fails to advance funds which are necessary in order to maintain positive Working Capital and Inventories at reasonable levels for a Hotel, Manager shall have the right to elect to terminate this Agreement upon sixty (60) days’ prior written notice to Lessee with respect to the affected applicable Hotel. During such sixty (60) day period, Lessee and Manager shall use reasonable efforts to resolve the dispute over such Working Capital and Inventory requirements. If such dispute is not resolved, then this Agreement shall terminate with respect to the affected applicable Hotel on the sixtieth (60th) day following Manager’s delivery of written notice of termination as provided above. If such dispute is resolved, then the notice will be deemed rescinded and this Agreement shall not be terminated pursuant to the notice with respect to the affected applicable Hotel. Further, if Manager should so terminate this Agreement with respect to the affected applicable Hotel and if Manager in good faith incurs expenditures, or otherwise accrues liabilities in accordance with the Annual Operating Budget and variances allowed herein, in each case, prior to the date of termination, Lessee agrees to promptly indemnify and hold Manager harmless from and against (i) any and all liabilities, costs and expenses properly incurred by Manager in connection with the operations of the applicable Hotel through the date of Termination of this Agreement with respect to such Hotel, and (ii) any and all liabilities, costs and expenses properly incurred by Manager as a result of Lessee’s failure to perform any obligation or pay any liability arising under any service, maintenance, franchise or other agreements, employment relationships (other than Excluded Employee Claims), leases or contracts pertaining to the applicable Hotel after Termination of this Agreement with respect to such Hotel. Lessee acknowledges that liabilities arising in connection with the operation and management of the applicable Hotel including, without limitation, all Deductions, incurred in accordance with the terms of this Agreement, are and shall remain the obligations of Lessee, and Manager shall have no liability therefor unless otherwise expressly provided herein. In the event of a Termination by Manager pursuant to this Section 7.01, Manager shall be entitled to a termination fee as liquidated damages but not as a penalty, as set forth in connection with a termination for convenience as described in Section 2.03(c) and subject to Section 2.03(d) above.

7.02 Fixed Asset Supplies. Lessee shall provide the funds necessary to supply the Premises initially with Fixed Asset Supplies as reasonably determined by Manager consistent with the cost budgeted therefor in the Annual Operating Budget and otherwise consistent with the intent of the parties that the level of such supplies will be adequate for the proper and efficient operation of the Premises at the Applicable Standards. Fixed Asset Supplies shall remain the property of Lessee.

ARTICLE VIII

MAINTENANCE, REPLACEMENT AND CHANGES

8.01 Routine and Non-Routine Repairs and Maintenance. Manager, at the expense of Lessee, shall maintain the Premises in good repair and condition as is required by the Applicable Standards. Manager, on behalf of Lessee, shall make or cause to be made such routine maintenance, repairs and minor alterations as Manager from time to time deems reasonably necessary for such purposes, the cost of which: (i) can be expensed under GAAP, (ii) shall be paid from Gross Revenues, and treated as a Deduction, and (iii) are consistent with the Annual Operating Budget. In addition, Manager, on behalf of Lessee, shall make or cause to be made such non-routine repairs and maintenance, either to the Premises’ building or its fixtures, furniture, furnishings and equipment (“FF&E”), pursuant to the Capital Improvement Budget approved by Lessee and Landlord, the cost of which shall be paid for in the manner described in Section 8.02. Manager and Lessee shall use their respective best efforts to prevent any liens from being filed against the Premises which arise from any maintenance, changes, repairs, alterations, improvements, renewals or replacements in or to the Premises. Lessee and Manager shall cooperate fully in obtaining the release of any such liens. If the lien arises as a result of the fault of either party, then the party at fault shall bear the cost of obtaining the lien release. All changes, repairs, alterations, improvements, renewals or replacements made pursuant to this Article VIII shall be the property of the Lessee.

8.02 Capital Improvement Reserve.

Manager shall establish (on behalf of Landlord), in respect of each Fiscal Year during the term of this Agreement, a reserve account on each Hotel’s books of account (“Capital Improvement Reserve”) to cover the cost of:

Replacements and renewals to the Premises’ FF&E; and

Certain non-routine repairs and maintenance to the Hotel’s building(s) which are normally capitalized under GAAP such as, but not limited to, exterior and interior repainting, resurfacing, building walls, floors, roofs and parking areas, and replacing folding walls and the like, and major repairs, alterations, improvements, renewals or replacement to the Hotel’s building structure or to its mechanical, electrical, heating, ventilating, air conditioning, plumbing or vertical transportation systems.

For each Fiscal Year, the Capital Improvement Reserve shall be an amount equal to four percent (4%) of the Hotel’s Gross Revenues for the applicable year (or greater if required by any Landlord, Holder or Franchisor), or in such other amount as agreed to by Landlord, Lessee and Manager.

Payments of the percentage amounts specified above shall be made on an interim accounting basis as specified in Section 11.02 hereof. Calculations and payments from the Capital Improvement Reserve made with respect to each Accounting Period shall be accounted for cumulatively for each Fiscal Year. After the close of each Fiscal Year, any adjustments required by the Fiscal Year accounting shall

be made by Manager. Any proceeds from the sale of the Premises’ FF&E no longer necessary to the operations of the Premises shall also be credited to the Capital Improvement Reserve. All payments from the Capital Improvement Reserve shall be reserved and paid from Gross Revenues. Such payments and sale proceeds shall be placed in an escrow account or accounts consistent with the requirements of the Cash Management Agreements, if any. Any interest earned in said account attributable to funds deposited pursuant to this Agreement shall be added to such Capital Improvement Reserve, thereby reducing the amount required to be placed in the account from Gross Revenues.

Manager shall, in accordance with and subject to the Capital Improvement Budget described in Section 8.02E, from time to time make such substitutions and replacements of or renewals to FF&E and non-routine repairs and maintenance as described in Section 8.01 as it deems necessary to maintain the Hotel as required by this Agreement. Except as hereinafter provided, no expenditures will be made except as otherwise provided in the Capital Improvement Budget without the approval of Lessee and Landlord, and provided further, however, that if any such expenditures which are required by reason of any (i) emergency, or (ii) applicable Legal Requirements, or (iii) the terms of the Franchise Agreement, or (iv) are otherwise required for the continued safe and orderly operation of the Hotel, Manager shall immediately give Lessee and Landlord notice thereof and shall be authorized to take appropriate remedial action without such approval whenever there is a clear and present danger to life, limb or property of the Hotel or its guests or employees. The cost of all such changes, repairs, alterations, improvements, renewals, or replacements will be paid for first from the Capital Improvement Reserve or other monies advanced by Lessee from funds received or owned by Landlord. At the end of each Fiscal Year any amount remaining in the Capital Improvement Reserve in excess of the amounts unspent but contemplated to be spent pursuant to the Capital Improvement Budget for such Fiscal Year or as otherwise approved by Lessee and Landlord may be withdrawn by the Lessee on behalf of Landlord.

All changes, repairs, alterations, improvements, renewals or replacements made pursuant to this Article VIII shall be the property of Landlord.

Manager shall prepare a budget (“Capital Improvement Budget”) of the expenditures necessary for replacement of FF&E and building repairs of the nature contemplated by Section 8.01 during the ensuing Fiscal Year and shall provide such Capital Improvement Budget to Lessee and Landlord for approval at the same time Manager submits the Annual Operating Budget. The Capital Improvement Budget shall not be deemed accepted by Lessee and Landlord in the absence of their respective express written approval. Not later than thirty (30) days after receipt by Lessee and Landlord of a proposed Capital Improvement Budget (or such longer period as Lessee and Landlord may reasonably request on Notice to the Manager), Lessee and/or Landlord may deliver a Notice (a “CIB Objection Notice”) to the Manager stating that Lessee

and/or Landlord objects to any information contained in or omitted from such proposed Capital Improvement Budget and setting forth the nature of such objections with reasonable specificity. Failure of Lessee and/or Landlord to deliver a CIB Objection Notice shall be deemed rejection of the Manager’s proposed Capital Improvement Budget in its entirety. Upon receipt of any CIB Objection Notice, the Manager shall, after consultation with Lessee and Landlord, modify the proposed Capital Improvement Budget, taking into account Lessee’s and/or Landlord’s objections, and shall resubmit the same to Lessee and Landlord for Lessee’s approval within fifteen (15) days thereafter, and Lessee and/or Landlord may deliver further CIB Objection Notices (if any) within fifteen (15) days thereafter (in which event, the re-submission and review process described above in this sentence shall continue until the proposed Capital Improvement Budget in question is accepted and consented to by Lessee and Landlord). Notwithstanding anything to the contrary set forth herein, Lessee and Landlord shall have the right at any time subsequent to the acceptance and consent with respect to any Capital Improvement Budget, on Notice to the Manager, to revise, with the reasonable approval of Manager, such Capital Improvement Budget or to request that the Manager prepare for Lessee’s and/or Landlord’s approval a revised Capital Improvement Budget, taking into account such circumstances as Lessee and Landlord deem appropriate; provided, however, that the revision of a Capital Improvement Budget shall not be deemed a revocation of the Manager’s authority with respect to such actions as the Manager may have already taken prior to receipt of such revision notice in implementing a previously approved budget or plan. Manager shall have the right and discretion to expend funds from the Capital Improvement Reserve for replacements and renewals of FF&E in the Hotel’s interior public areas and guest rooms and routine maintenance, repairs and minor alterations during the Fiscal Year in question (but not for any other capital expenditures) in accordance with the provisions of the Capital Improvement Budget.

It is the intent of Manager and Lessee to maintain the Premises in conformance with the Applicable Standards. Accordingly, as the Hotel ages, if the Capital Improvement Reserve established pursuant to the terms hereof is insufficient to meet such standards, and if the Capital Improvement Budget prepared in good faith by Manager and approved by Lessee and Landlord exceeds the available and anticipated funds in the Capital Improvement Reserve, Lessee, Landlord and Manager will consider the matter and Lessee and Landlord may elect to:

increase the annual reserve provision to provide the additional funds required; or

obtain financing for the additional funds required.

In consideration of the Project Management Fee (as defined below), Manager shall be responsible for managing, coordinating, planning and executing the Capital Improvement Budget and all major repositionings of the Hotel and, to the

extent Lessee has the right to direct such matters (e.g., the manager for the Non-Managed Hotel does not have the right under its management agreement to direct such matters or elects not to exercise such right), each Non-Managed Hotel (for such purposes with respect to a Non-Managed Hotel, the term Capital Improvement Budget shall mean the capital improvement budget for such Non-Managed Hotel). In addition, Manager shall be paid additional fees at current market rates (determined with reference to other third party providers of such services who are not discounting such fees as result of fees generated from other services) (collectively, the “Market Service Fees”), subject to the Approval Requirement (defined in subparagraph 8.02(I) below), for the following services (the “Project Related Services”) to be provided in accordance with the Applicable Standards (with the understanding that Manager may subcontract for any or all of the following Project Related Services) for the Hotel and, to the extent Lessee has the right to direct such matters, Non-Managed Hotel:

Construction Management - Manager shall, on major renovation tasks which involve the selection and engagement of a general contractor, coordinate the selection process with Lessee and/or Landlord, shall assist in the negotiation of construction contracts, manage such construction contracts and related issues, and shall engage separate contractors and subcontractors for specific tasks outside the scope of the general contractor.

Interior Design - With respect to any interior design elements involved in the implementation of the Capital Improvement Budget, Manager shall be responsible for overseeing the development of conceptual plans (consistent with Lessee’s and Landlord’s objectives), shall arrange for preparation of specifications, coordinate and make all fabric, flooring, furniture and wall treatment selections (both colors and finishes), coordinate reselections and document all selections in specification books as required under the terms of the Franchise Agreement and coordinate all related franchise approvals, and will manage the applicable Franchisor process on approval of all selections relating to initial and final selections.

Architectural - Manager shall, if applicable, make recommendations of engagement of architects, negotiate architectural agreements on behalf of Lessee and Landlord (with Lessee’s and Landlord’s approval), manage all architects applicable to the implementation of the Capital Improvement Budget, oversee all conceptual designs and sketches, review all necessary plans, drawings, shop drawings and other matters necessary for the proper implementation of the Capital Improvement Budget, and coordinate and manage all approvals necessary for the implementation of the Capital Improvement Budget such as Franchisor approvals, governmental approvals and Holder approvals.

FF&E Purchasing - Manager shall be responsible for the evaluation of all specifications and negotiations of all prices associated with the purchasing of FF&E, shall manage and issue all purchase orders and place orders necessary for the proper and timely delivery of all FF&E.

FF&E Expediting/Freight Management - Manager shall be responsible for the expediting of all FF&E contemplated in an applicable Capital Improvement Budget including managing the freight selection and shipping process in a cost effective manner.

FF&E Warehousing - Manager shall be responsible, if applicable, for the management and coordination of all warehousing of goods delivered at the job site, inspection of materials delivered, and the filing of all claims associated with the delivery of defective or damaged goods.

FF&E Installation and Supervision - Manager shall be responsible for the management and oversight of the installation of all FF&E in compliance with specifications and Franchisor standards as required to implement the Capital Improvement Budget.

Manager shall be paid a project management fee (herein, the “Project Management Fee”) equal to four percent (4%) of the total project costs associated with the implementation of the Capital Improvement Budget (both hard and soft) payable monthly in arrears based upon the prior calendar month’s total expenditures under the Capital Improvement Budget until such time that the Capital Improvement Budget and/or renovation project involves the expenditure of an amount in excess of five percent (5%) of Gross Revenues of the applicable Hotel or Non-Managed Hotel, whereupon the Project Management Fee shall be reduced to three percent (3%) of the total project costs in excess of the five percent (5%) of Gross Revenue threshold. The Project Management Fee shall be accounted for and documented and consistent with the requirements of Section 11.02 herein. Any onsite or dedicated personnel required for the direct supervision of the implementation of a Capital Improvement Budget or other renovation project will be a direct cost to, and shall be reimbursed by, the Landlord.

Except as otherwise provided herein, in no event shall Manager realize any kick backs, rebates, cash incentives, administration fees, concessions, profit participations, investment rights or similar payments or economic consideration from or in, as applicable, vendors or suppliers of goods or services. Manager agrees that any such amounts or benefits derived shall be held in trust for the benefit of Lessee or Landlord (as applicable).

Any Market Service Fees for the Project Related Services shall be, once approved, reflected in the Capital Improvements Budget (such Market Service Fees subject to any adjustments necessary for then existing market conditions)

shall be submitted for approval to Lessee and Landlord with the applicable Capital Improvement Budget, and shall be deemed approved by the Lessee and Landlord unless a majority of the Independent Directors of AHP affirmatively vote that such Market Service Fees are not market (determined by reference to fees charged by third party providers who are not hotel managers or who are not discounting such fees as result of fees generated from other services) (herein called the “Approval Requirement”). In the event that the majority of the Independent Directors of AHP affirmatively votes that the Market Service Fees proposed by Manager are not market, the Lessee and Manager agree to engage a consultant reasonably satisfactory to both Lessee and Manager to provide then current market information with respect to the proposed Market Service Fees and a written recommendation as to whether such fees are market or not. If the consultant’s recommendation provides that such Market Service Fees as proposed by Manager are market, then the Landlord agrees to pay any consultant fees incurred by such consultant in making the recommendation. If the consultant’s recommendation does not support the Market Service Fees as proposed by Manager, then Manager agrees to pay the consultant’s fees incurred in connection with the recommendation and agrees to either re-submit Manager’s proposed Market Service Fees consistent with the market research and recommendation of the consultant for approval to Lessee and Landlord, or elect by Notice to Lessee and Landlord that Manager will not provide the Project Related Services. If Manager elects not to provide Project Related Services for a Non-Managed Hotel, no termination fee shall be payable by Lessee under Section 2.03(c) of this Agreement.

ARTICLE IX

EMPLOYEES

9.01 Employee Hiring. Manager will hire, train, promote, supervise, direct the work of and discharge all personnel working on the Premises. Manager shall be the sole judge of the fitness and qualification of such personnel and is vested with absolute discretion in the hiring, discharging, supervision, and direction of such personnel during the course of their employment and in the operation of the Premises.

9.02 Costs; Benefit Plans.

Manager shall fix the employees’ terms of compensation and establish and maintain all policies relating to employment, so long as they are reasonable and in accordance with the Applicable Standards and the Annual Operating Budget. Without limiting the foregoing, Manager may, consistent with the applicable budgets, enroll the employees of the Hotel in pension, medical and health, life insurance, and similar employee benefit plans (“Benefit Plans”) substantially similar to plans reasonably necessary to attract and retain employees and generally remain competitive. The Benefit Plans may be joint plans for the benefit of employees at more than one hotel owned, leased or managed by Manager or Manager Affiliate Entities. Employer contributions to such plans

(including any withdrawal liability incurred upon Termination of this Agreement) and reasonable administrative fees (but without further markup by Manager), which Manager may expend in connection therewith, shall be the responsibility of Lessee and shall be a Deduction. The administrative expenses of any joint plans will be equitably apportioned by Manager among properties covered by such plan.

Manager may elect to enroll employees in a medical and health Benefit Plan that is a self insured health plan (the “Plan”) without collection of any fee or profit to Manager or any Manager Affiliate Entity. The aggregate actual costs incurred by Manager in operating and managing the Plan shall be allocated on a pro rata basis by Manager among the properties covered by the Plan based on the number of members participating in the Plan, and such costs shall include, without limitation, the administration and payment of claims, costs and fees of third party administration and gateway or reference pricing services, and premiums for stop-loss insurance and reinsurance policies (collectively, the “Health Plan Costs”). Prior to the commencement of each Plan year, Manager shall in good faith establish premium levels for employee individual and family coverages based on relevant factors such as historic health service consumption by members participating in the Plan, participation in wellness programs, and the projected Health Plan Costs for the upcoming Plan year (the “Health Care Premiums”). The amount of employer contribution to Health Care Premiums for each employee at a Hotel shall be a Deduction for such Hotel, and Manager may periodically draw down from Gross Revenues for the Hotel the amount of such employer contribution to Health Care Premiums as same become payable under the terms of the Plan. Manager shall establish an account into which all Health Care Premiums for the Plan shall be deposited and out of which Health Plan Costs shall be paid (the “Plan Account”). Upon implementation of a Plan, Lessee shall initially fund into a reserve (the “Reserve Account”) a cash amount equal to fifteen percent (15%) of the estimated Health Plan Costs for the first Plan year allocable to the Hotels (the “Plan Reserve”). Thereafter, Lessee shall be responsible to maintain the level of the Plan Reserve in an amount not less than ten percent (10%) of the estimated Health Plan Costs allocable to the Hotels for the then current Plan year, as same may be adjusted from time to time during such Plan year (the “Minimum Plan Reserve Balance”). Manager may transfer funds (a) from the Plan Reserve to the Plan Account if and as reasonably necessary to maintain at all times sufficient amounts in the Plan Account to pay Health Plan Costs when due and payable, and (b) from the Plan Account to the Plan Reserve if Manager reasonably determines that the balance in the Plan Account (whether by deposit of Health Care Premiums or transfers from the Plan Reserve) exceeds that which is reasonably necessary to pay Health Plan Costs when due and payable. If in any Plan year the balance in the Plan Reserve falls below the Minimum Plan Reserve Balance, including by reason of transfers of funds to the Plan Account or an increase in the estimated Health Plan Costs allocable to the Hotels for the then current Plan year (the “Reserve Shortfall”), Lessee shall deposit into the Reserve Account the amount of the Reserve Shortfall within ten (10) days after receipt of Manager’s written request therefore. If Lessee fails to timely deposit the Reserve

Shortfall, Manager shall have the right (without affecting Manager’s other remedies under this Agreement) to draw down from Gross Revenues for the Hotels the amount of the Reserve Shortfall. If Gross Revenues are not sufficient to fund the Reserve Shortfall, Manager shall have the right to withdraw the amount of the Reserve Shortfall from the Operating Accounts, the Capital Improvements Reserves, Working Capital or any other funds of Lessee held by or under the control of Manager for the Hotels. If at any time the balance in the Plan Reserve exceeds twenty percent (20%) of the estimated Health Plan Costs allocable to the Hotels for the then current Plan year, as same may be adjusted from time to time during such Plan year, such excess amounts shall be returned to Lessee. Manager may elect in connection with the Plan to make contributions to health reimbursement accounts (HRA) or health savings accounts (HSA) maintained for the benefit of employees (“HRA/HSA Fundings”). In the event Manager makes HRA/HSA Fundings for employees at a Hotel, such HRA/HSA Fundings shall be a Deduction for such Hotel and shall be treated hereunder in the same manner as other Employee Costs and Expenses.

9.03 Manager’s Employees. It is expressly understood and agreed that all such personnel employed at the Hotel, including the Manager’s acting General Manager for the Hotel, will be the employees of Manager for all purposes including, without limitation, federal, state and local tax and reporting purposes, but the expense incurred in connection therewith will be a Deduction and for Lessee’s account. A General Manager’s compensation may be allocated to other Hotels on a fair and equitable basis if the General Manager oversees and supervises other Hotel operations. Manager shall use such care when hiring any employees as may be common to the hospitality business and consistent with the Manager’s standards of operation. Lessee acknowledges and agrees that Manager, as the employer of the Hotel’s employees, shall be entitled to all federal, state and/or local tax credits or benefits allowed to employers relating to the Hotel’s employees including, without limitation, the Work Opportunity Tax Credit, the Targeted Jobs Tax Credit, and similar tax credits (provided that Manager shall pay all incremental fees, if applicable, to qualify for such tax credits). Manager, in accordance with the Annual Operating Budget, may draw down from Gross Revenues all costs and expenses, of whatever nature, incurred in connection with such employees, including, but not limited to, wages, salaries, on-site staff, bonuses, commissions, fringe benefits, employee benefits, recruitment costs, workmen’s compensation and unemployment insurance premiums, payroll taxes, vacation and sick leave (collectively, “Employee Costs and Expenses”).

9.04 Special Projects - Corporate Employees. The costs, fees, compensation and other expenses of any persons engaged by Manager to perform duties of a special nature, directly related to the operation of the Premises, including, but not limited to, in-house or outside counsel, accountants, bookkeepers, auditors, employment search firms, marketing and sales firms, and similar firms of personnel, shall be operating expenses, payable from and consistent with the Annual Operating Budget and not the responsibility of the Manager. The costs, fees, compensation and other expenses of those personnel of Manager assigned to special projects for the Hotel shall also be operating expenses payable by the Lessee and not the responsibility of Manager. The daily per diem rate for those personnel shall be based upon the actual costs of Manager in providing its personnel for such special services or projects, without ▇▇▇▇-up for fee

or profit but including salary and employee benefit costs and costs of equipment used in performing such services, overhead costs, travel costs and long distance telephone. Such special services shall include, but not be limited to, those matters which are not included within the scope of the duties to be performed by Manager hereunder and, if not provided by Lessee, would involve the Lessee’s engagement of a third party to perform such services; for example, special sales or marketing programs, market reviews, assistance in opening new food and beverage facilities, legal services, accounting services, tax services, insurance services, data processing, engineering personnel, and similar services.

9.05 Termination. At Termination, subject to Section 2.01 above, Lessee shall reimburse Manager for costs and expenses incurred by Manager which arise out of either the transfer or termination of Manager’s employees at the Hotel, such as reasonable transfer costs, compensation in lieu of vacation and sick leave, severance pay (including a reasonable allowance for severance pay for Executive Employees of the Hotel, the amount of such allowance not to exceed an amount equal to Manager’s then current severance benefits for such terminated Executive Employees, unless Lessee otherwise approves), unemployment compensation, employer liability pursuant to the Consolidated Omnibus Budget Reconciliation Act (COBRA liability) and the Worker Adjustment and Retraining Notification Act (WARN Act) and other employment liability costs arising out of the termination of the employment of the Manager’s employees at the Premises (herein collectively called “Employee Related Termination Costs”). This reimbursement obligation shall not apply to any corporate personnel of Manager assigned to the Hotel for special projects or who perform functions for Manager at the corporate level. In order to be reimbursable hereunder, any Employee Related Termination Costs must be pursuant to policies of Manager which shall be consistent with those of other managers managing similar hotels in similar markets and geographical locations and which shall be subject to review and reasonable approval of Lessee from time to time upon Notice from Lessee and which review and approval shall occur no more than one time during each Fiscal Year during the term of this Agreement.

At Termination, an escrow fund shall be established from Gross Revenues (or, if Gross Revenues are not sufficient, with funds provided by Lessee) to reimburse Manager for all reimbursable Employee Related Termination Costs.

Employee Related Termination Costs shall include Health Plan Costs allocable to the Hotels that become payable under a Plan following a Termination. Manager shall be entitled to hold the balance of funds in the Plan Reserve to pay such Health Plan Costs as they become due for the following periods of time (the “Contingency Period”): (a) six (6) months following Termination with respect to Health Plan Costs relating to claims incurred prior to Termination, and eighteen (18) months following Termination with respect to COBRA liability (or such earlier date upon which there are no employees electing COBRA coverage relating to such Termination) (the “Contingent Costs”). In addition, in the event Manager reasonably determines that the balance of funds in the Plan Reserve is not sufficient to cover Manager’s estimate of Contingent Costs, Lessee shall deposit into the Plan Account on or before the date of Termination or following a Termination, within ten (10) days after receipt of Manager’s written request therefore, the amount that Manager reasonably determines is sufficient to cover Manager’s estimate of Contingent Costs (the “Contingent Shortfall”). If Lessee fails to timely

deposit the Contingent Shortfall, Manager shall have the right (without affecting Manager’s other remedies under this Agreement) to draw down from Gross Revenues for the Hotels the amount of the Contingent Shortfall. If Gross Revenues are not sufficient to fund the Contingent Shortfall, Manager shall have the right to withdraw the amount of the Contingent Shortfall from the Operating Accounts, the Capital Improvement Reserves, Working Capital or any other funds of Lessee held by or under the control of Manager for the Hotel(s). Following the expiration of the Contingency Period for a Termination of this Agreement in its entirety, any balance remaining in the Plan Reserve shall be returned to Lessee.

9.06 Employee Use of Hotel. Manager, in its discretion, may (i) provide lodging for Manager’s Executive Employees and corporate staff visiting the Hotel in connection with the performance of Manager’s services hereunder and allow them the use of the facilities of the Hotel, and (ii) provide the management of the Hotel with temporary living quarters within the Hotel and the use of all facilities of the Hotel, in either case at a discounted price or without charge, as the case may be. Manager shall, on a space available basis, provide lodging at the Hotel for Lessee’s employees, officers and directors visiting the Hotel and allow them the use of all facilities of the Hotel in either case without charge, except for recreational facilities for which a charge will apply.

9.07 Non-Solicitation. During the term of this Agreement and for a period of two (2) years thereafter, unless an Event of Default by Manager exists under this Agreement beyond applicable grace or cure periods, or the Agreement has been terminated as a result of an uncured Event of Default by Manager, Lessee agrees that it (and its Affiliates) will not, without the prior written consent of Manager, either directly or indirectly, alone or in conjunction with any other person or entity, (i) solicit or attempt to solicit any general manager (each a “General Manager” and, collectively, “General Managers”) of the Hotel or any other hotels managed by Manager or any of Manager’s Executive Employees (collectively, the General Manager and Executive Employees are herein called the “Key Employees”) to terminate, alter or lessen Key Employees’ employment or affiliation with Manager or to violate the terms of any agreement or understanding between any such Key Employee and Manager, as the case may be, or (ii) employ, retain, or contract with any Key Employee.

ARTICLE X

BUDGET, STANDARDS AND CONTRACTS

10.01 Annual Operating Budget. Not less than forty-five (45) days prior to the beginning of each Fiscal Year, Manager shall submit to Lessee for each Hotel, a budget (the “Annual Operating Budget”) setting forth in detail an estimated profit and loss statement for the next twelve (12) Accounting Periods, or for the balance of the Fiscal Year in the event of a partial first Fiscal Year, including a schedule of hotel room rentals and other rentals and a marketing and business plan for each Hotel, such budget to be substantially in the format of Exhibit “D” attached to the Addendum for such Hotel.

10.02 Budget Approval. The Annual Operating Budget submitted to Lessee by Manager shall be subject to the approval of Lessee (such approval not to be unreasonably withheld). The Annual Operating Budget shall not be deemed accepted by Lessee in the absence

of its express written approval. Not later than thirty (30) days after receipt by Lessee of a proposed Annual Operating Budget (or such longer period as Lessee may reasonably request on Notice to Manager), Lessee may deliver an AOB Objection Notice with reasonable detail to the Manager stating that Lessee objects to any information contained in or omitted from such proposed Annual Operating Budget and setting forth the nature of such objections with reasonable specificity. Failure of Lessee to deliver an AOB Objection Notice shall be deemed rejection of the Manager’s proposed Annual Operating Budget in its entirety. Upon receipt of any AOB Objection Notice, the Manager shall, after consultation with Lessee, modify the proposed Annual Operating Budget, taking into account Lessee’s objections, and shall resubmit the same to Lessee for Lessee’s approval within fifteen (15) days thereafter, and Lessee may deliver further AOB Objection Notices (if any) within fifteen (15) days thereafter (in which event, the re-submission and review process described above in this sentence shall continue until the proposed Annual Operating Budget in question is accepted and consented to by Lessee). Notwithstanding anything to the contrary set forth herein, Lessee shall have the right at any time subsequent to the acceptance and consent with respect to any Annual Operating Budget, on Notice to the Manager, to revise such Annual Operating Budget or to request that the Manager prepare for Lessee’s approval a revised Annual Operating Budget (with the approval of Manager, such approval not to be unreasonably withheld), taking into account such circumstances as Lessee deems appropriate; provided, however, that the revision of an Annual Operating Budget shall not be deemed a revocation of the Manager’s authority with respect to such actions as the Manager may have already taken prior to receipt of such revision notice in implementing a previously approved budget or plan. Lessee and Manager acknowledge and agree that the Annual Operating Budgets are merely forecasts of operating revenues and expenses for an ensuing year and shall be revised, by agreement of Lessee and Manager, from time to time as business and operating conditions shall demand. However, Manager shall use its reasonable best efforts to operate the Premises in accordance with the Annual Operating Budget. The failure of the Hotel to perform in accordance with such Annual Operating Budget shall not constitute a default by Manager of this Agreement, however, the Lessee has a right to terminate this Agreement with respect to a Subject Hotel if such Subject Hotel fails to satisfy the Performance Test as set forth in Section 2.03(c) above.

10.03 Operation Pending Approval. If the Annual Operating Budget (or any component thereof) has not yet been approved by Lessee prior to any applicable Fiscal Year, then, until approval of such Annual Operating Budget (or such component) by Lessee, Manager shall operate the Hotel substantially in accordance with the prior year’s Annual Operating Budget except for (a) those components of the Annual Operating Budget for the applicable Fiscal Year approved by Lessee, (b) the Necessary Expenses which shall be paid as required, (c) the Emergency Expenses which shall be paid as required, and (d) those expenses that vary in correlation with Gross Revenues and/or occupancy in the aggregate.

10.04 Budget Meetings. At each budget meeting and at any additional meetings during a Fiscal Year reasonably called by Lessee or Manager, Manager shall consult with Lessee on matters of policy concerning management, sales, room rates, wage scales, personnel, general overall operating procedures, economics and operation and other matters affecting the operation of the Hotel.

ARTICLE XI

OPERATING DISTRIBUTIONS

11.01 Management Fee. As consideration for the services to be rendered by Manager pursuant to this Agreement as manager and operator of the Premises, Manager shall be paid the following Base Management Fee and Incentive Management Fee (as such terms are hereinafter defined), collectively called the “Management Fee”, for each Hotel on a property by property basis as follows:

Base Management Fee. The base management fee (“Base Management Fee”) shall be equal to the greater of (i) $12,673.48 (to be increased annually based on any increases in CPI over the preceding annual period), or (ii) three percent (3%) of the Gross Revenues for each Accounting Period, to be paid monthly in arrears. If this Agreement shall commence or expire on other than the first and last day of a calendar month, respectively, the Base Management Fee shall be apportioned based on the actual number of days of service in the month.

Incentive Fee. The incentive fee (the “Incentive Fee”) shall be equal to the lesser of (i) one percent (1%) of Gross Revenues for each Fiscal Year and (ii) the amount by which the actual House Profit exceeds the Budgeted HP determined on a property by property basis (“HP Test”). The Incentive Fee shall be payable annually in arrears within ninety (90) days after the end of each Fiscal Year; provided, however, if based on actual operations and revised forecasts from time to time, it is reasonably anticipated that the Incentive Fee is reasonably expected to be earned for such Fiscal Year, Lessee shall reasonably consider payment of the Incentive Fee, pro-rata on a quarterly basis, within twenty (20) days following the end of each calendar quarter, subject to final adjustment within ninety (90) days following the end of the Fiscal Year.

11.02 Accounting and Interim Payment.

Manager shall submit monthly, pursuant to Section 15.02, an interim accounting to Lessee showing Gross Revenues, Deductions, House Profit, Gross Operating Profit and Net Operating Income before Debt Service.

Calculations and payments of the Base Management Fee made with respect to each Accounting Period shall be made on an interim accounting basis and shall be accounted for cumulatively for each Fiscal Year. After the end of each Fiscal Year, Manager shall submit to Lessee an accounting for such Fiscal Year, consistent with Section 15.03, which accounting shall be controlling over the interim accountings. Any adjustments required by the Fiscal Year accounting shall be made promptly by the parties.

The Incentive Fee shall only be calculated and earned based upon the House Profit achieving the required HP Test for any given Fiscal Year or a portion thereof if the period of calculation cannot include the full period from January 1 to December 31.

If Lessee raises no objection for any reason (excluding fraud) within one (1) year from the receipt of annual accounting statements as provided herein (or for fraud within any applicable statute of limitations period, and if no statute of limitations period exists, then in no event to exceed four (4) years from receipt of annual accounting statements as provided herein), such accounting shall be deemed to have been accepted by Lessee as true and correct, and Lessee shall have no further right to question its accuracy. Manager will provide Lessee profit and loss statements for the current period and year-to-date, including actual, budget and last year comparisons, as required by Section 15.03.

ARTICLE XII

INSURANCE

12.01 Insurance. Manager shall coordinate with Lessee, at all times during any period of development, construction, renovation, furnishing and equipping of the Premises, the procurement and maintenance in amount and scope as available and market for the hotel lodging industry for hotels of similar type and in similar markets and geographical locations as the Hotel, public liability and indemnity and property insurance with minimum limits of liability as required by Lessee, the Landlords, any Holder, or Franchisors, if applicable, to protect Lessee, Landlord, Manager, any Holder, and any Franchisor, if applicable, against loss or damage arising in connection with the development, construction, renovation, furnishing and equipping of the Premises (and pre-opening activities, if applicable), including, without limitation, the following:

12.01.1. Extended Coverage, Boiler, Business Interruption and Liability Insurance.

(a) Building insurance on the “Special Form” (formerly “All Risk” form) (including earthquake and flood in reasonable amounts as determined by Lessee) in an amount not less than 100% of the then “full replacement cost” thereof (as defined below) or such other amount which is acceptable to Lessee, and personal property insurance on the “Special Form” in the full amount of the replacement cost thereof;

(b) Insurance for loss or damage (direct and indirect) from steam boilers, pressure vessels or similar apparatus, now or hereafter installed in the Hotel, in the minimum amount of $5,000,000 or in such greater amounts as are then customary or as may be reasonably requested by Lessee from time to time;

(c) Loss of income insurance on the “Special Form”, in the amount of one year of the sum of Base Rent plus Percentage Rent (as such terms are defined in and as determined pursuant to the Leases) for the benefit of Landlords, and business interruption insurance on the “Special Form” in the amount of one year of Gross Operating Profit, for the benefit of Lessee. All loss of income insurance proceeds shall be part of Gross Revenues;

(d) Commercial general liability insurance, with amounts not less than $1,000,000 combined single limit for each occurrence and $2,000,000.00 for the aggregate of all occurrences within each policy year, as well as excess liability (umbrella) insurance with

limited of at least $35,000,000 per occurrence, covering each of the following: bodily injury, death, or property damage liability per occurrence, personal and advertising injury, general aggregate, products and completed operations, and “all risk legal liability” (including liquor law or “dram shop” liability if liquor or alcoholic beverages are served at the Hotel);

(e) Automobile insurance on vehicles operating in conjunction with the Hotel with limits of liability of at least $1,000,000.00 combined, single limit coverage; and

(f) Insurance covering such other hazards and in such amounts as may be customary for comparable properties in the area of the Hotel and is available from insurance companies, insurance pools or other appropriate companies authorized to do business in the State where the Hotel is located at rates which are economically practicable in relation to the risks covered as may be reasonably requested by Lessee and otherwise consistent with the costs allocated therefor in the Annual Operating Budget.

12.01.2. Operational Insurance.

(a) Workers’ compensation and employer’s liability insurance as may be required under Legal Requirements and as Manager may deem reasonably prudent covering all of Manager’s employees at the Premises, with such deductible limits or self-insured retentions as may be reasonably established from time to time by Manager;

(b) Fidelity bonds, with limits and deductibles as may be reasonably requested by Lessee, covering Manager’s employees in job classifications normally bonded under prudent hotel management practices in the United States or otherwise required by law; and

(c) Such other insurance in amounts as Manager in its reasonable judgment deems advisable for its protection against claims, liabilities and losses arising out of or connected with its performance under this Agreement, and otherwise consistent with the costs allocated therefor in the Annual Operating Budget.

12.02 Replacement Cost. The term “full replacement cost” as used herein shall mean the actual replacement cost of the Hotel requiring replacement from time to time including an increased cost of construction endorsement, if available, and the cost of debris removal. In the event either party to this Agreement believes that full replacement cost (the then-replacement cost less such exclusions) has increased or decreased at any time during the Term, it shall have the right to have such full replacement cost re-determined.

12.03 Increase in Limits. If either party to this Agreement at any time deems the limits of the personal injury or property damage under the comprehensive commercial general liability insurance then carried to be either excessive or insufficient, such parties shall endeavor in good faith to agree on the proper and reasonable limits for such insurance to be carried and such insurance shall thereafter be carried with the limits thus agreed on until further change pursuant to the provisions of this Section.

12.04 Blanket Policy. Notwithstanding anything to the contrary contained in this Article XII, Manager may include the insurance required hereunder within the coverage of a so-called blanket policy or policies of insurance carried and maintained by Manager; provided, however, that the coverage afforded to the parties as required herein will not be reduced or diminished or otherwise be different from that which would exist under a separate policy meeting all other requirements of this Agreement by reason of the use of such blanket policy of insurance, and provided further that the requirements of this Article XII are otherwise satisfied.

12.05 Costs and Expenses. Insurance premiums and any costs or expenses with respect to the insurance, including, without limitation, agent’s and consultant’s costs used to place insurance or adjust claims, shall be Deductions. Premiums on policies for more than one year shall be charged pro-rata against Gross Revenues over the period of the policies and to the extent, through blanket policies, cover other hotels managed by Manager or owned by Lessee or any of its Affiliates, shall be allocated based on rooms, number of employees, values or other methods as determined to be reasonable by Manager and Lessee. Any reserves, losses, costs, damages or expenses which are uninsured, self-insured, or fall within deductible limits shall be treated as a cost of insurance and shall be Deductions, subject to Article XXV.

12.06 Policies and Endorsements.

Where permitted, all insurance provided for under this Article XII shall name Lessee as insured, and Manager, any Holder, the Landlords, and, if required, the Franchisors, as additional insureds. The party procuring such insurance shall deliver to the other party certificates of insurance with respect to all policies so procured, including existing, additional and renewal policies and, in the event of insurance about to expire, shall deliver certificates of insurance with respect to the renewal policies not less than ten (10) days prior to the respective dates of expiration.

All policies of insurance provided for under this Article XII shall, to the extent obtainable, be with insurance companies licensed or authorized to do business in the state in which the Premises are located, with a minimum rating of A or better in the Best’s Insurance Guide and an S&P rating of at least A+V (or such higher rating if so required by any Holder, Landlord or Franchisor), and shall have attached thereto an endorsement that such policy shall not be cancelled or materially changed without at least thirty (30) days’ (and for Texas Hotels, ten (10) days’) prior written notice to Lessee. All insurance policies obtained pursuant to this Article XII shall contain a standard waiver of subrogation endorsement.

12.07 Termination. Upon Termination of this Agreement, an escrow fund in an amount reasonably acceptable to Manager shall be established from Gross Revenues (or, if Gross Revenues are not sufficient, with funds provided by Lessee) to cover the amount of any costs which, in Manager’s reasonable business judgment, will likely need to be paid by either Lessee or Manager with respect to pending or contingent claims, including those which arise after Termination for causes arising during the Term of this Agreement. Upon the final disposition of

all such pending or contingent claims, any unexpended funds remaining in such escrow shall be paid to Lessee.

ARTICLE XIII

TAXES AND DEBT SERVICE

13.01 Taxes.

(a) All real estate and ad valorem property taxes, assessments and similar charges on or relating to the Premises during the Term of this Agreement shall be paid by Manager, on behalf of Lessee, before any fine, penalty, or interest is added thereto or lien placed upon the Premises, unless payment thereof is stayed. All such payments shall be reserved and paid from Gross Revenues and treated as Deductions in determining Net Operating Income. Gross Revenues reserved for such purposes shall be placed in an escrow account or accounts established pursuant to the requirements of any applicable Holder. Interest earned in said account attributable to funds deposited pursuant to this Agreement shall be added to such reserve, thereby reducing the amount required to be placed in the account from Gross Revenues.

(b) Notwithstanding the foregoing, upon Lessee’s request, Manager shall, as a Deduction, contest the validity or the amount of any such tax or assessment. Lessee agrees to cooperate with Manager and execute any documents or pleadings required for such purpose, provided that Lessee is satisfied that the facts set forth in such documents or pleadings are accurate and that such execution or cooperation does not impose any unreasonable obligations on Lessee, and Lessee agrees to reimburse Manager as a Deduction for all expenses occasioned to Manager by any such contest, provided that such expenses shall be approved by Lessee prior to the time that they are incurred.

13.02 Debt Service; Ground Lease Payments. In the event of a Hotel Mortgage and/or Ground Lease and upon direction of Lessee, Manager shall establish an account (the “Property Service Account”) to pay Debt Service and/or Ground Lease Payments in such periodic payments as required by any applicable Holder under any applicable Hotel Mortgage and/or landlord under any Ground Lease. The Property Service Account shall be funded by Landlord under the Lease from funds paid by Landlord to Lessee. In the event sufficient funds are unavailable for the payment of Debt Service and/or Ground Lease Payments from the Property Service Account, then Manager shall notify Lessee in writing of such insufficiency who shall in turn advise the Landlord under the applicable Lease to replenish the Property Service Account to provide funds for payment of Debt Service and/or Ground Lease Payments.

ARTICLE XIV

BANK ACCOUNTS

All funds made available to Manager by Lessee for operations of the Premises, exclusive of those amounts described in Article VIII, shall be deposited into a banking checking account or accounts to be established in the name of Lessee (the “Operating Account”), consistent with the requirements of any Cash Management Agreements, if any. The Operating Account shall be interest bearing when possible. Subject to the limitation of Manager’s authority

set forth herein, both Manager and Lessee shall be authorized to withdraw funds from said Operating Account, except that Lessee may withdraw funds from said account only if an Event of Default by Manager has occurred under this Agreement or an event has occurred that with the passage of time might be an Event of Default by Manager. Prior to any such withdrawal by Lessee, Lessee shall provide Notice of same to Manager, and Manager shall not be liable to Lessee for any checks written by Manager for operating expenses which are returned due to insufficient funds caused by such Lessee withdrawal. From time to time both Manager and Lessee shall designate signatory parties on such account and shall provide written notice of such designation or change in designation to the other party, and the signatures of such persons shall be formally and expressly recognized by the bank in which such account or accounts are maintained. The bank or banks to be utilized shall be selected and approved by Lessee and Manager. All monies received shall be deposited in, including, but not limited to, Gross Revenues, and expenses paid, including, but not limited to, Deductions, shall be paid from such bank checking account(s) except that Manager shall have the right to maintain payroll and ▇▇▇▇▇ cash funds and to make payments therefrom as the same are customary and utilized in the lodging business. Such funds shall not be commingled with Manager’s funds. Lessee shall have the right, at its expense, to audit said account or accounts at any reasonable time.

Manager may establish one or more separate bank accounts for handling payroll costs in the name of Lessee. Such accounts shall be in a bank selected by Manager and approved by Lessee, and shall be handled exclusively by the individuals designated by Manager and approved in writing by Lessee. Funds shall be deposited in the payroll account or accounts from the Operating Account, as needed, in order to meet payroll requirements.

Until otherwise prescribed by Lessee in writing, the Operating Account shall be under the control of Manager, without prejudice, however, to Manager’s obligation to account to Lessee as and when provided herein. All receipts and income, including without limitation, Gross Revenues shall be promptly deposited in the Operating Account. Checks or other documents of withdrawal shall be signed only by the individual representatives of Manager approved in writing by Lessee and duly recognized for such purpose by the bank or banks in which the referenced accounts are maintained. Manager shall supply Lessee with fidelity bonds or other insurance insuring the fidelity of authorized signatories to such accounts, unless said bonds or other insurance shall have been placed by Lessee and delivered directly by the bonding or insurance company to Lessee. The cost of such fidelity bonds or other insurance shall be a Deduction, at Lessee’s expense, and subject to Lessee’s approval. Neither Lessee nor Manager shall be responsible for any losses occasioned by the failure or insolvency of the bank or banks in which the referenced accounts are maintained. Upon expiration or termination of this Agreement for the Hotel and the payment to Manager of all amounts due Manager hereunder upon such expiration or termination, as provided in this Agreement, all remaining amounts in the referenced accounts shall be transferred forthwith to Lessee, or made freely available to Lessee.

Manager shall not be required to advance funds, and Manager shall not be obligated to incur any liability or obligation for Lessee’s account, without assurance that necessary funds for the discharge thereof will be provided by Lessee.

All reserve accounts established pursuant to this Agreement shall be placed in segregated interest-bearing accounts in the name of Lessee which interest shall be added to such reserve and serve to reduce the amount required to be placed in such reserve account.

ARTICLE XV

ACCOUNTING SYSTEM

15.01 Books and Records. Manager shall maintain an adequate and separate accounting system in connection with its management and operation of the Premises. The books and records shall be kept in accordance with GAAP and the Uniform System of Accounts (to the extent consistent with GAAP) and shall be maintained at all times either on the Premises, at the principal office of the Manager, or in storage, for at least three (3) years after the Fiscal Year to which the books and records relate. Lessee, the beneficial owners of Lessee, the Landlords (to the extent permitted under the Leases), any Holder (to the extent permitted under the Hotel Mortgage), any Franchisor (to the extent permitted under any applicable Franchise Agreement), or their respective employees or duly authorized agents, shall have the right and privilege of examining and inspecting the books and records at any reasonable time. Upon termination of this Agreement for a Hotel, all such books and records shall be turned over to Lessee so as to insure the orderly continuance of the operation of the Hotel; provided however, that all such books and records thereafter shall be available to Manager at the Hotel at all reasonable times for inspection, audit, examination and copying for a period of three (3) years.

15.02 Monthly Financial Statements. Within twenty-five (25) days following each Accounting Period, Manager shall furnish Lessee with respect to the Hotel an accrual basis balance sheet on Manager’s standard format in reasonable detail, together with a reasonably detailed accrual basis profit and loss statement for the calendar month next preceding and with a cumulative calendar year accrual basis profit and loss statement to date, including a comparison to the Annual Operating Budget and the Capital Improvements Budget and a statement of cash flows for each monthly and cumulative period for which a profit and loss statement is prepared. Further, from time to time as reasonably requested by Lessee, Manager shall provide a statement of bank account balances, an allocation to reserve accounts, a sources and uses statement, a narrative discussing any of the aforementioned reports and material variances from the Annual Operating Budget and the Capital Improvements Budget, such other reports and financial statements as Lessee may reasonably request and as are customarily provided by managers of similar hotel properties in the area of the Hotel without Manager receiving additional fees to provide same.

15.03 Annual Financial Statements. Within forty-five (45) days after the end of each Fiscal Year, Manager shall furnish to Lessee year-end financial statements for the Hotel (including a balance sheet, income statement and statement of sources and uses of funds) which statements shall be unaudited and shall be prepared in accordance with GAAP and the Uniform System of Accounts (to the extent consistent with GAAP). Lessee will engage an independent national certified public accounting firm with hospitality experience and reasonably acceptable to Lessee to provide audited annual financial statements. Manager shall cooperate in all respects with such accountant in the preparation of such statements, including the delivery of any

financial information generated by Manager pursuant to the terms of this Agreement and reasonably required by the Lessee’s accountant to prepare such audited financial statements.

ARTICLE XVI

PAYMENT BY LESSEE

16.01 Payment of Base Management Fee. On the fifth (5th) day of each month during the term of this Agreement, Manager shall be paid out of the Operating Account, the Base Management Fee for the preceding Accounting Period, as determined from the books and records referred to in Article XV.

16.02 Distributions. Subject to retention of Reasonable Working Capital (including any amounts as required by the Capital Improvement Budget) and retention of such reserves as may be required under any Hotel Mortgage and/or Ground Lease, as applicable, Manager shall deliver to Lessee from the Operating Account, any excess Working Capital for the preceding Accounting Period on the 25th day of the following month, and such amounts of Lessee’s money in the possession or under the control of Manager as Lessee shall from time to time request. For purposes of this Article “Reasonable Working Capital” shall mean an amount reasonably determined by Manager at the same time as the monthly financial statements are prepared pursuant to Section 15.02 hereof, but in no event to exceed a sum equal to a ratio of current assets to current liabilities of 2:1 (but excluding from such calculation cash restricted or unavailable under any Cash Management Agreement).

16.03 Payment Option. Management Fees shall be paid in cash, except that subject to the requirements of Section 5.02.6 and Section 28.08 Manager may request, no later than thirty (30) days prior to the payment due date, by Notice to Lessee (such request to be subject to the approval of a majority of the Independent Directors of AHP, in their sole discretion, and to any applicable restrictions of a national securities exchange (including NASDAQ NMS and NASDAQ Small Cap) and to federal and state securities laws), payment of up to one-third (1/3^rd) of its Base Management Fee and up to one hundred percent (100%) of its Incentive Fee, in the form of shares of common stock of AHP priced at the “Strike Price,” or in the form of stock options priced in accordance with the “Black-Scholes Model” (the “Payment Option Request”), as follows:

Common Stock at “Strike Price”. The number of shares of common stock of AHP to be issued in lieu of the applicable Base Management Fees and/or Incentive Fee as noted in the Payment Option Request (the “Designated Fees”) shall be based upon the “Strike Price” of such common stock determined as follows: The term “Strike Price” shall be and mean the amount obtained (rounded upward to the next highest cent) by determining the simple average of the daily closing price of the common stock of AHP for the twenty (20) trading days ending on the last trading day of the calendar week immediately preceding the applicable payment due date on the New York Stock Exchange or, if the shares of such common stock are not then being traded on the New York Stock Exchange, then on the principal stock exchange (including without limitation NASDAQ NMS or NASDAQ Small Cap) on which such common stock is then

listed or admitted to trading as determined by AHP or, if such common stock is not then so listed or admitted to trading the average of the last reported closing bid and asked prices on such days in the over-the-counter market or, if no such prices are available, the fair market value per share of such common stock, as determined by a majority of the Independent Directors of AHP in their sole discretion. The Strike Price shall not be subject to any adjustment as a result of the issuance of any additional shares of common stock by AHP for any purpose, except for stock splits (whether accomplished by stock dividends or otherwise) or reverse stock splits occurring during the 20 trading days referenced in the calculation of the Strike Price. Upon determination of the Strike Price for such common stock (and provided payment in the form of common stock has been approved by the board of directors of AHP), AHP agrees to issue to Manager the number of shares of common stock in AHP determined by dividing the Designated Fees by the Strike Price per share of common stock, and any balance remaining shall be paid to Manager in cash.

Options based on Black-Scholes Model. The number of stock options to be issued in lieu of the Designated Fees shall be based upon the “Black-Scholes Model” as follows: The term “Black-Scholes Model” means the Black-Scholes model for valuing the “fair value” of an option calculated based on historical data and calculated probabilities of future stock prices, reasonably applied. Upon determination of the value of an option on the date such options are to be issued, as determined using the Black-Scholes Model (the “Black-Scholes Amount”), provided payment in the form of options has been approved by the board of directors of AHP, AHP agrees to issue to Manager the number of options for common stock of AHP determined by dividing the Designated Fees by the Black-Scholes Amount per option, and any balance remaining shall be paid to Manager in cash. The “Strike Price” for any option (which must be exercised within ten (10) years of issuance), shall have the meaning of the term “Strike Price” as used in subparagraph A above.

ARTICLE XVII

RELATIONSHIP AND AUTHORITY

Lessee and Manager shall not be construed as partners, joint venturers or as members of a joint enterprise and neither shall have the power to bind or obligate the other except as set forth in this Agreement. Nevertheless, Manager is granted such authority and power as may be reasonably necessary for it to carry out the provisions of this Agreement. This Agreement, either alone or in conjunction with any other documents, shall not be deemed to constitute a lease of any portion of the Premises. Nothing contained herein shall prohibit or restrict Manager or any affiliate of Manager from operating, owning, managing, leasing or constructing any hotel of any nature or description which may in any manner compete with that of the Premises, except as otherwise set forth in the Mutual Exclusivity Agreement; provided that Manager agrees to comply with the conflicts policies of AHP. Except as otherwise expressly provided in this Agreement, (a) all debts and liabilities to third persons incurred by Manager in the course of its operation and management of the Hotel in accordance with the

provisions of this Agreement shall be the debts and liabilities of Lessee only, and (b) Manager shall not be liable for any such obligations by reason of its management, supervision, direction and operation of the Hotel as agent for Lessee. Manager may so inform third parties with whom it deals on behalf of Lessee and may take any other reasonable steps to carry out the intent of this paragraph.

ARTICLE XVIII

DAMAGE, CONDEMNATION AND FORCE MAJEURE

18.01 Damage and Repair. If, during the Term hereof, a Hotel is damaged or destroyed by fire, casualty, or other cause, Lessee shall, subject to the requirements of the applicable underlying Lease, repair or replace the damaged or destroyed portion of the Hotel to the same condition as existed previously. In the event the underlying Lease relating to such damaged Hotel is terminated pursuant to the provisions of such Lease, Lessee may terminate this Agreement with respect to such Hotel upon sixty (60) days’ Notice from the date of such damage or destruction, in which case this Agreement shall then terminate with respect to such Hotel sixty (60) days from the date of such notice and neither party shall have any further rights, obligations, liabilities or remedies one to the other hereunder with respect to such Hotel, except as otherwise provided in Article II (provided that no termination fees shall be payable by Lessee pursuant to Article II) and Section 18.04. If this Agreement remains in effect with respect to such damaged Hotel and the damage does not result in a reduction of Gross Revenues at such Hotel, the Management Fee will be unabated. If however, this Agreement remain in effect with respect to such Hotel, but the damage does result in a reduction of Gross Revenues at such Hotel, Lessee shall be entitled to partial, pro rata abatement with respect to the Management Fee until such time as such Hotel is restored.

18.02 Condemnation.

In the event all or substantially all of a Hotel shall be taken in any eminent domain, condemnation, compulsory acquisition, or similar proceeding by any competent authority for any public or quasi-public use or purpose, this Agreement shall terminate with respect to such Hotel, subject to the requirements of the applicable underlying Lease. However, in any event of such termination, Lessee shall give Manager at least fifteen (15) days prior Notice of such termination. In the event of such termination, neither party shall have any further rights, remedies, obligations or liabilities one to the other hereunder with respect to such Hotel except as otherwise provided in Article II above (provided that no termination fees shall be payable by Lessee pursuant to Article II).

If a portion of the Premises shall be taken by the events described in Section 18.02A or the entire Premises are temporarily affected, the result of either of which is not to make it, in the reasonable business judgment of Lessee, unreasonable to continue to operate the applicable Hotel, subject to the requirements of the applicable underlying Lease, this Agreement shall not terminate with respect to such Hotel. However, so much of any award for any such partial taking or condemnation shall be made available to the extent

necessary to render the applicable Premises equivalent to its condition prior to such event and the balance shall be paid to Lessee or the Holder, if required by any Hotel Mortgage covering the Premises.

18.03 Force Majeure. If an event of Force Majeure directly involves a Hotel and has a significant adverse effect upon the continued operations of such Hotel, then Lessee shall be entitled to terminate this Agreement with respect to the applicable Hotel by written Notice within sixty (60) days from the date of such Force Majeure, and this Agreement shall then terminate with respect to the applicable Hotel sixty (60) days from such notice, in which event neither Lessee nor Manager shall have any further rights, remedies, obligations or liabilities, one to the other, hereunder, with respect to the applicable Premises except as otherwise provided in Article II (provided that no termination fees shall be payable by Lessee pursuant to Article II).

18.04 Liquidated Damages if Casualty.

Omitted.

Casualty of a Hotel. Notwithstanding anything contained in this Agreement to the contrary, if any Hotel is damaged pursuant to a casualty as set forth in Section 18.01 hereof within the first year of the initial 10-year term for such Hotel, and Lessee elects, for any reason, not to rebuild such Hotel, Lessee agrees to pay Manager (provided there does not then exist an Event of Default by Manager beyond any applicable cure periods), a termination fee, if any, that would be owed if such hotel were then sold, as set forth in Section 2.03(a)(i) above. However, if after the first year of the initial 10-year term for a Hotel, such Hotel is damaged and Lessee elects not to rebuild such hotel even though sufficient casualty proceeds are available to do so, then Lessee will pay to Manager a termination fee (provided there does not then exist an Event of Default by Manager beyond any applicable cure periods), equal to the product obtained by multiplying (i) 65% of the aggregate Base Management Fee and Incentive Fee estimated to be paid Manager budgeted in the Annual Operating Budget applicable to such Hotel (but in no event less than the Base Management Fee and Incentive Fee for the preceding full Fiscal Year) by (ii) nine (9).

Payment of the termination fees set forth in this Section 18.04 shall be subject to Section 2.03(d) above with respect to liquidated damages.

18.05 No Liquidated Damages if Condemnation or Force Majeure. No liquidated damages shall be payable in the event of a condemnation relating to a Hotel, provided that Manager shall be entitled to seek recovery from the condemning authority for its loss of contract and this Agreement shall not terminate for that purpose. No liquidated damages shall be payable by Lessee as a result of its termination of this Agreement as to a Hotel pursuant to Section 18.03 (Force Majeure).

ARTICLE XIX

DEFAULT AND TERMINATION

19.01 Events of Default. The following shall constitute events of default (each an “Event of Default”):

The filing of a voluntary petition in bankruptcy or insolvency or a petition for reorganization under any bankruptcy law by Lessee or Manager;

The entering of an order, judgment or decree by any court of competent jurisdiction, on the application of a creditor, adjudicating Lessee or Manager as bankrupt or insolvent, or approving a petition seeking reorganization or appointing a receiver, trustee, or liquidator of all or a substantial part of such party’s assets, and such order, judgment or decree continues unstayed and in effect for any period of ninety (90) days or more;

The appointment of a receiver for all or any substantial portion of the property of Lessee or Manager;

The failure of Lessee or Manager to make any payment required to be made in accordance with the terms of this Agreement within ten (10) days after receipt of Notice, specifying said default with reasonable specificity, when such payment is due and payable; or

The failure of Lessee or Manager to perform, keep or fulfill any of the other covenants, undertakings, obligations or conditions set forth in this Agreement, and the continuance of such default for a period of thirty (30) days after written notice of said failure; provided, however, if such default cannot be cured within such thirty (30) day period and Lessee or Manager, as the case may be, commences to cure such default within such thirty (30) day period and thereafter diligently and expeditiously proceeds to cure the same, such thirty (30) day period shall be extended so long as it shall require Lessee or Manager, as the case may be, in the exercise of due diligence to cure such default, it being agreed that no such extension (including the original 30 day cure period) shall be for a period in excess of one hundred twenty (120) days.

The Manager does not qualify as an Eligible Independent Contractor.

19.02 Consequence of Default. Upon the occurrence of any Event of Default, the non-defaulting party may give the defaulting party Notice of intention to terminate this Agreement (after the expiration of any applicable grace or cure period provided in Section 19.01), and upon the expiration of thirty (30) days from the date of such notice, this Agreement shall terminate, whereupon the non-defaulting party shall be entitled to pursue all of its rights and remedies, at

law or in equity, under this Agreement (including, without limitation, any indemnity obligations which shall survive termination of this Agreement) and any other rights and remedies available under Legal Requirements except as otherwise expressly limited by the terms of Article II. Notwithstanding the foregoing, in the event that an Event of Default is applicable to one or more of the Hotels but not all of the Hotels, such termination shall only be as to such applicable Hotel(s).

ARTICLE XX

WAIVER AND INVALIDITY

20.01 Waiver. The failure of either party to insist upon a strict performance of any of the terms or provisions of this Agreement or to exercise any option, right or remedy herein contained, shall not be construed as a waiver or as a relinquishment for the future of such term, provision, option, right or remedy, but the same shall continue and remain in full force and effect. No waiver by either party of any term or provision hereof shall be deemed to have been made unless expressed in writing and signed by such party.

20.02 Partial Invalidity. In the event that any portion of this Agreement shall be declared invalid by order, decree or judgment of a court, this Agreement shall be construed as if such portion had not been inserted herein except when such construction would operate as an undue hardship on the Manager or Lessee or constitute a substantial deviation from the general intent and purpose of said parties as reflected in this Agreement, in which event it shall be terminated.

ARTICLE XXI

ASSIGNMENT

Subject to the requirements of any Hotel Mortgage, Franchise Agreement, Ground Lease or any of the Leases, neither party shall assign or transfer (by operation of law or otherwise) or permit the assignment or transfer of this Agreement without the prior written consent of the other (which may be withheld in its sole discretion) and any such prohibited assignment or transfer shall be null and void; provided, however, that Manager shall have the right, without such consent, to assign its interest in this Agreement to any “Manager Affiliate Entity”, provided such Manager Affiliate Entity qualifies as an Eligible Independent Contractor as of the date of such transfer. The term “Manager Affiliate Entity” shall mean any entity controlled directly or indirectly by (i) ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇. and/or ▇▇▇▇▇ ▇▇▇▇▇▇▇, (ii) family partnerships or trusts (the sole members or beneficiaries of which are at all times lineal descendants of ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇. or ▇▇▇▇▇ ▇▇▇▇▇▇▇ (including step-children) and spouses of any of the foregoing), or (iii) by lineal descendants of ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇. or ▇▇▇▇▇ ▇▇▇▇▇▇▇ (including step-children) and spouses of any of the foregoing. For purposes hereof, “controlled” shall mean (i) the possession, directly or indirectly of a majority of the voting power and capital stock or ownership interest of such entity, or (ii) the power to direct or cause the direction of the management and policies of such entity in the capacity of chief executive officer, president, chairman, or other similar capacity where they are actively engaged and/or involved in providing such direction or control and spend a substantial amount of time managing such entity. Any such permitted assignee shall be deemed to be the Manager for purposes of this Agreement

provided such assignee assumes all of Manager’s future obligations under this Agreement pursuant to an assumption agreement reasonably acceptable to Lessee. Any and all such assignments, however, shall at all times be subject to the prior right, title and interest of Lessee with respect to the Premises. An assignment by Manager or any permitted assignee of its interest in this Agreement, shall not relieve Manager or any such permitted assignee, as the case may be, from their respective obligations under this Agreement, and shall inure to the benefit of, and be binding upon, their permitted successors and assigns. For purposes of this Article XXI any change in the ownership of the Manager or other event that would cause the Manager to fail to be a Manager Affiliate Entity shall be deemed to be a transfer of this Agreement, prohibited by this Article XXI unless first consented to in writing by Lessee.

ARTICLE XXII

NOTICES

All notices, demands, elections, or other communications that any party this Agreement may desire or be required to be given hereunder shall be in writing and shall be given by hand, by depositing the same in the United States mail, first class, postage prepaid, certified mail, return receipt requested, or by a recognized overnight courier service providing confirmation of delivery, to the addresses set forth below, or at such address as may be designated by the addressee upon written notice to the other party, (herein called “Notice”).


To Lessee:		Ashford Prime TRS Corporation (or its specified designee set forth in an Addendum)
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇
		▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: Chief Financial Officer
		Fax: (▇▇▇) ▇▇▇-▇▇▇▇

With a copy to:		Ashford Hospitality Prime Limited Partnership
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇
		▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: General Counsel
		Fax: (▇▇▇) ▇▇▇-▇▇▇▇

To Manager:		Remington Lodging & Hospitality, LLC
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇
		▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: ▇▇▇▇▇ ▇▇▇▇▇▇▇
		Fax: (▇▇▇) ▇▇▇-▇▇▇▇


With a copy to:		Remington Lodging & Hospitality, LLC
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇
		▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: Legal Department
		Fax: (▇▇▇) ▇▇▇-▇▇▇▇

To the Landlords:		c/o Ashford Hospitality Prime Limited Partnership
		▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇
		▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
		Attn: General Counsel
		Fax: (▇▇▇) ▇▇▇-▇▇▇▇

All notices given pursuant to this Article XXII shall be deemed to have been given (i) if delivered by hand on the date of delivery or on the date that delivery was refused by the addressee, or (ii) if delivered by certified mail or by overnight courier, on the date of delivery as established by the return receipt or courier service confirmation (or the date on which the return receipt or courier service confirms that acceptance of delivery was refused by the addressee).

ARTICLE XXIII

SUBORDINATION; NON-DISTURBANCE

23.01 Subordination. This Agreement shall be subject and subordinate to any Hotel Mortgage and Lease, and Manager agrees to enter into a lender-manager or landlord-manager (as applicable) agreement with respect to each Hotel, which agreement shall contain reasonable provisions, including, without limitation, Manager’s acknowledgment that its real estate interest in and to the applicable Hotel, if any, created by this Agreement is subject and subordinate to the applicable Hotel Mortgage or Lease, including providing any purchaser of such Hotel at a foreclosure sale or deed-in-lieu of foreclosure, including the Holder, with the right to terminate this Agreement with respect to the applicable Hotel; provided, however, in no event will Manager agree to subordinate or waive its right to receive fees, reimbursements or indemnification payments under this Agreement arising prior to termination (but (a) if this Agreement is terminated by the Holder or such purchaser or Landlord (or its assignee) with respect to such Hotel, Manager shall not look to the Holder for payment of such fees, reimbursements or indemnification payments and Manager’s right to receive such fees, reimbursements or indemnification payments shall be subordinated to the Holder’s rights and (b) if this Agreement is not terminated by the Holder or such purchaser with respect to such Hotel, then such fees, reimbursements or indemnification payments shall be payable by the Holder or such purchaser). Notwithstanding the foregoing, Manager shall in no event be obligated to perform its duties hereunder without payment and/or reasonable assurance of payment of such fees, reimbursements or indemnification payments.

23.02 Non-Disturbance Agreement. Notwithstanding Section 23.01, Lessee agrees that, prior to obtaining any Hotel Mortgage or executing any Lease, Lessee will use its commercially reasonable efforts to obtain from each prospective Holder or Landlord (as applicable), a Non-Disturbance Agreement pursuant to which Manager’s rights under this Agreement will not be

disturbed as a result of a default stemming from non-monetary factors which (i) relate to Lessee and do not relate solely to the applicable Hotel, and (ii) are not defaults by Manager under Section 19.01 of this Agreement. If Lessee desires to obtain a Hotel Mortgage or to execute a Lease, Manager, on written request from Lessee, shall promptly identify those provisions in the proposed Hotel Mortgage or Lease documents which fall within the categories described in clauses (i) and (ii) above, and Manager shall otherwise assist in expediting the preparation of an agreement between the prospective Holder and/or Landlord and Manager which will implement the provisions of this Section 23.02.

ARTICLE XXIV

PROPRIETARY MARKS; INTELLECTUAL PROPERTY

24.01 Proprietary Marks. During the Term of this Agreement, the name “Remington,” whether used alone or in connection with other another word(s), and all proprietary marks (being all present and future trademarks, trade names, symbols, logos, insignia, service marks, and the like) of Manager or any one of its Manager Affiliate Entities, whether or not registered (“Proprietary Marks”) shall in all events remain the exclusive property of Manager and its Manager Affiliate Entities. Lessee shall have no right to use any Proprietary ▇▇▇▇, except during the term of this Agreement to have signage installed using any Proprietary ▇▇▇▇ in conformance with the specifications provided by Manager. Upon Termination, any use of a Proprietary ▇▇▇▇ by Lessee under this Agreement shall immediately cease. Upon Termination, Manager shall have the option to purchase, at their then book value, any items of the applicable Hotel’s Inventories and Fixed Asset Supplies as may be marked with a Proprietary ▇▇▇▇. In the event Manager does not exercise such option, Lessee agrees that it will use any such items not so purchased exclusively in connection with the Hotel until they are consumed.

24.02 Computer Software and Equipment. All “Software” (meaning all computer software and accompanying documentation, other than software which is commercially available, which are used by Manager in connection with the property management system, any reservation system and all future electronic systems developed by Manager for use in the Hotel) is and shall remain the exclusive property of Manager or any one of its Manager Affiliate Entities (or the licensor of such Software, as the case may be), and Lessee shall have no right to use, or to copy, any Software. Upon Termination, Manager shall have the right to remove from the Hotel, without compensation to Lessee, all Software, and any computer equipment which is utilized as part of a centralized property management system or is otherwise considered proprietary by Manager, excepting any software which is owned by the applicable Franchisor; provided that Manager shall cooperate with Lessee in the transition of the centralized management system to the new manager, including in the change of any Software and computer equipment. If any of such computer equipment is owned by Lessee or Landlord, Manager shall reimburse Lessee for previous expenditures made by Lessee for the purchase of such equipment, subject to a reasonable allowance for depreciation.

24.03 Intellectual Property. All “Intellectual Property” (meaning all Software and manuals, brochures and directives issued by Manager to its employees at the Hotel regarding procedures and techniques to be used in operating the Hotel) shall at all times be proprietary to Manager or its Affiliates, and shall be the exclusive property of Manager or its Affiliates. Upon

Termination, all Intellectual Property shall be removed from the Hotel by Manager, without compensation to Lessee.

24.04 Books and Records. All Books and Records maintained with respect to the Hotel, including guest records but excluding employee records, shall be the sole property of Lessee but may be used by the Manager during the Term in connection with its management and operation of the Hotel.

ARTICLE XXV

INDEMNIFICATION

25.01 Manager Indemnity. Manager shall indemnify and hold Lessee (and Lessee’s agents, principals, shareholders, partners, members, officers, directors, attorneys and employees) harmless from and against all liabilities, losses, claims, damages, costs and expenses (including, but not limited to, reasonable attorneys’ fees and expenses) which are not covered by insurance proceeds that may be incurred by or asserted against any such party and that arise from (a) the fraud, willful misconduct or gross negligence of Manager; provided, however, that the act or omission of any employee of Manager who is not an Executive Employee, which act or omission is willful or constitutes fraud or gross negligence on the part of such employee, shall not constitute fraud, gross negligence or willful misconduct on the part of Manager unless Manager’s home office or regional staff, or an Executive Employee, acted with gross negligence in employing, training, supervising or continuing the employment of such employee; (b) the infringement by Manager on the intellectual property rights of any third party; (c) any Excluded Employee Claims; (d) knowing or reckless placing, discharge, leakage, use or storage of hazardous materials on the Premises or in the Hotel by Manager during the Term of this Agreement as set forth in Section 28.09C; or (e) the breach by Manager of any provision of this Agreement, including, without limitation, any action taken by Manager which is beyond the scope of Manager’s authority under this Agreement, which is not cured within any applicable notice and cure periods. Lessee shall promptly provide Manager with written notice of any claim or suit brought against it by a third party which might result in such indemnification.

25.02 Lessee Indemnity. Except with respect to matters for which Manager is obligated to provide indemnification pursuant to Section 25.01, Lessee shall indemnify and hold Manager (and Manager’s agents, principals, shareholders, partners, members, officers, directors, attorneys and employees) harmless from and against all liabilities, losses, claims, damages, costs and expenses (including, but not limited to, reasonable attorneys’ fees and expenses) which are not covered by insurance proceeds and that may be incurred by or asserted against such party and that arise from or in connection with (a) the performance of Manager’s services under this Agreement; (b) the condition or use of the Hotel, to the fullest extent permitted by law, including without limitation, any injury to person(s) or damage to property or business by reason of any cause whatsoever in or about the Hotel; (c) any Employee Related Termination Costs, including any liability to which Manager is subjected pursuant to the WARN Act in connection with the termination of this Agreement, provided that Manager has provided notices in the form (other than any reference to the time period) required by the WARN Act within five (5) business days of Manager’s receipt of a notice of the termination of this Agreement (excluding any termination of this Agreement which results from the commission of any theft, embezzlement or other

criminal misappropriation of funds of the Hotel or from the Lessee or any fraud or felony by any Executive Employee that relates to or materially affects the operation or reputation of the Hotel); (d) the Employee Costs and Expenses as set forth in Article IX herein above; or (e) any Employee Claims, but excluding any Excluded Employee Claims. Manager shall promptly provide Lessee with written Notice of any claim or suit brought against it by a third party which might result in such indemnification. THIS INDEMNITY PROVISION IS INTENDED TO INDEMNIFY MANAGER (i) AGAINST THE CONSEQUENCES OF ITS OWN NEGLIGENCE OR FAULT WHEN MANAGER IS SOLELY NEGLIGENT OR CONTRIBUTORILY, PARTIALLY, JOINTLY, COMPARATIVELY OR CONCURRENTLY NEGLIGENT WITH LESSEE OR ANY OTHER PERSON (BUT IS NOT GROSSLY NEGLIGENT, HAS NOT COMMITTED AN INTENTIONAL ACT OR MADE INTENTIONAL OMISSION) AND (ii) AGAINST ANY LIABILITY OF MANAGER BASED ON ANY APPLICABLE DOCTRINE OF STRICT LIABILITY.

25.03 Indemnification Procedure. Any party obligated to indemnify the other party under this Agreement (the “Indemnifying Party”) shall have the right, by Notice to the other party, to assume the defense of any claim with respect to which the other party is entitled to indemnification hereunder. If the Indemnifying Party gives such notice, (i) such defense shall be conducted by counsel selected by the Indemnifying Party and approved by the other party, such approval not to be unreasonably withheld or delayed (provided, however, that the other party’s approval shall not be required with respect to counsel designated by the Indemnifying Party’s insurer); (ii) so long as the Indemnifying Party is conducting such defense with reasonable diligence, the Indemnifying Party shall have the right to control said defense and shall not be required to pay the fees or disbursements of any counsel engaged by the other party for services rendered after the Indemnifying Party has given the Notice provided for above to the other party, except if there is a conflict of interest between the parties with respect to such claim or defense; and (iii) the Indemnifying Party shall have the right, without the consent of the other party, to settle such claim, but only provided that such settlement involves only the payment of money, the Indemnifying Party pays all amounts due in connection with or by reason of such settlement and, as part thereof, the other party is unconditionally released from all liability in respect of such claim. The other party shall have the right to participate in the defense of such claim being defended by the Indemnifying Party at the expense of the other party, but the Indemnifying Party shall have the right to control such defense (other than in the event of a conflict of interest between the parties with respect to such claim or defense). In no event shall (i) the other party settle any claim without the consent of the Indemnifying Party so long as the Indemnifying Party is conducting the defense thereof in accordance with this Agreement; or (ii) if a claim is covered by the Indemnifying Party’s liability insurance, take or omit to take any action which would cause the insurer not to defend such claim or to disclaim liability in respect thereof.

25.04 Survival. The provisions of this Article shall survive the termination of this Agreement with respect to acts, omissions and occurrences arising during the Term.

25.05 No Successor Liability. Notwithstanding anything herein to the contrary, Manager shall not be liable as a successor employer or entity for any actions Manager’s predecessors ( a “Predecessor Manager”) may have taken in the employer-employee

relationship with Manager’s current or former employees or employees of Manager’s agents before the commencement of the term.

ARTICLE XXVI

NEW HOTELS AND NON-MANAGED HOTELS

Lessee acknowledges and agrees that any Hotel leased by Lessee or its designees from any Affiliates of the Partnership (including the Landlords) from and after the Effective Date may at the election of the parties to the Mutual Exclusivity Agreement either be subject to the terms and provisions of this Agreement effective upon execution of an addendum to this Agreement (the “Addendum”) in the form of Exhibit “A” attached hereto, or pursuant to a management agreement in form and substance substantially similar to the terms of this Agreement with either Manager or an Affiliate of Manager (provided said Affiliate constitutes an Eligible Independent Contractor); provided that there does not then exist an uncured Event of Default by Manager under this Agreement and the independent director approval requirements under the Mutual Exclusivity Agreement have been satisfied. Effective upon execution of said Addendum, all terms and conditions of this Agreement shall be deemed amended to include and apply to such Hotel(s) as provided in the Addendum. Lessee further acknowledges and agrees that any Non-Managed Hotel leased by Lessee or its designees from any Affiliates of the Partnership (including the Landlords) from and after the Effective Date may at the election of the parties to the Mutual Exclusivity Agreement be subject to the terms and provisions of this Agreement that expressly relate to Non-Managed Hotels effective upon execution of an addendum to this Agreement (the “Project Management Addendum”) in the form of Exhibit “B” attached hereto; provided that there does not then exist an uncured Event of Default by Manager under this Agreement and the independent director approval requirements under the Mutual Exclusivity Agreement have been satisfied. Effective upon execution of said Project Management Addendum, all terms and conditions of this Agreement relating to Non-Managed Hotels shall be deemed amended to include and apply to such Non-Managed Hotel(s) as provided in the Project Management Addendum.

ARTICLE XXVII

GOVERNING; LAW VENUE

This Agreement and its interpretation, validity and performance shall be governed by the laws of the State of Texas without regard to its conflicts of laws principles. In the event any court of law of appropriate judicial authority shall hold or declare that the law of another jurisdiction is applicable, this Agreement shall remain enforceable under the laws of the appropriate jurisdiction. The parties hereto agree that venue for any action in connection herewith shall be proper in Dallas County, Texas. Each party hereto consents to the jurisdiction of any local, state or federal court situated in any of such locations and waives any objection which it may have pertaining to improper venue or forum non conveniens to the conduct of any proceeding in any such court.

ARTICLE XXVIII

MISCELLANEOUS

28.01 Rights to Make Agreement. Each party warrants, with respect to itself, that neither the execution of this Agreement nor the finalization of the transactions contemplated hereby shall violate any provision of law or judgment, writ, injunction, order or decree of any court or governmental authority having jurisdiction over it; result in or constitute a breach or default under any indenture, contract, other commitment or restriction to which it is a party or by which it is bound; or require any consent, vote or approval which has not been given or taken. Each party covenants that it has and will continue to have throughout the term of this Agreement and any extensions thereof, the full right to enter into this Agreement and perform its obligations hereunder.

28.02 Agency. Manager’s limited agency established by this Agreement is coupled with an interest and may not be terminated by Lessee until the expiration of the Term of this Agreement except as otherwise provided in this Agreement.

28.03 Failure to Perform. If Manager or Lessee at any time fails to make any payments as specified or required hereunder or fails to perform any other act required on its part to be made or performed hereunder without limitation, then the other party after thirty (30) days’ written notice to the defaulting party may (but shall not be obligated to) pay any such delinquent amount or perform any such other act on the defaulting party’s part. Any sums thus paid and all costs and expenses incurred in connection with the making of such payment or the proper performance of any such act, together with interest thereon at the lesser of (i) the interest rate allowed by the applicable usury laws or (ii) at the Prime Rate plus three percent (3%), from the date that such payment is made or such costs and expenses incurred, shall constitute a liquidated amount to be paid by the defaulting party under this Agreement to the other party on demand. For the purposes of this Section 28.03, the term “Prime Rate” shall mean the “prime rate” as published in the “Money Rates” section of The Wall Street Journal; however, if such rate is, at any time during the Term of this Agreement, no longer so published, the term “Prime Rate” shall mean the average of the prime interest rates which are announced, from time to time, by the three (3) largest banks (by assets) headquartered in the United States which publish a “prime rate”.

28.04 Headings. Headings of Articles and Sections are inserted only for convenience and are in no way to be construed as a limitation on the scope of the particular Articles or Sections to which they refer.

28.05 Attorneys’ Fees and Costs. If any action at law or in equity is necessary to enforce or interpret the terms of this Agreement, the prevailing party shall be entitled to reasonable attorneys’ fees, costs and necessary disbursements in addition to any other relief to which such party may be entitled.

28.06 Entire Agreement. This Agreement, together with other writings signed by the parties expressly stated to be supplementary hereto and together with any instruments to be executed and delivered pursuant to this Agreement, constitutes the entire agreement between the

parties and supersedes all prior understandings and writings, and may be changed only by a writing signed by the parties hereto.

28.07 Consents. Whenever the consent or approval of Lessee is required under the terms of this Agreement, unless otherwise stated to the contrary, such consent or approval may be granted or withheld by Lessee in its reasonable discretion.

28.08 Eligible Independent Contractor. During the Term of this Agreement, Manager shall at all times qualify as an “eligible independent contractor” as defined in Section 856(d)(9) of the Code (“Eligible Independent Contractor”). To that end, during the Term of this Agreement, Manager agrees that:

(a) Manager shall not conduct wagering activities at any of the Hotels;

(b) Manager shall not own, directly or indirectly (within the meaning of Section 856(d)(5) of the Code), more than thirty-five percent (35%) of the outstanding stock of AHP;

(c) no more than thirty-five percent (35%) of the Manager’s partnership interest (in its assets or net profits) shall be owned (within the meaning of Section 856(d)(5) of the Code), directly or indirectly, by one or more persons owning thirty-five percent (35%) (within the meaning of Section 856(d)(5) of the Code) or more of the outstanding stock of AHP;

(d) neither AHP, the Partnership, the Landlords, nor the Lessee, shall derive any income from the Manager or any of its subsidiaries; and

(e) Manager (or a person who is a “related person” within the meaning of Section 856(d)(9)(F) of the Code (a “Related Person”) with respect to Manager) shall be actively engaged in the trade or business of operating “qualified lodging facilities” within the meaning of Section 856(d)(9)(D) of the Code (defined below) for one or more persons who are not Related Persons with respect to AHP or Lessee (“Unrelated Persons”). For purposes of determining whether the requirement of this paragraph (e) has been met, Manager shall be treated as being “actively engaged” in such a trade or business if Manager (i) derives at least 10% of both its profits and revenue from operating “qualified lodging facilities” within the meaning of Section 856(d)(9)(D) of the Code for Unrelated Persons or (ii) complies with any regulations or other administrative guidance under Section 856(d)(9) of the Code that provide a “safe harbor” rule with respect to the hotel management business with Unrelated Persons that is necessary to qualify as an “eligible independent contractor” within the meaning of such Code section.

A “qualified lodging facility” is defined in Section 856(d)(9)(D) of the Code and means a “Lodging Facility” (defined below), unless wagering activities are conducted at or in connection with such facility by any person who is engaged in the business of accepting ▇▇▇▇▇▇ and who is fully authorized to engage in such business at or in connection with such facility. A “Lodging Facility” is a hotel, motel or other establishment more than one-half of the dwelling units in which are used on a transient

basis, and includes customary amenities and facilities operated as party of, or associated with, the lodging facility so long as such amenities and facilities are customary for other properties of a comparable size and class owned by other owners unrelated to AHP.

28.09 Environmental Matters.

For purposes of this Section 28.09, “hazardous materials” means any substance or material containing one or more of any of the following: “hazardous material,” “hazardous waste,” “hazardous substance,” “regulated substance,” “petroleum,” “pollutant,” “contaminant,” or “asbestos,” as such terms are defined in any applicable environmental law, in such concentration(s) or amount(s) as may impose clean-up, removal, monitoring or other responsibility under any applicable environmental law, or which may present a significant risk of harm to guests, invitees or employees of the Hotel.

Regardless of whether or not a given hazardous material is permitted on the Premises under applicable environmental law, Manager shall only bring on the Premises such hazardous materials as are needed in the normal course of business of the Hotel.

In the event of the discovery of hazardous materials (as such term may be defined in any applicable environmental law) on the Premises or in the Hotel during the Term of this Agreement, Lessee shall promptly remove, if required by applicable environmental law, such hazardous materials, together with all contaminated soil and containers, and shall otherwise remedy the problem in accordance with all environmental laws (except to the extent knowingly or recklessly caused by Manager during the Term of this Agreement, whereupon the responsibility to promptly remove and/or remedy the environmental problem shall be that of Manager and at Manager’s sole cost and expense). All costs and expenses of the compliance with all environmental laws shall be paid by Lessee from its own funds (except to the extent knowingly or recklessly caused by Manager during the Term of this Agreement as set forth herein above).

28.10 Equity and Debt Offerings. Neither Lessee nor Manager (as an “issuing party”) shall make reference to the other party (the “non-issuing party”) or any of its Affiliates in any prospectus, private placement memorandum, offering circular or offering documentation related thereto (collectively, referred to as the “Prospectus”), issued by the issuing party, unless the non-issuing party has received a copy of all such references. In no event will the non-issuing party be deemed a sponsor of the offering described in any such Prospectus, nor will it have any responsibility for the Prospectus, and the Prospectus will so state. The issuing party shall be entitled to include in the Prospectus an accurate summary of this Agreement but shall not include any proprietary ▇▇▇▇ of the non-issuing party without prior written consent of the non-issuing party. The issuing party shall indemnify, defend and hold the non-issuing party and its Affiliates (and their respective directors, officers, shareholders, employees and agents) harmless from and against all loss, costs, liability and damage (including attorneys’ fees and expenses, and the cost of litigation), arising out of any Prospectus or the offering described therein, except for any such

losses, costs, liability and damage arising from material misstatements or omissions in a Prospectus based on information provided in writing by the non-issuing party expressly for inclusion in the Prospectus.

28.11 Estoppel Certificates. Lessee and Manager will, at any time and from time to time within fifteen (15) days of the request of the other party or a Holder, or a Franchisor (if so permitted under the applicable Franchise Agreement), or a Landlord (if so permitted under the applicable Lease), execute, acknowledge, and deliver to the other party and such Holder, Franchisor or Landlord, as applicable, a certificate certifying:

That the Agreement is unmodified and in full force and effect (or, if there have been modifications, that the same is in full force and effect as modified and stating such modifications);

The dates, if any, to which the distributions of excess Working Capital have been paid;

Whether there are any existing Event(s) of Default or events which, with the passage of time, would become an Event of Default, by the other party to the knowledge of the party making such certification, and specifying the nature of such Event(s) of Default or defaults or events which, with the passage of time, would become an Event of Default, if any; and

Such other matters as may be reasonably requested.

Any such certificates may be relied upon by any party to whom the certificate is directed.

28.12 Confidentiality. The Manager shall keep confidential all non-public information obtained in connection with the services rendered under this Agreement and shall not disclose any such information or use any such information except in furtherance of its duties under this Agreement and as may be required by any of its lenders or owners (provided said lenders and/or owners, as applicable agree prior to disclosure to keep such information confidential as set forth in this subparagraph 28.12), or as may be required by applicable Legal Requirements or court order, or as may be required under any Franchise Agreement, Hotel Mortgage, Lease or Ground Lease.

28.13 Modification. Any amendment, supplement or modification of this Agreement must be in writing signed by both parties hereto.

28.14 Counterparts. This Agreement may be executed in multiple counterparts, each of which is an original and all of which collectively constitute one instrument.

[Signature Pages to Follow]

IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their duly authorized officers, as of the Effective Date.


LESSEE:

ASHFORD PRIME TRS CORPORATION, a Delaware corporation

By:
		▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇
		President

MANAGER:

REMINGTON LODGING & HOSPITALITY, LLC, a Delaware limited liability company

By:
		▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇
		Chief Executive Officer

EXHIBIT “A“

Addendum to Ashford Prime Hotel Master Management Agreement

, 20

Remington Lodging & Hospitality, LLC

▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇

▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇

Attn: ▇▇. ▇▇▇▇▇ ▇▇▇▇▇▇▇

Re:

Management of Hotel by Remington Lodging & Hospitality, LLC as Manager

Dear ▇▇. ▇▇▇▇▇▇▇:

Please refer to the Ashford Prime Hotel Master Management Agreement, dated as of , 20 (the “Management Agreement”), between Ashford Prime TRS Corporation, a Delaware corporation (“Lessee”) and Remington Lodging & Hospitality, LLC, a Delaware limited liability company, as Manager (“Remington”). Capitalized terms appearing but not defined herein shall have the meanings ascribed to such terms in the Management Agreement.

Lessee, through its wholly owned subsidiary, , a Delaware limited liability company (“New Lessee”), hereby appoints Remington to act as manager of the property located at the location set forth on Exhibit “A” attached to this Addendum (“Addendum”) and fully incorporated herein by reference for all purposes (the “New Hotel”).

Accordingly, effective as of , 20 (“Effective Date”), the Management Agreement is amended and modified as follows:

1. New Lessee shall be a party to the Management Agreement as a “Lessee” and agrees to be bound by all of the terms and conditions of the Management Agreement as “Lessee” thereunder to the extent same are applicable to the New Hotel. Lessee shall have no obligations under the Management Agreement with respect to the New Hotel, and New Lessee shall have no obligations under the Management Agreement with respect to any other Hotel (other than the New Hotel).

2. Remington’s retention by New Lessee as the manager of the New Hotel from and after the Effective Date shall be subject to the terms and conditions of the Management Agreement, as amended hereby, to the same extent as if New Lessee were the “Lessee” thereunder.

3. The following exhibits and schedules attached to the Management Agreement are hereby supplemented with the information on such exhibits as shown on the following exhibits attached hereto:

Schedule 1-1

Exhibits:

Exhibit “A” - Hotel Information for New Hotel

Exhibit “B” - Description of Lease for New Hotel

Exhibit “B-1” – Legal Description for Site of New Hotel

Exhibit “C” – Description of Franchise Agreement and Franchisor for New Hotel

Exhibit “D” – Annual Operating Budget for the Hotel

Schedules:

Schedule 1 - Competitive Set of New Hotel

[Signature pages to follow]

Please execute in the space provided for your signature below to evidence your agreement to the contents of this Addendum.


Sincerely yours,

LESSEE:

ASHFORD PRIME TRS CORPORATION, a Delaware corporation

By:
Name:		▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇
Title:		President

NEW LESSEE:

LLC, a Delaware limited liability company

By:
Name:		▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇
Title:		President


AGREED TO AND ACCEPTED

AS OF , 20 :

MANAGER:

REMINGTON LODGING & HOSPITALITY, LLC,

a Delaware limited liability company

By:

		▇▇▇▇▇ ▇▇▇▇▇▇▇

		CEO

EXHIBIT “A”

Hotel Information

Affiliate

Property Owner

Property

Commencement Date

EXHIBIT “B”

Description of Lease


PROPERTY	LANDLORD	LESSEE	DATE OF LEASE

EXHIBIT “B-1”

Legal Description of Site of New Hotel

Exhibit “C”

Description of Franchise Agreement and Franchisor

EXHIBIT “D”

Annual Operating Budget

SCHEDULE 1

Competitive Set of Hotel

EXHIBIT “B”

Project Management Addendum to Ashford Prime Hotel Master Management Agreement

, 20

Remington Lodging & Hospitality, LLC

▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇

▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇

Attn: ▇▇. ▇▇▇▇▇ ▇▇▇▇▇▇▇

Re:

Project Management of a New Non-Managed Hotel by Remington Lodging & Hospitality, LLC

Dear ▇▇. ▇▇▇▇▇▇▇:

Please refer to the Ashford Prime Hotel Master Management Agreement, dated as of , 2013 (the “Management Agreement”), between Ashford Prime TRS Corporation, a Delaware corporation (“Lessee”) and Remington Lodging & Hospitality, LLC, a Delaware limited liability company (“Manager”). Capitalized terms appearing but not defined herein shall have the meanings ascribed to such terms in the Management Agreement.

Effective as of the date hereof (the “Commencement Date”), Lessee, through its wholly owned subsidiary, Ashford TRS LLC, a Delaware limited liability company (“New Lessee”), hereby appoints Manager to manage, coordinate, plan and execute the capital improvements budget (“Project Management Work”) and Project Related Services for the property located at the location set forth on Exhibit “A” attached to this Project Management Addendum (the “New Non-Managed Hotel”), in exchange for payment by Lessee of the Project Management Fee and Market Service Fees, all in accordance with and subject to the terms and conditions of the Management Agreement.

In addition:

1. The New Non-Managed Hotel shall constitute a “Non-Managed Hotel” under the Management Agreement. New Lessee shall be a party to the Management Agreement as “Lessee” and agrees to be bound by all of the terms and conditions of the Management Agreement as “Lessee” thereunder to the extent same are applicable to the New Non-Managed Hotel. Lessee shall have no obligations under the Management Agreement with respect to the New Non-Managed Hotel, and New Lessee shall have no obligations under the Management Agreement with respect to any of the other Hotels or other Non-Managed Hotels (other than the New Non-Managed Hotel).

2. Remington’s retention by New Lessee to perform Project Management Work and Project Related Services at the New Non-Managed Hotel from and after the Effective Date shall be

subject to the terms and conditions of the Management Agreement to the same extent as if New Lessee were the “Lessee” thereunder.

[Signature pages to follow]

Please execute in the space provided for your signature below to evidence your agreement to the contents of this Project Management Addendum.


Sincerely yours,

LESSEE:

ASHFORD TRS CORPORATION, a Delaware corporation

By:
Name:		▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇
Title:		President

NEW LESSEE:

ASHFORD TRS LLC, a Delaware limited liability company

By:
Name:		▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇
Title:		President


AGREED TO AND ACCEPTED

AS OF , 20 :

MANAGER:

REMINGTON LODGING & HOSPITALITY, LLC,

a Delaware limited liability company

By:

		▇▇▇▇▇ ▇▇▇▇▇▇▇

		CEO

EXHIBIT “A”

Hotel Information


Affiliate Property Owner		Property

ASHFORD PRIME MUTUAL EXCLUSIVITY AGREEMENT

Document Metadata

Document Metadata

Table of Contents