BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE Dated July 2003 (1) BRITISH ENERGY GENERATION (UK) LIMITED (2) BRITISH NUCLEAR FUELS plc (3) BRITISH ENERGY plc

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE Dated July 2003 (1) BRITISH ENERGY GENERATION (UK) LIMITED (2) BRITISH NUCLEAR FUELS plc (3) BRITISH ENERGY plc

Document Metadata

Document Metadata

Table of Contents

Exhibit 4.07

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Dated July 2003

(1) BRITISH ENERGY GENERATION (UK) LIMITED

(2) BRITISH NUCLEAR FUELS plc

(3) BRITISH ENERGY plc

DEED OF AMENDMENT

relating to

Agreement dated 31 March 2003 for the Supply of Fuel for Use in Advanced Gas

Cooled Reactors from 1 April 2006

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

THIS DEED OF AMENDMENT is made the day of July 2003

BETWEEN

(1)

BRITISH ENERGY GENERATION (UK) LIMITED (formerly SCOTTISH NUCLEAR LIMITED), a company incorporated in Scotland (company number SC117121) whose registered office is at ▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇▇ ▇▇▇▇, ▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇ (BEG(UK) which term shall include its successors in title and permitted assigns);

(2)

BRITISH NUCLEAR FUELS plc, a company incorporated in England and Wales (company number 1002607) whose registered office is at Risley, Warrington, Cheshire WA3 6AS (BNFL which term shall include its successors in title and permitted assigns); and

(3)

BRITISH ENERGY plc, a company incorporated in Scotland (company number SC162273) whose registered office is at ▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇▇ ▇▇▇▇, ▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇ (▇▇ which term shall include its successors in title and permitted assigns),

herein also referred to individually as Party and collectively as Parties as the context requires.

WHEREAS

(A)

On 31 March 2003 BEG(UK), BNFL and BE entered into an agreement relating to the Supply of Fuel for Use in BEG(UK)’s Advanced Gas Cooled Reactors from 1 April 2006 (the Agreement).

(B)

The Parties wish to enter into this Deed of Amendment to make certain amendments to the Agreement with regard to the Conditions set out in Clause 1.5 of the Agreement and the parent-company guarantee set out in Clause 37 of the Agreement, and to amend Clause 33 of the Agreement.

NOW THIS DEED OF AMENDMENT WITNESSES as follows:

INTERPRETATION

1.1 Unless the context otherwise requires or unless otherwise defined in this Deed of Amendment, words and expressions defined in, or to be construed in accordance with, the Agreement shall have the same meaning and construction when used in this Deed of Amendment.

1.2 Words importing persons or Parties shall include firms, corporations and any organisation having legal capacity.

1.3 Words importing the singular only also include the plural and vice versa where the context requires.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

1.4 Headings in this Deed of Amendment are for ease of reference only and shall not be taken into consideration in the interpretation or construction of this Deed of Amendment.

COMMENCEMENT

This Deed of Amendment shall take effect as at and from the date of this Deed of Amendment.

AMENDMENTS

3.1 The following amendments shall be made to the Agreement to reflect the changes described in Recital B.

(a)

Clause 1.5.3 shall be deleted and replaced with the following:

“BE, the Material Creditors and HMG becoming bound under agreements and/or a scheme of arrangement of BE to give effect to the terms of the Restructuring disclosed by BE to BNFL prior to or at the same time as BNFL entering into this Agreement, and such agreements and/or scheme are not subject to any outstanding conditions (other than any condition in any such agreement to the effect that the unconditionality of such agreement and/or scheme is dependent upon the unconditionality of this Agreement or any other document listed in Appendix 19) and are consistent with the Heads of Terms;”

(b)

Clause 1.5.7 shall be deleted and replaced with: “1.5.7. [Not Used]”.

(c)

Clause 33 shall be deleted and replaced with:

“33.

ADJUSTMENT OF THE PAYMENT PROFILES BY BEG(UK)

33.1 BEG(UK) shall have an option exercisable at any time during the term of this Agreement to accelerate payments to BNFL subject to an aggregate upper limit of [ ]* ([ ]* pounds) per annum after adjustment in accordance with Clause 33.1.2 (or such other sum as may be agreed). For this purpose:

33.1.1 BEG(UK) shall give 36 months notice (or such other notice period as may be agreed) of any intent to accelerate payment;

33.1.2 BEG(UK) and BNFL shall discuss and agree which payments under this Agreement are to be accelerated and such payments shall be adjusted by a discount rate to be agreed by the Parties and escalated in accordance with the provisions of Appendix 7 of this Agreement;

33.1.3 BEG(UK) and BNFL shall forthwith agree to and maintain a financial model to facilitate and record the application of this Clause 33; and

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

33.1.4 the payment profile identified in this Agreement shall be modified to reflect any Agreement reached under this Clause 33. In all other respects this Agreement shall continue in full force and effect following such modification.”

(d)

Clause 37.5 shall be deleted and replaced with the following:

“In the event that BE ceases to be the ultimate holding company of BEG(UK), BE shall forthwith notify BNFL thereof and, at the request of BNFL, BE shall assign and part with its rights and obligations under (a) this Agreement and (b) all other agreements and deeds entered into by BE, BNFL and either BEG(UK) or BEG (as the case may be) under which BE has any rights or obligations, to the ultimate holding company of BEG(UK), subject to BE being released and discharged from all obligations, duties and liabilities under this Agreement and any such other agreements and deeds.”

3.2 Save as herein amended, the Agreement (including for the avoidance of doubt, the liabilities of, and the rights and remedies of BNFL as against, BE) shall continue in full force and effect.

INCONSISTENCY

4.1 In the event of any inconsistency between this Deed of Amendment and provisions contained in or incorporated into the Agreement, this Deed of Amendment shall prevail.

GOVERNING LAW

This Deed of Amendment shall be governed by and construed in accordance with English law.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

IN WITNESS WHEREOF the Parties hereto have caused this Deed of Amendment to be duly executed as their Deed the day and year first before written.

EXECUTED as a DEED by		)
		)
as attorney for		)
BRITISH ENERGY GENERATION		)
(UK) LIMITED		)

in the presence of:

Signature of Witness:
Name of Witness:
Address of Witness:
Occupation of Witness:

The Common Seal of		)
BRITISH NUCLEAR FUELS plc		)
was hereunto affixed in the		)
presence of		)

Director

Secretary/ Director

EXECUTED as a DEED by		)
		)
as attorney for		)
BRITISH ENERGY plc		)

in the presence of:

Signature of Witness:
Name of Witness:
Address of Witness:
Occupation of Witness:

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

EXECUTION COPY

Dated 31 March 2003

BRITISH NUCLEAR FUELS plc

BRITISH ENERGY GENERATION (UK) LIMITED

BRITISH ENERGY plc

AGREEMENT

for the Supply of Fuel for Use in Advanced Gas

Cooled Reactors from 1 April 2006

[LOGO OF FRESHFIELDS BRUCKHAUS ▇▇▇▇▇▇▇▇]

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

CONTENTS

Clause		Page
1.	INTERPRETATION	2

2.	DURATION OF AGREEMENT	12

3.	[NOT USED]	22

4.	SUPPLY	22

5.	CHARGES, INVOICING AND PAYMENT	26

6.	FUEL SPECIFICATION AND DESIGN	29

7.	ORDERING PROCEDURE	32

8.	WARRANTY	35

9.	QUALITY ASSURANCE	35

10.	PACKAGING	35

11.	STORAGE	36

12.	TRANSPORT AND DELIVERY	36

13.	FAULTY FUEL	39

14.	OPERATING RECORDS	42

15.	EFFICIENCY AND EFFECTIVENESS	43

16.	[NOT USED]	43

17.	NON-STANDARD URANICS	43

18.	LIABILITY FOR LOSS OR ▇▇▇▇▇▇	▇▇

▇▇.	LIMITATION OF LIABILITY	44

20.	CONFIDENTIALITY	45

21.	ASSIGNMENT	46

22.	FORCE MAJEURE	47

23.	WAIVER	47

24.	NON PERFORMANCE	48

25.	NOTICES	48

26.	INVALIDITY AND SEVERABILITY	49

27.	LAW	49

28.	DISPUTE RESOLUTION	49

29.	[NOT USED]	50

30.	TERMINATION AND SURVIVAL	50

31.	ENTIRE AGREEMENT	50

32.	NON-DISCRIMINATION	50

33.	ADJUSTMENT OF THE PAYMENT PROFILES BY BEG(UK)	51

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

34.	TERMINATION OF SUPPLY BY BNFL	52

35.	COMPETITION	52

36.	NO RIGHTS UNDER CONTRACTS (RIGHTS OF THIRD PARTIES) ACT 1999	54

37.	PARENT COMPANY GUARANTEE AND FURTHER ASSURANCE	54

38.	ACKNOWLEDGEMENTS BY BE AND BEG(UK)	55

APPENDIX 1 EXPECTED DATES FOR AGR POWER STATION LIFETIMES		56

APPENDIX 2 APPROVED PRODUCT LIST		57

APPENDIX 3 CONTRACT SPECIFICATION		58

APPENDIX 4 [NOT USED]		59

APPENDIX 5 ENRICHED URANIUM BREAKDOWN STATEMENT		60

APPENDIX 6 ENRICHED URANIUM BREAKDOWN STATEMENT (PIV)		61

APPENDIX 7 ESCALATION FORMULA		62

APPENDIX 8 QUALITY ASSURANCE ARRANGEMENTS		64

APPENDIX 9 ENRICHED URANIUM STATEMENT (WIP)		70

APPENDIX 10 EXAMPLE AGR FUEL DELIVERY PLAN		71

APPENDIX 11 [NOT USED]		73

APPENDIX 12 CHARGES FOR ANCILLARY COMPONENTS		74

APPENDIX 13 [NOT USED]		76

APPENDIX 14 EFFICIENCY AND EFFECTIVENESS		77

APPENDIX 15 AGR BURNABLE POISON CABLE FLEXIBILITY		87

APPENDIX 16 AGREED PRINCIPLES: CENTRAL FUEL STORE AT SPRINGFIELDS		88

APPENDIX 17 THE SHARING OF BENEFITS RESULTING FROM DESIGN CHANGES		90

APPENDIX 18 PRICES PAYABLE FOR AGR FUEL SUPPLY		92

APPENDIX 19 LIST OF DOCUMENTS FOR CONDITIONS		99

PART A: AGREEMENTS BETWEEN BNFL AND BEG		99

PART B: AGREEMENTS BETWEEN BNFL AND BEG(UK)		100

APPENDIX 20 CALCULATION OF OUTTURN ELECTRICITY PRICE		101

APPENDIX 21 PRICING PRINCIPLES		109

APPENDIX 22 SECURITY OF SUPPLY POLICY		112

APPENDIX 23 URANICS REVIEW BOARD		113

APPENDIX 24 REVIEW OF SECURITY OF SUPPLY POLICY		114

APPENDIX 25 STOCK AND PROCUREMENT STRATEGY CONSIDERATIONS		115

APPENDIX 26 PRICING REVIEW		117

APPENDIX 27 PORTFOLIO MANAGEMENT REPORT AND MONTHLY UPDATE TO THE PORTFOLIO MANAGEMENT REPORT		124

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 28 AMENDMENTS ON TERMINATION OF THE URANICS SUPPLY COMPONENT OF THIS AGREEMENT		125

APPENDIX 29 [NOT USED]		132

APPENDIX 30 [NOT USED]		133

APPENDIX 31 VALUATION MECHANISM		134

APPENDIX 32 WARRANTIES		139

III

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

THIS AGREEMENT is made this 31st day of March 2003

BETWEEN:

(1)

BRITISH NUCLEAR FUELS plc, a company incorporated in England and Wales (company number 1002607) whose registered office is at Risley, ▇▇▇▇▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇ (BNFL which term shall include its successors in title and permitted assigns);

(2)

BRITISH ENERGY GENERATION (UK) LIMITED (formerly SCOTTISH NUCLEAR LIMITED), a company incorporated in Scotland (company number SC117121) whose registered office is at ▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇▇ ▇▇▇▇, ▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇ (BEG(UK) which term shall include its successors in title and permitted assigns); and

(3)

herein also referred to individually as Party and collectively as Parties as the context requires.

WHEREAS:

(A)

BNFL carries on, through its business group Westinghouse, the business of, inter alia, the manufacture of uranium dioxide Fuel derived from enriched uranium hexafluoride and the supply of Fuel Elements suitable for use in advanced gas-cooled reactors and currently supplies BEG(UK) with such Fuel Elements together with associated Ancillary Components for delivery to BEG(UK)’s AGR Power Stations pursuant to an Agreement with Scottish Nuclear Limited dated 30 March 1995, as amended (the Existing Fuel Supply Agreement).

(B)

On 5 September 2002 BE, the parent company of BEG(UK), announced that it had entered into discussions with HMG with a view to seeking immediate financial support and to enable a longer term solvent restructuring to take place. On 9 September 2002, HMG granted BE a loan for up to £410 million in respect of its working capital requirements and cash collateral in the United Kingdom and North America. This loan was repayable on 27 September 2002 but, on 26 September 2002, was increased to £650 million and extended until 29 November 2002 and, on 28 November 2002, further extended until 9 March 2003.

(C)

In September 2002, BE informed BNFL both that it and its subsidiaries were unable to meet their obligations under the Existing Fuel Supply Agreement and certain of its other arrangements with BNFL and that a solvent restructuring of BE could not take place without the amendment of the commercial terms of the Existing Fuel Supply Agreement and such other arrangements.

(D)

On 28 November 2002, BNFL and BE entered into the Heads of Terms which contained non-binding summary proposals which, together with other proposals agreed between BE and HMG, were intended to lead to a solvent restructuring of BE (assuming that other interested third parties, including BE’s creditors, co-operated to put the solvent restructuring into effect).

(E)

In the Heads of Terms, BE and BNFL agreed, inter alia, to enter into negotiations with a view to entering into a new Fuel supply arrangement to be effective from 1 April 2006.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

(F)

This Agreement sets out the terms and conditions upon which BNFL will, subject to the satisfaction (or waiver) of the Conditions, supply Fuel to BEG(UK) from 1 April 2006 until the end of the Fuel Supply Period.

(G)

BNFL shall have the obligation to supply Uranic Elements to the AGR Power Stations in accordance with the terms and conditions set out in this Agreement.

(H)

BNFL shall use all reasonable endeavours to minimise the cost at which it obtains Uranic Elements in accordance with an agreed Security of Supply Policy and the Stock and Procurement Strategy by which BNFL will seek to implement the said policy.

INTERPRETATION

1.1

In this Agreement unless the context otherwise requires:

Account means a record of UOC, UF₆, Enriched UF₆or WIP held at a supplier or BNFL on behalf of BEG(UK), BNFL or a third party as the context requires;

Affiliate means, in relation to a Party, a company over which that Party has control or which controls that Party or which is controlled by the same company as that Party (and, for the purposes of this definition, control has the meaning given to such term in section 840 of the Income and Corporation Taxes Act 1988);

Agreed means agreed in writing between BEG(UK) and BNFL;

Agreement means this Agreement and the Appendixes hereto or agreement in writing between BEG(UK) and BNFL as the context may require;

AGR Power Station means a power station incorporating advanced gas-cooled reactors as specified in Appendix 1;

Ancillary Components means all the components, with the exception of Fuel Elements, required for the assembly of Fuel Stringers, which components are more particularly described in the Approved Product List;

Ao shall be as set forth in Appendix 18;

Approved Product List means the Agreed list of Fuel as amended from time to time which BEG(UK) may order and BNFL on acceptance of such order will supply under the terms of this Agreement. The Approved Product List at the date hereof is referred to in Appendix 2;

Assay means the total weight of U235 isotope divided by the total weight of all uranium isotopes expressed as a weight percent (wt%);

BEG means British Energy Generation Limited (formerly Nuclear Electric Limited), a company incorporated in England and Wales (Company No 3076445) whose registered office is at ▇▇▇▇▇▇▇ ▇▇▇, ▇▇▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇;

BEG Agreement means the agreement for the supply of Fuel for use in advanced gas-cooled reactors from 1 April 2006 between BEG, BE and BNFL dated the same date as this Agreement;

BEG AGR Power Station means the power stations incorporating advanced gas-cooled reactors operated by BEG at Dungeness B, Hartlepool, Heysham 1, Heysham 2 and ▇▇▇▇▇▇▇ Point B;

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

BEG(UK) Existing Fuel Supply Agreement means the Agreement for the Supply of Fuel for Use in Advanced Gas Cooled Reactors between BNFL and Scottish Nuclear Limited dated 30 March 1995, as amended;

BNFL Interim Sale Uranium has the meaning given to that term in Clause 2.23.2;

BNFL Pass-Through Contracts has the meaning given to that term in Clause 2.27;

Bo shall be as set forth in Appendix 18;

Book Transfer means the transfer of the Stocks on the books of BNFL and/or a supplier from BNFL’s Account to BEG(UK)’s Account as the context requires;

Book Value of the Remaining Termination A Stocks means the book value used by BNFL to determine the Remaining Termination A Stocks Purchase Price as at the last date of completion in respect of the Remaining Termination A Stocks as shall be certified by BNFL’s auditors pursuant to Clause 2.12.2;

Buying-in Price of Externally Sourced Components has the meaning given to such term in Appendix 12;

Central Store means the central Fuel store referred to in Appendix 16;

Completion means completion of the sale and purchase of the Termination A Stocks or the Termination B Stocks (as the case may be) under the terms of this Agreement;

Contracts means (i) such of those contracts entered into by BNFL before 1 April 2003 for the provision of UOC and/or UF₆ and/or Enriched UF₆and/or the conversion, enrichment and/or storage of such material as were entered into for the purposes of supplying Fuel to BEG(UK) under the BEG(UK) Existing Fuel Supply Agreement and this Agreement and (ii) such of those contracts entered into by BNFL after 31 March 2003 and before 1 April 2006 for the provision of UOC and/or UF₆ and/or Enriched UF₆and/or the conversion, enrichment and/or storage of such material as have been or are proposed to be entered into for the purposes of supplying Fuel to BEG(UK) under the BEG(UK) Existing Fuel Supply Agreement solely before 1 April 2006;

Conditions means the conditions set out in Clause 1.5;

Contract Specification means the Agreed specifications against which Fuel and its constituent parts are supplied by BNFL more particularly described in Appendix 3 as amended by Agreement from time to time;

Conversion Services means the process of converting natural uranium in the form of UOC into natural uranium in the chemical form of UF₆;

Day means any day of any Week without exception, including Saturday, Sunday and all public holidays;

Decommissioning means following post operational clean-out, the closure if required, the making safe and surveillance of BNFL facilities utilised for the performance of this Agreement and the ultimate dismantling of the said facilities, the undertaking of any other operations thereto as may be necessary and clearing that part or parts of the site on which the said facilities stand for release for unconditional use;

Deed for the Sale and Purchase of Enriched and Natural Uranium Stocks means the deed of the same name between BNFL and BEG dated the same date as this Agreement;

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Delivery means the Book Transfer of the Stocks and Deliver shall have a corresponding meaning;

EC Treaty means the Treaty Establishing the European Community of 25 March 1957 as from time to time amended;

Enriched means having a content of the isotope uranium 235 higher than 0.711% w/w;

Enriched UF₆ means uranium hexafluoride having a content of the isotope uranium 235 higher than 0.711% w/w;

Enriched Uranium Material means products created or used during the processing of enriched Fuel including but not limited to UF₆, UO2 and UOC powders, Fuel Pellets and process residues;

Enrichment means the process expressed in terms of SWU by which natural UF₆ is changed into Enriched UF₆ with an increased Assay of U235 and tails, with a lower Assay of U235, are produced;

Escalated means increased in line with the formula set out in Appendix 7 (as such may be amended in any particular Clause in this Agreement);

Existing Designs means designs for Fuel which are included on the Approved Product List at the date hereof;

Existing Fuel Supply Agreement shall have the meaning given to it in Recital (A);

Final Suppliers means the suppliers of Uranic Elements to BNFL under the Contracts and the New Contracts on the date of expiry or early termination of the Uranic Elements Supply Component of this Agreement;

Financial Year 2003 means the financial year ending 31 March 2003;

Forward Contract Cover means such quantity of Uranic Elements as may be made available by BNFL pursuant to the Contracts or New Contracts (or options within the Contracts or New Contracts) for the procurement of such material;

Fuel means Fuel Elements and Ancillary Components included in the Approved Product List;

Fuel Element means a cluster of Fuel Pins and associated components assembled within a single graphite sleeve or a combination of graphite sleeves to Contract Specification and included in the Approved Product List;

Fuel Pellet means a uranium dioxide pellet manufactured to meet a Contract Specification;

Fuel Pin means a quantity of Fuel Pellets assembled and sealed in a single can in accordance with Contract Specification and ready for incorporation in a Fuel Element;

Fuel ▇▇▇▇▇▇▇▇ means a complete channel of Fuel Elements together with the Ancillary Components;

Fuel Supply Period means the period from 1 April 2006 until the date specified in the written notice received by BNFL from BEG(UK) as the date following which no further Fuel of any type will be loaded into any Reactor in any AGR Power Station or BEG AGR Power Station;

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Group means, in relation to a Party, that Party and each Affiliate of that Party; and Group Company means any company within such a Group;

Heads of Terms means the non-binding heads of terms as initialled by Mr. ▇▇▇▇ ▇▇▇▇▇▇▇ and ▇▇. ▇▇▇▇▇ ▇▇▇▇▇, on behalf of BNFL and BE respectively, on 28 November 2002;

Historic Spent Fuel has the meaning given to the term “Fuel” in the Historic Spent Fuel Agreement;

Historic Spent Fuel Agreement means the agreement to be entered into by the Parties relating to the storage and reprocessing of irradiated oxide fuel and related services in relation to Historic Spent Fuel;

HMG means the Government of the United Kingdom;

Initial Stocks means the stocks held by BNFL for the purpose of supplying Fuel to BEG(UK) on 31 March 2006;

Initial Termination A Completion Date means:

(a)

in relation to the expiry of the Uranics Term, the date which is 5 Working Days after such date of expiry; or

(b)

in relation to termination of the Uranics Term pursuant to Clause 2.2.1, the date of termination specified in the notice served by either BNFL or BEG(UK) pursuant to Clause 2.2.1;

Initial Termination A Stocks means all Enriched Uranium Material (excluding the derivatives of Enriched UF₆ described in column numbers 8 and 9 of the latest Enriched Uranium Breakdown Statement issued prior to the Initial Termination A Stocks Completion Date pursuant to paragraph 4 of Appendix 10);

Initial Termination A Stocks Completion means completion of the sale and purchase of the Initial Termination Stocks A in accordance with Clause 2.9;

Initial Termination A Stocks Purchase Price means the purchase price of the Initial Termination A Stocks as determined in accordance with Clause 2.7;

Instrumented Fuel means that Fuel which is Agreed shall be supplied by BNFL to BEG(UK) under the provisions of the Agreement for the Manufacture of Non-Standard Fuel and Provision of Miscellaneous Services dated 31 March 1995, as amended;

Irradiated Fuel Element means a Fuel Element which has been supplied by BNFL and which has subsequently been irradiated in one of BEG’s or BEG(UK)’s Reactors;

Joint Study Team means the joint team established by BNFL, BEG and BEG(UK) to study the end of life optimisation programme for the AGR Power Stations and the BEG AGR Power Stations;

LIBOR means the three month London Inter-Bank Offer Rate for Sterling loans, quoted daily by the London edition of the Financial Times or, in the event that on a particular day that publication is not published, the three month London Inter-Bank Offer Rate at 11:00 am as quoted by the National Westminster Bank Plc for Sterling loans or such other rate as BEG(UK) and BNFL Agree;

LCIA means the arbitral institution formerly known as the London Court of International Arbitration;

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

LMA means the Liabilities Management Authority or any other body established by HMG for the purpose of assuming responsibility for cleaning up the “nuclear legacy”, as defined in and contemplated by the White Paper;

Material Creditors means the “Creditors” as defined in the Standstill Agreement;

Month means a period of time defined as a Month by ESI Standard 99-1 or its equivalent;

month means a calendar month;

New BNFL means a new company to be created pursuant to the restructuring of BNFL and its businesses in connection with the establishment of the LMA, as such restructuring is referred to in and contemplated by the White Paper;

New Contracts means such of those contracts entered into by BNFL for the provision of UOC and/or UF₆ and/or Enriched UF₆and/or the conversion, enrichment and/or storage of such material as have been or are proposed to be entered into for the purposes of supplying Fuel to BEG(UK) under this Agreement after 1 April 2006, excluding the Contracts;

New Pricing Period shall have the meaning given in Appendix 18, Part B;

New Spent Fuel has the meaning given to the term “Fuel” in the New Spent Fuel Agreement;

New Spent Fuel Agreement means the agreement to be entered into between the Parties for spent Fuel management services in respect of New Spent Fuel;

New Uranics Commitment means the exercise of an option under, the extension of the term of, or the renegotiation of, any agreement between BNFL and a Supplier or Final Supplier (as the case may be) for the purposes of supplying Fuel to BEG(UK) under this Agreement;

Non-Nuclear Risk means any risk in respect of which a nuclear site licensee is not responsible pursuant to the Nuclear Installations ▇▇▇ ▇▇▇▇, as amended, including any extension or re-enactment thereof;

Novation and Amendment Deed means a novation and amendment deed between BNFL, BEG(UK) and a Final Supplier to effect the novation and amendment of a Supply Agreement to which that Final Supplier is a party substantially in the form set out in Schedule 4 to the Deed for the Sale and Purchase of Enriched and Natural Uranium Stocks amended to reflect BNFL as Seller and BEG(UK) as Buyer and a new Effective Date determined in accordance with Clause 2.26.6;

OFC means the Oxide Fuel Complex at Springfields;

Packaging means the containers and all packing material in which Fuel is delivered and transported by BNFL;

PIE means post irradiation examination of Fuel;

Pricing Principles means those principles relating to the calculation of Uo, Vo, Wo and Xo as set out in Appendix 21;

Process Losses means irrecoverable Enriched Uranium Material losses. For the avoidance of doubt BEG(UK) shall have no entitlement to Enriched Uranium Material contained within Process Losses;

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Quarter means any period of three consecutive months ending 31 March, 30 June, 30 September or 31 December, and “Quarterly” shall be construed accordingly;

Quality Audit Programme means a schedule of audits which BNFL intends to carry out in any one calendar year on its suppliers;

Reactor means an advanced gas-cooled reactor incorporated in an AGR Power Station or BEG AGR Power Station operated by BEG(UK) or BEG, as appropriate;

Reactor Failure means BEG(UK) not generating enough electricity at one or more of its Reactors due to reasons beyond the control of BEG(UK) (including without limitation events of Force Majeure pursuant to Clause 22 but not including planned outages);

Regulatory Bodies means any local or national agency, authority, department, inspectorate, minister, ministry, official or public or statutory person (whether autonomous or not) of HMG or the European Union with the power of regulation over the activities of BNFL;

Remaining Stocks has the meaning given to that term in the Deed for the Sale and Purchase of Enriched and Natural Uranium Stock;

Remaining Termination A Stocks means all:

(a)

UOC, UF₆ and Enriched UF₆ held by the Final Suppliers on behalf of BNFL for the purposes of supplying Fuel to BEG(UK) under this Agreement;

(b)

Enriched UF₆ held by BNFL for the purposes of supplying Fuel to BEG(UK) under this Agreement; and

(c)

WIP held by BNFL at Springfields for the purposes of supplying Fuel to BEG(UK) under this Agreement,

to the extent that they are so held at the Remaining Termination A Stocks Completion Date and do not form part of the Initial Termination A Stocks or the BNFL Interim Sale Uranium (if any);

Remaining Termination A Stocks Completion means completion of the sale and purchase of the Remaining Termination A Stocks in accordance with Clause 2.10;

Remaining Termination A Stocks Completion Date means the date which is the later of (i) 3 months after the Initial Termination A Stocks Completion Date and (ii) five Working Days after the condition precedent in clause 2.1 of the Novation and Amendment Deed is satisfied;

Remaining Termination A Stocks Purchase Price means the purchase price of the Remaining Termination A Stocks as determined in accordance with Clause 2.8;

Reprocessing means the services outlined in clause 7 of the Historic Fuel Agreement;

Retail Price Index means the Retail Prices Index (All Items) published in the Monthly Digest of Statistics by the Office for National Statistics (or any successor entity performing an equivalent function) of the United Kingdom, which shall be used to the full precision with which it is published. In the event that the Retail Price Index is discontinued or the basis of its calculation is modified, BEG(UK) and BNFL shall adopt such alternative index as shall be specified in replacement by the body in the United Kingdom

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

responsible for the production of such statistics or, in the absence of such alternative index being specified or the alternative being unacceptable to BEG(UK) or BNFL, such index as may be Agreed;

Second Remaining Termination A Completion Date has the meaning given to such term in Clause 2.11.3;

Security Interest means any security interest of any nature whatsoever including, without limitation, any mortgage, charge, pledge, lien, assignment by way of security or other encumbrance;

Security of Supply Policy means the policy established pursuant to Clause 3.6;

Springfields means the nuclear Fuel manufacturing works of BNFL, at ▇▇▇▇▇▇▇▇▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇;

Standstill Agreement means the standstill agreement between BE, BNFL and the other companies and creditors listed in Schedule 2 and 3 thereto, dated 14 February 2003;

Stock and Procurement Strategy means the strategy established pursuant to Clause 3.7;

Stock Cover means such quantity of Uranium Material held in inventory by BNFL for the purpose of supplying Fuel to BEG and BEG(UK) at any time including those quantities required by BNFL to meet its obligations for the supply of Fuel to BEG(UK) pursuant to this Agreement;

Stock Cover Trigger means £[ ]* Escalated from 1 April 2006 in accordance with Appendix 7;

Stocks means the Termination A Stocks or the Termination B Stocks (as the context requires);

Storage means the services outlined in clause 5 of the Historic Fuel Agreement;

Supplier means a counterparty to a Contract or a New Contract;

SWU means Separative Work Unit;

TENEX means Techsnabexport Joint Stock Company, Moscow, Russia;

Technical Services Agreement means an agreement for design and development of fuel dated 30 March 1995 between BNFL and BEG(UK);

Termination A Stocks means the Initial Termination A Stocks and the Remaining Termination A Stocks;

Termination B Completion means completion of the sale and purchase of the Termination B Stocks in accordance with this Agreement;

Termination B Completion Dates mean the dates set out in the Termination B Completion Schedule, which shall be no later than the fifth anniversary of the date of termination of the Uranics Term pursuant to Clause 24;

Termination B Completion Schedule has the meaning given to that term in Clause 2.19;

Termination B Purchase Price means the purchase price of the Termination B Stocks as determined in accordance with Clause 2.18;

Termination B Stocks means all:

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

(a)

UOC, UF₆ and Enriched UF₆ held by the Final Suppliers on behalf of BNFL for the purposes of supplying Fuel to BEG(UK) under this Agreement;

(b)

Enriched UF₆ held by BNFL for the purposes of supplying Fuel to BEG(UK) under this Agreement; and

(c)

WIP held by BNFL at Springfields for the purposes of supplying Fuel to BEG(UK) under this Agreement,

to the extent that they are so held at the date of termination specified in the notice pursuant to Clause 24 and do not form part of the BNFL Interim Sale Uranium;

Third Party Risk means the risk of incurring liability to any persons or entities other than the Parties which may result from any damage to property or from any injury (including injury resulting in death) or loss which may be attributable wholly or in part to the matters referred to herein;

Transport Approval Certificates means those certificates issued by the Department for Transport to BNFL approving the use of containers to transport unirradiated Fuel;

tU means tonne(s) of uranium;

Uo has the meaning given to that term in Clause 4.1;

UOC means natural uranium ore concentrate, also known as U₃O₈ (or triuranium octoxide), which has been accepted by the relevant supplier holding such material;

UF₆ means natural uranium hexafluoride which has been accepted by the relevant supplier holding such material;

UO2 means uranium dioxide;

Uranic Elements means UOC (measured in kgU), Conversion Services (measured in kgU) and Enrichment (measured in SWU);

Uranic Elements Supply Component of this Agreement means the provisions relating to BNFL’s obligation to supply Uranic Elements to enable the delivery of Fuel to the AGR Power Stations;

Uranics means U308, natural UF₆and enriched UF₆;

Uranics Review Board means the review board referred to in Clause 3.5;

Uranics Term has the meaning given to that term in Clause 2.2;

Uranium Material means uranium in any form, including UOC, UF₆or Enriched Uranium Material;

Urenco means the United Kingdom, Netherlands and German joint venture respectively carrying out business under the names Urenco (Capenhurst) Limited, Urenco NL BV and Urenco Deutschland GmbH and represented for the purposes of relevant enrichment contracts with BEG by Urenco Ltd., ▇▇ ▇▇▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇;

Vo has the meaning given to that term in Clause 4.1;

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Warranty means a statement contained in Appendix 30;

Waste means all radioactive and non-radioactive material (including without limitation, solids, liquids or gaseous substances) that are produced under or result from the performance or failure thereof by BNFL or any of its sub-contractors under or pursuant to this Agreement;

Week means any period of seven consecutive days beginning on a Monday;

Westinghouse means Westinghouse Nuclear Fuel Business Unit, a business group of BNFL;

White Paper means the White Paper published by HMG with command number 5552 entitled “Managing the Nuclear Legacy: A Strategy for Action”, presented to Parliament by the Secretary of State for Trade and Industry in July 2002;

WIP means all Enriched UF₆used for the purposes of being manufactured into Fuel under this Agreement, and all Enriched UF₆in the process of being manufactured into Fuel under this Agreement, including those derivatives of such Enriched UF₆described in column numbers 1B, 2 and 4 to 9 of Table 4 in Appendix 10;

Wo has the meaning given to that term in Clause 4.1;

Working Day means any day from Monday to Friday between 0900 and 1600 inclusive, other than Christmas Day, Good Friday and statutory bank holidays in England or Scotland and local public holidays in East Kilbride (or wherever else in Scotland BEG(UK)’s registered office may be situated);

Xo has the meaning given to that term in Clause 4.1; and

Year means the period from 1 April to 31 March next following.

1.2 The expressions “in writing” and “written” include any means of representing or reproducing information in a visible, legible and permanent form.

1.3 The headings in this Agreement are for convenience only and shall not affect its interpretation and all references contained herein to Recitals, Clauses, Schedules, Annexes and Appendixes shall refer to the corresponding Recital, Clause, Schedule, Annex or Appendix of this Agreement unless specific reference is made to a recital, clause, schedule, annex or appendix of another document or instrument.

1.4 Words importing the singular meaning include where the context so admits the plural meaning and vice-versa; and all references to £ shall refer to pounds sterling.

1.5 If any of the following Conditions has not been satisfied (or waived) on or before 31 December 2004 (or such other date as is referred to in the relevant Condition) or such later date as is agreed by the Parties in order to ensure compliance with any conditions or obligations attached to a decision referred to in Clause 1.5.4(b) or if, at any time prior to that date, it becomes apparent that one or more of the Conditions which remain unsatisfied will not be satisfied on or before 31 December 2004 (or such other date as is referred to in the relevant Condition), this Agreement shall be terminated:

1.5.1

the documents listed in Appendix 19 having been executed and being subject to no outstanding conditions to their coming into full force and effect other than any condition in any such document to the effect that the unconditionality of such document is dependent on the unconditionality of this Agreement or any other document listed in Appendix 19;

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

1.5.2

prior to the Restructuring Date (as such term is defined in the Standstill Agreement, but save that for the purposes of this Clause, the definition of Restructuring Date shall be deemed not to include any reference to the execution or delivery of this Agreement or any reference to the satisfaction or waiver of the conditions to the effectiveness of this Agreement) BEG(UK) not having received a notice in writing from BNFL, which notice may only be served if the terms agreed between any BEG(UK) Group Company and any of the Material Creditors, particularly with respect to the timing of any payment of any sums, taking into account the respective circumstances of BNFL and such Material Creditor, including the differing types of obligation owed by BEG(UK) Group Companies to BNFL and such Material Creditor, are no more favourable to such Material Creditor than those agreed with BNFL or, having received such a notice, such notice has been withdrawn by BNFL. BNFL shall withdraw any such notice where the relevant conditions cease to exist. For the purpose of evidencing satisfaction of this condition, BE shall:

(i)

make to BNFL full and complete disclosure as to the terms applicable to BE’s Material Creditors and HMG; and

(ii)

provide BNFL with sufficient information and data both on BE’s current financial position and on BE’s likely financial position post BE’s solvent Restructuring;

1.5.3

the entry into by BE of agreements with the Material Creditors and HMG to give effect to the terms of the Restructuring disclosed by BE to BNFL prior to or at the same time as BNFL entering into this Agreement, and such agreements not being subject to any outstanding conditions (other than any condition in any such agreement to the effect that the unconditionality of such agreement is dependent on the unconditionality of this Agreement or any other document listed in Appendix 19) and are consistent with the Heads of Terms;

1.5.4

the Commission of the European Communities (the Commission) adopting a decision or decisions under Article 88(2) of the EC Treaty that:

(a)

the Restructuring does not involve any State aid granted by or through the resources of HMG within the scope of Article 87(1) of the EC Treaty, whether to any member of the BEG(UK) Group or to any other person or undertaking; and/or

(b)

to the extent that the Restructuring does involve State aid granted by or through the resources of HMG within the scope of Article 87(1) of the EC Treaty, whether to any member of the BEG(UK) Group or to any other person or undertaking, such aid is nevertheless compatible with the common market;

1.5.5

to the extent that any modification or amendment of this Agreement or any agreement or arrangement contemplated by it is required in order for the Commission to be able to adopt a decision referred to in Clause 1.5.4(a) or a decision referred to in Clause 1.5.4(b) is adopted by the Commission subject to conditions or obligations that require the modification or amendment of this Agreement or any agreement or arrangement contemplated by it, any such modifications or amendments being reasonably acceptable in terms and in form to each of BNFL and BE; and

1.5.6

if a decision referred to in Clause 1.5.4(b) is adopted by the Commission subject to conditions or obligations, such conditions and obligations being in terms and in form reasonably acceptable to each of BE and BNFL and to the extent that such conditions or obligations must be complied with or implemented prior to the date immediately following the date upon which all the Termination Conditions have been satisfied, any such conditions or obligations having been implemented or otherwise complied with by HMG.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

1.5.7

prior to the Restructuring Date (as such term is defined in the Standstill Agreement, but save that for the purposes of this Clause, the definition of Restructuring Date shall be deemed not to include any reference to the execution or delivery of this Agreement or any reference to the satisfaction or waiver of the conditions to the effectiveness of this Agreement) BEG(UK) not having received a notice in writing from BNFL, which notice may only be served if, no appropriate assurances from HMG are existing, including arrangements having been made with the relevant BEG(UK) Group Companies and BNFL, with regards to the assumption by HMG of all liabilities associated with all Historic Spent Fuel or, having received such a notice, such notice has been withdrawn. BNFL shall withdraw any such notice where the relevant conditions cease to exist.

For the purposes of this Clause 1.5, Restructuring means the implementation of a restructuring plan intended to achieve the solvent reconstruction and long-term financial viability of the BEG(UK) Group, as described in the State aid notification made by HMG to the Commission on 7 March 2003 (the State Aid Notification) and any other matters or measures arising therefrom.

1.6 Each of the Parties undertakes to use reasonable endeavours to ensure the Conditions are satisfied as soon as reasonably practicable and in any event by 31 December 2004, or such other date as is referred to in any such Conditions.

1.7 BNFL shall be entitled in its absolute discretion, by written notice (or written notices, from time to time) to the other Parties, to waive the Conditions in Clauses 1.5.1 to 1.5.4 either in whole or in part (provided that at the same time BNFL waives the equivalent Condition (if any) in each of the agreements listed in Appendix 19).

1.8 BNFL acknowledges and agrees that it will not claim that the terms of the Standstill Agreement fail to satisfy the Condition set out in Clause 1.5.2. For the avoidance of doubt, so far as concerns the non-binding heads of terms annexed to the Standstill Agreement, this acknowledgement does not extend to any eventual arrangements other than as expressly provided in such heads of terms.

DURATION OF AGREEMENT

2.1 Subject to the satisfaction (or waiver) of the Conditions this Agreement shall take effect on 1 April 2006 and, subject to the provisions of Clauses 22 (Force Majeure), 24 (Non-Performance) and 30 (Termination and Survival), continue in force until the end of the Fuel Supply Period. For the avoidance of doubt this Agreement shall remain in force even if BEG(UK) is no longer loading Fuel of any type into any Reactor in any AGR Power Stations, provided BEG continues to load Fuel of any type into any Reactor of at least one of the BEG AGR Power Stations.

2.1A This Agreement shall not take effect in the event that the Existing Fuel Supply Agreement has terminated for any reason other than expiry of its term.

2.2 The term of the Uranic Elements Supply Component of this Agreement (the Uranics Term), shall commence on 1 April 2006 and shall continue in force until the end of the Fuel Supply Period, unless:

2.2.1

(subject to BEG(UK)’s right to terminate the Uranics Term pursuant to Clause 24.2) either BEG(UK) or BNFL gives no less than 12 months’ written notice to the other that it wishes to terminate the Uranic Elements Supply Component of this Agreement (such termination to take effect on the date specified in the relevant notice), provided that such notice shall not be given by BEG(UK) or BNFL before 1 April 2009;

2.2.2

the Uranic Elements Supply Component of this Agreement is terminated earlier pursuant to Clause 24.2; or

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

2.2.3

this Agreement is terminated pursuant to Clauses 22 or 24.1.

2.3 At the end of the Uranics Term BNFL shall, during the 12 months following the end of the Fuel Supply Period or, in the case where the Uranics Term ends prior to the end of the Fuel Supply Period, during the 12 months following the date of service of the relevant termination notice (as the case may be), take the following actions in connection with BEG(UK) taking over the Uranic Elements Supply Component of this Agreement:

2.3.1

provide to BEG(UK), at no cost to BEG(UK), all reports and supporting information, as may reasonably be requested by BEG(UK);

2.3.2

in addition to the provision of information to BEG(UK) under Clause 2.3.1, provide to BEG(UK), at no cost to BEG(UK), the services of BNFL staff involved in operating and/or administering the Uranic Elements Supply Component of this Agreement as may reasonably be requested by BEG(UK) subject to a maximum cap of three man months’ services; and

2.3.3

where BNFL is providing commercial transport services to third parties, discuss with BEG(UK) the possible provision to BEG(UK) of such services on terms to be Agreed.

2.4 At the end of the Uranics Term:

2.4.1

BNFL shall sell and BEG(UK) shall purchase the Termination A Stocks or Termination B Stocks (as the case may be);

2.4.2

BNFL shall transfer the Contracts and New Contracts to BEG(UK), or in the event that such transfer cannot be obtained, pass-through the benefit of such Contracts or New Contracts to BEG(UK); and

2.4.3

the amendments to this Agreement set out in Appendix 28 shall come into force on the date determined under Clause 2.28 (and the rest of this Agreement shall continue unaffected),

in accordance with the provisions of this Agreement.

2.5 BEG(UK) and BNFL agree that:

2.5.1

Clauses 2.6 to 2.16 (inclusive) and Clauses 2.23 to 2.36 (inclusive) will apply at the end of the Uranics Term (including where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34), except where the Uranics Term has terminated in accordance with Clause 24; and

2.5.2

Clauses 2.17 to 2.22 (inclusive) and Clauses 2.23 to 2.36 (inclusive) will apply where the Uranics Term has terminated in accordance with Clause 24 (and not where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34, in which case, Clauses 2.6 to 2.16 (inclusive) and Clauses 2.23 to 2.36 (inclusive) shall apply).

Termination A Completion

2.6 At the end of the Uranics Term (including where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34), except where the Uranics Term has terminated in accordance with Clause 24, BNFL agrees to sell and BEG(UK) agrees to purchase the Termination A Stocks, on the terms that the same covenants shall be deemed to be given by BNFL on the Initial Termination A Stocks Completion Date and the Remaining Termination A Stocks Completion Date,

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

as are implied under Part I of the Law of Property (Miscellaneous Provisions) Act 1994 (as may be modified from time to time) where a disposition is expressed to be made with full title guarantee.

2.7 The Initial Termination A Stocks Purchase Price shall be an amount determined in accordance with Part B of Appendix 31, and BEG(UK) shall pay the Initial Termination A Stocks Purchase Price to BNFL on the Initial Termination A Stocks Completion Date in accordance with the provisions of Clause 2.9.

2.8 The Remaining Termination A Stocks Purchase Price shall be an amount determined in accordance with Part D of Appendix 31, and BEG(UK) shall pay the Remaining Termination A Stocks Purchase Price to BNFL on the Remaining Termination A Stocks Completion Date in accordance with the provisions of Clause 2.10.

2.9 Initial Termination A Stocks Completion shall take place upon the Initial Termination A Stocks Completion Date. At Initial Termination A Stocks Completion:

2.9.1

BEG(UK) shall pay the Initial Termination A Stocks Purchase Price in immediately available funds to BNFL or to such person as BNFL directs in writing by transfer of funds for same day value to the account which is notified to BEG(UK) by BNFL at least 3 Working Days before the Initial Termination A Stocks Completion Date; and

2.9.2

BNFL shall Deliver the Initial Termination A Stocks to BEG(UK).

2.10 Remaining Termination A Stocks Completion shall take place upon the Remaining Termination A Stocks Completion Date. At Remaining Termination A Stocks Completion:

2.10.1

BEG(UK) shall pay the Remaining Termination A Stocks Purchase Price in immediately available funds to BNFL or to such person as BNFL directs in writing by transfer of funds for same day value to the account which is notified to BEG(UK) by BNFL at least 3 Working Days before the Remaining Termination A Stocks Completion Date; and

2.10.2

BNFL shall Deliver the Remaining Termination A Stocks to BEG(UK) and provide to BEG(UK) a confirmation from each Final Supplier that Delivery will take place upon receipt by each Final Supplier of notice from BNFL that the Remaining Termination A Stocks Purchase Price has been received from BEG(UK). In this Clause 2.10.2, Delivery is deemed to have taken place upon receipt by each Final Supplier of the notice by BNFL that the Remaining Termination A Stocks Purchase Price has been received by BNFL; and

2.10.3

BNFL shall send a notice to each Final Supplier that the Remaining Termination A Stocks Purchase Price has been received by BNFL upon receipt of the Remaining Termination A Stocks Purchase Price from BEG(UK) as referred to in Clause 2.10.1.

2.11 If on the Remaining Termination A Stocks Completion Date BNFL cannot effect Delivery of all of the Remaining Termination A Stocks:

2.11.1

BEG(UK) shall accept that proportion of those Remaining Termination A Stocks which BNFL is able to Deliver on the Remaining Termination A Stocks Completion Date, provided that (except in the event that BNFL’s inability to effect Delivery of those Remaining Termination A Stocks is solely due to the failure of BEG(UK) to maintain an Account with the Final Suppliers or other act or omission of BEG(UK)) BEG(UK) may elect not to accept any of the Remaining Termination A Stocks to the extent that BNFL is

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

unable to Deliver equal to or more than 75% of the Book Value of the Remaining Termination A Stocks on the Remaining Termination A Stocks Completion Date;

2.11.2

BEG(UK) shall pay to BNFL, on account of the Remaining Termination A Stocks Purchase Price, an amount which represents that proportion of the Remaining Termination A Stocks Purchase Price applying to the Remaining Termination A Stocks which BNFL has Delivered on the Remaining Termination A Stocks Completion Date and in respect of which BEG(UK) has not exercised its right not to accept under Clause 2.11.1; and

2.11.3

completion in respect of such of the Remaining Termination A Stocks which BNFL has not Delivered on the Remaining Termination A Stocks Completion Date will take place at such later date (the Second Remaining Termination A Stocks Completion Date) as specified by BNFL to BEG(UK) (which in any case shall be no later than one month after the Remaining Termination A Stocks Completion Date or, in the event that BEG(UK) does not have an Account at the relevant Final Supplier or an act or omission of BEG(UK), such later date as BNFL shall stipulate to BEG(UK)), on which date:

(a)

BEG(UK) shall pay to BNFL in the same manner as referred to in Clause 2.10.1 (but not subject to Clause 2.11.1) on account of the Remaining Termination A Stocks Purchase Price, an amount which represents that proportion of the Remaining Termination A Stocks Purchase Price applying to the Remaining Termination A Stocks which BNFL has Delivered on the Second Remaining Termination A Stocks Completion Date; and

(b)

BNFL shall Deliver such Remaining Termination A Stocks to BEG(UK) in the same manner as set out in Clause 2.10.2.

2.12 On or before:

2.12.1

seven Working Days after the Remaining Termination A Stocks Completion Date or the Termination B Completion Date, BNFL shall deliver to BEG(UK) a statement of Enriched UF₆ and WIP held by BNFL at Springfields; and

2.12.2

one month after the Remaining Termination A Stocks Completion Date (or if any, the Second Remaining Termination A Stocks Completion Date) BNFL shall deliver to BEG(UK) certificates from BNFL’s auditors confirming:

(a)

the level of Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date; and

(b)

the Book Value of the Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date.

2.13 If on delivery of the certificates referred to in Clause 2.12, it is established that the Remaining Termination A Stocks Purchase Price is less than the Book Value of the Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date, BEG(UK) shall pay to BNFL within seven Working Days of the date of delivery of the certificates referred to in Clause 2.12:

2.13.1

the shortfall between that portion of the Remaining Termination A Stocks Purchase Price paid on the Remaining Termination A Stocks Completion Date and the Book Value of the Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date, together with any interest thereon at the rate of 1 per cent per annum plus LIBOR

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

applying as at the Remaining Termination A Stocks Completion Date accruing on a daily basis from the Remaining Termination A Stocks Completion Date to the date of payment by BEG(UK); and

2.13.2

the shortfall between that portion of the Remaining Termination A Stocks Purchase Price paid on the Second Remaining Termination A Stocks Completion Date and the Book Value of the Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date, together with any interest thereon at the rate of 1 per cent. per annum plus LIBOR applying as at the Remaining Termination Stocks Completion Date accruing on a daily basis from the Second Remaining Termination A Stocks Completion Date to the date of payment by BEG(UK).

2.14 If on delivery of the certificates referred to in Clause 2.12, it is established that the Remaining Termination A Stocks Purchase Price exceeds the Book Value of the Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date, BNFL shall repay to BEG(UK) within seven Working Days of the date of delivery of the certificate referred to in Clause 2.12;

2.14.1

the amount by which that portion of the Remaining Termination A Stocks Purchase Price paid on the Remaining Termination A Stocks Completion Date exceeds the Book Value of the Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date, together with any interest thereon at the rate of 1 per cent per annum plus LIBOR applying as at the Remaining Termination A Stocks Completion Date accruing on a daily basis from the Remaining Termination A Stocks Completion Date to the date of payment by BNFL; and

2.14.2

the amount by which that portion of the Remaining Termination A Stocks Purchase Price paid on the Second Remaining Termination A Stocks Completion Date (if any) exceeds the Book Value of the Remaining Termination A Stocks as at the Remaining Termination A Stocks Completion Date, together with any interest thereon at the rate of 1 per cent per annum plus LIBOR applying as at the Second Remaining Termination A Stocks Completion Date accruing on a daily basis from the Second Remaining Termination A Stocks Completion Date to the date of payment by BNFL.

2.15 Title and risk to the:

2.15.1

Initial Termination A Stocks shall pass to BEG(UK) on payment of the Initial Termination A Stocks Purchase Price; and

2.15.2

Remaining Termination A Stocks shall pass to BEG(UK) on payment of the Remaining Termination A Stocks Purchase Price.

2.16 BNFL warrants to BEG(UK) that each Warranty is true, accurate and not misleading immediately before the Initial Termination A Stocks Completion Date, the Remaining Stocks Completion Date and the Second Remaining Stocks Completion Date (if any).

Termination B Completion

2.17 Without prejudice to any other rights or obligations of the parties under this Agreement, where the Uranics Term has terminated in accordance with Clause 24 (and not where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34), BNFL agrees to sell and BEG(UK) agrees to purchase the Termination B Stocks, on the terms that the same covenants shall be deemed to be given by BNFL on each of the Termination B Stocks Completion Dates, as

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

are implied under Part I of the Law of Property (Miscellaneous Provisions) Act 1994 (as may be modified from time to time) where a disposition is expressed to be made with full title guarantee.

2.18 The Termination B Purchase Price shall be an amount determined in accordance with Part E of Appendix 31, and BEG(UK) shall pay the Termination B Purchase Price to BNFL on the Termination B Stocks Completion Date in accordance with the provisions of Clause 2.20.

2.19 As soon as reasonably practicable after the date on which BEG(UK) serves notice to BNFL pursuant to Clause 24, BEG(UK) shall provide to BNFL a schedule (the Termination B Completion Schedule) which sets out the dates on which the Termination B Stocks shall be sold by BNFL and purchased by BEG(UK), the proportion of the Termination B Stocks to be sold by BNFL and purchased by BEG(UK) on such dates, and the appropriate method of charging. BNFL shall have one month in which to give notice to BEG(UK) of its acceptance or rejection of the Termination B Completion Schedule. BNFL shall be deemed to have agreed the Termination B Completion Schedule if it has not provided such notice to BEG(UK) within the one month period referred to above. BEG(UK) may reasonably request amendments to the Termination B Completion Schedule, which shall take immediate effect subject to BNFL’s prior consent (which shall not be unreasonably withheld or delayed). The dates in the Termination B Completion Schedule shall be no later than the fifth anniversary of the date of termination specified in the notice served pursuant to Clause 24. BEG(UK) and BNFL hereby recognise and agree that, notwithstanding Clause 2.4.3 and Appendix 28, in agreeing the Termination B Completion Schedule, it shall be necessary to reflect the possibility that both BEG(UK) and BNFL will be responsible for the supply of Uranic Elements for the purposes of BNFL supplying Fuel to BEG(UK) under this Agreement until the final Termination B Completion Date. In reflecting such possibility, BEG(UK) and BNFL agree that neither of them shall be disadvantaged (financially or operationally) and that the value of Uo shall remain unaltered and calculated in accordance with Appendix 21.

2.20 Termination B Completion shall take place upon each Termination B Completion Date. On each Termination B Completion Date:

2.20.1

BEG(UK) shall pay that proportion of the Termination B Purchase Price as Agreed in accordance with the Termination B Completion Schedule in immediately available funds to BNFL or to such person as BNFL directs in writing by transfer of funds for same day value to the account which is notified to BEG(UK) by BNFL at least 3 Working Days before the relevant Second Termination Completion Date;

2.20.2

in respect of the Termination B Stocks which are held by BNFL, BNFL shall Deliver the relevant portion of the Termination B Stocks to BEG(UK) in accordance with the Termination B Completion Schedule;

2.20.3

in respect of the Termination B Stocks which are held by the Final Suppliers, BNFL shall Deliver the relevant portion of the Termination B Stocks to BEG(UK) in accordance with the Termination B Completion Schedule and provide to BEG(UK) a confirmation from each Final Supplier that Delivery will take place upon receipt by each Final Supplier of notice from BNFL that the relevant proportion of the Termination B Purchase Price has been received from BEG(UK). In this Clause 2.20.3, Delivery is deemed to have taken place upon receipt by each Supplier of the notice by BNFL that the relevant portion of the Termination B Purchase Price has been received by BNFL; and

2.20.4

BNFL shall send a notice to each Final Supplier that the relevant proportion of the Termination B Purchase Price has been received by BNFL upon receipt of such proportion of the Termination B Purchase Price from BEG(UK) as referred to in Clause 2.20.1.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

2.21 Title and risk to the Termination B Stocks shall pass to BEG(UK) on payment of the relevant proportion of the Termination B Purchase Price in accordance with the Termination B Completion Schedule.

2.22 BNFL warrants to BEG(UK) that each Warranty is true, accurate and not misleading immediately before each Termination B Completion Date.

Interim pass-through of Contracts and New Contracts

2.23 Between (i) the Initial Termination A Stocks Completion Date and the Remaining Termination A Stocks Completion Date where the Uranics Term ends (including where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34), except where the Uranics Term has terminated in accordance with Clause 24; or (ii) the date of termination specified in the notice served by BEG(UK) pursuant to Clause 24 where the Uranics Term has terminated in accordance with Clause 24, and the date on which the Contracts and New Contracts are novated or passed through to BEG(UK) under the provisions of this Agreement (as the context requires):

2.23.1

BNFL agrees that it shall do each act and thing reasonably requested of it by BEG(UK) to fulfil BNFL’s obligations under this Agreement and to enforce BNFL’s rights under the Contracts and the New Contracts;

2.23.2

BNFL shall at the request of BEG(UK), sell to BEG(UK) (subject to the provisions of Part C of Appendix 31), any UOC, UF₆or Enriched UF₆purchased under the Contracts and New Contracts pursuant to Clause 2.23.1 (the BNFL Interim Sale Uranium) and BNFL shall sell any BNFL Interim Sale Uranium to BEG(UK) and BEG(UK) shall purchase any BNFL Interim Sale Uranium from BNFL, for an amount which shall be determined in accordance with the provisions of Part C of Appendix 31, on the terms that the same covenants shall be deemed to be given by BNFL in relation to any BNFL Interim Sale Uranium on Delivery as are implied under Part I of the Law of Property (Miscellaneous Provisions) Act 1994 (as may be modified from time to time) where a disposition is expressed to be made with full title guarantee. BEG(UK) shall pay the relevant amount to BNFL and the risk in and title to such BNFL Interim Sale Uranium will transfer upon payment by BEG(UK) to BNFL of the amount referred to above on account of the purchase price of such BNFL Interim Sale Uranium.

2.24 BEG(UK) shall indemnify and hold harmless BNFL at all times against all and any losses, liabilities, costs (including legal costs), damages, expenses, actions, proceedings, claims, demands and awards that may be incurred by BNFL to the extent the same arises as a result of BEG(UK)’s requests to BNFL under Clause 2.23.1 but not to the extent that the same is a result of fraud, wilful default, bad faith or negligence on the part of BNFL.

2.25 BNFL shall indemnify and hold harmless BEG(UK) at all times against all and any losses, liabilities, costs (including legal costs), damages, expenses, actions, proceedings, claims, demands and awards incurred by BEG(UK) to the extent the same arises as a result of BNFL’s failure to comply with BEG(UK)’s reasonable requests to BNFL under Clause 2.23.1, but not to the extent that the same is a result of fraud, wilful default, bad faith or negligence on the part of BEG(UK).

Novation of the Contracts and New Contracts

2.26 At the end of the Uranics Term:

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

2.26.1

BNFL shall seek the consent of each Final Supplier to the disclosure of the Contracts and New Contracts to BEG(UK) and shall provide the Contracts and New Contracts to BEG(UK) immediately upon receiving such consent.

2.26.2

subject to the provisions of Clause 2.26.3, each of BEG(UK) and BNFL agrees to enter into a Novation and Amendment Deed with each Final Supplier, subject only to such amendments as BNFL may consent to (which consent shall not be unreasonably withheld or delayed), and BEG(UK) and BNFL agree to use all reasonable endeavours to procure that each Final Supplier enters into a Novation and Amendment Deed on, or as soon as reasonably practicable after, the date of expiry or earlier termination of this Agreement or the Uranics Term (as the case may be) as referred to in this Clause 2.26.

2.26.3

BNFL shall not be obliged to consent to the inclusion in a relevant Novation and Amendment Deed of any such amendment as is referred to in Clause 2.26.2 to the extent that to do so would impose any greater liability on BNFL under the relevant Novation and Amendment Deed than would be the case if that Novation and Amendment Deed were not to contain the proposed amendment.

2.26.4

BNFL shall introduce BEG(UK) to the Final Suppliers and use all reasonable endeavours to arrange a meeting (or meetings, as necessary) between itself, BEG(UK) and each Final Supplier to discuss the proposed novation of the relevant Contract or New Contract and such amendments as BEG(UK) proposes to the relevant Novation and Amendment Deed in accordance with Clauses 2.26.2 and 2.26.3.

2.26.5

during such discussions, BEG(UK) shall:

(a)

act reasonably and shall not permit the outcome of its discussions with each Final Supplier to prejudice its obligations under Clause 2.26.2; and

(b)

in the event that BNFL is unable to attend any such meeting or meetings, BEG(UK) shall keep BNFL regularly informed (on a reasonable basis having regard to any relevant confidentiality restrictions) of the progress of its discussions with each Final Supplier related to the relevant agreement.

2.26.6

The Effective Date of each Novation and Amendment Deed shall be either:

(a) the Remaining Termination A Stocks Completion Date, where the Uranics Term ends (including where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34), except where the Uranics Term has terminated in accordance with Clause 24; or

(b) the date which is the later of:

(i)

3 months after the date of termination specified in the notice of termination pursuant to Clause 24; and

(ii)

the date on which the condition precedent in clause 2.1 in that Novation and Amendment Deed is satisfied,

where the Uranics Term has terminated in accordance with Clause 24,

as the context requires. BEG(UK) and BNFL shall, after the date referred to above in this Clause 2.26, use reasonable endeavours to seek the consent of the Euratom Supply Agency

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

to each Novation and Amendment Deed in accordance with the provisions of Clause 2.1 of each Novation and Amendment Deed.

Pass-through of the Contracts and New Contracts if novation cannot be effected

2.27 In the event the consents of the Final Suppliers to the novation of any of the Contracts or New Contracts has not been obtained or novation of any of the Contracts or New Contracts cannot be effected prior to (i) the Remaining Termination A Stocks Completion Date where the Uranics Term ends (including where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34), except where the Uranics Term has terminated in accordance with Clause 24, or (ii) 3 months after the date of termination of the Uranics Term specified in the relevant termination notice pursuant to Clause 24, as the context requires (such agreements to be defined as the BNFL Pass-Through Contracts):

2.27.1

From the date specified in this Clause 2.27 above until the expiry or early termination of each relevant BNFL Pass-Through Contract:

(a)

BNFL agrees to provide BEG(UK) with such information in relation to each BNFL Pass-Through Contract as BEG(UK) reasonably requests (subject to any relevant confidentiality restrictions);

(b)

(subject to Clause 2.27.4) BNFL agrees that it shall do each act and thing reasonably requested of it by BEG(UK), to enable the performance of each BNFL Pass-Through Contract and to enforce its rights under the BNFL Pass-Through Contracts;

(c)

BNFL agrees to transfer title to any UOC, UF₆or Enriched UF₆acquired by BNFL pursuant to the BNFL Pass-Through Contracts to BEG(UK) immediately upon title to such material transferring from the relevant Final Supplier to BNFL, and BEG(UK) shall pay to BNFL the price paid by BNFL for such UOC, UF₆or Enriched UF₆; and

(d)

the risk in any UOC, UF₆or Enriched UF₆ purchased by BNFL on BEG(UK)’s instructions will pass to BEG(UK) immediately upon the risk thereon passing to BNFL in accordance with the provisions of the relevant BNFL Pass-Through Contract.

2.27.2

BEG(UK) shall indemnify and hold harmless BNFL at all times against all and any losses, liabilities, costs (including legal costs), damages, expenses, actions, proceedings, claims, demands and awards incurred by BNFL to the extent the same arises as a result of:

(a)

BEG(UK)’s requests to BNFL under Clause 2.27.1(b); or

(b)

the failure of BEG(UK) to comply with BNFL’s requests to BEG(UK) under Clause 2.27.4,

but not to the extent that the same is a result of fraud, wilful default, bad faith or negligence on the part of BNFL.

2.27.3

BNFL shall indemnify and hold harmless BEG(UK) at all times against all and any losses, liabilities, costs (including legal costs), damages, expenses, actions, proceedings, claims, demands and awards incurred by BEG(UK) to the extent the same arises as a result of:

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

(a)

the failure or inability of BNFL to provide information in relation to the BNFL Pass-Through Contracts as required under Clause 2.27.1(a); or

(b)

BNFL’s failure to comply with BEG(UK)’s requests to BNFL under Clause 2.27.1,

but not to the extent that the same is a result of fraud, wilful default, bad faith or negligence on the part of BEG(UK).

2.27.4

If necessary, BEG(UK) shall (to the extent it is able) do each act and thing reasonably requested of it by BNFL to enable the performance of each BNFL Pass-Through Contract.

BEG(UK) taking up Uranic Elements Supply Component of this Agreement

2.28 The amendments to this Agreement set out in Appendix 28 shall come into force on either:

2.28.1

the Remaining Termination A Stocks Completion Date where the Uranics Term ends (including where the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34), except where the Uranics Term has terminated in accordance with Clause 24; or

2.28.2

(subject to Clause 2.19) the date which is the later of:

(a)

3 months after the date of termination specified in the notice of termination pursuant to Clause 24; and

(b)

the date on which the condition precedent in clause 2.1 in that Novation and Amendment Deed is satisfied,

where the Uranics Term has terminated in accordance with Clause 24,

as the context requires.

Indemnity

2.29 BEG(UK) and BNFL declare that they each agree that the transaction contemplated by this Clause 2 does not constitute the transfer of an undertaking for the purpose of the Transfer of Undertakings (Protection of Employment) Regulations 1981 (as may be modified from time to time) (the Employment Regulations) and that, accordingly, the contracts of employment of the Employees (as defined in Clause 2.30 below) together with all rights powers duties and liabilities in respect of the Employees shall not pass to BEG(UK) by virtue of the transactions contemplated by this Clause 2.

2.30 BNFL shall indemnify BEG(UK) from and against any liabilities incurred by BEG(UK) by virtue of the operation of the Employment Regulations which are attributable to the termination or dismissal by BNFL prior to the close of business on the date on which the last portion of the Termination A Stocks or Termination B Stocks (as the case may be) is transferred by BNFL to BEG(UK) under this Clause 2 (the Relevant Date) of the employment of any employee or former employee of BNFL (the Employees). Those liabilities shall include any liability for unfair dismissal compensation, statutory redundancy pay and any contractual severance pay, increased pension costs, pay in lieu of any period of notice, and pay in respect of accrued holiday.

2.31 All amounts payable to or in relation to the Employees by BNFL in respect of the period to the close of business on the Relevant Date shall be discharged by BNFL and BNFL shall indemnify BEG(UK) against any liabilities which BEG(UK) may incur arising out of or in connection with such amounts. Amounts

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

payable under this Clause shall include wages and salaries, overtime, bonus or commission (earned but unpaid), expenses, accrued holiday pay, season ticket or other loans, income tax, national insurance contributions, pension contributions and premiums in respect of life assurance, private medical and permanent health insurance schemes.

2.32 BNFL shall indemnify BEG(UK) from and against any liabilities incurred by BEG(UK) which are attributable to any act or omission by BNFL prior to the close of business on the Relevant Date in respect of any of BNFL’s obligations or duties to or in relation to any of the Employees. This shall include any liability arising out of the termination or dismissal of any Employee.

2.33 BNFL shall indemnify BEG(UK) in respect of any awards, losses, damages, costs, liabilities and expenses (including legal expenses) that may be incurred by BEG(UK) and which arise from a failure on the part of either BEG(UK) or BNFL to comply with its obligation to inform and/or consult with Employees and/or any other affected employees and/or their representatives pursuant to Regulation 10 of the Employment Regulations.

2.34 BNFL shall use all reasonable endeavours to ensure that no such liability as is referred to in any of Clauses 2.30, 2.31, 2.32 and 2.33 arises prior to the Relevant Date by reassigning Employees to alternative duties where possible.

2.35 In the event that any Employee or any other employee asserts or establishes that his employment has transferred to BEG(UK) pursuant to the Employment Regulations as a result of this Agreement BNFL shall within 7 days of being so informed either by that individual or by BEG(UK) (whichever is the earlier) offer employment to that individual on terms and conditions which are the same in all material respects as that individual’s current terms and conditions of employment and in the event that (a) such an offer is not made within that 7-day period or (b) such an offer is made and not accepted by that individual then BEG(UK) shall be entitled to terminate that individual’s employment and BEG(UK) shall be indemnified by BNFL in respect of all and any awards, losses, damages, costs, liabilities, expenses and legal fees which it may sustain arising under or in connection with that individual’s contract of employment and/or the termination of his or her employment.

Value added tax

2.36 If value added tax is chargeable on the sale of the Stocks, BEG(UK) shall against delivery of tax invoices in respect of the Stocks, pay the amount of value added tax in addition to the relevant price.

[NOT USED]

SUPPLY

4.1 During the Fuel Supply Period BNFL shall sell and BEG(UK) shall purchase from BNFL Fuel required for the operation of the AGR Power Stations, which shall:

4.1.1

be within the relevant quantity ranges and supplied to a programme described in Clause 7; and

4.1.2

be to the specifications and designs described in Clause 6.

4.2 During the Uranics Term, BNFL shall provide Uranic Elements together with Incidental Services (as defined in Appendix 18, part C) for the purposes of the manufacture and delivery of Fuel to AGR Power Stations.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

4.3 All Uranium Material delivered to BEG(UK) pursuant to this Agreement shall be free from all Security Interests.

4.4 BEG(UK) and BNFL agree that the Uranics Review Board established and operated under the Existing Fuel Supply Agreement shall continue to exist and operate under this Agreement in the manner described in Appendix 23.

4.5 With respect to the final Security of Supply Policy:

4.5.1

BEG(UK) and BNFL agree that the final Security of Supply Policy being complied with in accordance with Clause 4.2A of the Existing Fuel Supply Agreement shall continue to apply in respect of the first Year under this Agreement. Thereafter, BEG(UK) shall develop a draft Security of Supply Policy for Enriched Uranium Material in accordance with (but not necessarily limited to) the items listed in Appendix 22. The draft Security of Supply Policy shall be reviewed and finalised by the Uranics Review Board in accordance with the provisions of Appendix 24.

4.5.2

The outcome of the final Security of Supply Policy will include (but not be limited to) the following:

(a)

Stock Cover measured in forward months’ Fuel requirements (n forward months);

(b)

Forward Contract Cover expressed in a proportion of years of future Fuel requirements; and

(c)

such other policy issues as may be deemed necessary by the Uranics Review Board.

4.6 On or before the last Working Day in April in each relevant Year and following the finalisation of the final Security of Supply Policy in accordance with the provisions of Appendix 24, BNFL shall deliver to the Uranics Review Board, for its information only, a copy of its Stock and Procurement Strategy. BNFL will develop its Stock and Procurement Strategy in accordance with the provisions of Appendix 25 to achieve the requirements of the final Security of Supply Policy.

4.7 Having regard to the final Security of Supply Policy BNFL shall, in executing its procurement obligations to BEG(UK) in accordance with the Stock and Procurement Strategy:

4.7.1

use all reasonable endeavours to achieve the lowest possible cost at which it obtains Uranic Elements; and

4.7.2

take into account the items listed in Appendix 22, and in particular:

(a)

existing Contracts (including any options available under such Contracts);

(b)

available BNFL contracts and options;

(c)

market conditions; and

(d)

other available sources of supply of Uranium Material.

4.8 During the Fuel Supply Period:

4.8.1

BNFL shall provide to BEG(UK):

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

4.8.1.1

within 7 days of the end of each Quarter, a statement, in the form of Appendix 9 (an Enriched Uranium Statement (WIP)), of the Enriched Uranium Material (other than the allowance for Process Losses) held at Springfields for the purpose of supplying Fuel to BEG(UK) under this Agreement.

4.8.1.2

by 30 April, 31 July and 31 January in each Year, a statement, in the form of Appendix 5 (an Enriched Uranium Breakdown Statement), giving a breakdown of Enriched Uranium Material held at Springfields for the purpose of supplying Fuel to BEG(UK) under this Agreement. BEG(UK) recognises that the breakdowns will constitute BNFL’s best estimate of the stock position. The statements provided on 30 April, 31 July and 31 January shall relate to the position on the preceding 31 March, 30 June and 31 December, respectively.

4.8.1.3

by 31 October in each Year, a uranium breakdown statement, in the form of Appendix 6 (an Enriched Uranium Breakdown Statement (PIV)), based on the September Physical Inventory Verification audit carried out by Euratom on behalf of the International Atomic Energy Agency.

4.8.2

BEG(UK) and BNFL shall meet regularly to exchange information conducive to the smooth running of this Agreement. Either BNFL or BEG(UK) shall have the right to call for a meeting and shall give the other, unless otherwise Agreed, at least three weeks’ notice of such a meeting. Such information shall include (but shall not be limited to) the following:

(a)

production programmes for BEG(UK) products;

(b)

notification of possible BNFL supply difficulties;

(c)

BEG(UK)’s predictions of Fuel requirements;

(d)

BEG(UK)’s future requirements for Fuel design changes;

(e)

quality assurance related matters;

(f)

copies of bid evaluations undertaken by BNFL in respect of the procurement of Uranic Elements;

(g)

details of inventory levels and forward contract cover for Uranic Elements;

(h)

in the event that BEG(UK) becomes aware of a Reactor Failure exceeding three months in duration, BEG(UK) shall advise BNFL in writing of the expected duration of the Reactor Failure. If the expected duration of the Reactor Failure advised in accordance with this Clause 4.8.2(h) changes then BEG(UK) shall advise BNFL of such revised period. In the event that the Reactor Failure exceeds three months then BEG(UK) shall advise BNFL in writing as soon as reasonably practicable thereafter of the exact duration of the Reactor Failure once the relevant Reactor has recommenced generating electricity. The provision of information by BEG(UK) relating to a Reactor Failure under this Clause 4.8.2(h) shall be subject to BEG(UK)’s obligations under the rules of any stock or investment exchange, or any other law or regulation to which BEG(UK) is subject at any time;

(i)

summaries of the material terms and conditions of each New Contract and New Uranics Commitment; and

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

(j)

such other information as may be reasonably requested by BEG(UK) relating to any matter in respect of BNFL’s procurement of Uranic Elements under this Agreement.

For the avoidance of doubt such information exchange shall in no way prejudice the operations, terms and conditions contained elsewhere in this Agreement.

4.9 If the total level of Uranium Material expressed as UOC, Conversion Services and Enrichment available for BEG and BEG(UK) combined is below, for a period of three consecutive months [ ]* multiplied by the Fuel requirements for BEG and BEG(UK) combined for “n” forward months, where “n” has been decided in accordance with Clause 4.5.2 (the Shortfall Level):

4.9.1

BEG(UK) may request BNFL in writing to procure sufficient Uranium Material to increase the level of Uranium Material above the Shortfall Level as soon as reasonably practicable and in any event within six weeks from receipt of BEG(UK)’s request by BNFL;

4.9.2

any costs (including but not limited to the cost of procuring such Uranium Material) incurred by BNFL in procuring such Uranium Material shall be borne by BNFL; and

4.9.3

if BNFL fails to procure sufficient Uranium Material in accordance with Clauses 4.9.1 and 4.9.2, BEG(UK) may give notice to BNFL that it will procure Uranium Material on its own account for delivery to Springfields, in which case BNFL shall reimburse BEG(UK)’s reasonable and direct costs in accordance with Clause 5.16 provided always that BEG(UK) exercises such right with reasonable skill and diligence.

4.10 On or before:

4.10.1

the last Working Day in November in each year preceding the relevant Year, BNFL shall provide to BEG(UK) a report (the Market Report) containing an overview of the market based upon publicly available trade publications and information of which BNFL has become aware in performing its obligations under this Agreement so as to assist BEG(UK) in its development of the draft Security of Supply Policy. BNFL shall also provide a quarterly review of the Market Report to BEG(UK) on or before the last Working Day in each of February, May and August in each relevant Year to the extent that such review identifies material changes which have occurred or, to the best knowledge of BNFL, may occur in relevant markets, or more frequently if such changes are of immediate significance in relation to the final Security of Supply Policy;

4.10.2

the last Working Day of each relevant Year, BNFL shall deliver to BEG(UK) the risk catalogue (the Risk Catalogue) setting out an overview of and BNFL’s opinions on, macro industry risk factors which could have a material adverse effect on either the final Security of Supply Policy or the Stock and Procurement Strategy. BNFL shall also update the Risk Catalogue in the event there is a material change in the risks referred to in the Risk Catalogue. BNFL shall also undertake a quarterly review of the Risk Catalogue and deliver this review to BEG(UK) on or before the last Working Day in each of February, May and August in each relevant Year;

4.10.3

the last Working Day in December in each year preceding each relevant Year, BNFL shall provide to BEG(UK) a report (the Portfolio Management Report) containing information regarding the items listed in Appendix 27). The purpose of the Portfolio Management Report is to provide BEG(UK) with information for its internal business planning;

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

4.10.4

the last Working Day of each calendar month in each relevant Year, BNFL shall provide to BEG(UK) an update (the Monthly Update to the Portfolio Management Report) to the information set out in the relevant Portfolio Management Report, which shall contain the information set out in Appendix 27.

4.11 BNFL shall not enter into a New Contract or New Uranics Commitment:

4.11.1

with a value (calculated by deriving the sum of all years of the contract by multiplying the annual base quantity of the contract for each year of the contract by the base price for that year, and factoring this by the relevant exchange rate if necessary, or if the price is market based, by multiplying the total base quantity of the contract for all years of the contract by the relevant market price at the time of submission, and factoring this by the relevant exchange rate if necessary) exceeding [ ]*; or

4.11.2

with any other member of the BNFL Group or any company in which a member of the BNFL Group has the ability to exercise or right to obtain direct or indirect control over that company’s affairs, in particular (without prejudice to the generality of the foregoing) the possession or entitlement to acquire 30% or more of the voting shares in that company,

without the prior written consent of BEG(UK) (such consent not to be unreasonably withheld or delayed).

4.12 The parties shall use reasonable endeavours to agree a basis for the use of the uranium recovered from the reprocessing of BEG(UK)’s Irradiated Fuel Elements.

4.13 With respect to the Initial Stocks, BNFL warrants to BEG(UK) that each Warranty is true, accurate and not misleading as of 1 April 2006.

4.14 On or before one month after 1 April 2006, BNFL shall deliver to BEG(UK) certificates from BNFL’s auditors confirming (i) the level of Initial Stocks as at 1 April 2006 and (ii) that the book value of the Initial Stocks is equal to the price paid by BNFL for the Initial Stocks.

4.15 If, on delivery of the certificate referred to in Clause 4.14, it is established that the book value of the Initial Stocks is not equal to the price paid by BNFL for the Initial Stocks, the book value of the Initial Stocks to be used in calculating Uo in accordance with Appendix 18 Part C shall be adjusted accordingly as of 1 April 2006. If at such time BNFL has already submitted an invoice to BEG(UK) in respect of April 2006 pursuant to Clause 5.15.1.2(a), BNFL shall re-calculate the amount payable in respect of Uo in respect of April 2006 using such adjusted book value of the Initial Stocks, and, at least 6 Working Days before the payment date indicated in the original invoice in accordance with Clause 5.15.1.2, shall render to BEG(UK) an adjusting invoice or credit note, as the case may be, equal in value to the difference between such re-calculated Uo and the Uo that was originally invoiced by BNFL. Where BNFL issues an adjusting invoice, BEG(UK) shall pay such adjusting invoice at the same time as it pays the original invoice in accordance with Clause 5.15.1.2. Where BNFL issues a credit note, BEG(UK) shall set off such credit note against the amount payable under the original invoice in accordance with Clause 5.15.1.2.

CHARGES, INVOICING AND PAYMENT

5.1 Charges for Fuel Elements (other than Instrumented Fuel) of Existing Designs on the Approved Product List within the quantity range described in Clause 7.1 shall comprise the following charging components: a fixed annual component (Ao) and a variable component (Bo) as specified in Appendix 18 and, during the Uranics Term, a further variable uranics component (Uo), together with variable components

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

covering incidental services (Vo), administration charge (Wo) and a fixed service charge (Xo) which are specifically set out in Appendix 18. Ao, Bo, Vo and Xo are subject to Escalation from 1 July 2002 or Financial Year 2003 or January 2003, as appropriate, in accordance with the formulae set out in Appendix 7 and shall cover all the costs and liabilities associated with providing the said Fuel Elements (including, for the avoidance of doubt, those associated with the manufacture, storage and transport, decommissioning, treatment and disposal of all Waste) except where specifically provided for elsewhere in this Agreement or other Agreements with BEG(UK).

5.2 During the Fuel Supply Period charges for Fuel Elements of new designs, for quantities outside the range described in Clause 7.1 and for changes in Fuel orders referred to in Clause 7.2 will be Agreed pursuant to Clauses 6 and 7.

5.3 In respect of the supply of Ancillary Components from 1 April 2006 for the duration of this Agreement pursuant to Clause 2.1, the charges shall be in accordance with Appendix 12. These charges shall be amended in accordance with the criteria laid down in Appendix 12.

5.4 [Not Used]

5.5 [Not Used]

5.6 [Not Used]

5.7 [Not Used]

5.8 [Not Used]

5.9 [Not Used]

5.11 [Not Used]

5.12 [Not Used]

5.13 [Not Used]

5.14 [Not Used]

5.15.1

BNFL shall invoice BEG(UK) and BEG(UK) shall pay BNFL in respect of Fuel delivered pursuant to Clause 12.8 or consigned to the Central Store pursuant to Clause 11 as follows:

5.15.1.1

BEG(UK) shall pay to BNFL on the first Working Day of each month an instalment of one twelfth of the annual charge (Ao) payable for the year in which that month occurs PROVIDED THAT BNFL has invoiced BEG(UK) for such instalment no later than 38 days prior to the end of the month preceding the month in which the instalment is due to be paid.

5.15.1.1.1

If an accurate value for the annual charge (Ao) is not available, then BEG(UK) shall pay to BNFL on the first Working Day of each month an instalment of one twelfth of the estimated annual charge (Aoest) calculated in accordance with Appendix 18 payable for the Year in which that month occurs PROVIDED THAT BNFL has invoiced BEG(UK) for such instalment no later than 38 days prior to the end of

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

the month preceding the month in which the instalment is due to be paid.

5.15.1.1.2

Any difference between the actual value of the annual charge (Ao) and the estimated annual charge (Aoest) will be reconciled in accordance with Appendix 7.

5.15.1.2

BNFL shall submit invoices to BEG(UK) on or before the last Sunday of the month for:

(a)

the per Fuel Element charges (Bo, Uo and Vo) in respect of each Fuel Element delivered, together with charges in respect of Wo and Xo during the month to which the invoices relate; and

(b)

the Ancillary Component charge referred to in Clause 5.3 (and such invoices will include copies of supplier invoices demonstrating the Buying-in Price of Externally Sourced Components procured) and any charges arising pursuant to Clause 5.2;

in respect of Fuel deliveries during the month to which the invoices relate and BEG(UK) shall pay the said invoices on or before the twentieth Day of the following month or the first Working Day thereafter.

5.15.2

If any Fuel delivered pursuant to Clause 12.8 or consigned to store pursuant to Clause 11 is established after payment therefor not to conform to the Contract Specification it shall be deemed not to have been delivered or consigned and the price therefor shall be credited to BEG(UK) and set-off against the invoices subsequently due for payment until such credit is utilised in full.

5.16 Where appropriate under this Agreement, BEG(UK) shall invoice BNFL for the sums due. Payment shall be due on the twentieth day of the month following the date of the invoice or the first Working Day thereafter.

5.17 All references to invoices in this Clause 5 are to tax invoices within the meaning of Part III of the Value Added Tax Regulations 1995.

5.18 All sums payable by a Party under this Agreement are exclusive of any applicable value added tax which shall be additionally payable by that Party together with the sum in question.

5.19 If a Party fails to pay on the due date any amount which is payable to the other hereunder then without prejudice to any other rights the Party so owed may have, that amount shall bear interest from the due date until payment is made to that Party (both before or after any judgement) at 2% per annum over the average LIBOR prevailing from the date the debt fell due to be paid until the date of actual payment thereof.

5.20 In the event of a dispute between BEG(UK) and BNFL relating to any charges or other sums invoiced by BNFL under this Agreement, BEG(UK) shall, if so requested by BNFL, pay to BNFL on a provisional basis the undisputed amount of any such invoice or invoices. On resolution of the dispute, any overpayment by BEG(UK) or underpayment to BNFL, as the case may be, in respect of any such invoice or invoices, shall bear interest at the average LIBOR prevailing from the date payment was made or the date payment should have been made, whichever is the earlier, until the date of repayment by BNFL or further payment by BEG(UK) whichever is appropriate. Such payment or repayment date shall not be more than 21 days after the date of settlement of the said dispute.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

5.21 [Not Used]

5.22 BNFL shall at no cost to BEG(UK) be responsible for:

5.22.1

the Decommissioning of all facilities and equipment used to provide and/or manufacture directly or indirectly the supply of Fuel to BEG(UK) and the treatment and disposal of all wastes arising.

5.22.2

for treatment and disposal of all Waste.

FUEL SPECIFICATION AND DESIGN

6.1 All Fuel shall be manufactured and supplied in accordance with the Contract Specification, which Contract Specification, together with any revisions thereto Agreed, shall be made available as controlled copies to BNFL by BEG(UK). All proposals relating to Fuel design that have potential implications for safety and performance and/or for acceptance of Fuel which is not fully compliant with the requirements of the Contract Specification must be submitted by BNFL to BEG(UK). The authority within BEG(UK) accountable for assessment of such proposals is the Director of Engineering (the Design Authority). The authority within BNFL accountable for decisions taken by BNFL pursuant to this Clause 6, resides with the Product Design Manager (the Fuel Designer).

6.2 The Contract Specification is set out in Appendix 3.

6.3 Both BEG(UK) and BNFL shall be entitled to propose changes (change being defined in section 3 of the Contract Specification) to the Fuel design, manufacturing specifications or process routes in respect of any proposed changes to the Fuel design, manufacturing specifications or process routes (whether at Springfields or at its subcontractor’s premises), which change may result in Fuel which would deviate from the Contract Specification. BNFL shall maintain an auditable procedure to manage the said changes. Within this system, BNFL shall review changes proposed by BEG(UK) or BNFL to establish their acceptability or otherwise. BNFL shall act reasonably in deciding whether a proposed change is acceptable. Proposed changes which are acceptable to BNFL shall be categorised by BNFL in line with the requirements of the Contract Specification and as follows:

Category A:

A minor change, defined as one having no impact on any of the functional performance of the Fuel, the Fuel safety case or the overall Fuel quality.

Category B:

A major change, defined as one having an impact or potential impact on any one (or more) of the Fuel functional performance, the Fuel safety case and the overall Fuel quality.

The staff authorised for the above mentioned review and categorisation of changes shall be competent and such competence shall be demonstrable through BNFL’s quality assurance procedures as referred to in Clause 9.1 and Appendix 8.

6.4 Full records relating to changes and to decisions on categorisation shall be retained by BNFL in accordance with the Agreed records schedule as referred to in Paragraph 8 of Appendix 8 and shall be available for review or audit pursuant to Clause 6.7 at Springfields by BEG(UK) in order for it to be satisfied that BNFL is acting in a proper and responsible manner.

6.5 All Category B changes shall be submitted in writing to BEG(UK) for its approval prior to implementation by BNFL. BNFL shall not implement a Category B change without the said approval of BEG(UK) in writing. BNFL shall provide supporting information as reasonably required by BEG(UK) for it to arrive at an informed decision on whether or not to approve the Category B changes. All said approvals

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

or rejections shall be made in writing. BEG(UK) shall use reasonable endeavours to effect a timely response. BNFL shall confirm in respect of any change that, immediately following such change and thereafter, Fuel Elements will be (i) acceptable for Reprocessing, and (ii) based on the best understanding at the time of such change, acceptable for long term storage of irradiated Fuel Elements. Any change that is implemented by BNFL shall be deemed to have been approved by BNFL.

6.6 BNFL shall maintain a list of all proposed and implemented Category A and B changes, (i.e. changes classified pursuant to Clause 6.3 by suitably qualified and authorised persons) together with those intended changes formally proposed for approval and which are under consideration and submit it to BEG(UK) monthly or as mutually Agreed. Assessment of each Category A change will be completed and details thereof submitted to BEG(UK) prior to the first scheduled delivery date for Fuel affected by the change. For the avoidance of doubt, it shall be BNFL’s responsibility to satisfy itself that each and every proposed Category A change has been properly assessed pursuant to Clause 6.3 prior to the delivery of any Fuel subject to such change. In the event that Fuel subject to any Category A change is delivered to BEG(UK) and BEG(UK) for any reason considers the change or change categorisation to be unacceptable, then such Fuel shall be deemed non-compliant with the Contract Specification.

6.7 BEG(UK) shall have the right to:

6.7.1

undertake surveillance of manufacturing processes at Springfields and/or at BNFL’s subcontractors’ premises for the purpose of making an informed decision on whether or not to approve Category B changes and to confirm that the procedures in place for reviewing, categorising and implementing changes are satisfactory and being worked to. Such surveillance shall not be exercised in an unreasonable manner and shall be limited to those plants and processes relevant, in the reasonable opinion of BEG(UK), to the change. Surveillance of subcontractors shall be undertaken only in conjunction with BNFL staff and to the extent that BNFL is able to secure such access with its suppliers. In cases where BNFL does not have contractual right of access to suppliers, it shall use all reasonable endeavours to secure such access for BEG(UK), and shall use all reasonable endeavours to ensure that such rights are incorporated into its contracts with suppliers on contract review; and

6.7.2

audit the systems in place at BNFL for the purpose of reviewing, categorising and notifying BEG(UK) of any proposed or implemented changes. Such audit shall include but not be limited to confirmation that the staff employed in making decisions on BNFL’s behalf are competent to do so.

Such rights are without prejudice to BEG(UK)’s existing contractual rights of access to BNFL and its subcontractors.

6.8 In the event that such surveillance/audit shows in BEG(UK)’s reasonable opinion that BNFL is not acting in accordance with the procedures, including BNFL’s quality assurance procedures, as referred to in Clause 9.1 and Appendix 8, BNFL, BEG(UK) and where appropriate BEG shall forthwith, consult to agree corrective actions and the timescale for implementation to ensure compliance as soon as reasonably practicable. In respect of any changes implemented prior to the said audit which in BEG(UK)’s reasonable opinion render the Fuel non-conformant (as defined in Paragraph 10(a) of Appendix 8), BEG(UK) shall have the right to reject any affected Fuel and BNFL shall identify and bond such Fuel (and any affected Fuel components) at Springfields pending resolution of the issue. No further changes shall be implemented until BEG(UK) is satisfied that adequate procedures have been implemented.

6.9 In the event of a proposed change to the Contract Specification, the Party requesting the change shall make available all relevant information to the other to enable it to make an informed decision.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

6.10 In the event that BEG(UK) can demonstrate to BNFL’s reasonable satisfaction that any changes adopted pursuant to this Clause 6 do or will result in the discharge burn-ups above the design Fuel ▇▇▇▇▇▇▇▇ mean irradiation referred to in Clause 13.3.3 not being achieved or do or will result in any reduction in Reactor performance or the ability to handle Fuel or any adverse impact on the safety case, then:

6.10.1

if the said change were a Category A change, BNFL shall, at its own cost, amend or reverse such change to result in the said deficiencies being rectified; and

6.10.2

if the said change were a Category B change, BNFL and BEG(UK) shall amend or reverse such change to result in the said deficiencies being rectified, the cost of such amendment or reversal to be borne:

(a)

by BNFL to the extent that any such deficiency arose due to any failing in an assessment, carried out by or on behalf of BNFL, of the impact of such change; and

(b)

by BEG(UK) to the extent that any such deficiency arose due to any failing in an assessment, carried out by or on behalf of BEG(UK), of the impact of such change.

In the event that any such change as aforesaid is amended or reversed, all Fuel manufactured by BNFL prior to such amendment or reversal shall be, or be deemed to be, capable of having Standard Services or Storage Services (as defined in the Historic Spent Fuel Agreement as the case may be, carried out on such Fuel for the purpose of both the Historic Spent Fuel Agreement and the New Spent Fuel Agreement.

Both BNFL and BEG(UK) shall use reasonable endeavours to assist each other to achieve the least cost solution in the case of any of the above.

6.11 New Fuel designs may be added to and obsolete Fuel designs may be removed from the Approved Product List, and enrichment levels may be altered on the Approved Product List, on terms and conditions to be Agreed. Such terms and conditions shall include, without limitation, Agreement on a new Contract Specification for the new Fuel designs. In reaching agreement on new Fuel designs, BNFL and BEG(UK) follow the procedures set out in Clause 6.12 and Appendix 17. Drawings on the Approved Product List may be amended at the request of BEG(UK) on terms and conditions to be Agreed.

6.12 If BEG(UK) requests a new Fuel design pursuant to Clause 6.11, BNFL shall, as soon as reasonably practicable and in consultation with BEG(UK), propose a costed development programme, a timescale for introduction and a best estimate of the charge for supplying Fuel of the requested new design. The proposed development costs will be as Agreed, whether in terms of the Technical Services Agreement or otherwise, and will be subject to audit (if required by BEG(UK)) by the auditors of BEG(UK) in order to verify the costs associated with the development programme. Immediately following completion of the development programme, BEG(UK) and BNFL shall Agree a charge for the new Fuel which shall take into account the said estimated charge together with the implications for costs of Fuel to the new design arising from the development programme. The timescale for supply of Fuel to the new design shall be as soon as reasonably practicable.

6.13 To assist in Fuel design and Reactor operation, BEG(UK) and BNFL agree to exchange certain technical information as follows:

6.13.1

BEG(UK) will accept from BNFL any reasonable request for PIE data and, as a minimum, it will make available at no charge PIE and Fuel performance information reasonably required by BNFL to meet its obligations during the Fuel Supply Period. In addition, BEG(UK) will grant BNFL facilities to discuss the programme for the said PIE.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

6.13.2

BNFL will accept from BEG(UK) any reasonable request for Fuel manufacturing data and materials property data and, as a minimum, it will make available at no charge any Fuel manufacturing and materials property data reasonably required by BEG(UK) for the purposes of Fuel development and PIE activities. In addition, BNFL shall grant to BEG(UK) facilities to discuss detailed drawings, material and other specifications and processes and shall provide BEG(UK) with copies of drawings and other information that BEG(UK) can reasonably demonstrate are necessary for the safe and efficient operation of its AGR Power Stations.

6.13.3

BNFL will notify BEG(UK) if it intends to undertake post storage examination of irradiated Fuel and will provide BEG(UK) with the results of any such examination.

6.14 Wherever in this Clause 6 there is a provision for BNFL and BEG(UK) to Agree on a charge or any other matter (other than a functional specification) and they fail to Agree, the said charge or other matter shall be settled in accordance with Clause 28.

ORDERING PROCEDURE

7.1 Subject to Clauses 7.2, 7.3, 7.5 and 22 of this Agreement and to Clauses 7.2, 7.3, 7.4, 7.5, 7.7 and 21 of the BEG Agreement, the total combined quantity of Fuel required by BEG(UK) under this Agreement and BEG under the BEG Agreement for any twelve month period of the Fuel Supply Period will be within the range of 2850 to 6100 Fuel Elements inclusive together with associated Ancillary Components.

7.2 The terms of this Agreement apply to Fuel requirements within the ranges defined in Clause 7.1. However, BNFL will endeavour subject to available manufacturing capacity to comply with any request for supplies outside the defined range subject to agreement as to charges, which said charges shall be demonstrably fair and reasonable, for additional quantities or reduced take.

7.3 Notwithstanding the provisions of Clause 7.1 but subject to the provisions of Clause 22:

7.3.1

if any Reactor is temporarily taken out of commission or cannot be refuelled for a continuous period of six months or more BEG(UK) shall not be obliged to order Fuel which is not required as a result of such outage and the Fuel requirements ranges specified in Clauses 7.1 shall be reduced pro rata at BEG(UK)’s option for so long as such Reactor remains out of commission or cannot be refuelled; or

7.3.2

if, for any other reason, it is likely that BEG(UK)’s actual Fuel requirements will be outside the then applicable ranges specified in Clause 7.1 for a period of not less than two years, the said Fuel requirements range shall be varied at BEG(UK)’s option for so long as it deems necessary.

7.3A It is recognised by both BEG(UK) and BNFL that BEG(UK) may desire additional services related to Fuel as a result of the closure of AGR Power Stations or BEG AGR Power Stations.

7.3A.1 For the period during which BEG(UK) and/or BEG are loading Fuel into either Reactor of four or more of the AGR Power Stations or the BEG AGR Power Stations, if requested by BEG(UK), BNFL agrees to provide services related to Fuel required as a result of the closure of AGR Power Stations or BEG AGR Power Stations (such as the decommissioning of surplus Fuel stocks, the refurbishment of surplus Fuel stocks at each AGR Power Station closure, the long term provision of Packaging for storage and return of surplus Fuel or the storage of surplus Fuel), subject to BEG(UK) and BNFL Agreeing the terms and conditions for such services;

7.3A.2 For the period during which BEG(UK) and/or BEG are loading Fuel into either Reactor of three, two or one of the AGR Power Stations or the BEG AGR Power Stations, the Joint Study

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Team shall make recommendations as to the provision of services related to Fuel by BNFL to BEG(UK) required as a result of the closure of AGR Power Stations or BEG AGR Power Stations;

7.3A.3 For the period during which BEG(UK) and BEG have ceased operating all Reactors of all of the AGR Power Stations and all of the BEG AGR Power Stations, if requested by BEG(UK), BNFL agrees either:

(a)

to provide services related to Fuel required as a result of the closure of AGR Power Stations or BEG AGR Power Stations subject to BEG(UK) and BNFL Agreeing the terms and conditions for such services; or

(b)

if BNFL is unable to provide such services, to provide access and rights for BEG(UK) to use BNFL intellectual property and such AGR-specific equipment needed to perform services related to Fuel required as a result of the closure of AGR Power Stations or BEG AGR Power Stations as BNFL has available at such time, subject to BEG(UK) and BNFL Agreeing the terms and conditions for such access to intellectual property and equipment (including, if appropriate, the terms of purchase or lease of such intellectual property and equipment);

PROVIDED that the terms and conditions to be Agreed in accordance with Clause 7.3A.1 and 7.3A.3 shall include a reasonable profit margin for BNFL and that, if requested by BEG(UK), BNFL shall procure that BNFL’s auditors shall certify to BEG(UK) that the information provided pursuant to Clause 4.14 (including information as to the allocation of overheads (including whether such allocation was made according to throughput or manpower) was prepared in accordance with applicable standards, principles and practice generally accepted in the United Kingdom; PROVIDED FURTHER that no Agreement under this Clause 7.3A as to terms and conditions shall be subject to the provisions of Clause 28.

7.4 BEG(UK) will place firm orders for Fuel on a monthly basis no later than the third Week of the seventh month preceding the delivery thereof, on condition that:

7.4.1

the Fuel is on the Approved Product List;

7.4.2

the total requirement is within the defined range in the twelve month period ending with that order; and

7.4.3

BEG(UK) shall confirm prior to the date the delivery is due to take place, as referred to in Clause 12.1, any changes to burnable poison cable requirements for said delivery in accordance with Appendix 15.

7.4.4

BEG(UK) shall provide on a monthly basis coincident with Fuel ordering, forecasts of the Fuel requirements for such a period that a combination of forecasts and firm orders are provided for the higher of 12 months and (n+3) months. The forecasts shall as a minimum detail BEG(UK)’s Fuel requirements by Assay on a monthly basis. BEG(UK) shall use reasonable endeavours to ensure that the forecasts accurately reflect its expected Fuel requirements.

7.4.5

BNFL shall place orders for Uranic Elements in accordance with contractual notice periods to ensure that Uranium Material is available to make deliveries of Fuel Elements as required by BEG(UK).

7.4.6

For the purpose of the supply of Uranium Material, the forecast described in this Clause 7 will be considered fixed and firm.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

7.4.7

After the end of each month, BNFL will prepare a forecast of Stock Cover values for the following 12 months, using material delivery data from firm orders placed with suppliers and the latest Fuel order forecast from BEG(UK) provided pursuant to this Clause 7.

7.4.8

Should the value of the Stock Cover forecast at the end of the first month of the forecast exceed the Stock Cover Trigger, to the extent that the resulting increase is due to a reduction in BEG(UK)’s Fuel order for that first month of the forecast from the BEG(UK) Fuel forecast given for the same month 12 months previously, BEG(UK) agrees to purchase from BNFL Enriched Uranium Material with a book value equal to the amount by which the value of the Stock Cover forecast exceeds the Stock Cover Trigger. For the avoidance of doubt, the total such excess shall be purchased by BEG under the BEG Agreement and BEG(UK) under this Agreement combined, and the respective portions of such total excess to be purchased by BEG and BEG(UK) shall be decided jointly between BEG and BEG(UK).


7.4.9	(a)	The purchase price for such Enriched Uranium Material shall be calculated in accordance with paragraph 1 of Appendix 21 and invoiced in accordance with Clause 5.15.1.2 and shall be treated as Uo for the purposes of invoicing and payment.

	(b)	Title to all material purchased by BEG(UK) in accordance with this Clause 7.4.9 shall pass to BEG(UK) on the first Working Day of the month following the month of the relevant forecast. For the avoidance of doubt, all risk in the material shall remain with BNFL until risk in the relevant Fuel passes to BEG(UK) pursuant to Clause 12.7.

	(c)	BNFL shall not utilise any Enriched Uranium Material purchased by BEG(UK) pursuant to this Clause 7.4.9 without the prior consent of BEG(UK) (such consent not to be unreasonably withheld or delayed). In the event BNFL wishes to utilise Enriched Uranium Material pursuant to this Clause 7.4.9(c), BNFL shall purchase such material from BEG(UK) and BEG(UK) shall sell such material to BNFL. In no event shall BEG(UK) be obliged to sell more material to BNFL than BEG(UK) has purchased pursuant to Clause 7.4.9(a).

	(d)	BNFL shall use reasonable endeavours to repurchase the relevant Enriched Uranium Material before taking delivery of additional Enriched Uranium Material under the Contracts or any New Contract.

7.5 BNFL agrees to consider requests for changes to Fuel orders placed pursuant to Clause 7.4 and will endeavour to comply with such requests on terms to be Agreed.

7.6 During October of each Year of the Fuel Supply Period, BEG(UK) shall, on a non-binding basis, provide an estimate of its requirements for the period beginning the following October and extending over the lifetime of each station. Such estimate will show:

7.6.1

for the first twelve months estimated detailed requirements on a month by month basis of Fuel (types and Assays) and Ancillary Components; and

7.6.2

for the remainder of the period overall annual requirements of Fuel Elements.

7.7 Wherever in this Clause 7 there is a provision for the Parties to Agree on a charge or any other matter and the Parties fail to Agree, the said charge or other matter shall be settled in accordance with Clause 28.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

7.8 The Parties will use their reasonable endeavours to reduce the timescales referred to in Clause 7.4 and will establish a joint working group to promote the efficient operation of their relationship.

WARRANTY

8.1 BNFL shall provide Fuel which is free of defective materials and workmanship and in accordance with the Contract Specification and the quality assurance arrangements in Appendix 8. BNFL undertakes to maintain control of its manufacturing processes.

8.2 The warranties set forth in this Clause 8 are in lieu of all other warranties whether statutory, express or implied including all warranties of merchantability and fitness for a particular purpose and all warranties arising from a course of dealing or usage of trade.

8.3 If BEG(UK) wishes to transfer title in any Fuel delivered hereunder to any third party (other than BEG while BEG is still a BEG(UK) Group Company), it shall obtain for BNFL written assurances from the transferee of limitation of and protection against liability following the proposed transfer at least equivalent to that afforded BNFL under the provisions of this Agreement. In the event of a transfer contrary to the provisions hereof, in addition to any other legal or equitable rights of BNFL, BEG(UK) shall indemnify BNFL against any liabilities incurred by BNFL in excess of those that would have been incurred had no such transfer taken place. Any transfer of title from BEG(UK) to BEG while BEG is still a BEG(UK) Group Company shall be treated as a delivery from the Central Store to a BEG AGR Power Station pursuant to Appendix 16 and therefore the relevant remedies, warranty and limitation of liability provisions of the fuel supply agreement relating to the Fuel in question will be those contained in the fuel supply agreement of the party taking ultimate delivery to its advanced gas-cooled reactor power station.

QUALITY ASSURANCE

9.1 Appendix 8 describes the quality assurance procedures established by BNFL which meet the applicable requirements of BS-EN-ISO 9000-2000 and BS-EN-ISO 14001 and which will be implemented for the performance of this Agreement.

9.2 BEG(UK) and BNFL agree to a review of the existing management arrangements for ensuring quality with a view to improving the efficiency of working between BEG(UK) and BNFL whilst not compromising current levels of Fuel quality. This Clause shall not apply to the Uranic Elements Supply Component of this Agreement.

9.3 Without prejudice to the provisions of Clause 8, BNFL shall give to representatives of BEG(UK) (but subject, in the case of an agent appointed by BEG(UK) after the date hereof, to the execution of a confidentiality undertaking in a form reasonably satisfactory to BNFL) the facilities described in Appendix 8 in order that BEG(UK) may satisfy itself regarding the implementation of BNFL’s quality assurance procedures and the related maintenance of the standard of inspection and quality control referred to in Appendix 8 and the keeping of adequate records.

9.4 If any of the representatives of BEG(UK) reasonably believe that any Fuel Element or Ancillary Component does not comply with the appropriate Contract Specification and or the said quality assurance procedures they shall inform BNFL and BNFL shall take such steps as are necessary to ensure compliance.

10.

PACKAGING

10.1 Subject to Clause 10.3, BNFL shall, without additional charge to BEG(UK), provide such Packaging as may be required for the proper and safe transport and storage of Fuel.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

10.2 The Packaging shall remain the property of BNFL and when empty and not required for the return of faulty or damaged Fuel Elements or Ancillary Components in pursuance of Clauses 13.1 and 13.2 shall be returned to BNFL in good condition.

10.3 If the return of the Packaging is delayed beyond six months from the date of its arrival at an AGR Power Station or from the due date of such arrival, whichever is the later, BNFL shall, after consultation with BEG(UK), purchase additional Packaging, in so far as it is necessary to meet the requirements of this Agreement and BEG(UK) shall pay to BNFL the cost of such additional Packaging, which Packaging shall remain the property of BNFL.

11.

STORAGE

11.1 BEG(UK) shall provide a suitable store at each AGR Power Station for the storage of Fuel under such conditions as are not likely to impair the quality. BEG(UK) shall grant to BNFL reasonable facilities at mutually convenient times to inspect the store to ensure that the provisions of this Clause have been and are being observed.

11.2 BNFL agrees to store during the Fuel Supply Period as requested by and on behalf of BEG(UK) Fuel Elements in accordance with the terms laid down in Appendix 16.

11.3 If at any time during the Fuel Supply Period BEG(UK) requests BNFL to store Fuel in excess of the maximum quantity specified in Appendix 16, BNFL shall provide accommodation suitable for the storage of said Fuel on its own premises if BNFL determines that suitable accommodation is available. Charges for such storage pursuant to this Clause 11.3 shall be Agreed from time to time and be demonstrably fair and reasonable to both parties.

11.4 In respect of Fuel stored pursuant to Clauses 11.2 and 11.3 BNFL shall take all reasonable steps to ensure the safe custody of such Fuel in storage. BNFL shall be liable for all injury or damage arising from any occurrence involving nuclear matter but subject thereto shall not be liable for any loss or damage to the said Fuel, howsoever caused (other than by reason of the negligence or wilful default of BNFL, its servants or agents). The containers shall be suitably and sufficiently marked by BNFL to indicate that the Fuel therein is the property of BEG(UK) and BNFL shall grant to BEG(UK) reasonable facilities to carry out such periodical sample inspection of the containers as may be agreed.

11.5 In the second Week of each month BNFL shall provide a statement of Fuel held in store on BEG(UK)’s behalf pursuant to Clauses 11.2 and 11.3 as of the last Day in the preceding month. The said statement shall be in the form to be Agreed between BEG(UK) and BNFL.

11.6 Where Fuel Elements are returned to BNFL under Clauses 13.1.1 or 13.1.2, BNFL shall store the said Fuel Elements until actions to rectify the Fuel or recover the uranium from the Fuel Elements are initiated. Such storage shall be in addition to that provided for in Clause 11.2.

12.

TRANSPORT AND DELIVERY

12.1 Subject to Clauses 12.1.1, 12.1.2 and 12.1.3, BNFL shall deliver Fuel in accordance with the Monthly delivery schedules for each AGR Power Station for each Year during the Fuel Supply Period, as specified in the plan set out in Appendix 10.

12.1.1

BNFL may at any time give at least one month’s notice that delivery cannot be made on the scheduled Day and provide in such notice at least two alternative days for such delivery to take place within two Weeks of the scheduled Day. In such case, BEG(UK) may accept delivery on any

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

one of the said alternative days or at its option postpone such delivery until the scheduled delivery Day in the following Month.

12.1.2

BEG(UK) may at any time give at least one month’s notice that delivery cannot be made on the scheduled Day and provide in such notice at least two alternative days for such delivery within two Weeks of the scheduled day. In such case BNFL may deliver on any one of the said alternative days or at its option postpone such delivery until the scheduled delivery Day in the following Month.

12.1.3

BEG(UK) and BNFL may Agree a revised delivery date in any Month for their mutual convenience.

As soon as reasonably practicable and from time to time during the Fuel Supply Period, BEG(UK) and BNFL shall review the provisions of this Clause 12.1 in order to permit flexible delivery patterns consistent with all of BEG(UK)’s AGR Power Station requirements, minimisation of BNFL costs and any related joint improvement activities.

12.2 Notwithstanding the provisions of Clause 11.3, BEG(UK) shall not be liable to pay any storage charges and notwithstanding the provisions of Clause 12.4 BNFL shall not be liable to pay liquidated damages arising from the postponed delivery of Fuel in accordance with Clause 12.1.

12.3 BNFL acknowledges that failure to make a delivery of Fuel which meets the provisions of Clause 8.1 to BEG(UK) on time in accordance with this Agreement could cause BEG(UK) substantial losses as a result of the delay or loss of use including, without limitation, generation losses. BEG(UK) and BNFL agree that the liquidated damages set out in Clause 12.4 are a pre-estimate of the minimum extent of loss likely to be incurred by BEG(UK) in the event of a failure by BNFL to deliver on time and as aforesaid.

12.4 Subject to Clause 12.2, if any deliveries of Fuel (other than Ancillary Components referred to in Clause 12.5) are made more than two Weeks after the due delivery date in accordance with Clause 12.1 or if Fuel delivered does not meet the provisions of Clause 8.1 for any reason other than the default of BEG(UK), its servants or agents and subject always to Clause 22 BNFL will pay BEG(UK) liquidated damages for each Week or part thereof beyond the due date that such Fuel delivery is delayed or for each Week or part thereof from notification of any failure to meet the provisions of Clause 8.1 until such failure is remedied in accordance with Clause 13.1 for the first 16 Weeks of any delay or loss of use. This Clause 12.4 shall not apply in the event that, and to the extent that, BNFL demonstrates to the reasonable satisfaction of BEG(UK) that its inability to deliver Fuel to BEG(UK) is solely and directly caused by the forecasts provided by BEG(UK) pursuant to Clause 7.4.4 resulting in insufficient Enriched UF₆being available for the manufacture of Fuel for delivery to BEG(UK) in accordance with this Agreement.

12.4.1

In respect of each Fuel Element at a rate of £128.74 per Fuel Element.

12.4.2

In respect of each Ancillary Component at a rate of £64.37 per Ancillary Component.

Thereafter, BNFL will pay an additional sum so that the total liquidated damages paid (i) for Ancillary Components is equivalent to the total price of such Ancillary Components and (ii) for Fuel Elements is equivalent to an amount calculated in accordance with the formula below:

where:

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Z =

total liquidated damages payable;

D =

quantity of BEG(UK) Fuel Elements delayed or not delivered in accordance with the provisions of Clause 8.1;

R =

combined requirements in Fuel Elements for BEG(UK) and BEG for the Year in which the said due delivery date falls; and

Bo, A1 and D2 are as defined in Appendix 18.

12.5 In respect of each Ancillary Component referred to below for which delivery is delayed beyond 16 Weeks of the due delivery date pursuant to Clause 12.1 or for which rectification is delayed beyond 16 Weeks of the date of notification of any failure to meet the provisions of Clause 8.1, BNFL shall pay BEG(UK) as liquidated damages an amount equal to the total charge for that Ancillary Component:

All Ancillary Components for which the charge does not exceed £1,500.

12.6 All liquidated damages payable pursuant to this Clause 12 shall be Escalated from 1 July 2002 until the month in which such liquidated damages become due in accordance with the formula set out in Appendix 7.

12.7 Delivery of the Fuel together with any Packaging shall be effected on the passage of each consignment in through the gates of the appropriate AGR Power Station. Property and risk in the Fuel and risk in any Packaging shall pass to BEG(UK) at whichever is the earlier of the following events:

12.7.1

the delivery of the Fuel as aforesaid; or

12.7.2

the marking of the containers in accordance with Clause 11.4 (subject to the provisions as to nuclear liability described therein); or

12.7.3

the delivery of the Fuel to the Central Store provided always that risk therein shall revert to BNFL when the Fuel is removed from storage for transport to the relevant AGR Power Station and shall finally pass to BEG(UK) pursuant to Clause 12.9.1 and that risk in any Fuel stored by BNFL which is potentially or proves to be not in compliance with Clause 8.1 shall revert forthwith to BNFL until compliance with Clause 8.1 is Agreed.

12.8

BNFL shall be responsible for:

12.8.1

the transport of the Fuel to the Central Store;

12.8.2

the transport of Packaging to Springfields in pursuance of Clause 10.2;

12.8.3

the transport of faulty or damaged Fuel to Springfields in pursuance of Clauses 13.1 and 13.2;

12.8.4

certification that items delivered from Springfields to AGR Power Stations including but not limited to Fuel and its Packaging shall be clean and decontaminated in accordance with the applicable International Atomic Energy Agency transport regulations;

12.8.5

providing the necessary clearances and documentation for Fuel transport containers to enable BEG(UK) to act as consignor for unirradiated Fuel (including faulty and damaged Fuel) from AGR Power Stations; and

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

12.8.6

insurance of the Fuel and Packaging during any transport pursuant to this Clause 12.8.

12.8.7

ensuring that suitable security measures are in place in accordance with BNFL policy; to demonstrate to BEG(UK) that the said BNFL policy complies with the Security Regulations in force from time to time the regulations may be amended from time to time; and to advise BEG(UK) of any changes in said BNFL policy.

12.9

BEG(UK) shall be responsible for:

12.9.1

off-loading the packed containers into the store as soon as possible after the arrival of each consignment;

12.9.2

loading empty Packaging for transport to Springfields;

12.9.3

packing and loading faulty or damaged Fuel for transport to Springfields; and

12.9.4

certification that items returned from AGR Power Stations to Springfields including but not limited to Fuel and its Packaging shall be clean and decontaminated in accordance with the applicable International Atomic Energy Agency transport regulations.

Risk in the items specified in Clauses 12.9.2 and 12.9.3 shall revert to BNFL when the vehicle carrying them passes out through the gates of the appropriate AGR Power Station.

12.10 If any container on arrival at the store referred to in Clause 11.1 is found to have sustained visible damage, BEG(UK) shall inform BNFL of such damage within three working days of the arrival of the container. The container shall be set aside in the store and as soon as practicable thereafter, shall be opened in the presence of a representative nominated by BNFL for the purpose and its contents inspected jointly with a representative nominated by BEG(UK) to assess the extent of the damage.

12.11 All containers which have not sustained any visible damage shall, except for such periodical sample inspection as may be Agreed, be left closed (excluding opening for the purposes of a Euratom inspection) in the said store except when it is necessary to prepare the Fuel immediately before loading into a Reactor or, after written notice to BNFL, immediately before testing any plant. If any Fuel Element or Ancillary Component is, in the opinion of BEG(UK), not in accordance with the Contract Specification when it is being prepared for loading, BEG(UK) shall inform BNFL within three Working Days of forming that opinion and shall set aside such Fuel Element or Ancillary Component suitably packed in a container for joint inspection as soon as possible to establish whether or not it complies with the Contract Specification and, if not, in what way it does not comply.

12.12 The preparation of Fuel for loading into a Reactor shall be carried out by and at the expense of BEG(UK) at the appropriate AGR Power Station. BEG(UK) shall give to authorised representatives of BNFL such facilities as may be Agreed in order that BNFL may satisfy itself regarding the standards adopted by BEG(UK) in carrying out such preparation but BNFL shall have no responsibility for any damage to the Fuel which may occur during such preparation unless caused or contributed to as a result of the negligence or wilful default of BNFL its servants or agents or failure of the Fuel to meet the Contract Specification.

13.

FAULTY FUEL

13.1 If, as soon as reasonably practicable, before irradiation BEG(UK) demonstrates or BNFL advises that any Fuel Element or Ancillary Component does not comply with the Contract Specification unless such non-compliance is caused by the negligence or wilful default of BEG(UK), its servants or agents or as a

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

result of deterioration of the Fuel resulting from storage at BEG(UK) sites after unpacking then unless BEG(UK) grants approval to accept said non-conforming Fuel under a concession pursuant to Paragraph 10 of Appendix 8, BNFL shall at its discretion, and as soon as reasonably practicable, either:

13.1.1

rectify the Fuel Element or Ancillary Component either at Springfields or, subject to BEG(UK)’s approval, at the relevant AGR Power Station. All such rectification shall be in conformance with the quality assurance arrangements specified in Appendix 8 or such other arrangements as may be approved by BEG(UK) in such a manner so that it complies with the Contract Specification; or

13.1.2

replace the Fuel Element or Ancillary Component provided that it has been returned to BNFL;

and subject to Clause 13.4 shall bear the cost of rectification or replacement as the case may be including any uranic recovery costs PROVIDED THAT, subject to the consent of BEG(UK), BNFL may, in respect of any Fuel Element or Ancillary Component returned to them under this Clause and instead of the alternatives set out in Clauses 13.1.1 and 13.1.2, credit with a sum which shall, in the case of a Fuel Element, take into account the charge which would have been payable for and appropriate to the Fuel Element if it had been due for delivery on the date on which it was so returned (including all charges associated with the supply of Uranic Elements by BNFL to BEG(UK)) or, in the case of an Ancillary Component, take into account the charge which would have been payable for the Ancillary Component if it had been due for delivery as aforesaid. For the avoidance of doubt BNFL shall be responsible for the recovery of the Enriched UO2 content of the Fuel so affected including any Process Losses and shall carry out such recovery in a timely manner. If for reasons solely attributable to BNFL, BNFL does not recover the Enriched UO2 content of the Fuel it shall reduce the quantity of Stock Cover by such amount.

In the event that BNFL elects to rectify or replace Fuel as specified in Clauses 13.1.1 and 13.1.2, it shall be deemed not to have been delivered until such rectification or replacement has been carried out and the Fuel delivered to BEG(UK). Accordingly, the provisions of Clause 12.7 shall apply. For the avoidance of doubt, when such Fuel is replaced by BNFL, BNFL shall not invoice BEG(UK) and BEG(UK) shall not be required to pay to BNFL, Uo or Vo in respect of such Fuel, except in the case of Uo and Vo applying to differences in the uranium weight of the returned Fuel and the replacement Fuel. Where the uranium weight of the returned Fuel is different from the uranium weight of the replacement Fuel, Uo and Vo shall apply to such difference.

13.2 BNFL will take all reasonable steps to rectify, if so requested by BEG(UK), any Fuel Element or Ancillary Component which has been damaged in the course of handling by BEG(UK). The terms and conditions of acceptance for rectification and the charge thereof and associated costs of transport and insurance shall be agreed. Any Fuel Element or Ancillary Component accepted by BNFL for rectification under this Clause shall be returned to BNFL suitably packed by BEG(UK).

13.3 If, during the irradiation of Fuel in a Reactor or in the two Years following its removal from the Reactor, BEG(UK) or BNFL has cause to believe that Fuel does not comply with the Contract Specification, then that Party shall inform the other Party of this as soon as is reasonably practicable, and after consultation, BEG(UK) shall take such actions as BEG(UK) deems necessary to minimise the cost to BEG(UK) of such non-compliance and the following shall apply:

13.3.1

If pursuant to Clause 13.3 BEG(UK) and BNFL cannot agree that such failed Fuel is non-compliant then the following shall apply: BEG(UK) shall provide to BNFL evidence of non-compliance of Fuel with the Contract Specification and BEG(UK) and BNFL shall Agree on the extent of the deviation from the Contract Specification. If BEG(UK) and BNFL cannot Agree that the Fuel does not comply with the Contract Specification or the extent of a deviation therefrom, BEG(UK) and BNFL shall have the option to have PIE carried out on any such Fuel to ascertain whether the Fuel

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

meets the Contract Specification or in the case of a deviation, the extent of that deviation. The Party exercising the option shall be responsible for the costs of the said PIE unless the results support the case of that Party in which instance the other Party shall pay.

13.3.2

Whenever there is a deviation from the Contract Specification, BEG(UK) and BNFL shall agree a factor F which shall determine the allocation to BNFL of responsibility for deterioration in Fuel performance taking into account the relative contribution to the deterioration of any deviation from the Contract Specification and any effects attributable to the Reactor in which the Fuel was irradiated being either shutdown or operated both in a manner which could not have reasonably been anticipated by BNFL at the time the Fuel was manufactured to meet the Contract Specification.

13.3.3

If BEG(UK) discharges any Fuel from a Reactor consequent upon a deviation from the Contract Specification, BNFL shall credit BEG(UK) with a sum which for each Fuel ▇▇▇▇▇▇▇▇ discharged, shall be calculated in accordance with the following formula:

R = P x A x F

where

R = sum credited

P = (P₁ + P₂) where

P₁ = Bo as defined in Appendix 18 and Escalated in accordance with the formula set out in Appendix 7 to the month of discharge multiplied by the number of Fuel Elements in the Fuel ▇▇▇▇▇▇▇▇;

P₂ = the price paid by BEG(UK) for Ancillary Components associated with the discharged Fuel ▇▇▇▇▇▇▇▇, where BEG(UK) can reasonably demonstrate that such Ancillary Components cannot be re-used;

A = IF - IA

IF = design Fuel ▇▇▇▇▇▇▇▇ mean irradiation, which shall be the lesser of 35GWd/tU and the mean Fuel ▇▇▇▇▇▇▇▇ irradiation that would have been achieved had failure not occurred;

IA = actual Fuel ▇▇▇▇▇▇▇▇ mean irradiation achieved on discharge;

F = responsibility factor determined in Clause 13.3.2.

13.3.4

In addition, BNFL shall at no cost to BEG(UK) reprocess or store a quantity of Fuel (Q) in respect of each of the aforementioned discharged Fuel Stringers calculated in accordance with the following formula:

Q = T x A x F

Where T = total quantity of Fuel in each discharged Fuel ▇▇▇▇▇▇▇▇.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Such reprocessing or storage under this Clause 13 by BNFL shall be undertaken in accordance with the terms and conditions of (a) the Historic Spent Fuel Agreement, for any Historic Spent Fuel or (b) the New Spent Fuel Agreement, for any New Spent Fuel.

13.3.5

If in the event of a non-compliance with the Contract Specification Fuel is not discharged, but BEG(UK) incurs costs in consequence of the said non-compliance, then BNFL will credit BEG(UK) with a sum equal to that incurred by BEG(UK) but not greater than R where R is calculated by the formula in Clause 13.3.3 except that IA = actual irradiation of Fuel affected by deviation from the Contract Specification at the date of notification of deviation and Bo is Escalated from 1 July 2002 in accordance with the formula set out in Appendix 7 to the month of notification of the said non-compliance.

13.3.6

If the Parties fail to agree on a matter to which this Clause 13.3 relates, it shall be settled in accordance with Clause 28.

Fuel which fails in service shall be deemed non-compliant with the Contract Specification and the factor F (set out in Clause 13.3.3) shall have the value of 1, provided that BEG(UK) has provided to BNFL evidence that such Fuel has not been subject to abnormal stresses in the Reactor. The said evidence shall be based on performance analysis of operational data (but for the avoidance of doubt shall not require BEG(UK) to submit such Fuel to Post Irradiation Examination) and must show, inter alia, that any failed Fuel has not been over pressurised as a result of increased fission gas release within its Fuel pins.

13.4 Subject to Clause 13.5 BNFL shall bear BEG(UK)’s reasonably demonstrable direct costs arising as a result of any non-compliance with the Contract Specification as specified in Clauses 13.1 and 13.3.5 and Paragraph 10 of Appendix 8. Such costs shall include, but not be limited to, the costs of technical evaluation of the non-compliant Fuel, preparation of reports and modification proposals and their independent nuclear safety assessment under the Nuclear Site Licence Condition compliance arrangements and where appropriate processing concession applications pursuant to and in accordance with Appendix 8.

13.5 The liability of BNFL in relation to any direct costs incurred by BEG(UK) as specified in Clause 13.4 shall not exceed £59,881 in any one Year, said sum to be subject to Escalation from July 2002. For the avoidance of doubt the claims brought by BEG(UK) against BNFL under this Agreement shall have priority in the order in which they are lodged.

14.

OPERATING RECORDS

14.1

BEG(UK) shall keep adequate records to enable:

14.1.1

the date of loading into and of discharge from a Reactor of Fuel to be established;

14.1.2

the isotopic composition of Irradiated Fuel Elements to be calculated by an Agreed method; and

14.1.3

the operating conditions of the Fuel to be established during the period of irradiation commencing on the date of loading for all purposes in connection with Clause 13.

BEG(UK) shall pursuant to Clause 6.13.1 grant BNFL reasonable access to such records and the data from which they were compiled and shall accord BNFL reasonable facilities to discuss such records and data with BEG(UK) and to observe the methods and equipment used by BEG(UK) in handling Fuel at each of the AGR Power Stations. The exercise by BNFL of the right to observe the said methods and equipment shall not imply its acceptance or approval of the said methods and equipment.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

14.2 Maintenance of, and access to, the records relating to Fuel shall be governed in accordance with Appendix 8.

15.

EFFICIENCY AND EFFECTIVENESS

BEG(UK) and BNFL have Agreed a number of areas related to the supply of Fuel where they consider that there is the potential opportunity for further efficiency improvements and cost savings, which together with the indicative probabilities, timescales for implementation, estimated cost savings and obligations of BEG(UK) and BNFL are set out in Appendix 14 hereto. BEG(UK) and BNFL recognise that achieving the same is in some cases dependent upon the co-operation of BEG. BEG(UK) and BNFL anticipate that further such opportunities for efficiency improvements and cost savings may arise over the term of this Agreement. BEG(UK) and BNFL undertake to work together in good faith on a continuous basis to identify, develop and exploit any such opportunities and BNFL agrees to give to BEG(UK) an appropriate share of the benefit of all such efficiency improvements and cost savings.

The provision of this Clause 15 shall not apply to the Uranic Elements Supply Component of this Agreement except where:

(a)

they relate to proposed changes to all or part of the Uranic Elements Supply Component of this Agreement which could have an impact on all or part of the process of manufacturing of Fuel Elements by BNFL; or

(b)

they relate to proposed changes to all or part of the process of manufacturing of Fuel Elements by BNFL which could have an impact on all or part of the Uranic Elements Supply Component of this Agreement.

16.

[NOT USED]

17.

NON-STANDARD URANICS

17.1 From time to time, BNFL has potential opportunities to purchase uranic materials with specifications out with the ASTM specifications which may potentially satisfy BEG(UK)’s specifications for use in BEG(UK)’s Reactors, inasmuch as the specification falls within that historically provided through enriching Magnox depleted uranium. BEG(UK) and BNFL agree to assess the use of such non-conformant uranic materials for BEG(UK)’s Fuel Elements and to use reasonable endeavours to agree a revised specification or to authorise the use of the existing specification for use of such Fuel Elements in BEG(UK)’s Reactors. The revised specification will include a range of tolerances to allow uranic material between the existing specification and the revised specification to be used, always provided that the Fuel Elements so delivered will have no detrimental effect on performance, financial or otherwise.

17.2 The benefits of using non-standard Uranics will be shared between BEG(UK) and BNFL as described in Appendix 17.

17.3 [Not Used]

18.

LIABILITY FOR LOSS OR DAMAGE

18.1 In respect of Non-Nuclear Risks BNFL shall have no responsibility for any damage to any property or for any Third Party Risk or any other loss which may be attributable wholly or in part to any Fuel Element, Ancillary Component or Packaging after the delivery thereof to BEG(UK) pursuant to Clause 12.8 unless due to the fault or deficiency of BNFL.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

18.2 In respect of Non-Nuclear Risks, BEG(UK) shall have no responsibility for any damage to any property or for any Third Party Risk or any other loss which may be attributable wholly or in part to any Fuel Element, Ancillary Component or Packaging before the delivery thereof by BNFL pursuant to Clause 12.8 or any such item returned to BNFL pursuant to Clause 13.1 or 13.2, unless due to the fault or deficiency of BEG(UK).

18.3 Notwithstanding the generality of Clause 18.1, it is Agreed that BNFL shall have no responsibility for any damage to any Reactor or for any damage to any other property of BEG(UK) or third party claim as a consequence of damage to a Reactor which may be attributable wholly or in part to any Fuel Element or Ancillary Component supplied under this Agreement.

18.4 Notwithstanding any other provision of this Agreement, in respect of damage or injury to any person or property arising out of or resulting from ionising radiations or contamination by radioactivity, the liability of the Parties shall be governed by the Nuclear Installations Acts 1965, as amended. For the avoidance of doubt, Clauses 11.4 and 12.8 shall constitute written agreements to accept liability pursuant to section 12(3A) of the Nuclear Installations ▇▇▇ ▇▇▇▇, as amended.

19.

LIMITATION OF LIABILITY

19.1 (Without prejudice to BEG(UK)’s obligations to make payments to BNFL under Clauses 2.13, 2.24 and 2.27.2, or BNFL’s obligations to make payments to BEG(UK) under Clauses 2.14, 2.25 and 2.27.3), the liability of BNFL and BEG(UK) (and BE for the purposes of Clauses 1.6, 20, 22 and 35) to the other whether in contract or in tort (including negligence or otherwise) arising out of or in connection with the performance or non performance of its obligations under this Agreement shall be limited as follows:

19.1.1

liability for incidental, special, indirect or consequential loss or damage (even if the possibility of any such loss or damage is known to the Parties) is excluded, including but not limited to that arising from loss of use of equipment or power generating systems or cost of capital, loss of profits or revenues or the loss of use thereof provided always that the liability in respect of the latter three specifically identified instances of loss shall not hereby be excluded where such loss flows as a direct loss from a relevant breach of contract or a relevant act or default;

19.1.2

liability of BNFL to BEG(UK) arising from or in connection with BEG(UK)’s contractual liability to third parties in respect of the sale or supply of electricity is excluded; and

19.1.3

liability for economic loss in tort (including negligence or otherwise) is excluded.

19.2 BNFL’s total cumulative liability for any failure to deliver Fuel on time or for any defective Fuel shall in respect of claims of any kind whether based on contract, tort (including negligence) or otherwise under any warranty, provision for liquidated damages or otherwise, in no case exceed the provisions of the remedies expressly set forth in this Agreement at Clauses 12.4 and 13.

19.3 Without prejudice to BEG(UK)’s obligations to pay the Initial Termination A Stocks Purchase Price and Remaining Termination A Stocks Purchase Price or the Termination B Purchase Price (as the case may be) and to make payments to BNFL under Clauses 2.13, 2.24 and 2.27.2, any liability of BEG(UK) for any loss or damage, however caused or suffered by BNFL in connection with or as a result of the Uranic Elements Supply Component of this Agreement is limited to [ ]*

19.4 Without prejudice to BNFL’s obligations to make payments to BEG(UK) under Clauses 2.14, 2.25 and 2.27.3, any liability of BNFL for any loss or damage, however caused or suffered by BEG(UK) in connection with or as a result of the Uranic Elements Supply Component of this Agreement is limited to [ ]*

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

20.

CONFIDENTIALITY

20.1 The terms and conditions of this Agreement shall be confidential and no Party shall disclose the same to any third party except its Group Companies without the consent of the other Parties (which consent shall not be unreasonably withheld) except to such extent as may be necessary for the proper performance of this Agreement and after such third party (if not a director, officer or employee of the disclosing party to whom disclosure is reasonably necessary) has agreed in a legally binding manner to be bound by the provisions of this Clause or as may be required under proper statutory authority by relevant Government authorities or other authorities having due legal competence or as required by the rules of the Stock Exchange.

20.2 Each Party shall keep confidential all data, drawings, designs and other information received by it from the other Parties in the course of, or in connection with, the performance of this Agreement and shall not use the same for any purpose other than the performance of its obligations hereunder, and the receiving Party shall not disclose the same to any third party except its Group Companies without the consent of the disclosing Party which consent shall not be unreasonably withheld.

20.3 Notwithstanding the provisions of Clause 20.2, BEG(UK) shall, on giving notice to BNFL, be entitled to disclose information given to it by BNFL to relevant BEG(UK) contractors for the purpose only of carrying out contracts with BEG(UK) provided that such contractors first enter into a confidentiality undertaking in favour of BNFL, unless BNFL decides this is not required.

20.4 Without prejudice to the foregoing provisions of this Clause 20 and subject to Clause 20.7, each Party shall treat all information supplied to it by the other Party under this Agreement as Commercial Information.

20.5 BNFL shall not knowingly use Commercial Information in any way which would place a BNFL Group Company or any company in which it has a shareholding in either case which is an electricity generator at a competitive advantage to BEG(UK) in the UK electricity generation market.

20.6 BE and BEG(UK) shall not knowingly use Commercial Information concerning BNFL’s electricity generation business to place a BNFL Group Company at a competitive disadvantage in the UK electricity generation market.

20.7 Notwithstanding the provisions of Clause 20.2, BEG(UK) and BE shall, on giving notice to BNFL, be entitled to disclose information given to them by BNFL to relevant BEG(UK) or BE contractors for the purpose only of carrying out contracts with BEG(UK) or BE, provided that such contractors first enter into a confidentiality undertaking in favour of BNFL, unless BNFL agrees this is not required.

20.8 Subject to Clause 20.9, BE and BEG(UK) shall keep confidential all data, drawings, designs and other information which may come into their knowledge as a result of them attending at the premises of BNFL’s suppliers and that any such information shall not be disclosed to any third party without BNFL’s prior written consent.

20.9 The provisions of Clauses 20.1, 20.2, 20.3, 20.4, 20.5, 20.6, 20.7 and 20.8 shall not, however, apply to any Commercial Information which:

20.9.1

is or becomes within the public domain through no act of the receiving Party in breach of the provisions of this Clause 20;

20.9.2

was lawfully in the possession of the receiving Party prior to its receipt from another Party; or

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

20.9.3 is legally received from another source without any restriction on use or disclosure.

20.10 The restrictions in Clauses 20.5 and 20.6 shall also not apply to information provided in good faith at multiparty meetings involving the Parties, BEG and other parties whose objective is to optimise the services provided by BNFL of the kind covered by this Agreement in the interests of all parties concerned.

21.

ASSIGNMENT

21.1 No Party shall, save as is set out in the remainder of this Clause 21, have any right to assign or to part with or to sub-contract any of its rights and obligations under this Agreement without the prior written consent of the other Parties. Such consent may only be withheld if an assignment is not Reasonable.

For the purposes of this Clause an assignment shall be Reasonable if:

21.1.1

the intended assignor can demonstrate that the intended assignee is financially and technically competent to carry out the obligations of this Agreement, and in particular the financial obligations; and

21.1.2

if so requested in writing by the non-assigning Party, an appropriate parent-company guarantee is provided from the intended assignee’s parent company, if any, or the intended assignee enters into a further agreement in relation to this Agreement containing such reasonable provisions as the non-assigning Party would reasonably need to ensure that the intended assignee is able to carry out the obligations of this Agreement until each and every obligation has been fully discharged.

21.2 It is acknowledged and agreed by BE and BEG(UK) that BNFL may, upon or at any time after the establishment of the LMA, assign or part with or sub-contract any of its rights and obligations under this Agreement to the LMA to the extent required by or in consequence of, or to take a benefit available by reason of, any relevant legislation. No consent under Clause 21.1 shall be required for an assignment under this Clause 21.2.

21.3 It is acknowledged and agreed by BE and BEG(UK) that BNFL may assign or part with or sub-contract any of its rights and obligations under this Agreement to New BNFL with the prior written consent of BEG(UK), such consent not to be unreasonably withheld (but for the purposes of this Clause 21.3, the definition of “Reasonable” in Clause 21.1 shall not apply). For the avoidance of doubt, the Parties acknowledge that, in determining whether or not consent has been unreasonably withheld, any considerations may be taken into account, including without limitation those specified in Clauses 21.1.1 and 21.1.2.

21.4 It is acknowledged and agreed by BNFL that BEG(UK) may at any time assign or part with or sub-contract any of its rights and obligations under this Agreement to any BEG(UK) Group Company which holds a nuclear site licence in respect of any of the AGR Power Stations or the BEG AGR Power Stations. No consent under Clause 21.1 shall be required for an assignment under this Clause 21.4.

21.5 It is acknowledged and agreed by BE and BEG(UK) that BNFL may at any time assign or part with or sub-contract any of its rights and obligations under this Agreement to any BNFL Group Company, subject to a parent-company guarantee being provided by BNFL with the liability of the parent company in relation to each obligation guaranteed not being greater than that which BNFL would incur in respect of that obligation. No consent under Clause 21.1 shall be required for an assignment under this Clause 21.5.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

22.

FORCE MAJEURE

22.1 Subject to Clause 22.2 hereof if performance of this Agreement or of any obligation hereunder by any of the Parties is prevented through any cause arising from or due to circumstances beyond its reasonable control, which circumstances shall include but not be limited to war, hostile or criminal act, revolution, riot, civil commotion, blockade, embargo, industrial action (including strike) by workpeople, lockout, act or restraint of government or government agency (other than the Parties) or damage by fire, flood, explosion or natural catastrophe, it shall upon giving notice to the other Parties indicating the cause and likely duration of non-performance:

22.1.1

be excused from such performance to such extent and for such period as may be reasonably necessary in the circumstances; and

22.1.2

have no responsibility for the financial or other consequences of such non-performance.

22.2 The Parties shall consult together as soon as practicable after receipt of the aforementioned notice with the object of reaching Agreement on any means by which the cause or consequence of non-performance may be overcome or alleviated.

22.3 If BNFL is prevented from delivering Fuel to one or more AGR Power Stations as a consequence of circumstances beyond its reasonable control the charge Ao shall be reduced in proportion to the reduction in the quantity of Fuel delivered to AGR Power Stations and BEG(UK) shall be entitled to obtain from any other source such quantity of Fuel as BNFL is unable to deliver as aforesaid. Notwithstanding the minimum quantity of Fuel that BEG(UK) is required to take in accordance with Clause 7.1 BEG(UK) will only be obliged to pay for actual Fuel delivered. Such quantity of Fuel as is obtained from another source shall for the purposes only of BEG(UK)’s obligations pursuant to Clause 4.1 be deemed to have been supplied pursuant to this Agreement.

22.4 If BNFL is unable to supply Fuel for a continuous period of three months BNFL will thereafter use its reasonable endeavours to acquire supplies of Fuel for BEG(UK) from alternative sources.

22.5 If BNFL is unable to supply Fuel for a continuous period of nine months BEG(UK) shall be entitled to terminate this Agreement by notice to expire at the end of the said nine month period or at any time thereafter. In case of such termination BNFL will use its best endeavours to assist BEG(UK) to acquire supplies of Fuel at reasonable prices from alternative sources.

22.6 If BEG(UK) is prevented from receiving deliveries of Fuel at one or more AGR Power Stations under this Agreement as a consequence of circumstances beyond its reasonable control it shall not be obliged to place firm orders for Fuel pursuant to Clause 7.4 in respect of the AGR Power Station or AGR Power Stations so affected for so long as it is so prevented from receiving deliveries. As soon as it is reasonably practicable to do so, BEG(UK) shall accept deliveries of all Fuel ordered by it which it was unable to accept as a consequence of such circumstances. BEG(UK) shall continue to pay the monthly instalments of the charge Ao Escalated but shall not be obliged to pay charges set out in Clause 4.12, in respect of Fuel not delivered which was specifically ordered for the AGR Power Station so affected.

22.7 Each Party shall use reasonable endeavours to avoid, remove or minimise all financial consequences, damage or other effect on the other Party as a result of any force majeure event.

23.

WAIVER

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

No delay or failure by a Party in exercising any right, power or remedy hereunder shall operate as a waiver of such right, power or remedy, nor shall any single or partial exercise of any such right, power or remedy preclude other or further exercise thereof or the exercise of any other right, power or remedy.

24.

NON PERFORMANCE

24.1 If BNFL persistently commits any breach of contract and BEG(UK) serves notice on BNFL specifying such breach the Parties shall consult as to how such breach of contract shall be remedied and as to how similar breaches of contract can be avoided in future. If BNFL fails to participate in such consultation or if after such consultation BNFL does not remedy such breach or continues to commit similar breaches of contract and as a result BEG(UK) can demonstrate that it has suffered substantial loss including (but without limitation) loss of generation BEG(UK) shall be entitled to terminate this Agreement on such timescales as BEG(UK) considers will enable it to secure supplies from other sources. BNFL shall provide to BEG(UK) or as BEG(UK) directs such reports, supporting information and the services of BNFL staff as BEG(UK) can reasonably demonstrate it may require to enable BEG(UK) to secure supplies from other sources. BEG(UK) shall not copy or disclose to third parties such information, except to the extent that it is necessary to do so for such purposes. BNFL shall grant such licences as is necessary for such purposes.

24.2 BEG(UK) may terminate the Uranic Elements Supply Component of this Agreement and the rest of this Agreement shall continue unaffected:

24.2.1

with immediate effect if BNFL has failed to exercise reasonable care and reasonable diligence in fulfilling its material obligations in relation to the Uranic Elements Supply Component of this Agreement provided BEG(UK) has given written notice to BNFL of such failure and BNFL does not remedy the situation within one month from the date of such notice; and

24.2.2

on 12 months’ notice where the Execution Effectiveness Ratio as referred to in Appendix 26 is greater than 1.05 in any month, such notice to be served within 3 months of BEG(UK)’s receipt of the Execution Effectiveness Ratio for that month.

25.

NOTICES

25.1 All notices and other communications required or authorised to be given hereunder shall be in writing and may be given by hand, transmitted by facsimile or mailed by certified, registered or first class mail, postage prepaid.

25.2 All such notices or other communications shall be deemed to have been duly given when delivered, if given by hand during office working hours of the recipient or when transmitted, if transmitted by facsimile transmission (despatch confirmed) during office working hours of the recipient or on the third Working Day following mailing. Any notice or other communication given by hand or sent by facsimile transmission otherwise than during the Working Day shall be deemed to have been given at 10.00 a.m. on the next Working Day following despatch. Any notice or other communication sent by facsimile transmission shall also be confirmed as soon as possible by some other method.

25.3 In each case, unless amended by notice, notices shall be addressed to BNFL, BEG(UK) or BE, as the case may be, as follows:

British Nuclear Fuels plc

Westinghouse UK Fuel Business

Springfields

Salwick

Preston

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

▇▇▇▇▇▇▇▇▇▇

▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇

Fax: ▇▇▇▇▇ ▇▇▇▇▇▇

For the attention of:

Business Manager Oxide, AGR Fuel

British Energy Generation (UK) Limited

▇▇▇▇▇▇▇ ▇▇▇

▇▇▇▇▇▇▇▇

▇▇▇▇▇▇▇▇▇▇

▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇

Fax: ▇▇▇▇▇ ▇▇▇▇▇▇

For the attention of:

Head of Fuel Supply

British Energy plc

▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇

▇▇▇▇ ▇▇▇▇

▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇

Fax: ▇▇▇▇▇ ▇▇▇▇▇▇

For the attention of: Company Secretary

26.

INVALIDITY AND SEVERABILITY

If any provision of this Agreement shall be found by any court or administrative body of competent jurisdiction to be invalid or unenforceable the invalidity or unenforceability of such provision shall not affect the other provisions of this Agreement and all provisions not affected by such invalidity or unenforceability shall remain in full force and effect. The Parties hereby agree to attempt to substitute for any invalid or unenforceable provision a valid or enforceable provision which achieves to the greatest extent possible the economic, legal and commercial objectives of the invalid or unenforceable provision.

27.

LAW

27.1 This Agreement shall in all respects be construed and operate as an Agreement made and performed in England and subject to English Law.

27.2 In the event of conflict between the provisions of the Clauses and the provisions of the Appendixes hereto, the provisions of the Clauses shall prevail.

28.

DISPUTE RESOLUTION

28.1 Subject to Clause 28.3 and Clause 28.4, in the event a dispute, controversy or claim arises out of or in connection with this Agreement (including any question regarding its existence, validity or termination) (Dispute), a Party may give the other Parties notice that a Dispute has arisen (a Dispute Notice). Following the service of the Dispute Notice the Parties shall use all reasonable endeavours to settle such Dispute amicably within a period of 60 calendar days (or such longer period as the Parties may mutually agree) starting from the date of receipt of the Dispute Notice by the relevant Party. In the event that the Parties are

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

unable to settle any Dispute within such 60 calendar day period (or such longer period), then such Dispute shall be referred for resolution by negotiation between the respective Chief Executives of BE and BNFL. If the Parties are unable to settle a Dispute by such negotiation within 60 calendar days (or such longer period as the Parties may mutually agree) of it being referred to the Chief Executives, then such Dispute shall be referred to arbitration in accordance with the terms of Clause 28.2.

28.2 Subject to Clause 28.1, any Dispute shall be referred to and finally resolved by arbitration under the LCIA Rules, which Rules are deemed to be incorporated by reference into this Clause. The tribunal shall consist of one arbitrator. The seat of the arbitration shall be London. The language of the arbitration shall be English.

28.3 Any matter subject to determination by an Expert pursuant to Appendix 20 shall not be subject to Clauses 28.1 and 28.2.

28.4 Any agreement between BEG(UK) and BNFL under Clause 7.3A shall not be subject to Clauses 28.1 and 28.2.

28.5 Where any dispute or difference between BEG(UK) and BNFL is in connection with Uo or the calculation of Uo, Vo, Wo and Xo, BEG(UK) and BNFL agree that the Pricing Principles shall form part of the agreed scope of reference of the Arbitrator (who, in respect of a dispute or difference under this Clause 28.5, shall have appropriate experience in the uranics market) when dealing with such dispute or difference.

29.

[NOT USED]

30.

TERMINATION AND SURVIVAL

Clauses 2.3 to 2.35 (inclusive), 5.1, 5.15 to 5.20 (inclusive), 7.3A.3, 13, 18, 19, 20 and 28 and Appendixes 18 and 31 and any provisions of this Agreement which are expressed to survive the termination or expiration of this Agreement shall survive the termination or expiration of this Agreement.

31.

ENTIRE AGREEMENT

31.1 This Agreement constitutes the entire agreement between the Parties with respect to the subject matter hereof and supersedes any prior written or oral agreement(s) or arrangements between the Parties in relation thereto. No prior or collateral representation, promise, warranty or condition made or given by any of the Parties to another Party and not contained herein shall be binding upon any of them and no amendment, modification or extension of this Agreement or waiver of any of the terms and conditions hereof shall be binding upon any of them unless it is Agreed in writing by duly authorised representatives of each of the Parties. For the avoidance of doubt, this Clause 31.1 shall not exclude any liability for, or remedy in respect of, fraudulent misrepresentation by any Party or any of its Connected Persons, where Connected Person means in each case, to the extent that they are involved on behalf of a Party, (a) a Party’s officers, employees, group undertakings, agents and advisers; (b) officers, employees, agents and advisers of a Party’s group undertakings and (c) officers, employees and partners of any such agent or adviser or of any group undertaking of such agent or adviser.

31.2 No agreement, modification or extension of this Agreement or waiver of any of the terms and conditions hereof shall be binding upon a Party unless it is evidenced in writing by all Parties.

32.

NON-DISCRIMINATION

32.1 BNFL shall not during the term of this Agreement unreasonably discriminate against BEG(UK) in favour of any other party (including without limitation Magnox Electric plc) in respect of the performance

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

by BNFL of any services of the kind provided for under this Agreement. For the avoidance of doubt, this Clause shall not relate to the terms on which relevant services are provided by BNFL to its other customers but shall be directed at the manner of performance of those services by BNFL as between BEG(UK), Magnox Electric plc and its other customers.

32.2 Without prejudice to the generality of Clause 32.1, in the event that BNFL is unable, or foresees that it will be unable, to perform its obligations under this Agreement with the result that BEG(UK) is likely to suffer serious operational difficulties at its power stations in circumstances where there are likely to be similar effects on third parties in the UK electricity generation market to whom BNFL owes similar obligations, BNFL shall:

32.2.1

forthwith consult with BEG(UK) and any relevant third party with a view to minimising the loss to and effect on operations of all concerned; and

32.2.2

BNFL shall not unreasonably discriminate in these circumstances against BEG(UK) in any way in favour of any such third party.

32.3 Notwithstanding the foregoing, BNFL shall not in any event be obliged to compromise the safety of its operations which shall be paramount.

32.4 If (for the purposes of Clauses 32.1 and 32.2) BEG(UK) has reasonable grounds to believe that BNFL has unreasonably discriminated in favour of such a third party, it shall notify BNFL in writing of the basis of its concerns. Following receipt of such notifications:

32.4.1

BNFL and BEG(UK) shall meet as soon as possible (and in any event no later than four Weeks after such receipt) to discuss the basis of BEG(UK)’s concerns; and

32.4.2

BNFL shall be obligated to provide to BEG(UK) all information reasonably necessary to demonstrate to BEG(UK) whether or not discrimination has taken place and BNFL shall not act unreasonably in this regard.

32.5 If BNFL and BEG(UK) reach Agreement that BNFL has unreasonably discriminated against BEG(UK) in favour of any third party, BNFL and BEG(UK) shall agree an appropriate remedy to resolve the unreasonable discrimination.

32.6 Any failure by the Parties to reach Agreement on any aspect of this Clause shall be referred to an independent arbitrator for resolution as provided for under Clause 28 of this Agreement. For the avoidance of doubt, the arbitrator shall have the right to call for whatever additional information he deems necessary from BNFL and BEG(UK) in order to provide the basis for his ruling.

33.

ADJUSTMENT OF THE PAYMENT PROFILES BY BEG(UK)

33.1 BEG(UK) shall have an option exercisable at any time during the term of this Agreement to accelerate payments to BNFL subject to an aggregate upper limit of £15,000,000 (fifteen million pounds) per annum after adjustment in accordance with Clause 33.1.2 (or such other sum as may be agreed) taken over this Agreement and the Historic Spent Fuel Agreement. For this purpose:

33.1.1

BEG(UK) shall give 36 months notice (or such other notice period as may be agreed) of any intent to accelerate payment;

33.1.2

BEG(UK) and BNFL shall discuss and agree which payments under this Agreement and the Historic Spent Fuel Agreement are to be accelerated and such payments shall be adjusted by a discount rate to be agreed by the Parties and escalated in accordance with the provisions of Appendix 7 of this

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Agreement, or the escalation provisions of the Historic Spent Fuel Agreement whichever is appropriate;

33.1.3

BEG(UK) and BNFL shall forthwith agree to and maintain a financial model to facilitate and record the application of this Clause 33; and

33.1.4

the payment profile identified in this Agreement shall be modified to reflect any Agreement reached under this Clause 33. In all other respects this Agreement shall continue in full force and effect following such modification.

34.

TERMINATION OF SUPPLY BY BNFL

Notwithstanding BEG(UK)’s rights under other Clauses in this Agreement:

34.1 If BNFL ceases to carry on business in Fuel supply or notifies BEG(UK) that it is otherwise unwilling or permanently unable to provide Fuel supply services under this Agreement and, in any such circumstance, BEG(UK) is unable to procure such services from another party, then:

34.1.1

BNFL shall provide access and rights for BEG(UK) to use all relevant BNFL intellectual property and (where appropriate) facilities reasonably necessary to provide such services; and

34.1.2

BNFL shall also seek to secure rights for BEG(UK) to utilise any rights or licences which BNFL may have with third parties which are reasonably necessary for the supply of those services.

The terms and conditions for such access to intellectual property, facilities referred to in Clause 34.1.1 and for the securing of rights by BNFL on behalf of BEG(UK) pursuant to Clause 34.1.2, shall be agreed between the Parties (including, if appropriate, the terms of purchase of such facilities and intellectual property).

34.2 If BNFL is unable for technical reasons at any stage to supply a service provided for under this Agreement, BNFL shall (at BEG(UK)’s request) use its reasonable endeavours to secure such service from an alternative supplier.

35.

COMPETITION

35.1 Immediately following the signing of this Agreement, the Parties shall jointly approach HMG to see what assistance the Parties may be able to provide to HMG in relation to the State Aid Notification (as defined in Clause 1.5) either immediately or at any time whilst the Commission is considering the State Aid Notification and in particular within the framework of an investigation under Article 88(2) of the EC Treaty.

35.2 The Parties shall make, on or before 9 April 2003 or such later date as they may agree in respect of this Agreement and any other agreement or arrangement contemplated by it, a notification for negative clearance and an application for an individual exemption on Form A/B to the Commission pursuant to Council Regulation (EEC) No. 17/62 (as amended). They shall also discuss and Agree upon whether to make a notification and an application for a decision on Form N to the Office of Fair Trading pursuant to ▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇ (Director’s Rules) Order 2000.

35.3 The Parties shall:

35.3.1

use their reasonable endeavours and co-operate with each other to ensure that all information necessary or desirable for making (or responding to any requests for further information following) any notification or filing made in respect of the Restructuring, this Agreement or any agreement or arrangement contemplated by this Agreement (whether such notification or filing is to be made by a

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Party or by HMG) is supplied to the person preparing such notification or filing (or response to any information request) and that such notifications, filings and responses to any information requests are properly, accurately and promptly made and in any event in accordance with any applicable time limit laid down by applicable legislation, or set by the Commission or the Office of Fair Trading (as the case may be) or any extension permitted by the Commission or the Office of Fair Trading (as the case may be);

35.3.2

respond promptly and fully to any request for information by the Commission or the Office of Fair Trading (as the case may be) or in relation to the State Aid Notification made by HMG, any request for information or other assistance that may be made by HMG;

35.3.3

before making any notification, filing, submission, response or other communication (whether orally, in writing, in electronic format, or otherwise), other than of a purely administrative nature (each a Communication), with the Commission or the Office of Fair Trading (as the case may be) or, in relation to the State Aid Notification made by HMG, provide draft copies of the Communication (or in respect of an oral Communication, an indication of the proposed content of such oral Communication), together with copies of any supporting documentation or other relevant material to the other Parties and take due consideration of any reasonable comments that the other Parties may have, who shall communicate any comments promptly to the Party that is proposing to make the Communication; and

35.3.4

keep each other informed on a timely basis of the progress of any notification to or investigation by the Commission or the Office of Fair Trading (as the case may be), including any meetings or conference calls and shall to the extent permitted by the Commission, the Office of Fair Trading or HMG (as the case may be) permit the other Parties and their advisers to attend any such meetings or participate in any such conference calls.

35.4 Nothing in Clause 35.3 shall require a Party to provide to the other Parties any confidential information or business secrets relating to any business of their respective group, insofar as the provision of such information does not infringe any UK or EC competition laws. Furthermore, nothing in Clause 35.3 or elsewhere in this Agreement shall require BE or any member of the BEG(UK) Group to provide any communication or other information (whether orally, in writing, in electronic format or otherwise) to BNFL in connection with the financial position of BE or any member of the BEG(UK) group or with any financial assistance of any kind whatsoever that HMG may provide to BE or any member of the BEG(UK) Group during the consideration by the Commission of the Restructuring, including in connection with the aid measures approved by the Commission on 27 November 2002.

35.5 Following the making of the notifications referred to in Clauses 35.1 and 35.2, the Parties shall use their reasonable endeavours to ensure, and shall not take any steps or commit any act that may reasonably be considered as prejudicial to, the obtaining of a decision by the Commission that the Restructuring does not involve unlawful State aid and a negative clearance, exemption, or analogous decision (or decisions) by the Commission and/or the Office of Fair Trading under Article 81(1) EC and/or the Competition Act 1998 (as the case may be) in relation to this Agreement or any agreement or arrangement contemplated by this Agreement.

35.6 If, notwithstanding the Parties’ compliance with their obligations under Clause 35.5, in relation to any notification, filing or investigation (whether made by the Parties or HMG) the Commission and/or the Office of Fair Trading (as the case may be) shall indicate, or it becomes reasonably apparent to the Parties or HMG that the Commission and/or the Office of Fair Trading (as the case may be) may indicate, that any provision of the Restructuring, this Agreement or any agreement or arrangement contemplated by it, requires to be amended, modified or deleted in order to obtain approval of the Restructuring or this Agreement (or the granting of negative clearance, an individual exemption or any similar or analogous

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

decision), the Parties shall promptly meet to enter into good faith negotiations with a view to meeting the requirements of the Commission and/or the Office of Fair Trading provided that if any modifications or amendments to this Agreement or any agreement or arrangement contemplated by it are required or advisable any such modifications or amendments are reasonably acceptable to BNFL and BE.

36.

NO RIGHTS UNDER CONTRACTS (RIGHTS OF THIRD PARTIES) ACT 1999

A person who is not party to this Agreement shall have no right under the Contracts (Rights of Third Parties) ▇▇▇ ▇▇▇▇ to enforce any of its terms.

37.

PARENT COMPANY GUARANTEE AND FURTHER ASSURANCE

37.1 In consideration of BNFL entering into this Agreement, BE unconditionally and irrevocably guarantees as a continuing obligation the proper and punctual performance by BEG(UK) (to the extent that performance by BE would not be illegal) of all its obligations under or pursuant to this Agreement. BE shall take all reasonable steps within its powers to ensure that it is not illegal for it to comply with its obligations under this Clause.

37.2 BE acknowledges that, although BEG is not a party to this Agreement, the co-operation of BEG is necessary to implement and/or give effect to this Agreement. BE agrees to procure the performance by BEG of all further acts and things as BNFL may reasonably require to implement and/or give effect to this Agreement and the transactions contemplated by it and for the purpose of vesting in BNFL the full benefit of this Agreement.

37.3 BE’s liability under this Clause 37 shall not be discharged or impaired by:

37.3.1

any amendment to or variation of this Agreement, or any waiver of or departure from its terms, or any assignment of it or any part of it (including any assignment pursuant to Clause 21), or any document entered into under this Agreement;

37.3.2

any release of, or granting of time or other indulgence to, BEG(UK) or any third party, or the existence or validity of any other security taken by BNFL in relation to this Agreement or any enforcement of or failure to enforce or the release of any such security;

37.3.3

any winding up, dissolution, reconstruction, arrangement or reorganisation, legal limitation, incapacity or lack of corporate power or authority or other circumstances of, or any change in the constitution or corporate identity or loss of corporate identity by, BEG(UK) or any other person (or any act taken by BNFL in relation to any such event); or

37.3.4

any other act, event, neglect or omission whatsoever (whether or not known to BEG(UK), BNFL or BE) which would or might (but for this Clause) operate to impair or discharge BE’s liability under this Clause or any obligation of BEG(UK) or to afford BE or BEG(UK) any legal or equitable defence.

37.4 In relation to each obligation of BEG(UK) guaranteed by BE pursuant to Clause 37.1, BE’s liability under Clause 37.1 shall not be greater than that which BEG(UK) would incur towards BNFL in respect of that obligation.

37.5 In the event that BEG(UK) ceases to be a subsidiary of BE, BE shall forthwith notify BNFL thereof and, at the request of BNFL, BE shall assign and part with its rights and obligations under (a) this Agreement, and (b) all other agreements and deeds entered into by BE, BNFL and either BEG or BEG(UK)

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

(as the case may be) under which BE has any rights or obligations, to the ultimate holding company of BEG(UK), subject to BE being released and discharged from all obligations, duties, and liabilities under this Agreement and any such other agreements and deeds.

38.

ACKNOWLEDGEMENTS BY BE AND BEG(UK)

38.1 BE and/or BEG(UK) have from time to time in the past made various statements concerning the terms of this Agreement and certain other agreements between BNFL and BEG(UK) Group Companies, including, inter alia, that certain terms of this Agreement and such other agreements infringe or have infringed EU and/or UK competition law and circumstances exist or have existed that entitle or have entitled BEG(UK) to invoke the “hardship” provisions of previous agreements between BNFL and BEG(UK) Group Companies (the Past Statements).

38.2 In consideration of BNFL entering into this Agreement, each of BE and BEG(UK) hereby acknowledges and agrees, for itself and on behalf of each BEG(UK) Group Company, that:

(a)

BNFL’s sole reason for entering into this Agreement is to participate in a process that is intended to lead to the solvent restructuring of BE with a view to ensuring the long term financial viability of a valuable customer;

(b)

any amendments to previous arrangements effected by this Agreement do not represent an admission by BNFL (whether express or implied) that any of the Past Statements have any merit or foundation; and

(c)

neither it nor any BEG(UK) Group Company shall bring any claim in relation to the subject matter of the Past Statements, the Heads of Terms or the arrangements contemplated by the Heads of Terms (whether implemented in this Agreement or otherwise), in particular any claim that any of the terms of this Agreement infringe EU or UK competition law or that hardship conditions exist or have existed.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 1

EXPECTED DATES FOR AGR POWER STATION LIFETIMES

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 2

APPROVED PRODUCT LIST

The current issues (as at 1 February 2003) of the BEG and BEG(UK) Approved Product Lists are as follows:

BEG Approved Product List

Approved Product List (APL): AGR Fuel & ▇▇▇▇▇▇▇▇ Components for Use by BEG, formerly known as Nuclear Electric Limited, dated 30 April 2002

BEG(UK) Approved Product List

Approved Product List (APL): AGR Fuel & ▇▇▇▇▇▇▇▇ Components for Use by BEG(UK), formerly known as Scottish Nuclear Limited, dated 8 February 2002

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 3

CONTRACT SPECIFICATION

The current issue (as at 1 February 2003) of the ‘Head Document’ defining the Contract Specification is the following BEG/BEG(UK) controlled document:

EPD/AGR/REP0269/97 Issue 2 (BEG Reference)

E/DR/97/NT/25 Issue 2 (BEG(UK) Reference)

“AGR Fuel Specification for British Energy Generation Ltd and British Energy Generation (UK) Ltd—The Design and Manufacturing Requirements for Stage 3 and Stage 1c Fuel Elements and for Ancillary Components. Issue 2, dated 13 December 2000”.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 4

[NOT USED]

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 5

ENRICHED URANIUM BREAKDOWN STATEMENT

AS AT / / 20

BRITISH NUCLEAR FUELS PLC

WESTINGHOUSE UK FUEL BUSINESS

SPRINGFIELDS

											Units = kgU
U ACCOUNT % U235		UF₆ Not in WIP (1A)	UF₆ in WIP (1B)	UNINVOICED FUEL (2)	INVOICED FUEL (3)	UO2 POWDER (4)	GRANULES TO FUEL PINS (5)	IMMEDIATELY USEFUL MATERIAL (6)	CLEAN RESIDUES (7)	DIRTY RESIDUES (8)	IRREC RESIDUES (9)	TOTAL STOCK (10)
Misc
0.712	0.749
0.750	0.799
0.800	0.849
0.850	0.899
0.900	0.949
0.950	0.999
1.000	1.049
1.050	1.099
1.100	1.149
1.150	1.199
1.200	1.249
1.250	1.299

4.600	4.649
4.650	4.699
4.700	4.749
4.750	4.799
4.800	4.849
4.850	4.899
4.900	4.949
4.950	4.999
5.000	5.049
5.050	5.099
9.450	9.499
9.500	9.549

REPORT TOTALS

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 6

ENRICHED URANIUM BREAKDOWN STATEMENT (PIV)

AS AT / /20

BRITISH NUCLEAR FUELS PLC

WESTINGHOUSE UK FUEL BUSINESS

SPRINGFIELDS

Units = kgU

U ACCOUNT
% U235

UF₆ Not in WIP
(1A)

UF₆ in WIP
(1B)

UNINVOICED
FUEL
(2)

INVOICED
FUEL
(3)

UO2
POWDER
(4)

GRANULES
TO FUEL
PINS
(5)

CLEAN
RESIDUES
(6)

DIRTY
RESIDUES
(7)

IRREC
RESIDUES
(8)

TOTAL
STOCK
(9)

IA miscellaneous 0.000% Assay 0.007% Assay Sub total

IA 0.712—0.749 0.712% Assay 0.713% Assay 0.714% Assay Sub total

IA 0.750—0.799 0.750% Assay 0.790% Assay Sub total

IA 0.800—0.849 0.800% Assay 0.848% Assay Sub total

IA 5.00—5.049 5.500% Assay 5.015% Assay Sub total

IA over 5.049 5.544% Assay 5.548% Assay Sub total

REPORT TOTALS

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 7

ESCALATION FORMULA

The elements of the Ao and Bo and other charges set out in this Agreement are stated in either July 2002 money values or Financial Year 2003 money values as stated in the specific clauses and shall be escalated in accordance with the following formulae:

For prices escalated monthly from July 2002 money values (or such other money values as are Agreed)	Cy=	CoRm	For prices escalated annually from Financial Year 2003 money values	Cy=	CiRy
	Cy=	Ro		Cy=	Ri

where:

is the relevant charge as escalated;

is the base charge in July 2002 money values or such other money values as are Agreed;

are the base values £[ ]* and £[ ]* used in the calculation of D2;

is the Retail Price Index for the month in which the event occurs which gives rise to the charge due and shall be estimated as follows if the Retail Price Index for the month in question is not available:

Rm = Rmn + n (Rmn - Rmn3);

is the month for which the Retail Price Index is to be estimated;

is the number of months between the month of payment and the month in which the Retail Price Index has been most recently published;

Rmn

is the Retail Price Index for the month in which the index has been most recently published;

Rmn3

is the Retail Price Index for the month three months prior to Rmn;

is the Retail Price Index for the month of July 2002 (which is 175.9) or such other month as is Agreed;

is derived by summing the 12 monthly Retail Price Indices for the period from 1 April 2002 until 31 March 2003 and dividing the summation by 12; and

is the Retail Price Index for the Year in which the event occurs which gives rise to the charge due, derived by summing the 12 monthly Retail Price Indices for that Year and dividing the summation by 12.

14 days prior to the date on which BNFL is required to invoice BEG(UK) the Retail Price Index for the relevant Year shall be estimated according to the following formula:

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Ryest is the estimated Retail Price Index for the Year in which the event occurs which gives rise to the charge due, derived by summing the 12 monthly Retail Price Indices for that Year and dividing the summation by 12.

Where a monthly Retail Price Index is not available it will be derived in accordance with the formula for Rm above.

Upon the later of (a) publication of the Retail Price Index for the month of March in each Year hereunder and (b) the derivation of the final values for OEP for each Year in accordance with Appendix 20, such date being referred to as the Reconciliation Date, BNFL shall calculate the value of all sums which would have been payable by either BEG(UK) or BNFL during that Year had the Retail Price Indices and Outturn Electricity Prices been known at the times of invoicing and shall within 21 days after the Reconciliation Date render to BEG(UK) an adjusting invoice or credit note as the case may be equal in value to the difference between such calculated value and the value of the sums actually paid by BEG(UK) or BNFL in that Year. Payment by BEG(UK) or BNFL shall be due 38 days after the date of the invoice or credit note as the case may be.

In the event that the Reconciliation Date is later than 35 Working Days after the end of the Year to which it applies, an interim reconciliation shall take place using the best data available on the 35^th Working Day after the end of the Year. In such a case, invoicing and settlement on the basis of such data shall take place as outlined above as if the Reconciliation Date were the 35^th Working Day after the end of the Year. Following such an interim reconciliation, subsequent reconciliations (including any final reconciliation as outlined above) for that Year shall take place in the following circumstances and no other:

(i)

In the event of manifest error in any relevant calculation or data used;

(ii)

In the event of the resolution of any relevant dispute between BEG(UK) and BNFL;

(iii)

If either BEG(UK) or BNFL believes in good faith that the impact of updated information will affect payments by more than £[ ]*; or

(iv)

With the Agreement of both BEG(UK) and BNFL.

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 8

QUALITY ASSURANCE ARRANGEMENTS

GENERAL

(a)

In the following provisions, unless otherwise stated all references to BEG(UK) shall be deemed to also include its duly appointed representatives or agents.

(b)

BNFL Westinghouse UK Fuel Business does and shall operate a total quality assurance system compliant with the requirements of BS-EN-ISO 9000-2000 and BS-EN-ISO 14001 or subsequent revisions. This Agreement shall operate and be managed within the Westinghouse quality assurance system.

QUALITY ASSURANCE PROGRAMME

(a)

BNFL’s quality assurance system covers design, procurement and manufacturing activities. BNFL will provide to BEG(UK) for approval a Quality Assurance Programme document which identifies the parts of the quality assurance system applicable to Fuel supply and which will be used to give assurance that BNFL complies with the requirements of the Agreement. Any changes shall be reflected prior to implementation in a revised Quality Assurance Programme which shall be submitted to BEG(UK) for approval prior to formal issue. BNFL reserves the right to make changes to the said quality assurance system subject always to maintaining compliance with BS-EN-ISO 9000-2000. For the avoidance of doubt approval of the Quality Assurance Programme shall be made by BEG(UK) and not its representatives or agents.

(b)

All supporting documents shall, upon receipt of written request, be made available for BEG(UK) to review at Springfields. The Quality Assurance Programme and any revisions thereto shall be made available as a controlled copy to BEG(UK) by BNFL.

SUB-CONTRACTORS

(a)

BNFL shall require its sub-contractors to control the quality of their products and services by systems and procedures appropriate to the product or services being provided. The requirement for sub-contractors to adopt appropriate quality management arrangements shall be included in the relevant contracts. All such systems and procedures shall meet with the requirements of the relevant part of BS-EN-ISO 9000 series.

(b)

BNFL shall maintain an approved supplier system of the products or services it requires for the manufacture of Fuel, such system to consist of a data base of suppliers and associated BNFL management control system. This system shall be made available for BEG(UK) to review at Springfields on written request for the purposes of this Appendix 8.

(c)

BNFL shall provide BEG(UK) with a controlled copy of the BNFL Quality Audit Programme on its suppliers indicating thereon those supply components or services that contribute directly to the integrity of Fuel.

(d)

Subject to the giving of reasonable notice BEG(UK) shall be allowed to participate in BNFL’s scheduled audits of its suppliers. Such participation will be undertaken on a joint basis, with BNFL retaining the lead auditor role and BEG(UK) involved in the planning of audits and assessment of findings, as well as participation in the audit activity. Each of BNFL and BEG(UK) shall bear its own costs associated with such audits.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

(e)

Subject to Paragraph 3(g) BEG(UK) shall inform BNFL of any additional audits that BEG(UK) requires to be undertaken and which audits it, would wish to participate in as either a joint auditor under a BNFL lead auditor, or as an observer, or where it would wish to review the audit report.

(f)

BEG(UK)’s participation in BNFL’s audits as provided for in Paragraph 3 shall be periodically reviewed by BEG(UK) to reflect inter-alia ongoing confidence in the adequacy and effectiveness of BNFL’s suppliers.

(g)

BNFL shall not refuse to accommodate requests for additional audits as referred to in Paragraph 3(e) above provided that such requests are reasonable having regard to supplier performance, the period of notice, working hours, the normal frequency of BNFL quality audits, the results of previous quality audits and BNFL’s contractual rights of access. Where BNFL has no contractual rights of access, BNFL shall use reasonable endeavours to obtain said access. In the event BNFL cannot obtain the said access it shall seek an alternative means other than additional audit of providing BEG(UK) with the assurance it requires.

(h)

In respect of its suppliers BNFL shall ensure that documentation is in place at Springfields or at BNFL’s suppliers’ premises to ensure the adequacy and effectiveness of the implementation of quality assurance arrangements, including evidence of conformance to the Contract Specification, effective quality auditing and surveillance. Said documentation shall be made available for review by BEG(UK) at Springfields or BNFL’s suppliers’ premises on written request.

(i)

BNFL agrees to arrange a programme of visits, including any necessary follow-up action, to key suppliers for BEG(UK) to assure themselves that there is adequate control of the processes that are important to the functional performance of the Fuel and that sufficient surveillance is undertaken by BNFL to provide objective evidence of conformance to the Contract Specification.

(j)

The programme described in Paragraph 3(i) would include a review of appropriate documentation which BNFL shall make available where it is contractually able for review by BEG(UK) at Springfields or its suppliers’ premises. Where BNFL has no contractual rights of access to such documentation, BNFL shall use reasonable endeavours to obtain said information or to seek an alternative means of providing BEG(UK) with the assurance it requires.

(k)

BEG(UK) shall ensure that all matters raised during audits and visits at BNFL suppliers’ premises are communicated to and via BNFL for action.

(l)

Where BEG(UK) can reasonably demonstrate that a quality shortfall has operational or safety implications, BNFL shall provide or arrange access to BNFL’s suppliers’ premises in order for BEG(UK) to assure itself that all relevant manufacturing processes are adequately controlled.

(m)

In the above context, suppliers shall be deemed to include sub-contractors, and sub-sub-contractors where BNFL has rights of access for BEG(UK). Where BNFL does not have such rights, it shall use all reasonable endeavours to secure such access and shall report to BEG(UK) on its progress in so securing.

MANUFACTURING PLANS

BNFL shall prepare manufacturing plans or process outlines which identify the manufacturing sequence, and Quality Control Plans or Inspection Schedules as the case may be in support of the Contract Specification identified in Appendix 3 of this Agreement. These manufacturing plans or process outlines shall be

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

submitted to BEG(UK) for information and the said Quality Control Plans or Inspection Schedules shall be made available to BEG(UK) at Springfields.

AUDIT BY BNFL

(a)

BNFL shall provide BEG(UK) on an annual basis with its intended schedule of internal audits in respect of Fuel supplied under this Agreement, and a Quality Audit Programme in respect of suppliers in accordance with Paragraph 3(b).

(b)

Audits conducted by BNFL internally at Springfields and externally on sub-contractors shall be recorded in such a manner that the relevant documentation constitutes evidence of the audit activities and findings. Corrective action, if necessary, shall be taken by BNFL or its sub-contractors in accordance with Agreed timescales to address the audit findings.

(c)

All audit records shall be available to BEG(UK) at Springfields for review.

(d)

BEG(UK) shall be allowed to participate in internal audits conducted by BNFL at Springfields. BEG(UK) shall provide BNFL with reasonable notice (normally four weeks) of BEG(UK)’s intention to participate in such an audit. BEG(UK) shall at least one week in advance of the said audit provide details of its representatives.

BEG(UK) AUDIT

(a)

BEG(UK) shall be allowed to conduct formal audits in order to satisfy itself of the implementation of BNFL’s Quality Assurance Programme. A corrective action programme shall be Agreed and implemented in respect of any deficiencies revealed by any such audit. The results of said corrective actions shall, if deemed by BEG(UK) to be required, be re-audited by BEG(UK).

(b)

BNFL shall provide the necessary facilities, including access, which may be required by BEG(UK) to conduct a quality audit, provided that BEG(UK) has given BNFL reasonable notice of its intention to conduct such an audit. Any such notice shall also state the programme and scope for the audit. The precise timing of any such audit shall be by mutual Agreement and such Agreement shall not unreasonably delay the commencement and conduct of a quality audit. BEG(UK) shall provide details of its representatives prior to arrival at Springfields.

(c)

BNFL shall provide the necessary facilities, including access and appropriate documents for review at Springfields which may be required by BEG(UK) for auditing purposes.

(d)

BNFL shall ensure that documentation is in place such that BEG(UK) can satisfy itself as to the effectiveness with which BNFL is implementing its quality assurance arrangements both at Springfields and at sub-contractors’ sites.

INSPECTION/SURVEILLANCE

(a)

BEG(UK) shall be allowed to monitor the implementation of BNFL’s Quality Control Plans or their equivalent and any related documents. Monitoring shall be by means of surveillance of activities associated with the manufacture of BEG(UK)’s products at Springfields. Corrective action shall be Agreed and implemented in respect of any deficiencies revealed by any such monitoring activities.

(b)

Where BEG(UK) wishes a representative to conduct regular surveillance of BNFL activities, then, subject to the necessary security clearances, the representative will be issued with a P3 pass permitting access to the Springfields site at any time. BNFL employees will be available to answer

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

surveillance questions during their normal working hours. Attendance by BNFL staff outside their normal working hours may be arranged in advance between the BEG(UK) and BNFL. Any such monitoring activity shall in no way prevent or delay BNFL’s manufacturing operations.

(c)

BNFL will accept a request for a repeat of any tests it performs and shall carry out that request subject to Agreement of satisfactory terms and conditions.

RECORDS

BEG(UK) and BNFL have Agreed to a lifetime records schedule which is set out in the Quality Assurance Programme referred to in Paragraph 2(a) of this Appendix 8.

QUALITY RELEASE

(a)

Before delivery of any Fuel consignment, BNFL shall provide a document confirming that the Fuel meets the requirements of the Contract Specification identified in Appendix 3, said document shall be authorised in accordance with the Quality Assurance Programme.

(b)

Where the said Fuel is not compliant with the Contract Specification but has been accepted by BEG(UK) pursuant to Paragraph 10 of this Appendix, BNFL shall ensure that the said records on release/despatch shall identify clearly as a minimum those Fuel Elements to which the relevant concession approval applies, together with a reference to the relevant concession approval granted by BEG(UK) pursuant to Paragraph 10.

(c)

BNFL shall be responsible for issuing all records identified on the record schedule specified in Paragraph 8 of this Appendix, as may be required on release/despatch of the Fuel consignment and make these available to BEG(UK) prior to or with each Fuel consignment delivered to BEG(UK) and make available to BEG(UK) verification information as Agreed verifying that the Fuel is compliant with the Contract Specification. For the avoidance of doubt, the said verification information shall be part of the aforementioned record schedule.

10.

NON CONFORMANCES

(a)

A non-conformance with the Contract Specification is defined in Section 3 of the Contract Specification. Non-conformances shall be dealt with as set out below. The procedures described in this Paragraph 10 shall not relieve BNFL of any of its obligations under the quality assurance programme.

(1)

BNFL shall establish and maintain an auditable procedure to manage non-conformances. Relevant staff shall be authorised to accept or to reject non-conformances in accordance with the requirements stated within BNFL’s quality assurance system. All rejected non-conformances shall be submitted to BEG(UK) for information. All accepted non-conformances shall be submitted to BEG(UK) as a concession application for approval.

(2)

Where BNFL is seeking BEG(UK)’s approval of a concession application, pursuant to sub-paragraph (1) of this Paragraph 10, such requests shall be made in writing by BNFL. BNFL shall provide supporting information as detailed in sub-paragraph 4 sub-sub-paragraphs (i) to (iv) of this Paragraph 10 below as soon as reasonably possible in order for BEG(UK) to come to an informed decision. All approvals shall be made in writing. Where appropriate, BEG(UK) and BNFL shall Agree the timescale on which sentencing of the concession application is required. BNFL shall provide any additional information, as requested by

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

BEG(UK), on a timescale consistent with that Agreed for sentencing the concession application.

(3)

BEG(UK) shall have the right to refuse approval of any concession application submitted giving reasons therefor, which shall be accepted by BNFL.

(4)

BNFL shall keep full records relating to non-conformances to cover inter alia:

the description of the non-conformance,

ii.

in the case of Fuel or Ancillary Components, the quantity of Fuel Elements or Ancillary Components as the case may be subject to the said non-conformance, the Fuel Element identification numbers and the AGR Power Station or Stations to which they relate, or

iii.

in the case of materials or components used in the manufacture of Fuel or Ancillary Components, the quantity of material or number of components subject to the said non-conformance as the case may be and wherever possible, the quantity of Fuel Elements and/or Ancillary Components, and the AGR Power Station or Stations to which they relate, and

iv.

adequate verified technical information to enable BEG(UK) to judge whether or not the said Fuel can be accepted, and determine the limits and conditions (if any) which should be attached to its use.

(5)

All non-conformances and decisions on classification, including records, shall be retained by BNFL in accordance with the Agreed record schedule and shall be available for review at Springfields by BEG(UK) in order for it to be satisfied that BNFL is acting in a proper and responsible manner.

(6)

BNFL shall maintain a list of all non-conformances and submit it to BEG(UK) for information on a quarterly basis.

(7)

BEG(UK) shall have the right to:

undertake surveillance of manufacturing processes at Springfields and/or subcontractors’ premises for the purposes of making an informed decision on whether or not to approve concession applications and to confirm that the procedures in place for reviewing and sentencing concession applications, prior to submission to BEG(UK) for approval, are satisfactory and being worked to. Such surveillance shall be exercised in a reasonable manner and shall be limited to those plants and processes appropriate to the non-conformance event. Surveillance of subcontractors shall be undertaken only in conjunction with BNFL staff and to the extent that BNFL are able to secure such access with their suppliers. In cases where BNFL does not have contractual right of access to suppliers it shall use all reasonable endeavours to secure such access for BEG(UK) and shall use all reasonable endeavours to ensure that such rights are incorporated into its contract with suppliers on contract review; and

ii)

audit the system in place at BNFL for the purpose of reviewing, categorising and notifying BEG(UK) of the concession applications, including confirmation of the competence of the staff employed in making decisions on BNFL’s behalf.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Such rights are without prejudice to BEG(UK)’s existing contractual rights of access to BNFL and its subcontractors.

(8)

In the event that such surveillance/audit shows in BEG(UK)’s reasonable opinion that BNFL is not acting in accordance with the procedures, including BNFL’s Quality Assurance System, referred to in Clause 6, BNFL shall forthwith and in consultation with BEG(UK), identify and implement corrective actions to ensure compliance within an Agreed timescale. BNFL shall identify and bond any Fuel and any affected Fuel components at Springfields which is subject to any concession application pending implementation of corrective action. No further concession applications shall be processed until BEG(UK) are satisfied that adequate procedures have been implemented.

(9)

In the event that BEG(UK) approves BNFL’s concession application for the said Fuel, it shall be deemed to be compliant with the Contract Specification but notwithstanding the provisions of Clause 12 shall apply, and BEG(UK) shall be entitled to recover its direct costs as provided for in Clause 13.4.BNFL shall notify BEG(UK) when all Fuel to which BEG(UK) has granted a concession has been delivered to the relevant AGR Power Station.

(10)

In the event that BEG(UK) is unable to approve BNFL’s concession application, it shall nevertheless be entitled to recover its direct costs as provided for in Clause 13.4. All costs incurred by BNFL in applying for a concession for non-compliant Fuel shall be borne by BNFL.

(11)

Notwithstanding Paragraph 10(a) of this Appendix, BNFL recognises the undesirability of supplying to BEG(UK) Fuel which is non-compliant with the Contract Specification. It shall therefore use its endeavours, through inter alia application of continuous improvement methods to control its processes and those of its suppliers, to minimise the incidence of non-compliances with the objective of eliminating non-compliances as soon as reasonably practicable.

11.

REVIEW

(a)

The quality management arrangements described by the Quality Assurance Programme shall be reviewed by BEG(UK) and BNFL at intervals of not more than one year to ensure that adequate quality assurance arrangements are maintained in order that BEG(UK) continues to receive Fuel which conforms with the Contract Specification.

(b)

The scope of the review referred to in Paragraph 11(a) shall be Agreed prior to the said review.

This Appendix 8 shall not apply to the Uranic Elements Supply Component of this Agreement prior to the passage of Uranium Material through the gates of the Springfields site.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 9

ENRICHED URANIUM STATEMENT (WIP)

AS AT / /20

BRITISH NUCLEAR FUELS PLC

WESTINGHOUSE UK FUEL BUSINESS

SPRINGFIELDS

									Units =kgU
U ACCOUNT % U235		OPENING BALANCE / /20 (1)	RECEIPTS TO FABRICATION (2)	MISC RECEIPTS (3)	MISC ISSUES (4)	BLENDING ADJUSTMENTS (5)	FUEL ISSUES (6)	OTHER ADJ (7)	FABRICATION LOSSES (8) [ ]%	CLOSING BALANCE / /20 (9)
misc
0.712	0.749
0.750	0.799
0.800	0.849
0.850	0.899
0.900	0.949
0.950	0.999
1.000	1.049
1.050	1.099
1.100	1.149
1.150	1.199

4.450	4.499
4.500	4.549
4.550	4.599
4.600	4.649
4.650	4.699
4.700	4.749
4.750	4.799
4.800	4.849
4.850	4.899
4.900	4.949
4.950	4.999
5.000	5.049
5.050	5.099
9.450	9.499
9.500	9.549

REPORT TOTALS

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 10

EXAMPLE AGR FUEL DELIVERY PLAN

STATION

WEEK 1

WEEK 2

WEEK 3

WEEK 4

AGR

Hunterston B

Central Store

Where orders are placed in the form of AGR Power Station orders and BEG AGR Power Station orders along with a replenishment order for the Central Store:

(a)

X is the contractual delivery arrival date at the AGR Power Station;

(b)

Y is the date of the return journey from the AGR Power Station to Springfields;

(c)

C is the contractual delivery date at the Central Store;

(d)

Where contractual deliveries to AGR Power Stations are redirected to the Central Store to provide additional flexibility for BEG(UK), then the contractual delivery date to the Central Store shall be the date on which the delivery would have been made to the AGR Power Station; and

(e)

In the case of Torness and Hunterston B, the outward journey and the delivery are made on the same Day and the return journey is made on the following Day.

Where, in order to streamline their Fuel ordering processes, BEG and BEG(UK) wish to place aggregate orders:

(a)

BEG(UK) shall provide to BNFL, at the time of Fuel ordering, an indicative schedule of intended deliveries to its AGR Power Stations and replenishment deliveries to the Central Store. Until the third week of the sixth Month preceding the Month of delivery, BEG(UK) may vary this schedule at its discretion. Delivery dates under this schedule shall be determined in accordance with the table above.

(b)

Deliveries on dates different from those contemplated in the table above may be scheduled by agreement between BEG(UK) and BNFL.

(c)

BNFL and BEG(UK) shall each use reasonable endeavours to develop revised delivery schedules which meet BEG(UK)’s requirements for Fuel deliveries and BNFL’s requirement for level manufacturing rates. For the avoidance of doubt, BNFL agrees that where a request from BEG(UK) results in a delivery being delayed within the Month this shall be acceptable to BNFL.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Where an order involves the use of more than one vehicle, the remaining Fuel shall be delivered on the same Day the following week, subject to prior agreement from the relevant AGR Power Station.

The AGR Fuel Delivery Plan will be updated as BEG(UK) ceases to load Fuel into any Reactor. Revised AGR Fuel Delivery Plans will be issued annually following the cessation of such Fuel loading to at least one of the Reactors.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 11

[NOT USED]

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 12

CHARGES FOR ANCILLARY COMPONENTS

Prices for the supply of Ancillary Components (as listed in Annex 1) shall be derived by adding a combined 20% engineering, procurement and warranty charge to the buying in price of externally sourced components. The prices charged to BEG(UK) shall be reviewed annually.

The price for the supply of Ancillary Components to BEG(UK) shall be determined as follows:

Sales Price equals Buying-in Price of Externally Sourced Components multiplied by 1.2

Where:

Sales Price is the price charged to BEG(UK) in Clause 5. 3; and

Buying-in Price of Externally Sourced Components is the total amount paid (whether in respect of fixed or variable costs) by BNFL for externally sourced components.

Commencing in January 2005 BNFL shall provide annually to BEG(UK) information it has determined sufficient to procure externally sourced components and to enable BEG(UK) to understand the structure and magnitude of the Buying-in Price of Externally Sourced Components for each Ancillary Component. The package of information to be provided in respect of each Ancillary Component shall be as follows:

•

The duration of the current purchase contracts.

•

BNFL’s proposals regarding purchase beyond the current purchase contract.

•

The component purchase pricing structure and price levels that apply under the current purchase contract, subject to BNFL obtaining permission from the supplier to pass on this information.

•

Anticipated changes in the manufacturing route or location.

•

The procedure that BNFL will employ to put in place a purchase contract beyond the current purchase contract for new procurements.

•

Substantial capacity and/or capital investment which may be required to maintain continuity of supply or capability.

Any proposed payments in respect of capital investment which may be required to maintain continuity of supply or capability to external suppliers that exceed the higher of £50,000 or half the annual Buying-in Price of an Externally Sourced Component shall be notified to BEG(UK) in advance.

BEG(UK) and BNFL shall meet on an annual basis prior to April each year (commencing in 2005) to review the following:

•

The Buying-in Price of Externally Sourced Components which will apply for the following financial year.

5.1

Prior to April 2005 and prior to April 2006 the values to be reviewed are those which relate to financial year 2006.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 12

ANNEX 1

TABLE OF ANCILLARY COMPONENTS

Part No.	Description	Station
021963	Tie Bar	HNB/TOR

009009	Tie Bar Retaining Collet	HNB/TOR

009010	Tie Bar Retaining Sleeve	HNB/TOR

009011	Adjusting Screw	HNB/TOR

022950	Top Reflector Assembly	HNB/TOR

022951	Finned Upper Stabilising Brush Assembly	HNB/TOR

225010	Anti Gapping Unit	HNB/TOR

015178	E Seal	HNB/TOR

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 13

[NOT USED]

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 14

EFFICIENCY AND EFFECTIVENESS

This Appendix sets down areas relating to the supply of Fuel which have been identified to date by BEG(UK) and BNFL as providing the potential for efficiency and effectiveness improvements and cost savings beyond those forming the basis upon which the charges specified in Clause 5 have been calculated.

Category 1:

The following issues have been discussed in detail and subject to the satisfactory resolution of a number of issues BEG(UK) and BNFL agree that mutual benefits can be secured. Subsequent Annexes (as indicated) set out the key issues currently identified as requiring resolution and an indication of the timescales for implementation.

•

Leadtime Reductions (see Annex 3).

•

Recycle of BEG(UK)’s reprocessed uranium ex ▇▇▇▇▇ (“ORP”) (see Annex 4).

•

Redesign of AGR Fuel brace (see Annex 5).

Category

Areas which have not been discussed in detail but which BEG(UK) and BNFL are Agreed could potentially secure benefits but require considerable further development and as such timescales for implementation and benefits cannot be estimated at the present time:

•

Reduction in number of design variants

•

Improved processes and organisational structures and elimination of non-value added activity

•

Gadolinium doping of Fuel (sleeve coating or pellet doping)

•

Uranics specification and procurement

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 14

ANNEX 1

[NOT USED]

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 14

ANNEX 2

[NOT USED]

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 14

ANNEX 3

REDUCTION IN FUEL ORDERING LEADTIME

BNFL and BEG(UK) shall seek to improve Fuel ordering lead times and associated level of uranic stock in process with the objective of reducing the cost of capital in respect of enriched uranium forming part of the Fuel manufacturing process.

BNFL and BEG(UK) agree that the introduction of the Central Store as part of finished Fuel stocks optimisation will facilitate the reduction in lead times referred to above through inter-alia smoother deliveries to AGR Power Stations and smoother Fuel manufacturing throughput.

The key issues requiring resolution are as follows:

Establish OFC monthly maximum capability.

Agree monthly Fuel range.

Establish BEG(UK) capability in respect of Fuel orders forecasting capability.

Financing of forecast errors and/or premiums for short leadtime.

Agreement on forecast accuracy commercial issues.

Rundown of OFC buffer stocks.

Agreement on level of and payment for additional costs associated with an increase in the number of Assay changes.

Agree interim arrangements that order is placed 3^rd Week of 5^th month for a 4 month leadtime and 3^rd Week of 4^th month for 3 month leadtime.

Implement 3 month leadtime, including agreement on terms and conditions to apply.

An indicative implementation programme is set out below. It is noted that this programme is outdated; BNFL and BEG(UK) will work to develop jointly a revised programme.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Uranic Lead-time reduction Implementation Programme, 1997

Task

Apr

May

Jun

Jul

Aug

Sep

Oct

Nov

Dec

OFC, Consent to operate paper preparation

▇▇▇ ▇▇▇▇▇ consent to operate

OFC reaches full capacity

OFC Change of Assay work completed

Maximum monthly capacity calc

BNFL & BEG(UK) agree interim monthly order range

Maximum monthly capacity review

BNFL & BEG(UK) agree monthly order range

BNFL, Calculate forecast accuracy costs

BEG(UK) demonstrate improved forecast accuracy

BNFL & BEG(UK) agree forecast accuracy issues

BNFL runs fuel stocks down to 2 weeks buffer

BNFL runs pins stocks down to 10,000

Trial Run 1

BEG(UK) ceases placing orders at 7 months LT

BEG(UK) takes back hex for 5^th and 6^th month ##

BNFL attempts to run at 4 months LT

1^st 4 month LT order placed on 3^rd wk of 5^th month

Surplus hex released from pseudo wip for BEG(UK) use

Trial Run 2

BEG(UK) ceases placing orders at 4 months LT

BEG(UK) takes back hex for 4^th month ##

BNFL attempts to run at 3 months LT

1^st 3 month LT order placed on 3^rd wk of 4^th month

Surplus hex released from pseudo wip for BEG(UK) use

BEG(UK) retains the hex stock for cover as pseudo wip

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Uranic Lead-time Reduction Implementation Programme, 1998

Task

Jan

Feb

Mar

Apr

May

Jun

Jul

Aug

Sep

Oct

Nov

Dec

OFC, Consent to operate paper preparation

▇▇▇ ▇▇▇▇▇ consent to operate

OFC reaches full capacity

OFC Change of Assay work completed

Maximum monthly capacity calc

BNFL & BEG(UK) agree interim monthly order range

Maximum monthly capacity review

BNFL & BEG(UK) agree monthly order range

BNFL, Calculate forecast accuracy costs

BEG(UK) demonstrate improved forecast accuracy

BNFL & BEG(UK) agree forecast accuracy issues

BNFL runs fuel stocks down to 2 weeks buffer

BNFL runs pins stocks down to 10,000

Trial Run 1

BEG(UK) ceases placing orders at 7 months LT

BEG(UK) takes back hex for 5^th and 6^th month ##

BNFL attempts to run at 4 months LT

Trail 1

1^st 4 month LT order placed on 3^rd wk of 5^th month

Surplus hex released from pseudo wip for BEG(UK) use

Trial Run 2

BEG(UK) ceases placing orders at 4 months LT

BEG(UK) takes back hex for 4^th month ##

BNFL attempts to run at 3 months LT

1^st 3 month LT order placed on 3^rd wk of 4^th month

Surplus hex released from pseudo wip for BEG(UK) use

BEG(UK) retains the hex stock for cover as pseudo wip

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Uranic Lead-time Reduction Implementation Programme, 1999

Task

Jan

Feb

Mar

Apr

May

Jun

Jul

Aug

Sep

Oct

OFC, Consent to operate paper preparation

▇▇▇ ▇▇▇▇▇ consent to operate

OFC reaches full capacity

OFC Change of Assay work completed

Maximum monthly capacity calc

BNFL & BEG(UK) agree interim monthly order range

Maximum monthly capacity review

BNFL & BEG(UK) agree monthly order range

BNFL, Calculate forecast accuracy costs

BEG(UK) demonstrate improved forecast accuracy

BNFL & BEG(UK) agree forecast accuracy issues

BNFL runs fuel stocks down to 2 weeks buffer

BNFL runs pins stocks down to 10,000

Trial Run 1

BEG(UK) ceases placing orders at 7 months LT

BEG(UK) takes back hex for 5^th and 6^th month ##

BNFL attempts to run at 4 months LT

1^st 4 month LT order placed on 3^rd wk of 5^th month

Surplus hex released from pseudo wip for BEG(UK) use

Trial Run 2

BEG(UK) ceases placing orders at 4 months LT

BEG(UK) takes back hex for 4^th month ##

BNFL attempts to run at 3 months LT

Trial 2

1st 3 month LT order placed on 3^rd wk of 4^th month

Surplus hex released from pseudo wip for BEG(UK) use

BEG(UK) retains the hex stock for cover as pseudo wip

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 14

ANNEX 4

RECYCLE OF ▇▇▇▇▇ REPROCESSED URANIUM IN AGR FUEL

ISSUES TO BE RESOLVED

BEG(UK) and BNFL shall seek to establish a supply of AGR Fuel utilising a proportion of BEG(UK)’s ex-▇▇▇▇▇ reprocessed uranium with the objective of saving avoidable costs and reducing BEG(UK)’s cost of uranics and providing BNFL with additional recycled uranium business.

Confirm MDU raw data

– Spec level to mimic MDU content of baseload material

Confirm ▇▇▇▇▇ output predictions

– Correct for level of MDU used. Comparison with actual analysis ex-▇▇▇▇▇

Crude assessment using 0.25ppb U232 as nominal spec limit, if Items 1 and 2 are not possible.

– Material usage in total. Overall savings. Material usage by year.

Savings year by year.

Confirm estimate of benefits.

Develop and agree cost model including mutual cost savings/benefits.

Safety Case Assessments

– In reactor case

– Station operations case

– BNFL transport case

– BNFL operations case

Establish the most beneficial/practical blending point.

Testing of blending logistics with the appropriate facility.

Assessment of benefits/practicalities/pitfalls of using third party conversion to start project early.

10.

Refine crude estimate identified at 4.

11.

Conclude outstanding commercial issues including terms and conditions to apply.

12.

Define implementation date.

An indicative implementation programme is set out below. Notwithstanding this programme, BNFL shall, subject to agreement of commercial terms, use all reasonable endeavours to secure conversion of BEG(UK)’s reprocessed uranium on the earliest possible timescales.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

RECYCLE OF ▇▇▇▇▇ REPROCESSED URANIUM IMPLEMENTATION PROGRAMME

Activity

Mar

Apr

May

Jun

Jul

Aug

Sep

1. Confirm MDU raw data

Establish U232 level to mimic

Establish MDU content of baseload

2. Confirm ▇▇▇▇▇ output predictions

Adjust NAMAG report figures to include initial MDU levels

New ▇▇▇▇▇ product analysis available

Compare predictions with actual analysis results ex ▇▇▇▇▇

3. Crude assessment using 0.25 ppb

Overall usage and savings calculation

Yearly usage and savings calculation for 7/4/97

4. Develop cost model

5. Safety Case assessments

6. Establish the most beneficial/practical blending point

7. Testing of blending logistics with appropriate facility

8. Assessment of the benefits/practicalities/pitfalls of using third party Conversion to start project early (ie in advance of Line 3 start up)

9. Conclude known commercial issues where appropriate

10. Refine assessment (3) and input to cost model

11. Conclude outstanding commercial issues

12. Confirm Line 3 operational dates

13. British Energy reserve capacity in Line 3

14. Define implementation date/phasing

Fabrication Milestones

OFC ORP capable (deliveries)	January	1999
First possible AGR ORP fuel (using third party conversion)	June	2000
First possible AGR ORP fuel (using Line 3 conversion) min delay	March	2001
First possible AGR ORP fuel (using Line 3 conversion) 12 mths delay	January	2002

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 14

ANNEX 5

MACHINED BRACE

ISSUES TO BE RESOLVED

BEG(UK) and BNFL shall seek to establish an improved design of AGR Fuel brace that, compared with the current design, has reduced parasitic neutron absorption properties and is simpler and quicker to manufacture, whilst ensuring the Fuel Element integrity is preserved at all stages of its life cycle. The key issues requiring resolution are as follows:

Agree a full understanding of current brace fretting mechanism subject to which BEG(UK) and BNFL shall:

Undertake a joint risk analysis study of rimmed machined braces.

Agree programme/timescales for achieving financial benefit of rimmed machine brace.

[Not Used]

Agree commercial terms to apply.

[Not Used]

An indicative implementation programme will be Agreed when the current brace fretting mechanism is understood.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 15

AGR BURNABLE POISON CABLE FLEXIBILITY

When placing a firm order for Fuel pursuant to Clause 7 of this Agreement, BEG(UK) shall provide the combination in terms of number of cables and their gadolinium density for each Fuel Element applicable to that order.

BEG(UK) shall be entitled to amend the said cable combination at any time up to the third Friday of the third Month prior to delivery up to a maximum additional cable requirement applying to all 7 stations including both BEG and BEG(UK) stations of 1400 cables, with no limitation on changes from cabled to uncabled or vice versa. BEG(UK) shall use all reasonable endeavours to provide the most accurate information in terms of cabling requirements.

Recognising that stations in the past have amended their cable requirements at the third Week of the third month prior to delivery and that due to unforeseen circumstances stations may need to change cable requirements after this date, BEG(UK) shall also be entitled up to two calendar months prior to delivery to increase or decrease cables, up to a maximum additional cable requirement applying to all 7 stations including both BEG(UK) and BEG stations of 1400, with a maximum net change at any time during each delivery period from cabled to uncabled, or vice versa, of four Fuel Stringers worth of Stage 3 Fuel.

BNFL will use all reasonable endeavours to meet BEG(UK)’s reasonable requirements above and beyond the flexibility provided in this Appendix.

The charges for this arrangement are made under the BEG Agreement.

The aforementioned arrangements shall be reviewed periodically by the Parties until at least 1 April 2006 after which BEG and BEG(UK) are required to provide a minimum of two months notice of their requirement to terminate this arrangement.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 16

AGREED PRINCIPLES: CENTRAL FUEL STORE AT SPRINGFIELDS

BEG(UK) and BNFL shall maintain a Central Store, to reduce stocks of finished Fuel at AGR Power Stations above those required to meet BEG(UK)’s stocking policy and reduce stocks held by BNFL.

Where Fuel is manufactured and delivered to the Central Store on behalf of BEG and subsequently delivered from the Central Store to a BEG(UK) AGR Power Station; or, where Fuel is manufactured and delivered to the Central Store on behalf of BEG(UK) and subsequently delivered from Central Store to a BEG AGR Power Station; then the relevant remedies, warranty and limitation of liability provisions of the fuel supply agreement relating to the Fuel in question will be those contained in the fuel supply agreement(s) of the party taking ultimate delivery from the Central Store to its AGR Power Station.

For the avoidance of doubt, BNFL’s liabilities under the arrangements above shall not be changed by any action of clause 8.3 of the BEG Agreement or of Clause 8.3 of this Agreement.

BEG(UK) and BNFL have agreed the following principles:

1. BEG(UK) shall be invoiced for Fuel (Bo, Uo and Vo) following delivery into the Central Store, subject to Paragraph 2 below.

2. BEG(UK) shall be free to bypass the Central Store and instead specify that Fuel should be delivered directly to its AGR Power Station.

3. Tripartite BEG/BEG(UK)/BNFL planning meetings shall take place on a monthly basis to discuss, inter alia:

BEG/BEG(UK)’s delivery requirements;

ii.

the Central Store stock levels; and

iii.

replenishment schedules.

4. BEG(UK) shall use all reasonable endeavours to assist BNFL to smooth production whilst not prejudicing its own commercial requirements.

5. BEG(UK) shall express any requirements it has for BNFL to adjust production rates to satisfy its requirements. Such views shall not be unreasonably disregarded by BNFL.

6. For the purposes of ordering leadtimes, delivery will be deemed to be into the Central Store, subject to paragraph 2 above.

7. Delivery destination for Fuel existing in the Central Store shall be specified by BEG(UK) one month ahead with provision for the occasional shorter period of notice by agreement with BNFL and subject to payment of any reasonable and demonstrable additional costs, if the period of notice given is less than one month. For the avoidance of doubt, subject to paragraph 2, BEG(UK) cannot request Fuel to be delivered to an AGR Power Station until it is physically in the Central Store.

8. Further arrangements regarding Fuel order details and timescales shall be Agreed as part of the agreement on the operation of the Central Store.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

9. Ownership of the Fuel (including associated uranics) in the Central Store as between BEG and BEG(UK) shall be agreed between them. Risk in the Fuel shall pass to BEG or BEG(UK) as agreed between them when the Fuel passes into the Central Store and they shall make appropriate insurance arrangements. Said risk shall revert to BNFL when the Fuel passes out through the door of the Central Store.

10. BEG(UK) and BNFL shall work together, in good faith, to agree ways to reduce or eliminate the documentation flowing from the current operation of Clause 8.3 and/or to simplify the same.

11. Operating costs and any capital expenditure for the duration of the contract related to the Central Store shall be borne by BNFL. BNFL shall be responsible for day to day management of the Central Store.

12. The maximum capacity of the Central Store shall be 1000 elements in respect of all 7 BEG/BEG(UK) advanced gas—cooled power stations. The allocation of said capacity shall be as agreed between them.

13. Current liquidated damages arrangements shall be retained in their entirety and be applicable to both delivery to the store and delivery to stations in accordance with a delivery programme Agreed with BNFL, except in the case of delivery to station where there will be 50% of the current rate for Fuel which has been supplied from the Central Store. Late delivery into the Central Store would result in liquidated damages being incurred at the rate of 100% of the current rate for Fuel.

14. Subject to paragraph 11 above, each of BEG(UK) and BNFL shall bear its own costs of implementing the Central Store.

15. Costs of any changes in transport requirements beyond the current frequency shall be Agreed on a case by case basis.

16. BEG(UK) and BNFL agree to co-operate to continuously work to identify improvements to the process and utilisation of the Central Store to their mutual benefit.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 17

THE SHARING OF BENEFITS RESULTING FROM DESIGN CHANGES

1. Fuel Design Changes

These are changes that alter the design of Fuel such that Fuel burn-up can be improved and thereby provide benefits in one or more of the following forms:

•

reduced uranium requirement.

•

reduced Fuel fabrication.

•

reduced New Spent Fuel management services.

The guiding principle on Fuel design change benefits sharing will be:

For each Fuel design change not covered by section 2 below, all benefits arising from reduced requirements for uranium, Fuel fabrication and spent Fuel management services will be recorded in a joint account (the Joint Account) (dedicated to the design change) which will accumulate such benefits for an Agreed period of time (Agreed Period). The Joint Account will then be used to provide reimbursement to a party for a demonstrated cost or loss (reasonably incurred and agreed in advance between the parties), which was directly and solely attributable to the particular Fuel design change in question. At the end of the Agreed Period, the accumulated net benefit will be shared between BEG(UK) and BNFL in direct proportion to the agreed relative commercial risks taken by the parties in implementing the change.

BEG(UK) and BNFL may also consider the sharing of further benefits following on from the Agreed Period. In this event BEG(UK) and BNFL shall consider the sharing of any further benefits as they arise from the irradiation of such Fuels provided that they have been supplied under the Fuel supply agreement(s) prior to the closure of the final AGR Power Station. Where mechanisms which do not require cash transfer can be identified, these will be applied to provide settlement.

Each proposed project will be reviewed at a very early stage to confirm whether this principle can be applied. Where the principle cannot be applied, Agreement on an alternative will be sought. Where such an alternative cannot be Agreed, the project will not proceed.

It is agreed that this principle should be applied to the optimised can wall project, with costs lying where they fall and therefore not affecting this project’s particular joint account, the net benefit of which is to be shared equally between BEG(UK) and BNFL. The method for calculating the benefits arising is to be Agreed.

2. Alterations within the Current Design Framework

These are changes that alter the configuration of the Fuel within the current design framework, for example, altering uranium Assays or burnable poison cable configurations, such that Fuel burn-up can be improved and thereby provide benefits in the following forms:

•

reduced Fuel fabrication.

•

reduced New Spent Fuel management services.

•

increased Reactor availability.

The guiding principle on current design framework benefits sharing will be:

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

BEG(UK) and BEG will retain all benefits from all alterations within the current design framework that may lead to reduced requirements for Fuel fabrication or New Spent Fuel management services, or to increased Reactor availabilities. BNFL will be compensated for any Agreed and substantiated increased costs (reasonably incurred and Agreed in advance) that it was not possible to mitigate by working jointly.”

It is agreed that this principle should be applied to the implementation of Fuel with U-235 weight percent Assay greater than 2.67% and 3.42% for positioning in the inner and outer zones respectively with a maximum Assay of 3.78% achieved in 2001.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 18

PRICES PAYABLE FOR AGR FUEL SUPPLY

Part A

For so long as BEG and BEG(UK) together are loading Fuel into either Reactor of four or more of the BEG AGR Power Stations or the AGR Power Stations, the following charges shall apply:

Subject to Schedule A of this Appendix, the Annual Fixed Charge Ao shall be derived as follows:

Annual Fixed Charge Ao = ((1-P_i)*A1) minus ((1-P_i)* D2)

Where:

A1 equals the fixed charge detailed in the table below.

P_i equals the final BEG annual fixed charge discount proportion, being a value between zero and one, jointly agreed by BEG and BEG(UK) and notified to BNFL, by BEG(UK) under this Agreement and by BEG under the BEG Agreement, for use in the annual reconciliation. For the avoidance of doubt, Pi shall have the same numerical value when used both in this Agreement and in the BEG Agreement.

D2 equals the variable discount derived as follows:

D2 = the higher of (i) zero and (ii) the lower of

[ ]* and (([ ]* minus OEP)*5TWh)

Where:

OEP is calculated as laid down in Appendix 20, and shall be specified to five significant figures.

The sums of [ ]* and [ ]* are quoted in Financial Year 2003 money values and will be escalated annually in accordance with Appendix 7. The multiplier of 5.0 TWh is a fixed figure and shall not be subject to escalation.

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

		FIXED (A1) £Million pa
Combined Range under this Agreement and the BEG Agreement (Fuel Elements)		[ ]*


		[ ]*


		VARIABLE (Bo) £/Fuel Element
Combined Range under this Agreement and the BEG Agreement (Fuel Elements)		[ ]*


		[ ]*

The values for A1 and Bo are quoted in July 2002 money values and will be escalated in accordance with Appendix 7.

14 days prior to the date on which BNFL is required to invoice BEG(UK) pursuant to Clause 5.15, the estimated annual fixed charge (Aoest) pertaining to the month of invoice shall be calculated according to the following formula:

Aoest = ((1-Piest)*A1est) – minus ((1-Piest)*D2est))

Where:

A1est

is the estimated escalated value of A1 for the relevant month derived in accordance with Appendix 7.

Piest

is, for monthly invoicing purposes, the fixed charge discount proportion (being a value between zero and one) agreed jointly between BEG and BEG(UK) and notified to BNFL by BEG(UK) under this Agreement and by BEG under the BEG Agreement. The value of Piest used in the pre—reconciliation monthly invoicing may be changed by BEG and BEG(UK), provided that BNFL is notified at least 2 weeks prior to the date by which the fixed charge invoice for the particular month in question is to be received by BEG(UK) in accordance with Clause 5.15. For the avoidance of doubt, Piest shall have the same numerical value when used both in this Agreement and in the BEG Agreement.

D2est

is the estimated value of D2 for the Year derived using a forecast value of OEP (= OEPest) and escalating the terms in the equation for D2 above in accordance with Appendix 7.

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Where:

OEPest

is derived in accordance with Appendix 20, and shall be specified to five significant figures.

The monthly fixed charge invoiced in each month shall be adjusted such that the Year to date value of the discount D2 as invoiced at that month end, equals the latest projected cumulative Year to date value of the discount D2 applicable to that month end.

In executing the algorithms outlined in this Appendix 18, all calculations will be performed to maximum normal computational accuracy, with no imposed rounding to specific levels of precision.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Part B

For the period where BEG and/or BEG(UK) are loading Fuel into either Reactor of three, two or one of the BEG AGR Power Stations or the AGR Power Stations (the New Pricing Period), the price shall be set on the basis of the recommendations of the Joint Study Team, with a view to lowering the full costs of production of Fuel and sharing the benefits. BEG(UK) and BNFL agree to use their respective reasonable endeavours to achieve this objective to the maximum feasible extent, including with respect to the sharing of information. In the event that the Joint Study Team is unable to Agree upon any recommendations which lead to the lowering of the full costs of production of Fuel and the sharing of the benefits, BEG(UK) and BNFL agree that in such circumstances, the provisions of Clause 28 shall be applicable. In particular, BEG(UK) and BNFL hereby agree that the terms of reference of the arbitration shall be Agreed and shall include but not necessarily be limited to:

(i)

estimated cost of providing services over the New Pricing Period, including allowance for new capital investment;

(ii)

efficiency of labour and resource utilisation in the supply of Fuel to BEG(UK), together with any scope for improvement during the New Pricing Period;

(iii)

allocation of plant, overheads and other costs to the overall cost of supplying Fuel to BEG(UK); and

(iv)

costs associated with ensuring the security of supply of components and Ancillary Components.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Part C

Uranics (Uo)

1.1

The quantity of Uranic Elements contained in the Enriched Uranium Material which is fed to the Fuel fabrication process to produce the said Fuel will be invoiced pursuant to Clause 5.15.1.2 by BNFL to BEG(UK) at the date the Fuel containing the Enriched Uranium Material is delivered to BEG(UK). To cover for Process Losses, an equivalent of [ ]* of the Enriched Uranium Material contained in the delivered Fuel shall be added to the total quantity of Enriched Uranium Material used to produce the said Fuel and this shall be included in the derivation of Uo. The value of [ ]* shall be reviewed periodically by BEG(UK) and BNFL.

1.2

The quantities of the Uranic Elements delivered in Fuel will be multiplied by the [ ]* of the Uranic Elements at the date of delivery of Fuel to BEG(UK) in accordance with this Agreement.

1.3

The quantity of Uranic Elements contained in Enriched Uranium Material will be identified as originating from one of the 3 following tranches:

1.3.1

Inventory Tranche: comprising material owned by BNFL as Initial Stocks;

1.3.2

Contract Tranche: comprising material supplied under the Contracts (the Contract Stocks); and

1.3.3

Market Tranche: comprising all other materials (the Market Stocks).

1.4

The [ ]* of the Uranic Elements will be established on a First In First Out (FIFO) basis of tranche exhaustion as follows:

1.4.1

The [ ]* of the Initial Stocks, until the quantity of the Initial Stocks is deemed to be exhausted;

1.4.2

The [ ]* of the Contract Stocks, until the total quantity procured under the Contracts is deemed to be exhausted;

1.4.3

The [ ]* of the Market Stocks once the total quantity procured under the Contracts is deemed exhausted on a FIFO basis.

1.5

The following formulae shall be used sequentially in the order in which they appear below to determine the tranche from which each Uranic Element (“x”) contained in the quantity of Uranium Material despatched in Fuel for each month (“r”) is deemed to have been sourced.

1.5.1

If ISQ_xr>0 , then R_xr=R(IS)_xr

1.5.2

If ISQ_xr>0 and if R_xr > ISQ_xr and if R_xr <= ISQ_xr + CSQ_xr, then R_xr = ISQ_xr + R(CS)_xr where R(CS)_xr = R_xr-ISQ_xr

1.5.3

If ISQ_xr>0 and if CSQ_xr >0 and if R_xr > ISQ_xr and if R_xr >ISQ_xr + CSQ_xr, then R_xr = ISQ_xr + CSQ_xr + R(MS)_xr where R(MS)_xr = R_xr-ISQ_xr-CSQ_xr

1.5.4

If ISQ_xr=0 and if R_xr <= CSQ_xr, then R_xr = R(CS)_xr

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

1.5.5

If ISQ_xr=0 and if CSQ_xr >0 and if R_xr > CSQ_xr, then R_xr= CSQ_xr + R(MS)_xrwhere R(MS)_xr = R_xr-CSQ_xr

1.5.6

If ISQ_xr=0 and if CSQ_xr =0, then R_xr = R(MS)_xr

Where:

CSQ_xr represents the quantity of Contract Stocks of Uranic Element x in month r

ISQ_xr represents the quantity which remains of the Initial Stocks of Uranic Element x in month r

R_xrrepresents the quantity of Uranic Element x required for the fabrication of Fuel in month r

R(CS)_xr represents the quantity of Uranic Element x required for the fabrication of Fuel in month r deemed to have been supplied from the Contract Stocks of Uranic Element x in month r

R(IS)_xr represents the quantity of Uranic Element x required for the fabrication of Fuel in month r deemed to have been supplied from the Initial Stocks of Uranic Element x in month r

R(MS)_xr represents the quantity of Uranic Element x required for the fabrication of Fuel in month r deemed to have been supplied from Market Stocks of Uranic Element x in month r

Incidental Services (Vo)

2.1

The incidental services shall cover transport, insurance, cylinder washing, cylinder hire and uranic analysis.

2.2

The price for Fuel will be calculated by multiplying the tonnes of uranium delivered in Fuel of each Assay by a charge of [ ]* per tonneU.

2.3

The incidental services charge Vo will be invoiced on a monthly basis as described in Clause 5.15.1.2.

2.4

The prices referred to in paragraph 2.2 are expressed in January 2003 money values and shall be Escalated in line with the Retail Price Index from this date as determined in accordance with Appendix 7.

Administration Charge (Wo)

3.1

The monthly Administration Charge shall be the sum of Administration Charges for each Uranic Element [ ]*

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

3.2

Fourteen Working Days prior to the date on which BNFL is required to invoice BEG(UK) under Clause 5.15.1.2, BEG(UK) shall notify BNFL of the proportion of the Administration Charge which shall apply to BEG(UK) in the calculation under paragraph 3.1 above, and the proportion of the Administration Charge which shall apply to BEG in the relevant clause under the BEG Agreement for the relevant month. For the avoidance of doubt, the sum of the proportions of the Administration Charge given to BNFL by BEG(UK) shall always be equivalent to the total Administration Charge at the date on which BNFL is required to invoice BEG(UK) under Clause 5.15.1.2.

3.3

In the event that the Uranic Elements Supply Component of this Agreement is terminated pursuant to Clause 2.2.1, 22 or 24 of this Agreement, or the Uranics Term ends in connection with BNFL ceasing to carry on business in Fuel supply or as described in Clause 34, the monthly Administration Charge shall be the sum of Administration Charges for each Uranic Element, [ ]*

3.4

The Administration Charge (Wo) will be invoiced on a monthly basis as described in Clause 5.15.1.2.

3.5

The Administration Charge Rate is [ ]*

Service Charge (Xo)

4.1

A Service Charge of [ ]* per annum in respect of the Uranic Elements Supply Component of this Agreement shall be payable by BEG(UK) under this Agreement and by BEG under the BEG Agreement in the amounts determined pursuant to paragraph 4.2 below.

4.2

Fourteen Working Days prior to the date on which BNFL is required to invoice BEG(UK) under Clause 5.15.1.2, BEG(UK) shall notify BNFL of the proportion of the Service Charge which shall be invoiced to BEG(UK) under this Agreement, and the proportion of the Service Charge which shall be invoiced to BEG under the BEG Agreement, for the relevant month. For the avoidance of doubt, the sum of the proportions of the Service Charge given to BNFL by BEG(UK) and BEG shall always be equivalent to the Escalated value of the total Service Charge of £[ ]* applicable at the date on which BNFL is required to invoice BEG(UK) under Clause 5.15.1.2.

4.3

The Service Charge Xo will be invoiced on a monthly basis as described in Clause 5.15.1.2.

4.4

The Service Charge referred to in paragraph 4.1 is in January 2003 money values and will be Escalated in line with the Retail Price Index from this date in accordance with Appendix 7.

* Confidential treatment requested.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 19

LIST OF DOCUMENTS FOR CONDITIONS

PART A: AGREEMENTS BETWEEN BNFL AND BEG

BACK-END AGREEMENTS

1.1 The Agreement for New Spent Fuel Management Services to be entered into between BNFL, BEG and BE.

1.2 Deed of Amendment to be entered into between BNFL and BEG, relating to the agreement for the Storage and Reprocessing of Irradiated Oxide Fuel and Related Services between BNFL and Nuclear Electric plc dated 31 March 1995, as amended and novated.

1.3 Deed of Amendment to be entered into between BNFL and BEG, relating to the agreement for Spent Fuel Management Services between BNFL and Nuclear Electric Limited dated 3 June 1997, as amended.

1.4 Deed of Amendment to be entered into between BNFL and BEG, relating to the agreement for Oxide Flask Maintenance between BNFL and Nuclear Electric plc dated 31 March 1996, as amended and novated.

1.5 Deed of Amendment to be entered into between BNFL and BEG, relating to the new agreement for Oxide Flask Maintenance between BNFL and Nuclear Electric Limited dated 3 June 1997, as amended.

1.6 Deed of Amendment to be entered into between BNFL and BEG, relating to the agreement for Rail Transport Services of Irradiated Nuclear Fuel in the United Kingdom between BNFL and Nuclear Electric Limited dated 3 June 1997, as amended.

1.7 Deed of Amendment to be entered into between BNFL and BEG, relating to the agreement for Oxide Miscellaneous Services between BNFL and Nuclear Electric plc dated 31 March 1996, as amended and novated.

FRONT-END AGREEMENTS

2.1 Deed of Amendment and Guarantee between BNFL, BEG and BE dated the same date as this Agreement, relating to the Agreement for the Supply of Fuel for Use in Advanced Gas Cooled Reactors between BNFL and Nuclear Electric Limited dated 3 June 1997, as amended.

2.2 Agreement for the Supply of Fuel for Use in Advanced Gas Cooled Reactors from 1 April 2006 between BNFL, BEG and BE dated the same date as this Agreement.

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

PART B: AGREEMENTS BETWEEN BNFL AND BEG(UK)

BACK-END AGREEMENTS

1.1 The Agreement for New Spent Fuel Management Services to be entered into between BNFL, BEG(UK) and BE.

1.2 Deed of Amendment to be entered into between BNFL and BEG(UK), relating to the agreement for the Storage and Reprocessing of Irradiated Oxide Fuel and Related Services between BNFL and Scottish Nuclear Limited dated 30 March 1995, as amended, and to the agreement for the Long Term Storage of Irradiated Oxide Fuel and Related Services dated 30 March 1995 between BNFL and Scottish Nuclear Limited, as amended.

1.3 Deed of Amendment to be entered into between BNFL and BEG(UK), relating to the agreement for Oxide Flask Maintenance between BNFL and Scottish Nuclear Limited, dated 29 March 1996, as amended.

1.4 Deed of Amendment to be entered into between BNFL and BEG(UK), relating to the new agreement for Oxide Flask Maintenance Services between BNFL and Scottish Nuclear Limited, dated 3 June 1997, as amended.

1.5 Deed of Amendment to be entered into between BNFL and BEG(UK), relating to the agreement for Rail Transport Services of Irradiated Nuclear Fuel in the United Kingdom between BNFL and Scottish Nuclear Limited, dated 3 June 1997, as amended.

1.6 Deed of Amendment to be entered into between BNFL and BEG(UK), relating to the agreement for Oxide Miscellaneous Services between BNFL and Scottish Nuclear Limited, dated 29 March 1996, as amended.

FRONT-END AGREEMENT

2.1 Deed of Amendment and Guarantee between BNFL, BEG(UK) and BE dated the same date as this Agreement, relating to the Agreement for the Supply of Fuel for Use in Advanced Gas Cooled Reactors between BNFL and Scottish Nuclear Limited dated 30 March 1995, as amended.

100

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 20

CALCULATION OF OUTTURN ELECTRICITY PRICE

Intention

BNFL and BEG(UK) agree that it is their intention to establish a price index that reflects the baseload wholesale electricity price that the BEG(UK) Group’s advanced gas-cooled reactor generation would be exposed to, subject to a specified treatment of any future environmental legislation. This price index (the Outturn Electricity Price or OEP) will be used to calculate rebates and surcharges on contractual payments for Fuel and receipt of spent Fuel and so provide the BEG(UK) Group with a partial hedge of the electricity price risk associated with its advanced gas-cooled reactor output.

The price is calculated on the basis of publicly available market price indicators, with a weighting of 75% to contracts sold for a season during the preceding six months, and the remaining 25% to contracts sold on a month-ahead basis. For the Year commencing on 1 April 2003, an annual pricing mechanism shall be used in place of the seasonal calculation, so as to ensure consistency of value with the Heads of Terms.

BNFL and BEG(UK) will establish a means of calculating, before all of the data are available that are required to calculate the Outturn Electricity Price for a particular Year, a forecast of the Outturn Electricity Price for that Year (Forecast Outturn Electricity Price).

THE OUTTURN ELECTRICITY PRICE

Definitions

Actual Level of AGR Generation – defined in section 3.

Additional AGR Environmental Value – for any Year, the additional effective price achievable by baseload advanced gas-cooled reactor generation beyond that captured in Initial Outturn Electricity Price, that arises directly from Environmental Legislation. The calculation of such achievable price shall take into account the potential to access the most favourable price across different market segments (including for the avoidance of doubt sales directly to consumers), net of the incremental costs of accessing such market segments to achieve such prices or any other costs imposed on nuclear generation associated with such Environmental Legislation. For the avoidance of doubt, the Additional AGR Environmental Value may only be a positive number or zero.

Agreed Price Reporter – A Price Reporter whose prices BNFL and BEG(UK) have agreed or the Expert has determined should be included in making the calculations required in this contract.

Average Price for the Month – the arithmetic mean of the Daily Price for the Month across all Trading Days that fall predominantly within the period from the start of the previous Pricing Month to its end.

Average Price for the Season – the arithmetic mean of the Daily Price for the Season across all Trading Days that fall predominantly within the period from the start of the previous Pricing Season to its end.

Average Price for the Year – for any Year, the arithmetic mean across all Trading Days within the two Pricing Seasons that fall predominantly within the previous Year and across

101

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

both Pricing Seasons that fall predominantly within the Year, of the Daily Price for the Season for the two Pricing Seasons that fall predominantly within the Year.

Daily Price for the Month – for any Trading Day, the volume-weighted mean across all Agreed Price Reporters of the prices of contracts traded on that Trading Day for baseload electricity for a particular Pricing Month. In the event that no such trades are reported by any Agreed Price Reporter for that Trading Day, the arithmetic mean of the bid and offer prices quoted on that day across all Agreed Price Reporters for the relevant Pricing Month shall be used in place of the mean of the prices of contracts traded.

Daily Price for the Season – for any Trading Day, the volume-weighted mean across all Agreed Price Reporters of the prices of contracts traded on that Trading Day for baseload electricity for a particular Pricing Season. In the event that no such trades are reported by any Agreed Price Reporter for that Trading Day, the arithmetic mean of the bid and offer prices quoted on that day across all Agreed Price Reporters for the relevant Pricing Season shall be used in place of the mean of the prices of contracts traded.

Environmental Legislation – any carbon tax, exemption of nuclear generation from the Climate Change Levy, or any other climate change related measure put in place by HMG subsequent to 29 November 2002 which affects the value of nuclear generation (but for the avoidance of doubt excluding any changes in rates payable by BEG or BEG(UK)).

Fuel Contract Equivalent Electricity Volume – for the period where BEG and BEG(UK) taken together are loading Fuel to 4 or more advanced gas-cooled reactor power stations the Fuel Contract Equivalent Electricity Volume shall be 5 TWh. For the period where BEG and BEG(UK) taken together are loading Fuel to 3 or fewer AGR power stations the Fuel Contract Equivalent Electricity Volume shall be set on the basis of recommendations of the joint team established to study the end of life optimisation programme, as contemplated in Part B of Appendix 5 of this Agreement.

Initial Outturn Electricity Price – (a) for the Year ending 31 March 2004, the sum of 0.75 times the Average Price for the Year and 0.25 times the arithmetic mean of each Average Price for the Month for the twelve Pricing Months falling predominantly within that Year; and (b) for each subsequent Year, the sum of 0.75 times the arithmetic mean of each Average Price for the Season for the two Pricing Seasons falling predominantly within that Year and 0.25 times the arithmetic mean of each Average Price for the Month for the twelve Pricing Months falling predominantly within that Year.

Outturn Electricity Price – for any Year, the Initial Outturn Electricity Price plus the Additional AGR Environmental Value minus (the Prior Contract Value Pass-through divided by (the sum of 50% of the Actual Level of AGR Generation and the Fuel Contract Equivalent Electricity Volume)).

Price Reporter – an organisation which regularly publishes price indices and/or traded prices that are generally accepted to correspond closely with the fair price obtainable in the market for baseload wholesale electricity contracts in the English and Welsh market (or following the introduction of the British Electricity Trading and Transmission Arrangements (BETTA), the English, Welsh and Scottish market) covering Pricing Seasons and Pricing Months.

Pricing Month – a period of time for delivery of electricity, usually either 4 or 5 weeks in length, that corresponds to the delivery period for electricity contracts referred to as “months” in the reports compiled by the Agreed Price Reporters.

102

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Pricing Season – a period of time for delivery of electricity, usually 26 weeks in length, that corresponds to the delivery period for electricity contracts referred to as “seasons” (either summer or winter) in the reports compiled by the Agreed Price Reporters.

Prior Contract Value Pass-through – for any Year, the financial equivalent of all benefits arising from Environmental Legislation passed from any company within the BEG(UK) Group to third parties other than BNFL as a result of contracts already in force as at 29 November 2002.

Trading Day – any day, other than a Saturday, a Sunday, Christmas Day, Good Friday, or a day which is a bank holiday in England within the meaning of the Banking and Financial Dealings ▇▇▇ ▇▇▇▇.

2. THE FORECAST OUTTURN ELECTRICITY PRICE

Definitions

Forecast AGR Generation in Year – The sum of Forecast BEG AGR Generation in Year and Forecast BEG(UK) AGR Generation in Year.

Forecast BEG AGR Generation in Year – The latest forecast provided by BEG(UK) to BNFL of the total metered generation delivered by the BEG AGR Power Stations to the electricity transmission system within the current Year. This will be on a basis consistent with any external announcements of forecast advanced gas-cooled reactor generation adjusted to be net of transmission losses as applicable.

Forecast BEG(UK) AGR Generation in Year – The latest forecast provided by BEG(UK) to BNFL of the total metered generation delivered the AGR Power Stations to the electricity transmission system within the current Year. This will be on a basis consistent with any external announcements of forecast advanced gas-cooled reactor generation adjusted to be net of transmission losses as applicable.

Forecast Average Price for the Month – (a) The Forecast Average Price for the Month for a Pricing Month that falls wholly or partly in the past shall equal the Average Price for the Month for that Pricing Month. (b) The Forecast Average Price for the Month for Pricing Months that fall wholly in the future (but excluding the first Pricing Month that falls wholly in the future) shall equal the Spot Balance of Season Price for the Pricing Season in which the Pricing Month falls. (c) The Forecast Average Price for the Month for the first Pricing Month that falls wholly in the future shall equal:

((d * (Arithmetic mean of the Daily Price for the Month calculated over the first d Trading Days for which data are available of the current Pricing Month)) + ((n-d)*(the Daily Price for the Month calculated on Trading Day d of the current Pricing Month for which data are available)))/(n)

where d is the number of Trading Days for which data are available at the point of calculation and n is the total number of Trading Days in the current Pricing Month

Forecast Average Price for the Season – (a) Prior to the start of the Pricing Season the Forecast Average Price for the Season shall equal

103

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

((D’ * (Arithmetic mean of the Daily Price for the Season on the first D’ Trading Days for which data are available of the previous Pricing Season)) + ((N’-D’)*(the Daily Price for the Season calculated on Trading Day D’ of the previous Pricing Season for which data are available)))/(N’)

where D’ is the number of Trading Days for which data are available at the point of calculation and N’ is the total number of Trading Days in the previous Pricing Season;

and (b) during a Pricing Season, the Forecast Average Price for the Season for that Pricing Season shall equal the Average Price for the Season for that Pricing Season.

Forecast Average Price for the Year – Prior to the start of the Year the Forecast Average Price for the Year shall equal the arithmetic mean of the Year Ahead Forecast Season Price for the two Pricing Seasons falling predominantly within the Year. During the Year the Forecast Average Price for the Year shall equal the Average Price for the Year.

Forecast Environmental Adjustment – the latest estimate as provided by BEG(UK), or as determined by an Expert, of the expected difference between Outturn Electricity Price and Initial Outturn Electricity Price for any Year.

Forecast Initial Outturn Electricity Price – (a) for the Year ending 31 March 2004, the sum of 0.75 times the Forecast Average Price for the Year and 0.25 times the arithmetic mean of each Forecast Average Price for the Month for the twelve Pricing Months falling predominantly within that Year; and (b) for each subsequent Year, the sum of 0.75 times the arithmetic mean of each Forecast Average Price for the Season for the two Pricing Seasons falling predominantly within that Year and 0.25 times the arithmetic mean of each Forecast Average Price for the Month for the twelve Pricing Months falling predominantly within that Year.

Forecast Outturn Electricity Price – the sum of Forecast Initial Outturn Electricity Price and Forecast Environmental Adjustment.

Spot Balance of Season Price – The arithmetic mean across all Agreed Price Reporters of the bid-offer midpoints for the period starting on the first Trading Day of the second Pricing Month falling wholly in the future or the first Trading Day of the Pricing Season, whichever is the later, and ending on the last Trading Day of the Pricing Season. The period mid points should be constructed from the finest granularity bid-offer data available from each Agreed Price Reporter.

Year Ahead Forecast Season Price – The Year Ahead Forecast Season Price for a Pricing Season falling predominantly in a given Year shall equal:

104

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

((D * (Arithmetic mean of the Daily Price for the Season on the first D Trading Days for which data are available of the two Pricing Seasons that fall predominantly within the previous Year)) + ((N-D)*(the Daily Price for the Season calculated on Trading Day D of the two Pricing Seasons that fall predominantly within the previous Year for which data are available)))/(N), where D is the number of Trading Days for which data are available at the point of calculation and N is the total number of Trading Days in the two Pricing Seasons that fall predominantly within the previous Year

THE ACTUAL LEVEL OF AGR GENERATION

The Actual Level of AGR Generation shall represent the total amount of electricity delivered by the AGR Power Stations and the BEG AGR Power Stations in the Year to the point on the electricity transmission system at which the Outturn Electricity Price is determined.

BNFL and BEG(UK) agree that the calculations below shall be used:

For England and Wales Stations:

Actual Level of BEG AGR Generation in England and Wales = [GRAPHICS APPERAS HERE]

Where:

i = BM Units belonging to Reactors in the BEG AGR Power Stations that have not permanently ceased generation

j = Settlement Periods in Year

QM_ij=BMU Metered Volume for BMU i in Settlement Period j

TLM_ij=BMU Transmission Loss Multiplier for BMU i in Settlement Period j

For Scottish Stations:

Actual Level of BEG(UK) AGR Generation in Scotland =

Where:

i= BM Units over the England and Wales system as a whole

j= Settlement Periods in Year

k = BM Units belonging to Reactors in the AGR Power Stations that have not permanently ceased generation

105

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

QM_ij⁺ = BMU Metered Volume for exporting BMU i in Settlement Period j

QM_ij^- = BMU Metered Volume for importing BMU i in Settlement Period j

a = the percentage share from time to time determined of the total net system losses attributable to the BM Units that belong to delivering trading units (as those terms are used in paragraph T2 of the Balancing and Settlement Code) for Settlement Period j, which as at the date hereof is 45%.

V_jk= GNN Station output of Reactors in the AGR Power Stations k in Settlement Period j.

GNN Station output represents the electricity sent to the grid net of what is used on the power station site.

Actual Level of AGR Generation = Actual Level of BEG AGR Generation in England and Wales + Actual Level of BEG(UK) AGR Generation in Scotland.

Where appropriate, the terms above shall be used in the sense in which they are used in the Balancing and Settlement Code.

In the event that the allocation of transmission losses is varied, or BETTA is introduced, or the ownership of any of the AGR Power Stations or the BEG AGR Power Stations changes, or any of the terms above ceases to be available to either or both of BNFL and BEG(UK), then such parties shall agree such changes to the above calculation to give effect to the principle outlined in the definition of Actual Level of AGR Generation. In the event that BNFL and BEG(UK) are unable to reach agreement on such changes, then the matter shall be referred to an Expert for determination.

In the event that some or all of the items of data required to calculate the Actual Level of AGR Generation is not available to BNFL, BEG(UK) shall provide BNFL with such items of data that BNFL reasonably requires within 5 Trading Days of BNFL requesting said items of data.

PROTOCOL

Agreed Price Reporters

BNFL and BEG(UK) shall from time to time agree who shall represent the Agreed Price Reporters. Initially the Agreed Price Reporters shall be:

•

Argus European Energy Report

•

The Heren Report – European Daily Electricity Markets

There shall always be at least one and not more than five Agreed Price Reporters. If BNFL and BEG(UK) are unable to agree on the Price Reporters then the matter will be referred to an Expert who will be required to determine which Price Reporters shall be the Agreed Price Reporters. BNFL and BEG(UK) may agree to exclude or adjust a price quoted from one or more Agreed Price Reporters. Any corrections issued by the Agreed Price Reporters after the initial publication of their reports shall be taken into account in these calculations. BNFL and BEG(UK) may agree to exclude or adjust such corrections.

In the event that the relevant reported market prices become unavailable from any Agreed Price Reporter on either a temporary or permanent basis, or that such prices have ceased to be appropriate for use (e.g. due to illiquidity underlying such index) such that the Outturn

106

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Electricity Price calculated by this methodology has ceased to provide a fair reflection of the baseload wholesale electricity prices that the BEG(UK) Group’s advanced gas-cooled reactor generation would be exposed to (subject to the specified treatment of any future environmental legislation), BNFL and BEG(UK) shall agree a suitable alternative, and/or an adjustment to the overall mechanism for the establishment of the Initial Outturn Electricity Price, such that the commercial basis of the agreement is not altered.

In the event of any market developments or other changes, the effect of which is to render any part of the calculation of Outturn Electricity Price unworkable or inappropriate, BNFL and BEG(UK) will negotiate in good faith to reach an agreement on such changes as are required to preserve the original economic intent. In the event that BNFL and BEG(UK) are unable to reach agreement on such changes, then the matter shall be referred to an Expert for determination.

Environmental Legislation

In the event that BNFL and BEG(UK) are unable to reach agreement on the existence of any Environmental Legislation or the treatment of any of the calculations associated with such Environmental Legislation then the matter shall be referred to an Expert for determination. The scope of any Expert determination shall include all aspects of the process of deriving Outturn Electricity Price from Initial Outturn Electricity Price except where both BNFL and BEG(UK) explicitly waive this condition.

Provision of Estimates

BEG(UK) shall make good faith estimates of the Forecast Environmental Adjustment as required to meet the timescales of invoicing. In the absence of such an estimate for any particular invoice, the last estimate provided or determined for that Year shall be used, where the initial estimates of Forecast Environmental Adjustment for each Year in the contract are deemed to be zero. In the event of any dispute by BNFL of the level of, or requirement for, such an estimate that is not resolved within 10 Trading Days of the dispute being raised, either BNFL or BEG(UK) may refer the matter to an Expert for determination.

BEG(UK) shall make good faith estimates of the Forecast AGR Generation in Year as required to meet the timescales of invoicing. In the event of any dispute by BNFL of the level of such an estimate that is not resolved within 10 Trading Days of the dispute being raised, either BNFL or BEG(UK) may refer the matter to an Expert for determination.

Expert Determination

If any matter is referred to an independent expert (the Expert) in accordance with this Appendix, the Expert shall be appointed by agreement between BNFL and BEG(UK). If BNFL and BEG(UK) fail to agree upon that appointment within 10 Trading Days of either BNFL or BEG(UK) notifying the other of its decision to refer the matter to an Expert, the President of the Law Society of England and Wales may appoint the Expert on the application of the relevant Party.

The Expert shall have power to make amendments to this Agreement binding on the Parties consistent with any relevant requirements, purposes or restrictions concerning those amendments expressly provided for in this Agreement. The Parties agree that it is their intention that in the absence of their ability to agree any required amendments to this Agreement, this Agreement should continue and not come to an end or be deemed to be void or voidable in accordance with the doctrine of frustration or any other legal theory. Accordingly, if the Expert is unable to decide upon any amendments based on the express or

107

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

implied intentions of the Parties, the Expert shall be entitled to have regard to the way in which similar issues or amendments are addressed or are proposed to be addressed by other electricity industry participants and to substitute the Expert’s own view of what is reasonable in all the circumstances.

The Expert shall act as an expert and not as an arbitrator and shall give his or her determination in writing. In the absence of fraud or manifest error, the determination of the Expert shall be final, conclusive and binding upon the Parties.

The Expert shall determine the procedure to be followed by the Expert for the purpose of making a determination provided that the Parties shall use their respective reasonable endeavours to ensure that he or she makes his or her determination within 20 Trading Days of being appointed. Each of the Parties shall bear one half of the costs of the Expert unless the Expert determines otherwise. Pending the determination of any amendments to this Agreement by the Parties or the Expert, the Parties shall continue to the extent possible to perform their obligations under this Agreement.

Audit

In the event that BNFL is wholly reliant on information provided by BEG(UK) to enable BNFL to calculate or check BEG(UK)’s calculations of any of the factors required to calculate the Outturn Electricity Price, the Forecast Outturn Electricity Price, or the Actual Level of AGR Generation, BEG(UK) shall at all times upon reasonable notice allow BNFL’s auditors, its officers, agents and other persons authorised by BNFL in writing (or, at BEG(UK)’s request, as applicable, an independent auditor agreed between the Parties or appointed by the Expert in the event that the Parties cannot agree) to have access to inspect the basis on which BEG(UK) has provided such information. BEG(UK) shall keep such books and records as BNFL may reasonably require for the purpose of verifying said information. The records detailed in this clause shall be retained by BEG(UK) and made readily available upon reasonable notice for inspection by BNFL, its officers appointed agents or independent auditor as applicable for a minimum period of 2 Years from the date of the record.

108

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 21

PRICING PRINCIPLES

General

1.1

Enriched Uranium Material delivered from each of the Inventory Tranche, Contract Tranche or Market Tranche shall be disaggregated into the Uranic Elements. The method of disaggregation shall be as described in Part F of Appendix 31.

1.2

The quantity deemed to be derived from each tranche for each Uranic Element shall be calculated in accordance with paragraph 1 of Part C, Appendix 18.

1.3

The total amount to be charged to BEG(UK) for Uo in any month will be:

Uo= (CI_xr +CC_xr+ CM_xr) *PL

Where:

CC_xr means the charge for each Uranic Element x in month r from the Contract Tranche.

CI_xr means the charge for each Uranic Element x in month r from the Inventory Tranche.

CM_xr means the charge for each Uranic Element x in month r from the Market Tranche.

PL is the factor which accounts for the allowance for Process Losses referred to in Appendix 18 Part C paragraph 1.1, which at the date of this Agreement shall be [ ]*.

Inventory Tranche

2.1

Initial Stocks

2.1.1

An [ ]* for each Uranic Element shall be determined by dividing the [ ]* for that Uranic Element by the quantity of that Uranic Element of the Initial Stocks. The resulting value will be expressed as £ per Uranic Element and shall be calculated as follows:

[ ]*

2.1.2

The quantity of each Uranic Element delivered from the Inventory Tranche in any month shall be multiplied by the [ ]* for that Uranic Element when determining the amount to be charged for any Fuel delivery and shall be calculated as follows:

* Confidential treatment requested.

109

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

[ ]*

Contract Tranche

3.1

In respect of the Contract Stocks, a [ ]* for each Uranic Element will be determined by dividing [ ]*. The resulting value will be expressed as £ per Uranic Element and shall be calculated as follows:

[ ]*

3.2

The Contract Stock Quantity for each Uranic Element in any month will be determined as the aggregate of the quantities of all deliveries of the Uranic Elements under the Contracts under which such Uranic Elements are supplied, less the quantity of each Uranic Element supplied from the Contract Tranche for that Uranic Element to the date of such determination.

3.3

The Contract Stock Purchase Price for each Uranic Element in any month will be determined as [ ]*

3.4

The quantity of the Uranic Element delivered from the Contract Tranche in any month will be multiplied by the [ ]* for that Uranic Element at that date when determining the amount to be charged for any Fuel delivery until such time as each relevant Uranic Element comprised in the Contract Stocks is reduced to zero and shall be calculated as follows:

[ ]*

Market Tranche

4.1

In respect of Market Stocks, a [ ]* for each Uranic Element will be established by dividing the Market Stocks Price for that Uranic Element by the quantities of Market Stocks of that Uranic Element. The resulting value will be expressed as £ per Uranic Element and shall be calculated as follows:

[ ]*

* Confidential treatment requested.

110

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

4.2

The quantity of Market Stocks for each Uranic Element in any month will be determined as the aggregate of the quantities of all deliveries under the New Contracts or New Uranics Commitments for that Uranic Element at any time, less the quantity of each Uranic Element supplied from the Market Stocks for that Uranic Element to the date of such determination.

4.3.

The Market Stocks Price for each Uranic Element in any month will be determined as [ ]*

4.4

The quantity of the Uranic Element delivered from the Market tranche in any month will be multiplied by the [ ]* for that Uranic Element at that date when determining the amount to be charged for any Fuel delivery until such time as each Uranic Element comprised in the Contract Stocks is reduced to zero, and shall be calculated as follows:

[ ]*

Currency Conversion

The conversion rate for any currency to its Pounds Sterling Equivalent (as defined in Appendix 26) will be the spot rate as published by the Financial Times within two Working Days of the receipt of the invoice from a supplier for relevant goods and services (or such rate as may be Agreed between BEG(UK) and BNFL in the event that such rate or publication is discontinued).

* Confidential treatment requested.

111

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 22

SECURITY OF SUPPLY POLICY

The Security of Supply Policy shall take into account the following considerations:

1.1

a reasoned analysis of security of supply in the whole supply chain based on contracts and stocks specifically allocated by BNFL for the supply of Fuel to BEG(UK) under this Agreement, commencing with procurement through to finished Fuel stocks in the Central Store in relation to Fuel orders and addressing the probability of interruption at each separate stage;

1.2

the level of uranic stocks required to safeguard:

1.2.1

the continuity of delivery into the fabrication process; and

1.2.2

generation;

1.3

the level of stocks required to protect against any reasonable risk of disruption in respect of the items in paragraph 1.2;

1.4

information on the level of stocks, BNFL’s own global uranic stocks and BNFL’s access to other security stocks and contracts portfolio, together with the terms under which such security stocks could be made available to BEG(UK) in the event that it is called upon. This will allow BEG(UK) to decide upon reducing its level of security stocks;

1.5

supply source diversity;

1.6

corporate risk of each relevant supplier;

1.7

A schedule of critical security measures; and

1.8

mismatched lead times for fabrication and Enrichment.

The Security of Supply Policy may have due regard to the items listed in paragraph 1 of Appendix 25.

The target level of inventory including all Uranium Material will be “n” months of forward Fuel requirements and “n” will be decided by BEG(UK), provided that “n” shall not exceed the policy levels set out in the Side Letter Agreement dated the same date as this Agreement between BEG and BNFL.

The Security of Supply Policy shall also take into account other considerations, including quality assurance and environmental issues, to the extent that they are relevant notwithstanding that such considerations may not be listed in paragraph 1 above.

The list of items in paragraph 1 above may be amended upon the request of either BEG(UK) or BNFL to the Uranics Review Board, which will consider such request and agree or reject the proposed amendments. Upon agreement of the proposed amendments, BEG(UK) and BNFL shall conclude the amendments to this Appendix in writing, which amendments shall take immediate effect.

112

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 23

URANICS REVIEW BOARD

The Uranics Review Board shall comprise two representatives of each of BEG(UK) and BNFL appointed by BEG(UK) and BNFL respectively.

The primary role of the Uranics Review Board is to review and recommend the draft Security of Supply Policy for the approval of the Board of Directors of BEG(UK). The Uranics Review Board may also consider such information or requests from either BEG(UK) or BNFL which BEG(UK) or BNFL are permitted to put before the Uranics Review Board for acceptance under this Agreement.

The Uranics Review Board shall meet annually, on or before the last Working Day in January in each relevant Year. The purpose of the meeting shall be to accept (if necessary, subject to such modifications as shall be agreed with BEG(UK) and BNFL) or reject the Draft Security of Supply Policy proposed by BEG(UK) under Clause 4.5 or BNFL under paragraph 7 of Appendix 24. The Uranics Review Board shall also meet at other times as required by this Agreement.

The Uranics Review Board shall decide its own order of business for its annual and other meetings referred to in paragraph 3 above.

The Uranics Review Board shall issue detailed minutes of meetings within 3 Working Days of any meeting. The original copies of such minutes will be held by the Uranics Review Board, and a copy of such minutes shall be sent to each of BEG(UK) and BNFL promptly after such minutes are issued.

113

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 24

REVIEW OF SECURITY OF SUPPLY POLICY

Two weeks prior to the last Working Day in January in each relevant Year, BEG(UK) shall submit to the Uranics Review Board a draft Security of Supply Policy in writing for the procurement of uranic supplies and for the assurance of security of supply. The draft Security of Supply Policy shall address the issues listed in Appendix 22—Security of Supply Policy.

The Uranics Review Board shall consider the draft Security of Supply Policy submitted by BEG(UK) at its annual meeting, and shall either accept (subject to such modifications as may be proposed by it) or reject the draft Security of Supply Policy.

If the Uranics Review Board accepts the draft Security of Supply Policy in the form proposed by BEG(UK) or subject to such modifications as may be proposed by it, the draft Security of Supply Policy shall become the final Security of Supply Policy.

The Uranics Review Board is deemed to have rejected the draft Security of Supply Policy if it does not accept the draft Security of Supply Policy on or before the last Working Day in February of each relevant Year.

If the Uranics Review Board rejects the draft Security of Supply Policy (or is deemed under paragraph 4 to have rejected the draft Security of Supply Policy), BNFL shall be entitled to present to the Uranics Review Board its own draft Security of Supply Policy by no later than the last Working Day of the second week of February of each relevant Year, which the Uranics Review Board shall either accept (subject to such modifications as may be proposed by it) or reject the draft Security of Supply Policy.

If the Uranics Review Board rejects the draft Security of Supply Policy pursuant to paragraph 5 above, the failure to agree the draft Security of Supply Policy shall be referred to Arbitration pursuant to Clause 28. Notwithstanding the timescales as set out in Clause 28, but subject to the following conditions: the Arbitrator shall present a determination by no later than the last working day in March of the relevant Year. Upon receipt of the decision of the Arbitrator, the draft Security of Supply Policy subject to any modifications proposed by the Arbitrator shall become the final Security of Supply Policy.

Each new final Security of Supply Policy referred to in paragraphs 3 and 6 shall replace any previous final Security of Supply Policy in its entirety.

If either BNFL or BEG(UK) have reasonable grounds to believe at any time that the final Security of Supply Policy requires amendment to meet the objectives of this Agreement, either party may propose such amendment for the Uranics Review Board for consideration. If such amendments are accepted by the Uranics Review Board, the final Security of Supply Policy will be amended in accordance with the amendments accepted by the Uranics Review Board with effect from the date of acceptance by the Uranics Review Board.

114

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 25

STOCK AND PROCUREMENT STRATEGY CONSIDERATIONS

The Stock and Procurement Strategy will consider the following amongst other considerations. A reasoned analysis of the optimum contract portfolio designed to minimise the prices of delivering Uranic Elements to BEG(UK) in each year and to provide the optimum level of supply security. The portfolio shall be specified in terms of the following, with reasons given for inclusion or exclusion of possible recommendations:

1.1

prices and price mechanism options;

1.2

geographical origins and options;

1.3

corporate origin and options;

1.4

safeguards obligations and options;

1.5

trade restrictions;

1.6

quantity options;

1.7

advance and deferment options;

1.8

interpretability based on reactor performance;

1.9

Uranic Elements form and form options;

1.10

delivery and delivery options;

1.11

currency and currency options; and

1.12

all other relevant distinguishing characteristics.

The analysis referred to in paragraph 1 shall take account of existing stocks, BNFL’s existing contract portfolio, forecast stocks, the condition of manufacturing at Springfields, and all other relevant factors including (but not limited to):

2.1

access to supply markets;

2.2

relative costs of holding stocks;

2.3

long term contract coverage;

2.4

supply source diversity;

2.5

corporate risk of each relevant supplier;

2.6

fabrication lead times;

2.7

management of operational stocks;

115

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

2.8

UOC, Conversion Services and Enrichment risks;

2.9

trade restrictions;

2.10

logistics issues; and

2.11

fabrication catch-up times.

116

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 26

PRICING REVIEW

The following definitions shall apply in this Appendix 26:

1.	*New Uranics Commitment*	means New Contracts and New Uranics Commitments;

2.	*Monthly New Supply Cost*	means the sum of the Monthly New UOC Cost, Monthly New UF₆, Monthly New Enriched UF₆ Cost, Monthly New Conversion Services Cost and the Monthly New Enrichment Cost in any month;

3.	*Monthly New Supply Value*	means the sum of the Monthly New UOC Value, Monthly New UF₆, Monthly New Enriched UF₆ Value, Monthly New Conversion Services Value and the Monthly New Enrichment Value in any month;

4.	*Monthly New UOC Cost*	means the price paid or to be paid in Pounds Sterling Equivalent by BNFL for the delivery of the applicable quantity of UOC to BNFL pursuant to a New Uranics Commitment in any month;

5.	*Monthly New UF₆ Cost*	means the price paid or to be paid in Pounds Sterling Equivalent by BNFL for the delivery of the applicable quantity of UF₆ to BNFL pursuant to a New Uranics Commitment in any month;

6.	*Monthly New Enriched UF₆ Cost*	means the price paid or to be paid in Pounds Sterling Equivalent by BNFL for the delivery of the applicable quantity of Enriched UF₆ to BNFL pursuant to a New Uranics Commitment in any month;

7.	*Monthly New Conversion Services Cost*	means the price paid or to be paid in Pounds Sterling Equivalent by BNFL for the delivery of the applicable quantity of Conversion Services to BNFL pursuant to a New Uranics Commitment in any month;

8.	*Monthly New Enrichment Cost*	means the price paid or to be paid in Pounds Sterling Equivalent by BNFL for the delivery of the applicable quantity of Enrichment to

117

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

		BNFL pursuant to a New Uranics Commitment in any month;

9.	*Monthly New UOC Value*	means the sum calculated in Pounds Sterling Equivalent by multiplying each Relevant Market Price to each applicable quantity of UOC delivered to BNFL pursuant to a New Uranics Commitment in any month;

10.	*Monthly New UF₆ Value*	means the sum calculated in Pounds Sterling Equivalent by multiplying each Relevant Market Price to each applicable quantity of UF₆ delivered to BNFL pursuant to a New Uranics Commitment in any month;

11.	*Monthly New Enriched UF₆ Value*	means the sum calculated in Pounds Sterling Equivalent by multiplying each Relevant Market Price to each applicable quantity of Enriched UF₆ delivered to BNFL pursuant to a New Uranics Commitment in any month;

12.	*Monthly New Conversion Services* *Value*	means the sum calculated in Pounds Sterling Equivalent by multiplying each Relevant Market Price to each applicable quantity of Conversion Services delivered to BNFL pursuant to a New Uranics Commitment in any month;

13.	*Monthly New Enrichment*	means the sum calculated in Pounds Sterling Equivalent by multiplying each Relevant Market Price to each applicable quantity of Enrichment delivered to BNFL pursuant to a New Uranics Commitment in any month;

14.	*Relevant Market Price*	has the meaning given to that term in paragraph 4 of this Appendix 26; and

15.	*Pounds Sterling Equivalent*	means the cost or value stated in 1 April 2003 money values after conversion from another currency in accordance with paragraph 7 of this Appendix 26 and adjusted in accordance with the provisions of paragraph 6 of this Appendix 26.

16.	*TTLT U₃O₈ (R)*	means the Restricted Long Term U₃O₈ Price in US$ per lb U₃O₈ published by TradeTech LLC;

17.	*TTST U₃O₈ (R)*	means the Exchange Value in US$ per lb U₃O₈ published by TradeTech LLC;

118

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

18.	*UX U₃O₈ (R)*	means the Spot U₃O₈ Price in US$ per lb U₃O₈ published by Ux Consulting Company LLC;

19.	*RN U₃O₈ (R)*	means the maximum price specified in the Uranium Spot Market Price Range in US$ per lb U₃O₈ published by RWE Nukem Inc;

20.	*RN U₃O₈ (UR)*	means the minimum price specified in the Uranium Spot Market Price Range in US$ per lb U₃O₈ published by RWE Nukem Inc;

21.	*TTLT CS (Europe)*	means the European Long Term Conversion Services Price in US$ per kgU published by TradeTech LLC;

22.	*TTST CS (Europe)*	means the European Spot Conversion Services Price in US$ per kgU published by TradeTech LLC;

23.	*UX CS (Europe)*	means the European Spot Conversion Services Price in US$ per kgU published by Ux Consulting Company LLC;

24.	*RN CS (Europe)*	means the maximum price specified in the Spot Conversion Price Range in US$ per kgU published by RWE Nukem Inc;

25.	*TTST CS (UR)*	means the North American Spot Conversion Services Price in US$ per kgU published by TradeTech LLC;

26.	*UX CS (UR)*	means the North American Conversion Services Price in US$ per kgU published by Ux Consulting Company LLC;

27.	*RN CS (UR)*	means the minimum price specified in the Spot Conversion Price Range in US$ per kgU published by RWE Nukem Inc;

28.	*TTLT SWU (R)*	means the Long Term SWU Price in US$ per SWU published by TradeTech LLC;

29.	*TTST SWU (R)*	means the Restricted Spot SWU Price in US$ per SWU published by TradeTech LLC;

30.	*UX SWU (R)*	means the Restricted Spot SWU Price in US$ per SWU published by Ux Consulting Company LLC;

31.	*RN SWU (R)*	means the maximum price specified in the Separative Work Spot/Secondary Price Range in US$ per SWU published by RWE Nukem Inc;

119

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

32.	*UXRU Discount*	means the Spot U₃O₈ discount in US$ per lb from the Restricted U₃O₈ price in US$ per lb published by Ux Consulting Company LLC to calculate the price for Unrestricted U₃O₈;

33.	*TTST SWU (UR)*	means the Unrestricted Spot SWU Price in US$ per SWU published by TradeTech LLC

34.	*UX SWU (UR)*	means the Unrestricted Spot SWU Price in US$ per SWU published by Ux Consulting Company LLC

35.	*RN SWU (UR)*	means the minimum price specified in the Separative Work Spot/Secondary Price Range in US$ per SWU published by RWE Nukem Inc;

BNFL shall calculate the following items in relation to deliveries to BEG(UK) of each of UOC, UF₆, Enriched UF₆, Conversion Services and Enrichment during each month:

1.1.

the Monthly New Supply Cost;

1.2.

the Monthly Supply Value;

1.3.

the Execution Effectiveness Ratio brought out by dividing the sum of the Monthly New Supply Costs (in pounds sterling) for the immediately preceding 12 months by the sum of the Monthly Supply Values (in pounds sterling) for the immediately preceding 12 months; and

1.4.

Where quantities of any good or service are excluded in the calculation of Monthly Supply Value under paragraph 1.2 of this Appendix due to the unavailability of the relevant price indicators applicable to such goods or services, such quantities if any shall also be excluded from the calculation in paragraph 1.1 of Part B of this Appendix. In any event, the quantities of any good or service used for the calculations in paragraphs 1.1 and 1.2 of this Appendix shall only be included if they are identical in respect of such good or service and if a relevant value can be applied pursuant to paragraph 4 of this Appendix.

BNFL shall provide the calculations under paragraph 1 of this Appendix to BEG(UK) on or before the last Working Day in each month immediately following the month to which the calculations are based, together will sufficient detail as may be necessary for BEG(UK) to satisfy itself of the correctness of the calculations and the information and assumptions upon which the calculations are based. BEG(UK) shall act reasonably in making any decision with regard to the detail and accuracy of the calculation.

The Relevant Market Prices are intended to reflect the prices that a reasonably competent procurer of Uranic Elements would be capable of achieving by the competent execution of the Security of Supply Policy. The Relevant Market Prices are also intended to reflect the prices pertaining to the month in which the commitment of any future delivery was executed by BNFL taking into account (where relevant):

3.1.

the geographical origin of the Uranic Elements;

120

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

3.2.

relevant nuclear safeguards obligation code;

3.3.

trade restrictions; and

3.4.

any other relevant matter that is reflected in published or otherwise obtainable prices.

Subject to the provisions of paragraph 5 of this Appendix 26, the following market prices (the Relevant Market Prices) shall apply:

*BASE ESCALATED CONTRACTS WITH FLOOR AND CEILING*

Commodity and Service		Applicable Relevant Price (The levels of Floors and Ceilings shall be deemed to be as agreed between the parties in the final Security of Supply Policy, prior to BNFL entering into any New Uranics Commitments, as being reasonable in all the circumstances prior to BNFL entering into any New Uranics Commitments.)

New UOC (Restricted) “UOC(R)”		Arithmetic Mean of TTLT U₃O₈ (R) and ((TTST U₃O₈ (R) + UX U₃O₈ (R) + RN U₃O₈ (R)) divided by 3)

New Conversion Services (Restricted) “CS(R)”		Arithmetic Mean of (TTLT CS (Europe) and ((TTST CS (Europe) + UX CS (Europe) + RN CS (Europe) divided by 3)

New Enrichment (Restricted) “SWU(R)”		Arithmetic Mean of (TTLT SWU (R) and ((TTST SWU (R) + UX SWU (R) + RN SWU (R)) divided by 3)

New UOC (Unrestricted) “UOC(UR)”		Arithmetic Mean of ((TTLT U₃O₈ (R) less the UXRU Discount and (((TTST U₃O₈ (R) + UX U₃O₈ (R)) each less the UXRU Discount) + RN U₃O₈ (RU) divided by 3))

New Conversion Services (Unrestricted) “CS(UR)”		Arithmetic Mean of (TTLT CS (UR) + ((TTST CS (UR) + UX CS (UR) + RN CS (UR)) divided by 3))

New Enrichment (Unrestricted) “SWU(UR)”		Arithmetic Mean of ((TTST SWU (UR) + TTLT SWU (R) – TTST SWU (R)) + ((TTST SWU (UR) + UX SWU (UR) + RN SWU (UR)) divided by 3))

*MARKET RELATED CONTRACTS WITH FLOOR AND CEILING*

Commodity and Service		Applicable Relevant Price (The levels of Floors and Ceilings shall be deemed to be as agreed between the parties in

121

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

		the final Security of Supply Policy as being reasonable in all the circumstances prior to BNFL entering into any New Uranics Commitments.)

New UOC (Restricted) “UOC(R)”		Arithmetic Mean of TTST U₃O₈ (R) + UX U₃O₈ (R) + RN U₃O₈ (R)

New Conversion Services (Restricted) “CS(R)”		Arithmetic Mean of TTST CS (Europe) + UX CS (Europe) + RN CS (Europe)

New Enrichment (Restricted) “SWU(R)”		Arithmetic Mean of TTST SWU (R) + UX SWU (R) + RN SWU (R)

New UOC (Unrestricted) “UOC(UR)”		Arithmetic Mean of (TTST U₃O₈ (R) + UX U₃O₈ (R)) each less UXRU Discount + RN U₃O₈ (UR)

New Conversion Services (Unrestricted) “CS(UR)”		Arithmetic Mean of TTST CS (Europe) + UX CS (Europe) + RN CS (Europe)

New Enrichment (Unrestricted) “SWU(UR)”		Arithmetic Mean of (TTST SWU (UR) + UX SWU (UR) + RN SWU (UR)

*SPOT CONTRACTS*

New UOC (Restricted) “UOC(R)”		Arithmetic Mean of TTST U₃O₈ (R) + UX U₃O₈ (R) + RN U₃O₈ (R)

New Conversion Services (Restricted) “CS(R)”		Arithmetic Mean of TTST CS (Europe) + UX CS (Europe) + RN CS (Europe)

New Enrichment (Restricted) “SWU(R)”		Arithmetic Mean of TTST SWU (R) + UX SWU (R) + RN SWU (R)

New UOC (Unrestricted) “UOC(UR)”		Arithmetic Mean of (TTST U₃O₈ (R) + UX U₃O₈ (R)) each less UXRU Discount + RN U₃O₈ (UR)

New Conversion Services (Unrestricted) “CS(UR)”		Arithmetic Mean of TTST CS (Europe) + UX CS (Europe) + RN CS (Europe)

New Enrichment (Unrestricted) “SWU(UR)”		Arithmetic Mean of TTST SWU (UR) + UX SWU (UR) + RN SWU (R)

*EXERCISE OF CONTRACT OPTIONS*

New UOC (Restricted) “UOC(R)”		TTLT U₃O₈ (R)

New Conversion Services (Restricted) “CS(R)”		TTLT CS (Europe)

122

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

New Enrichment (Restricted) “SWU(R)”		TTLT SWU (R)

New UOC (Unrestricted) “UOC(UR)”		TTLT U₃O₈ (R) less UXRU Discount

New Conversion Services (Unrestricted) “CS(UR)”		TTLT CS (UR)

New Enrichment (Unrestricted) “SWU(UR)”		(TTST SWU(UR) + TTLT SWU(R) - TTST SWU(R))

*OTHER PRICING MECHANISMS*

Other Price Mechanisms		Methodology to be agreed between the parties as may be reasonable at the time.

4.1

The evaluation of each of the market prices shall be for the month end immediately prior to the month of execution of New Uranic Commitment unless stated otherwise.

4.2

For the purpose of calculating the value of natural UF₆ for any mechanism, the relevant value for UOC will be multiplied by 2.61286, and added to the relevant value of Conversion Services.

4.3

For the purpose of calculating the value of enriched UF₆ for any mechanism, the Feed Factor and SWU Factor will be calculated in accordance with Appendix 31 Part G. The calculation of the value of any item of Enriched UF₆ will be in accord with Appendix 31 Part F where BV_UF6 is the value of natural UF₆ for any mechanism (where the relevant value for UOC will be multiplied by 2.61286, and added to the relevant value of Conversion Services and the result multiplied by the Feed Factor) and BV_SWU is the value of SWU for any mechanism (where the relevant value for SWU will be multiplied by the SWU Factor) for any Assay.

If in the reasonable opinion of either BEG(UK) or BNFL more than one of the spot or long term price indicators referred to in paragraph 4 of this Appendix are discontinued, or no longer reflect the spot or long term market price for the Uranic Elements to which they relate, BNFL and BEG(UK) shall give notice to the other and request a meeting to discuss and select a replacement indicator or a new method for determining such spot or long term price. If BNFL and BEG(UK) cannot agree on a replacement indicator(s) or a new method within sixty (60) days after the date of the notice referred to above, either BEG(UK) or BNFL may, at any time thereafter, submit a selection of new indicator(s) or a new method for determining spot or long term price to Arbitration pursuant to Clause 28.

All charges, sums and other monetary values contained in this Appendix are stated in 1 April 2003 money values (unless expressly provided otherwise) and shall be Escalated in accordance with the provisions of Appendix 7.

The conversion rate for any currency to Pounds Sterling Equivalent will be at the spot rate as published by the Financial Times two days following the date of execution of each New Uranics Commitment (or such rate as Agreed between BEG(UK) and BNFL in the event that such rate or publication is discontinued).

123

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 27

PORTFOLIO MANAGEMENT REPORT AND

MONTHLY UPDATE TO THE PORTFOLIO MANAGEMENT REPORT

The Portfolio Management Report shall include the following information in relation to the supply to BEG(UK) of Uranic Elements under this Agreement:

1.1

a monthly forecast for the following 3 year period in respect of invoiced Fuel and procured Uranic Elements;

1.2

an annual forecast for the remaining lives of the AGR Power Stations;

1.3

a valuation of Uranium Material held by BNFL for the purpose of supplying Fuel to BEG(UK);

1.4

a summary of planned and actual supplies into and out of the stocks held by BNFL pursuant to this Agreement in respect of each component of uranics or Enrichment and Conversion Services;

1.5

a summary of Uranic Elements transactions in accordance with the Stock and Procurement Strategy;

In respect of the items listed in paragraph 1 above, BNFL shall also include in the Portfolio Management Report information relating (but not limited to) the origin of the Uranic Elements supplied or to be supplied by BNFL to BEG(UK) under this Agreement, relevant safeguards obligation codes of all Uranic Elements supplied under this Agreement, and applicable Euratom Supply Agency contract numbers.

The items listed in paragraphs 1 and 2 above may be amended upon agreement between BEG(UK) and BNFL. Upon agreement as to the proposed amendments, BEG(UK) and BNFL shall conclude the amendments to this Appendix in writing, which amendments shall take immediate effect.

124

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 28

AMENDMENTS ON TERMINATION OF THE URANICS SUPPLY COMPONENT

OF THIS AGREEMENT

1. General

This Appendix lists the amendments to this Agreement which shall take effect where the Uranics Term ends on the date specified in Clause 2.28, as referred to in Clause 2.4.3.

2. Amendments

2.1

Recitals (G) and (H) shall be deleted.

2.2

The following definitions shall be inserted:

“Certified UF₆means Enriched UF₆ which has been received by BNFL and for which a certificate of analysis has been issued pursuant to clause 7 of the Agreement for the Provision of Services Relating to the Transportation and Storage of Enriched UF₆ and Tails UF₆ dated 31 March 1995, or has a self certification certificate issued by either TENEX, Urenco, Eurodif or USEC;”

Eurodif means Eurodif SA, ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇▇▇▇▇;

Operational Stock means that operational account referred to in Clause 8 of the Agreement for the Provisions of Services Relating to the Transportation and Storage of Enriched UF₆ and Tails dated 31 March 1995 as amended;

Process Float means Enriched Uranium Material in process at Springfields in excess of material to be fabricated into Fuel currently on order;

USEC means the United States Enrichment Corporation.”

2.3

The definitions of “Enriched Uranium Material” and “UF₆” shall be deleted and replaced as follows:

“Enriched Uranium Material means products belonging to BEG(UK) created during the processing of enriched Fuel including but not limited to UF₆, UO2 and UOC powders, Fuel Pellets and process residues;”

“UF₆ means uranium hexafluoride;”

2.4

Clauses 2.2 and 2.36 shall be deleted.

2.5

Clauses 4.2 to 4.7 (inclusive) shall be deleted and replaced with:

“4.2 BNFL shall provide all materials other than Enriched UF₆ and Process Float, and all services necessary to manufacture and deliver Fuel to AGR Power Stations, throughout the Fuel Supply Period.

4.3 BNFL shall maintain a WIP account for Enriched UF₆or other Enriched Uranium Material for the purposes of carrying out services under this Agreement. BEG(UK) shall

125

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

make available to BNFL at Springfields, sufficient Enriched UF₆or other Enriched Uranium Material to allow BNFL to fulfil the relevant order together with an additional 10% of the said material for Process Float and an allowance for Process Losses of 0.3% of the said material less the Enriched Uranium Material made available as Process Float with the order for Fuel placed pursuant to Clause 7.6 previous to the said order, one month following the placing of an order for Fuel pursuant to Clause 7.4 or, in the event that the Fuel ordering leadtime has been reduced from the third week of the seventh Month, at the same time as the Fuel order. Subject to Clause 4.3.4, the allocations of uranium for the supply of Fuel at the higher enrichments of 3.07% and 3.78% shall be managed as follows:

4.3.1

WIP_i, kg-U = 43.0* (1 + Process Float % + Process Losses %) * S(FE Order)_i;

Where S(FE order)_iis the total number of Fuel Elements at Assay i% for which uranium is required to be allocated in accordance with Clause 4.3;

4.3.2

Each month the Enriched Uranium Materials’ quantities for the most recent month’s Fuel orders to be included in the WIP requirement will be adjusted as follows:

(a)

For 3.78% Fuel – increase mass requirement by 20%

(b)

For 3.07% Fuel – a mass equal to the increase in mass at 3.78%

(c)

For 3.42% Fuel – decrease mass requirement by mass increases made at 3.78% and 3.07% in (a) and (b) above

(d)

For 2.67% Fuel – no change

4.3.3

BEG(UK) entitlement to such additional allocations at 3.78% and 3.07% in the WIP account at Springfields shall be equivalent to the quantity and Assay that would result if such materials were blended together;

4.3.4

Where BEG(UK) is not utilising the Assays referred to in Clause 4.3.2, then within one month of the date of expiry or early termination of the Uranics Term, BNFL and BEG(UK) shall Agree the basis upon which BEG(UK) shall make Enriched Uranium Material available to BNFL, provided that the basis upon which BEG(UK) shall make Enriched Uranium Material available to BNFL shall be consistent with the basis upon which BNFL utilised Enriched Uranium Material during the Uranics Term.

4.4

The Enriched Uranium Material specified in Clause 4.3 shall be made available by BEG(UK) to BNFL at Springfields either as Certified UF₆, as UF₆prior to certification as Certified UF₆, or as otherwise Agreed and in standard international 30B transport containers or other such containers as may be Agreed. The said Enriched UF₆or Enriched Uranium Material referred to in Clause 4.3 shall be made available to BNFL by means of a written instruction from BEG(UK) which shall specify the Enriched UF₆or Enriched Uranium Material to be transferred from BEG(UK)’s Operational Stock account at BNFL to BEG(UK)’s AGR WIP account at BNFL.

126

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

4.5

On termination of the Fuel Supply Period BNFL shall return to BEG(UK) in a prompt manner and in accordance with an Agreed programme Enriched Uranium Material and Process Float in a form suitable for Fuel fabrication.

4.6

Any loss of separative work due to blending and residue recovery shall be dealt with in accordance with the procedures described in Appendix 4.

4.7

4.7.1

BNFL’s production programmes for BEG(UK) products;

4.7.2

notification of possible BNFL supply difficulties;

4.7.3

BEG(UK)’s predictions of Fuel requirements;

4.7.4

BEG(UK)’s future requirements for Fuel design changes; and

4.7.5

quality assurance related matters.

For the avoidance of doubt, such information exchange shall in no way prejudice the operations, terms and conditions contained elsewhere in this Agreement.”

2.6

The words “for the purpose of supplying Fuel to BEG(UK) under this Agreement” appearing in Clauses 4.8.1.1 and 4.8.1.2 shall be deleted and replaced with the words “on BEG(UK)’s behalf.”

2.7

Clauses 4.9 to 4.15 (inclusive) shall be deleted and replaced with:

“4.9

BNFL shall be liable for risk of damage to or loss of Enriched UF₆or Enriched Uranium Material made available by BEG under Clause 4.3. In the event of such damage or loss, BNFL shall forthwith and at BEG(UK)’s request either replace the damaged or lost material with material of equivalent quantity, specification and quality, or reimburse BEG(UK) for the actual cost of the damaged or lost material.

4.10

[NOT USED]

4.11

[NOT USED]”

2.8

Clause 5.1 shall be deleted and replaced with:

“5.1 Charges for Fuel Elements (other than Instrumented Fuel) of Existing Designs on the Approved Product List within the quantity range described in Clause 7.1.1 shall be comprised of two charging components, a fixed annual component (Ao) and a variable component (Bo). Ao and Bo are specified in Appendix 18. The said charges set down in Appendix 18 are subject to escalation from 1 July 2002 or Financial Year 2003 as appropriate, in accordance with the formulae set out in Appendix 7 and shall cover all the costs and liabilities associated with providing the said Fuel Elements (including for the avoidance of doubt, those associated with the manufacture, storage and transport, decommissioning, treatment and disposal of all Waste) except where specifically provided for elsewhere in this Agreement or other agreements with BEG(UK).”

127

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

2.9

Clause 5.15.1.2 shall be deleted and replaced with the following:

“5.15.1.2

BNFL shall submit invoices to BEG(UK) on or before the last Sunday of the month for:

(a)

the per Fuel Element charges (Bo) in respect of each Fuel Element delivered; and

(b)

in respect of Fuel deliveries during the month to which the invoices relate and BEG(UK) shall pay the said invoices on or before the twentieth day of the following month or the first Working Day thereafter.”

2.10

Sub-clauses 7.4.4 to 7.4.9 (inclusive) shall be deleted.

2.11

The following words appearing at the end of Clause 9.2 shall be deleted:

“This Clause shall not apply to the Uranic Elements Supply Component of this Agreement.”

2.12

The following words appearing at the end of 12.4 shall be deleted.

“This Clause 12.4 shall not apply in the event that, and to the extent that, BNFL demonstrates to the reasonable satisfaction of BEG(UK) that its inability to deliver Fuel to BEG(UK) is solely and directly caused by the forecasts provided by BEG(UK) pursuant to Clause 7.4.4 resulting in insufficient Enriched UF₆being available for the manufacture of Fuel for delivery to BEG(UK) in accordance with this Agreement.”

2.13

Clause 13.1 shall be deleted and replaced with:

“13.1 If, before irradiation, BEG(UK) demonstrates or BNFL advises that any Fuel Element or Ancillary Component does not comply with the Contract Specification unless such non-compliance is caused by the negligence or wilful default of BEG(UK), its servants or agents or, as a result of deterioration of the Fuel resulting from storage at BEG(UK) sites after unpacking, then unless BEG(UK) agrees to accept the said Fuel notwithstanding such non-compliance with the Contract Specification, BNFL shall, at its discretion and within a reasonable time either:-

13.1.1

rectify the Fuel Element or Ancillary Component at the appropriate AGR Power Station or at Springfields so that it complies with the Contract Specification; or

13.1.2

replace the Fuel Element or Ancillary Component provided that it has been returned to BNFL;

128

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

and shall bear the cost of rectification or replacement as the case may be including any uranic recovery costs PROVIDED THAT subject to the consent of BEG(UK), BNFL may, in respect of any Fuel Element or Ancillary Component returned to them under this Clause and instead of the alternatives set out in Clauses 13.1.1 and 13.1.2, credit BEG(UK) with a sum which shall, in the case of a Fuel Element, take into account the charge which would have been payable for and appropriate to the Fuel Element if it had been due for delivery on the date on which it was so returned or, in the case of an Ancillary Component, take into account the charge which would have been payable for the Ancillary Component if it had been due for delivery as aforesaid. For the avoidance of doubt BNFL shall be responsible for the recovery of the Enriched UO2 content of the Fuel so affected including any Process Losses and shall carry out such recovery in a timely manner and shall credit such recovered Enriched UO2 to BEG(UK)’s Operational Stock account at Springfields. If for reasons solely attributable to BNFL, BNFL does not recover the Enriched UO2 content of the Fuel it shall forthwith credit BEG(UK) with an amount of UO2 in the same form as if BNFL had recovered the said UO2. In the event that BNFL elects to rectify or replace Fuel as specified in Clauses 13.1.1 and 13.1.2, it shall be deemed not to have been delivered until such rectification or replacement has been carried out and the Fuel delivered to BEG(UK). Accordingly, the provisions of Clause 12.4 shall apply.”

2.14

The following words appearing at the end of Clause 15 shall be deleted:

“The provisions of this Clause 15 shall not apply to the Uranic Elements Supply Component of this Agreement except where:

(a) they relate to proposed changes to all or part of the Uranic Elements Supply Component of this Agreement which could have an impact on all or part of the process of manufacturing of Fuel Elements by BNFL; or

(b) they relate to proposed changes to all or part of the process of manufacturing of Fuel Elements by BNFL which could have an impact on all or part of the Uranic Elements Supply Component of this Agreement.”

2.15

Clause 24.2 shall be deleted.

2.16

Clause 28.5 shall be deleted.

2.17

Appendix 4 shall be deleted and replaced with:

129

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

“APPENDIX 4

SWU LOSS PROCEDURE

BLENDING

In order to meet the requirements of BEG(UK) with regard to Fuel Assay, BNFL may have to undertake isotopic blending of UO2 powder. This requirement may arise as a result of one of the following circumstances:-

(i) BEG(UK) requires that its stocks of enriched uranium material at Springfields are utilised to reduce in process stocks.

(ii) Insufficient UF₆/UO2 at the required Assay is available on site.

In cases where a blending operation will result in a SWU loss of 0.5% or less then BNFL shall not be required to inform BEG(UK) in advance of blending taking place.

Where a blending operation will result in a SWU loss of greater than 0.5% then BNFL shall be required to obtain the prior approval of BEG(UK) for the blending operation to be undertaken, such approval not being unreasonably withheld. Any such request by BNFL shall be in writing and BEG(UK) shall reply to it within seven days of receipt thereof. BNFL’s request shall be submitted not less than seven days before the intended commencement of blending operations.

BEG(UK) shall, after consultation with BNFL, provide BNFL with a list indicating particular materials assays which, unless otherwise indicated by BEG(UK) at a later date, are not to be made available for blending. BEG(UK) shall provide this list to BNFL on a 12 monthly basis no later than one month prior to the commencement of any such 12 month period.

BNFL shall provide BEG(UK), on a Quarterly basis within 7 days of the end of each Quarter, with a blending statement giving details of all blending operations undertaken. This statement shall be known as the Enriched Uranium Blend Statement and shall be in the form shown in Table 1 of this Appendix.

RESIDUE RECOVERY

As part of the fabrication process, BNFL undertakes activities to allow production residues to be recovered for use in subsequent Fuel manufacture. Within the recovery operations, there will be a need to process enriched uranium material from different sources and hence mixing will take place.

As from 1 April 1992 the following procedure will take place:-

In cases where a residue recovery operation will result in a SWU loss of 0.5% or less then BNFL will not be required to inform BEG(UK) in advance of a residue recovery operation taking place.

Where a residue recovery operation will result in a SWU loss of greater than 0.5% then BNFL shall be required to obtain the prior approval of BEG(UK) for the

130

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

residue recovery operation to be undertaken, such approval not being unreasonably withheld. Any such request by BNFL shall be in writing and BEG(UK) shall reply to it within seven days of receipt thereof. BNFL’s request shall be submitted not less than seven days before the intended commencement of residue recovery operations.

BNFL shall provide BEG(UK) by 31 October in each year with a residue recovery statement giving details of all residue recovery operations undertaken. This statement shall be known as the Residue Recovery Statement and shall be in the form shown in Table 2 of this Appendix. This statement shall relate to residue recovery operations for the preceding 12 months ending 30 September.”

2.18

The following words appearing at the end of Appendix 8 shall be deleted:

“This Appendix 8 shall not apply to the Uranic Elements Supply Component of this Agreement prior to the passage of Uranium Material through the gates of the Springfields Site.”

2.19

Appendix 18 part C shall be deleted.

2.20

The following shall be deleted from paragraph 1 of Appendix 16:

“, Uo and Vo”.

2.21

Appendixes 21 – 27 (inclusive), 29, 30 and 32 shall be deleted.

131

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 29

[NOT USED]

132

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 30

[NOT USED]

133

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 31

VALUATION MECHANISM

Part A - General

This Appendix sets out the mechanism for determining the Initial Termination A Stocks Purchase Price and the Remaining Termination A Stocks Purchase Price or the Termination B Purchase Price (as the case may be), as well as the price of BNFL Interim Sale Uranium as referred to in Clause 2.23.2.

Terms used in this Appendix are defined in Parts F and G.

Part B - Initial Stocks Termination A Purchase Price

In this Part B, TPIS means the Initial Termination A Stocks Purchase Price in pounds sterling.

The Initial TPIS = TP_WIP + TP_EUF

Part C - Price to be paid in respect of BNFL Interim Sale Uranium

The value of an individual sale of BNFL Interim Sale Uranium (if any) under Clause 2.23.2 shall be determined in accordance with paragraph 3 of Part E of this Appendix.

The value in pounds sterling of enriched uranium contained in Fuel purchased by BEG under this Agreement after the Initial Termination A Stocks Completion Date and prior to the Remaining Termination A Stocks Completion Date or the Second Remaining Termination A Stocks Completion Date (if any), shall be the sum of all UF₆ and SWU values in pounds sterling determined in accordance with the derivation of Uo under this Agreement in any given month m.

Part D - Remaining Termination A Stocks Purchase Price

The Remaining Termination A Stocks Purchase Price shall be the sum of the value of WIP in pounds sterling determined in accordance with paragraph 4 of Part F of this Appendix, the value of Enriched UF₆in pounds sterling determined in accordance with paragraph 3 of Part E of this Appendix, the value of UF₆in pounds sterling determined in accordance with paragraph 2 of Part F of this Appendix, and the value of UOC in pounds sterling determined in accordance with paragraph 1 of Part F of this Appendix on the Remaining Termination A Stocks Completion Date or if any, the Second Remaining Termination A Stocks Completion Date (as the case may be).

Part E - Termination B Purchase Price

The Termination B Purchase Price shall be the sum of the value of WIP in pounds sterling determined in accordance with paragraph 4 of Part F of this Appendix, the value of Enriched UF₆ in pounds sterling determined in accordance with paragraph 3 of Part F of this Schedule, the value of UF₆ in pounds sterling determined in accordance with paragraph 2 of Part F of this Appendix, and the value of UOC in pounds sterling determined in accordance with paragraph 1 of Part F of this Appendix on each Termination B Completion Date.

Part F - Component Values of UOC, UF₆, Enriched UF₆ and WIP

134

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

UOC

1.1

The conversion formula for converting lbs UOC in the form of U₃O₈ into kg U as UOC is:

W_UOC = W_UL / 2.59978

1.2

The total price in pounds sterling of UOC is:

P_UOC = W_UOC x BV_UOC

Where:

W_UOC means the weight of UOC in kg U transferred by BNFL to BEG(UK).

W_ULmeans the total weight of UOC in lbs U₃O₈ transferred by BNFL to BEG(UK).

P_UOCmeans the price to be paid in pounds sterling by BEG(UK) to BNFL for UOC.

BV_UOC means the book value of UOC per kg U as UOC.

UF₆

2.1

The total price in pounds sterling of UF₆ is:

P_UF6 = W_UF6 x BV_UF6

Where:

P_UF6 means the price to be paid in pounds sterling by BEG(UK) to BNFL for UF₆.

W_UF6 means the weight of UF₆ in kg U transferred by BNFL to BEG(UK).

BV_UF6 means the book value of UF₆per kg U as UF₆.

2.2

The amount of UOC needed to produce UF₆ shall be deemed to be:

W_UOC = W_UF6/0.995

2.3

The weight of conversion shall be:

W_CON = W_UF6

Where W_CON is the weight of conversion.

Enriched UF₆

The total price in pounds sterling of Enriched UF₆ shall be calculated as follows:

P_EUFx = (W_EUFx x BV_SWU x SFx) +(W_EUFx x BV_UF6 x FFx)

and:

TP_EUF = S₁^zP_EUF_x

135

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

Where:

P_EUFx means the price in pounds sterling for Enriched UF₆ at a specific Assay number x.

W_EUFx means the weight in kg U of Enriched UF₆ at a specific Assay number x transferred by BNFL to BEG(UK).

BV_SWU means the book value of SWU per kg SWU.

SF_x and FF_x shall each have the meaning ascribed to it in Part G for Assay number x.

x shall be assigned as a number between 1 and z which uniquely represents 1 discrete Assay in Enriched UF₆ (determined to 3 decimal places) which BNFL is selling and BEG(UK) is buying.

z shall be the total number of discrete Assays of Enriched UF₆ (determined to 3 decimal places) which BNFL is selling and BEG(UK) is buying.

TP_EUF means the total price in pounds sterling of Enriched UF_6.

WIP

The total price in pounds sterling of WIP shall be calculated as follows:

WF_WIPx = W_WIPx x FFx

WS_WIPx = W_WIPx x SFx

and:

TF_WIP = S₁^yWF_WIPx

TS_WIP = S₁^yWS_WIPx

and:

TP_WIP = (TF_WIP x BV_UF6) + (TS_WIP x BV_SWU)

Where:

W_WIPx means the weight in kg U of WIP at a specific Assay number x transferred by BNFL to BEG(UK).

WF_WIPx means the equivalent weight of UF₆ in WIP in kg U at a specific Assay number x.

WS_WIPx means the equivalent weight of SWU in WIP in kg at a specific Assay number x.

TS_WIP means the total equivalent weight of SWU in WIP in kg.

TP_WIPmeans the total price of WIP in pounds sterling.

136

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

TF_WIP means the total equivalent weight of Feed in WIP in kgU.

BV_UF6has the meaning in paragraph 2.1 of this Part F.

BV_SWU has the meaning in paragraph 3 of this Part F.

SF_x and FF_x shall have the meaning ascribed to it in Part G of this Appendix for Assay number x.

x shall be assigned as a number between 1 and y which uniquely represents 1 discrete Assay in WIP (determined to 3 decimal places) which BNFL is selling and BEG(UK) is buying.

y shall be the total number of discrete Assays in WIP (determined to 3 decimal places) which BNFL is selling and BEG(UK) is buying.

Part G - Feed Factor and SWU Factor

The feed material component or uranium feed per unit of Enriched UF₆ or WIP (the Feed Factor) shall be calculated as follows:

Where:

FF is the Feed Factor.

Xp is the Enriched UF₆ or WIP Assay (wt% U235).

Xw is the Tails Assay (wt% U235) and shall be 0.35%.

Xf is the UF₆ Assay (equal to 0.711 wt% U235).

The SWU component per unit of Enriched UF₆ or WIP (the SWU Factor) shall be calculated as follows:

SF = (V(Xp)—V(Xw))—FF(V(Xf)—V(Xw))

where:

Where:

137

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

X_p, X_w, and X_f are as defined in paragraph 1 of Part F above.

ln is the natural logarithm.

For the application of the above formulae in this Appendix 31:

3.1

The quantity of UF₆ is to be expressed in kgU, and rounded to the nearest gramme (that is, the third decimal place).

3.2

The U₂₃₅ Assay is expressed in wt% and rounded to the third decimal place.

3.3

The weight percents (wt%) are to be converted to decimal fractions (i.e. ÷ 100) for use in the SWU equations above.

3.4

All intermediate calculations are to be carried to at least eight decimal places.

3.5

The Feed and SWU Factors are to be rounded to the third decimal place.

3.6

The amounts of SWU are to be rounded to the third decimal place (1/1000 SWU).

3.7

Rounding is done by the standard rounding procedure, that is, by rounding each figure up when the following figure is equal to or higher than five (5), and by rounding each figure down when the following figure is less than five (5).

3.8

Assay means the total weight of U235 isotope divided by the total weight of all uranium isotopes expressed as a weight percent (wt%).

3.9

Tails means Depleted UF₆ resulting from the Assay process.

3.10

SWU means a unit of measurement for Enrichment.

3.11

Feed means UF_6.

3.12

Depleted UF₆ means uranium hexafluoride with an Assay lower than in UF_6.

138

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

APPENDIX 32

WARRANTIES

The same covenants shall be deemed to be given by BNFL in relation to the Initial Stocks, Termination A Stocks or Termination B Stocks (as applicable) as are implied under Part I of the Law of Property (Miscellaneous Provisions) ▇▇▇ ▇▇▇▇.

The Initial Stocks, Termination A Stocks or Termination B Stocks (as applicable) are free from all Security Interests.

The Initial Stocks, Termination A Stocks or Termination B Stocks (as applicable) have not been obtained under or through any arrangement, swap or exchange that violates any laws regarding the importation or use of uranium or which is designed to circumvent any import limits for uranium and are subject to the obligation of use for exclusively peaceful, non-explosive purposes and to all applicable safeguards obligations.

The Initial Stocks, Termination A Stocks or Termination B Stocks (as applicable), as identifiable in the following elements shall, in respect of:

4.1

UOC have been accepted for conversion by the relevant converter; and

4.2

UF₆ have been accepted for Enrichment by the relevant enricher.

To the best of BNFL’s knowledge, information and belief:

5.1

no party to a Contract or New Contract has given notice of its intention to terminate, or has sought to repudiate or disclaim, the Contract or New Contract;

5.2

no party to a Contract or New Contract is in material breach of the Contract or New Contract; and

5.3

no fact or circumstances exists which might give rise to a material breach.

BNFL has not received any notices of default under the Contracts or New Contracts.

No Contract or New Contract was entered into other than in the usual course of the business of BNFL.

No Contract or New Contract was entered into by BNFL other than by way of a bargain at arm’s length.

139

BNFL/BEG(UK) COMMERCIAL IN CONFIDENCE

IN WITNESS whereof the duly authorised representatives of the Parties have hereunto set their hands the Day and Year first before written.

SIGNED on behalf of

BRITISH NUCLEAR FUELS plc

Signature:

Name:

In the presence of:-

Witness Signature:

Witness Name:

SIGNED by

a duly authorised representative of

BRITISH ENERGY GENERATION (UK) LIMITED

Signature:

Name:

In the presence of:-

Witness Signature:

Witness Name:

SIGNED by

a duly authorised representative of

BRITISH ENERGY plc

Signature:

Name:

In the presence of:-

Witness Signature:

Witness Name:

140

Accounting Lifetime
(Years)

Accounting
Closure Date
(Last Reactor)

▇▇▇▇▇▇▇▇▇▇ ▇