EXHIBIT 10.16
-------------
Ground Lease
Tejon Ranchcorp
and
Pastoria Energy Facility L.L.C.
This Lease is entered into as of July 19, 2001 between Tejon Ranchcorp, a
California corporation ("Ranchcorp"), and Pastoria Energy Facility L.L.C., a
Delaware limited liability company ("PEF"). Capitalized terms used in this Lease
have the meanings stated in Section 23 or the provisions there referred to.
RECITALS
Ranchcorp is the owner of the Tejon Ranch. PEF is a special purpose entity
created for the purpose of developing a combined-cycle, natural gas-fired
combustion turbine merchant electric power plant to be located on a portion of
the Tejon Ranch (the "Project"). Ranchcorp and PEF and certain of their
Affiliates have agreed to work together toward development of the Project
pursuant to a Transaction Agreement dated April 30, 1999, between the Tejon
Interests and the Developer Interests (as originally executed and as thereafter
amended (if at all) in accordance with its terms, the "Transaction Agreement").
Ranchcorp and PEF also are party to an Option Agreement dated April 30, 1999 (as
originally executed and as thereafter amended (if at all) in accordance with its
terms, the "Option Agreement"). This Lease is being entered into following PEF's
exercise of the option contained in the Option Agreement.
IN THIS CONTEXT, the parties agree as follows:
Section 1. Premises
Ranchcorp leases to PEF, and PEF leases from Ranchcorp, that certain real
property which is legally described in the attached Schedule 1 (the "Premises").
Notwithstanding the foregoing, the leasehold hereby conveyed does not include,
and Ranchcorp expressly reserves to itself, all water, water rights and water
stock (other than the right to use ground water from a well drilled for the
purpose of providing basic water service to the Project only for drinking,
bathrooms, kitchens, landscape irrigation and other comparable uses), minerals
and mineral rights belonging to the Premises; provided that Ranchcorp shall have
no surface rights related to any minerals or mineral rights, and shall not, in
the exercise of any mineral rights, disturb the surface of the Premises,
interfere with or disturb the occupancy or operations of PEF on the Premises, or
drill at a depth which is less than five hundred (500) feet below the surface of
the Premises.
Section 2. Term
2.1 Initial Term. The initial term of this Lease (the "Initial Term") shall
commence upon the date of this Lease, and shall continue until the last day of
the month containing the twenty-fifth (25th) anniversary of the Commencement
Date, unless sooner terminated pursuant to the terms and conditions of this
Lease. The "Commencement Date" is the earlier of (x) the Commercial Operation
Date, and (y) the Nominal COD. The "Commercial Operation Date" is the date on
which PEF, following completion of customary commissioning and testing of the
Project, formally accepts the Project from its construction contractor as
available for commercial operation for the purpose of producing electric energy
and/or of providing Ancillary Services for sale to wholesale, retail or other
purchasers on a continuous basis. The "Nominal COD" is the third anniversary of
the date of this Lease; provided, if construction, commissioning or testing of
the Project shall be delayed for any number of days by any Excepted Cause(s),
the Nominal COD shall be extended by the same number of days. In that event, PEF
must provide notice thereof to Ranchcorp within fifteen (15) days of the
commencement of the Excepted Cause and if it fails to deliver timely notice, the
date of the commencement of the Excepted Cause shall be
deemed to have occurred no earlier than fifteen (15) days prior to the date
notice is delivered. PEF also shall notify Ranchcorp in writing when the
Commercial Operation Date has occurred, which notice shall also identify the
date of expiration of the Initial Term.
2.2 Option to Extend. Ranchcorp grants to PEF an option to extend the
Initial Term for three additional five (5) year periods (each an "Extended
Term"). This option to extend shall be exercised by PEF by giving Ranchcorp
written notice of its intent to extend this Lease not less than twelve (12)
months, nor more than twenty-four (24) months, prior to the expiration of the
preceding Term. Each Extended Term shall be on the same terms, covenants and
conditions as provided in this Lease. As used in this Lease, the word "Term"
means the Initial Term and, after exercise of any option to extend pursuant to
this Section 2.2, includes any Extended Term.
2.3 Possession. Possession of the Premises shall be delivered to PEF on the
date of this Lease.
Section 3. Rent
3.1 Fixed and Variable Rent. PEF shall pay rent to Ranchcorp during the
Term in a fixed component and a variable component. The fixed component, as
described in Section 3.2 (the "Fixed Rent"), shall be paid monthly in advance on
or before the first day of each month for which it is payable. The variable
component is described in Section 3.4 (the "Variable Rent"), and shall be
payable as set forth in that Section. All sums due under this Lease, whether
payable to Ranchcorp or to third parties, shall be defined as "Rent" for the
purposes of enforcement of this Lease.
3.2 Fixed Rent After Commercial Operation.
(a) PEF shall pay Fixed Rent in the amount of $216,666.66 per month for the
month in which the Commencement Date occurs and for each month thereafter during
the Term until PEF completes decommissioning of the Project under Section 8.13,
provided, however, that Fixed Rent shall be fully abated from the date on which
PEF commences decommissioning the Project and for each month thereafter until
the earlier of (x) completion of decommissioning or (y) twelve (12) months after
PEF commences decommissioning. PEF shall be deemed to have commenced
decommissioning on the day it permanently ceases operation of the Project to
produce electric energy or to provide Ancillary Services. Completion of
decommissioning means that all Improvements and personal property have been
removed from the Premises to the extent required by Section 8.13 and the
Premises have been restored to their pre-construction condition. Fixed Rent for
any partial month at the beginning or end of the Term shall be prorated based on
a 30-day month.
(b) The Fixed Rent shall be escalated on each anniversary of the first day
of the month in which the Commencement Date occurs by an amount reflecting the
annual percentage increase (if any) in the Consumer Price Index for All Urban
Consumers, Los Angeles-Anaheim-Riverside Area, All Items (Base Year 1982-1984 =
100), published by the United States Department of Labor, Bureau of Labor
Statistics (the "CPI"), during the twelve-month period from the date that is
fifteen (15) months prior to the date of the escalation to the date that is
three (3) months prior to the date of the escalation. In the event the CPI is
ever discontinued, the parties shall substitute any generally recognized
successor or substitute index published by a governmental agency and reflecting
changes in consumer prices in the greater Los Angeles area.
(c) Notwithstanding the foregoing, in the event "C" (as defined in Section
3.4(c)) is less or more than 750 megawatts ("MW"), the monthly Fixed Rent
payable under Section 3.2(a) will be adjusted as follows:
(i) In the event C exceeds 750 MW, the monthly Fixed Rent payable
under Section 3.2(a) (as adjusted if at all under Section 3.2(b))
shall be increased by that percentage which is equal to:
(x - 750)/750
where "x" is equal to the lesser of C and 1000 MW.
(ii) In the event C is less than 750 MW, the monthly Fixed Rent
payable under Section 3.2(a) (as adjusted if at all under Section
3.2(b)) shall be decreased by that percentage which is equal to:
(750 - y)/750
where "y" is equal to the greater of C and 600 MW.
(d) The monthly Fixed Rent payable under Section 3.2(a) shall be increased
by $0.1667 per foot for every linear foot of flood control berms which PEF
locates off the Premises in "Parcel D" (as defined in the Project Easement
Agreement); provided, there shall be no change in any of the payments required
under this Section 3.2(d) in the event of any relocation of the berms at
Ranchcorp's request under the Project Easement Agreement.
(e) In the event the Project does not utilize air cooled condensers as
either its primary or backup cooling source, the monthly Fixed Rent payable
under Section 3.2(a) shall be increased by $1,666.67 per acre for every acre by
which the Project Site exceeds 30 acres.
3.3 Advances Against Fixed Rent. Commencing on the first day of the month
next succeeding the month in which this Lease is executed and continuing on the
first day of each month thereafter until the earlier of the Commercial Operation
Date and the date on which $2.4 million has been advanced by PEF under this
Section 3.3, PEF will advance the sum of $100,000 per month to Ranchcorp. All
portions of such advances that Ranchcorp has not previously repaid, plus
interest thereon at the rate of 10 percent per annum without compounding from
the date of advance until the date of repayment, shall be credited against the
Fixed Rent payments (if any) required from PEF under Section 3.2, in equal
monthly amounts calculated to repay all such advances, plus the prescribed
interest, to PEF over the first four years after PEF begins paying Fixed Rent
under Section 3.2. In the event that this Lease is terminated before all
advances have been repaid, Ranchcorp shall be entitled to retain, and shall have
no obligation to repay any portion of, any advances it received from PEF
pursuant to this Section prior to termination of this Lease.
3.4 Variable Rent.
(a) Payable After Commercial Operation. The Variable Rent payable under
this Section 3.4 is payable for the calendar month in which the Commercial
Operation Date occurs and for each calendar month thereafter through and
including the calendar month in which this Lease terminates. The Variable Rent
payable under this Section 3.4 for any calendar month
shall be due and payable within 20 days after the end of that calendar month.
Each payment of Variable Rent under this Section 3.4 shall be accompanied by
PEF's detailed calculation of the amount due and shall include the statement
required from PEF under Section 3.4(e).
(b) Basic Calculation. The Variable Rent payable for a calendar month under
this Section 3.4 will be an amount equal to 1 percent (1%) of the Spark Spread
for that calendar month.
(c) Spark Spread. The "Spark Spread" for any calendar month is an amount
equal to:
H x [(C x PX) - (HR x C x GP)]
where:
"H" is equal to the aggregate number of Revenue Hours occurring during the
calendar month; and
"C" is equal to the maximum electrical output of the Project (expressed in
MW) which is guaranteed to PEF by its contractor for construction of the
Project.
"PX" is equal to the quotient of (x) the sum of the PX Prices for each
Revenue Hour occurring during the calendar month, divided by (y) the
aggregate number of Revenue Hours occurring during the calendar month; and
"HR" is equal to 7.250; and
"GP" is equal to the quotient of (x) the sum of the Daily Gas Prices for
each Revenue Day during the calendar month, divided by (y) the aggregate number
of Revenue Days occurring during the calendar month.
(d) Other Defined Terms.
Ancillary Services -- has the meaning specified in the ISO Tariff.
Daily Gas Price - for any Revenue Day is the daily price (expressed in
$/MMBTU) of natural gas at the California-Arizona border, as published by Gas
Daily for the Revenue Day under the "Others" table, under the heading titled
"SoCal gas, large packages (deliveries at Topock, Daggett, Blythe, Needles,
Ehrenberg)."
Gas Daily - Pasha Publications' Gas Daily, and any successor thereto.
---------
ISO -- the California Independent System Operator Corporation, a California
non-profit corporation, and any successor thereto
ISO Controlled Grid - the transmission lines and associated facilities
controlled by the ISO.
ISO Tariff -- the California Independent System Operator Agreement and
Tariff dated March 31, 1997, as modified through the date of this Agreement.
ISO Zone - the ISO zone in which the Pastoria substation may from time to
time be located. The Pastoria Substation currently is located in (and the ISO
Zone therefore currently is at the date of the Transaction Agreement) the ISO
zone known as SP 15.
Pastoria Substation - the electrical substation through which the Project
delivers electrical energy to the ISO Controlled Grid, planned at the date of
the Option Agreement to be the substation located in the vicinity of
hypothetical Section 19, Township 10 North, Range 18 West, SBBM, in Rancho El
Tejon, ▇▇▇▇ County, California.
PX - the California Power Exchange Corporation, a California non-profit
corporation, and any successor thereto.
PX Price -- for any Revenue Hour is the Day Ahead Zonal Price (Constrained)
for that Revenue Hour for the ISO Zone as published by the PX.
Revenue Day -- any calendar day during which a Revenue Hour occurs.
Revenue Hour -- any hour for which the Project is paid to produce electric
energy or to provide Ancillary Services.
(e) Audit Rights. PEF shall provide to Ranchcorp monthly with PEF's payment
of the Variable Rent provided for in this Section 3.4 a statement of the total
Revenue Hours which occurred during the month for which the Variable Rent is
payable. No more frequently than once each year, PEF shall, upon Ranchcorp's
request, afford Tejon access to PEF's books and records during normal business
hours for the purpose of verifying (and to the extent necessary to verify) the
accuracy of PEF's statements as to the Revenue Hours occurring during any period
not previously audited by Ranchcorp or previously reported on by a Big 6 Firm
pursuant to this Section 3.4(e). In lieu of such access, PEF may instead elect
to provide such access to a Big 6 Firm which Ranchcorp selects and to cause such
firm to report, based on its examination of PEF's books and records, as to the
number of Revenue Hours which occurred during such period. Any such report shall
be conclusive as the subject thereof. All information to which Tejon or a Big 6
Firm is afforded access or which Tejon otherwise learns pursuant to this Section
3.4(e) shall be deemed "Confidential Information" for purposes of the
Confidentiality Agreement referred to in Section 9 of the Transaction Agreement.
"Big 6 Firm" means as of any given date of determination any of the six largest
national accounting firms as of the determination date.
(f) Changes. In the event of any change in the tariffs, practices or
operations of the PX, the ISO or Gas Daily subsequent to the date of the
Transaction Agreement which results in any of the following:
(i) The PX Price not being published by the PX as necessary to permit the
calculation of Variable Rent payable under this Section 3.4;
(ii) The PX Price being materially less representative than on the date of
the Transaction Agreement of the day ahead wholesale market price of
electric energy delivered to the ISO Zone; or
(iii) GP not being published by Gas Daily as necessary to permit the
calculation of Variable Rent payable under this Section 3.4; or
(iv) GP being materially less representative than on the date of the
Transaction Agreement of the wholesale price of natural gas delivered
at the Arizona/California Border (Topock, Daggett, Blythe, Needles,
Ehrenberg) in volumes of 5,000 MMBTU or more per day;
then, promptly upon request by either Ranchcorp or PEF, the parties will meet
and attempt to agree on one or more amendments to this Lease which will permit
the Spark Spread to be calculated, as near as practicable, on the same basis and
with the same results as it was calculated prior to the change. In the event the
parties are unable to agree on any such amendment thought by either party to be
necessary, the matter shall be settled by binding arbitration under Section 12
of the Transaction Agreement.
3.5 Late Charge. For any payment of Fixed Rent or Variable Rent not paid
within ten (10) days after the date it is due, PEF shall pay Ranchcorp, as
additional Rent, a late charge equal to one percent (1%) of the amount past due
as compensation to Ranchcorp for the extra costs incurred as a result of the
late payment. With any Fixed Rent or Variable Rent Payment that PEF makes more
than 30 days after it was due, PEF shall also pay interest on the overdue amount
calculated at the lesser of 18 percent per annum or the maximum rate allowed by
law, without compounding, from the day after the payment was due until the date
such Rent is paid in full. For any other Rent payment not paid within ten (10)
days after the date it is due, PEF shall pay Ranchcorp, as additional Rent, a
late charge equal to three percent (3%) of the amount past due as compensation
to Ranchcorp for the extra costs incurred as a result of the late payment. With
any other Rent payment that PEF makes more than 30 days after it was due, PEF
also shall pay interest on the overdue amount calculated at the lesser of 10%
per annum or the maximum rate allowed by law, without compounding, from the day
after the payment was due until the date such Rent is paid in full. The parties
agree that the late charge and the interest prescribed by this section represent
fair and reasonable estimates of the detriment that Ranchcorp will suffer by
reason of late payment of Rent by PEF.
3.6 Real Estate Taxes and Assessments. As additional rent ("Additional
Rent") payable under this Lease, PEF shall pay before delinquency all real and
personal property taxes, general and special assessments, levies and other
governmental charges of every description (the "Property Taxes") which are
levied, assessed, charged or imposed upon or against the Premises or the Project
(the Project and all other improvements to the Premises and all alterations,
additions or improvements to any thereof are referred to in this Lease as the
"Improvements"), or against any legal or equitable interest of Ranchcorp in the
Premises, or against any of PEF's personal property now or hereafter located on
the Premises, for or attributable to any portion of the Term. Ranchcorp shall
cause the Premises to be separately assessed from any other real property owned
by Ranchcorp. All Property Taxes required to be paid by PEF shall be prorated
for the first year of the Term and for the year in which the Lease expires or
terminates. If the law permits the payment of the Property Tax in installments
(whether or not interest accrues on the unpaid balance) PEF may elect to pay the
tax before delinquency in installments.
Ranchcorp will promptly notify PEF of all notices, levies and assessments
of Property Taxes received in connection with the Premises, and PEF shall pay
them prior to delinquency, provided, however, PEF may, at its expense , contest
in all desirable proceedings the validity of, amount of, or assessment of any
Property Tax agreed to be paid by PEF, provided, however, that PEF at all times
shall keep the Premises free from any delinquent tax lien. Any penalty, interest
or delinquency charge that may result from the contest shall be the obligation
of PEF. Ranchcorp shall not be required to join in any proceeding or contest
brought by PEF unless the
provisions of any law require that the proceeding or contest be brought by or in
the name of the fee owner of the Premises. In that case, Ranchcorp shall join in
the proceeding or contest or permit it to be brought in Ranchcorp's name and all
costs, including Ranchcorp's attorneys' fees, shall be borne by PEF. Ranchcorp
agrees to execute any documents necessary to perfect PEF's right of contest as
provided for in this Section.
3.7 Apportionment of Property Taxes. In the event that the Premises are
included in the same tax parcel as other real or personal property owned by
Ranchcorp, Ranchcorp and PEF agree to cooperate in requesting that the Premises
be separately assessed from other property owned by Ranchcorp. In the event that
the Premises are included in a tax ▇▇▇▇ with other property owned by Ranchcorp,
Ranchcorp shall pay the property tax ▇▇▇▇ before delinquency and PEF shall
reimburse Ranchcorp for the portion of the tax ▇▇▇▇ attributable to the land and
Improvements comprising the Premises, based on the actual assessed value of the
land and Improvements comprising the Project. Any dispute between the parties
regarding the amount of PEF's property tax obligation under this section shall
be resolved by arbitration as provided by Section 12 of the Transaction
Agreement.
3.8 Other Taxes. Property Taxes shall not include and PEF shall not be
required to pay the following: water district assessments and liens, business,
income or profit taxes levied or assessed against Ranchcorp by federal, state,
county, municipal or other governmental agencies, estate, succession, or
inheritance tax, or capital levy of Ranchcorp; or corporation, franchise or
other profit taxes imposed on Ranchcorp; any net income, profits or excess
profits taxes, or any tax which may, at any time during the Term, be required to
be paid on any gift or demise, deed, mortgage, descent or other alienation of
any part or all of the estate of Ranchcorp in and to the Premises or the
Improvements, provided, however, that PEF shall pay any recording costs or
documentary transfer taxes or fees arising from execution of this Lease or from
recording a memorandum of this Lease.
3.9 Deferral. PEF shall have the right to allow any assessment or any other
charge PEF is required to pay as Additional Rent to go to bond or otherwise
defer payment thereon, other than through voluntary delinquency, for the maximum
lawful period, provided that PEF shall not permit any liens for delinquent taxes
or other assessments to be placed on the Premises. Regardless of whether any
such obligation is so deferred, PEF shall be liable for any portion of the
obligation, plus any applicable interest, which applies or is attributable to
any portion of the Term.
3.10 No Abatement. Except as otherwise expressly provided in this Lease,
this Lease shall continue in full force and effect, and the obligations of PEF
hereunder shall not be released, discharged or otherwise affected, by reason,
of: (a) any damage to or destruction of the Premises or any portion thereof or
any Improvements thereon, or any Taking thereof in eminent domain; (b) any
restriction or prevention of or interference with any use of the Premises or the
Improvements or any part thereof; (c) any bankruptcy, insolvency,
reorganization, composition, adjustment, dissolution, liquidation or other
proceeding relating to Ranchcorp, PEF, or any subtenant, licensee or
concessionaire or any action taken with respect to this Lease by a trustee or
receiver, or by any court, in any proceeding; (d) any claim that PEF or any
other person has or might have against Ranchcorp; (e) any failure on the part of
Ranchcorp to perform or comply with any of the terms of this Lease or of any
other agreement with Ranchcorp; (f) any failure on the part of any sublessee,
licensee, concessionaire, or other person to perform or comply with any of the
terms of any sublease or other agreement between Ranchcorp and any such person;
(g) any termination of any sublease, license or concession, whether voluntary or
by operation of law; or (h) any other occurrence whatsoever, whether
similar or dissimilar to the foregoing. The obligations of PEF under this Lease
shall be separate and independent covenants and agreements. PEF hereby waives,
to the full extent permitted by applicable law, all rights now or hereafter
conferred by statute, including without limitation the provisions of California
Civil Code Sections 1932, 1933, 1941 or 1942 or any similar law, to quit,
terminate or surrender this Lease or the Premises or any part thereof, or to any
abatement, suspension, deferment, diminution or reduction of any Rent, unless
otherwise expressly provided in this Lease.
3.11 Effect on Ranchcorp's Rights. Ranchcorp's rights pursuant to this
Section 3, including without limitation, Ranchcorp's rights to collect Rent,
Additional Rent and other charges due under this Lease for any period during
which this Lease is in effect, shall survive any termination of the Lease,
regardless of the provision under which termination is effected. Notwithstanding
anything to the contrary contained herein, Ranchcorp shall have no obligation or
duty to mitigate or attempt to offset any damages which are or may be suffered
by Ranchcorp as a result of any default of PEF under this Lease; provided that
PEF shall retain its rights under Sections 18.1 (b) and (c) to submit proof as
to the rental loss that Ranchcorp could avoid by such mitigation. Any payment by
PEF of a sum of money less than the entire amount due Ranchcorp at the time of
such payment shall be applied to the obligations of PEF then furthest in
arrears. No endorsement or statement on any check or accompanying any payment
shall be deemed an accord and satisfaction and any payment accepted by Ranchcorp
shall be without prejudice to Ranchcorp's right to obtain the balance due or to
pursue any other remedy available to Ranchcorp under this Lease or in law or
equity for any default still outstanding.
Section 4. Priority
PEF shall not be required to subordinate the leasehold estate created by
this Lease to any lien or encumbrance whatsoever. Ranchcorp shall have no
obligation to subordinate its interest in this Lease, or in the rents deriving
from it, or its fee interest in the Premises to any liens or encumbrances
related to any leasehold or project financing arranged by or on behalf of PEF.
Section 5. Quiet Enjoyment.
Upon the payment by PEF of Rent and upon the performance of all covenants,
terms and conditions on PEF's part required to be observed and performed, PEF
shall peaceably and quietly hold and enjoy the Premises without hindrance or
interruption by Ranchcorp or any other Person lawfully or equitably claiming by,
through, or under Ranchcorp.
Ranchcorp agrees that during the Term:
(i) Neither Ranchcorp nor any of Ranchcorp's Agents will commit or permit
waste or create a nuisance that affects the Premises.
(ii) Neither Ranchcorp nor any of Ranchcorp's Agents will unlawfully
Release a Hazardous Substance on, about or beneath any portion of the
Tejon Ranch which affects surface water or groundwater, or the surface
or subsurface environment, of the Premises. In the event any unlawful
Release of a Hazardous Substance to the environment occurs on or about
or beneath any portion of the Tejon Ranch which affects the Premises
as a result of any act or omission of Ranchcorp or Ranchcorp's Agents,
Ranchcorp shall promptly undertake reasonable measures to ▇▇▇▇▇ the
unlawful Release at Ranchcorp's sole cost, and to remediate to the
extent required by and in accordance with applicable
Environmental Laws and at Ranchcorp's sole cost any portion of such
Release that affects the Premises. Ranchcorp shall indemnify, defend,
protect and hold PEF harmless from and against any and all claims,
losses, damages, liabilities and costs, including without limitation
reasonable consultants' and attorneys' fees and costs, arising out of
or relating to the presence of Hazardous Substances on or about the
Premises as a result of any act or omission of Ranchcorp or
Ranchcorp's Agents.
(iii) Neither Ranchcorp nor any of Ranchcorp's Agents will use any portion
of the Tejon Ranch within one mile of the Premises for a purpose which
could be reasonably anticipated to interfere materially with, or to be
incompatible with, PEF's permitted use of the Premises, provided that
PEF acknowledges that the gravel quarry and permanent crops, and
operations related to those uses, as conducted at the date of the
Option Agreement in such portions of the Tejon Ranch are compatible
with PEF's use of the Premises and do not contravene this Section 5.
Except as otherwise expressly provided in this Section 5, nothing in this Lease
shall limit or restrict in any way Ranchcorp's rights to develop or use any
portion of the Tejon Ranch as it deems appropriate in its sole and absolute
discretion.
Section 6. Use; Operation of the Project.
6.1 Use.
(a) PEF shall have the right to use the Premises for the purposes of (i)
constructing, maintaining and decommissioning the Project, (ii) operating the
Project for the purpose of producing and selling electric energy and providing
Ancillary Services, and (iii) undertaking other lawful uses incidental to the
production of electricity and the provision of the Ancillary Services, all such
purposes to be in accordance with all present and future zoning laws, rules and
regulations of governmental authorities having jurisdiction over the Premises.
(b) PEF (i) shall not undertake or permit any subsurface drilling on the
Premises other than that required for constructing and maintaining foundations
for structures, for installing well(s) for the production of basic water service
to the Project only for drinking, bathrooms, kitchens, landscape irrigation and
other comparable uses and for installing pipelines and other underground
facilities that are integral parts of the Project; and (ii) shall refrain from
entering into any transactions or agreements, and from providing any services in
a manner, that would cause PEF or the Project to become a public utility subject
to the regulatory jurisdiction of the Public Utilities Commission of the State
of California.
(c) All uses of the Premises other than the permitted uses described in
this Section 6 are prohibited.
6.2 Operation of the Project. At all times after the Commercial Operation
Date, the Project shall be operated, maintained and managed (either directly by
PEF or its permitted successors and assigns through its or their own employees
or those of its or their Affiliates or indirectly through independent
contractors employed by it or them) by persons experienced in operating
gas-fired electric power generation facilities of at least 300 MW in the
aggregate, including at least one gas-fired facility of at least 110 MW.
6.3 Compliance With Law. PEF, at PEF's cost and expense, shall comply with
all Applicable Laws. Any work or installations made or performed by or on behalf
of PEF or any person or entity claiming through or under PEF in order to conform
the Premises to Applicable Laws shall be subject to and performed in compliance
with the provisions of Section 9. PEF shall promptly notify Ranchcorp of, and
shall promptly rectify, any violation of Applicable Laws.
6.4 No Waste or Nuisance. PEF shall not commit or permit waste or create or
permit a nuisance upon the Premises or create same upon any other land or waters
owned by Ranchcorp.
Section 7. Utilities
PEF shall pay for all water, sewer, gas, heat, light, power, steam,
communications, waste removal and other utilities and services supplied to the
Premises and the Improvements.
Section 8. Improvements, Alterations and Personal Property.
8.1 Construction of the Project. PEF hereby is granted permission, at PEF's
sole cost and expense and if PEF elects, to design, develop, construct operate
and maintain the Project in such manner as PEF deems appropriate, subject always
however to the requirements of this Lease, and the Final Project Decision. PEF
is under no obligation to develop, construct, operate or maintain the Project,
and may decline to do so for any or no reason PEF deems appropriate.
8.2 Additional Improvements; Alterations. PEF shall have the right to
construct additional improvements and alterations to the Project on the Premises
("Alterations") without the consent of Ranchcorp provided all such Alterations
are permitted uses under Section 6.1. Any Alterations shall be at PEF's sole
cost and expense, and shall be subject to the terms of this Section 8.
8.3 Permits and Approvals. PEF shall be solely responsible for obtaining,
at its sole cost and expense, any approval or other governmental action
necessary to permit the development, construction, operation and decommissioning
of the Project and any Alterations in accordance with this Lease; provided
Ranchcorp shall support PEF's activities as provided in the Transaction
Agreement.
8.4 Prerequisites to Commencement of Construction.
(a) In addition to all other requirements set forth in this Section 8, before
commencing the construction of the Project or any Alterations and before
any building materials have been delivered to the Premises by PEF or under
PEF's authority, PEF shall obtain and maintain, or cause to be obtained and
maintained, at its own expense, the following insurance coverage in full
force and effect to cover all activities contemplated herein throughout the
term of this Lease, unless otherwise specified:
(i) Broad form commercial general liability insurance, including products,
completed operations and contractual liability coverage in limits of
not less than $1 million per occurrence combined single limit for
bodily injury and property damage. This insurance shall include
coverage related to any construction exposure.
(ii) Statutory workers' compensation insurance in legally required limits.
(iii) Employers' liability insurance with limits of not less than $1
million per occurrence.
(iv) Excess liability insurance providing excess commercial general
liability, automobile liability and employers' liability insurance
with a limit not less than $24 million per occurrence.
(v) At the sole discretion of PEF, either (A) pollution liability
insurance, including liability and site remediation coverage for both
sudden and accidental and non-sudden occurrences with limits of the
greater of $5 million per occurrence combined single limit for bodily
injury and property damage with $5 million annual aggregate, or such
limits as may be required according to applicable CFR Codes of the
State of California, or (B) in the event that PEF elects, in its sole
discretion, not to obtain and maintain, or cause to be obtained and
maintained, pollution liability insurance as contemplated by this
Section 8.4(a)(v), PEF shall cause a guaranty, in form and substance
substantially equivalent to the decommissioning security contemplated
by Section 8.14, or otherwise in form and substance satisfactory to
Ranchcorp, to be issued by Calpine Corporation, a Delaware corporation
("Calpine"), in favor of Ranchcorp (a "Calpine Guaranty"),
guaranteeing the payment and performance of all of PEF's obligations
under Section 10, up to a maximum guaranteed amount of $5,000,000 per
occurrence, with a $5,000,000 annual aggregate limit for all
occurrences in any calendar year.
If PEF has elected under Section 8.4(a)(v) not to maintain, or cause
to be maintained, the pollution liability insurance as contemplated in
Section 8.4(a)(v)(A) and either the tangible net worth (as such term
is defined under generally accepted accounting principles ("GAAP")) of
Calpine shall be less than Four Hundred Fifty Million Dollars
($450,000,000), or any voluntary or involuntary bankruptcy proceeding
has been commenced against Calpine, then PEF shall promptly, and in
any event within the number of days specified below, obtain or cause
to be obtained either (1) pollution liability insurance satisfying the
requirements of Section 8.4(a)(v)(A) within 45 days after PEF acquires
actual knowledge of the decrease in net worth or the commencing of
bankruptcy proceedings as contemplated above, or (2) replacement
security for such Calpine Guaranty provided pursuant to Section
8.4(a)(v) within 15 business days after PEF acquires actual knowledge
of the decrease in net worth or the commencing of bankruptcy
proceedings as contemplated above, which replacement security shall be
reasonably satisfactory to Ranchcorp, and it being acknowledged and
agreed by Ranchcorp that either (x) a replacement guaranty issued by
an affiliate of Calpine which maintains a tangible net worth (as
defined under GAAP) of not less than Four Hundred Fifty Million
Dollars ($450,000,000), in form and substance substantially equivalent
to the Calpine Guaranty being replaced, (y) cash or cash-equivalents
of not less than $5,000,000, which are pledged as collateral security
for PEF's obligations under Section 8.4(a)(v)(B) to Ranchcorp pursuant
to a security agreement in form and substance reasonably satisfactory
to Ranchcorp which, together with any additional documents or
instruments provided by or on behalf of PEF, provide a perfected,
first-priority security interest in and to such collateral to
Ranchcorp, or (z) a letter of credit drawable in the United States of
America in form and substance reasonably satisfactory to Ranchcorp and
in a stated amount of not less than $5,000,000
issued by a banking institution (such banking institution meeting the
requirements of this Section 8.4(a)(v), a "LOC Bank") organized in the
United States or in another country but having a place of business in
the United States engaged in the banking business, the senior
long-term unsecured United States Dollar-denominated debt obligations
of which are rated A or better by Standard & Poor's Ratings Services,
a division of The ▇▇▇▇▇▇-▇▇▇▇ Companies, Inc., and any successor
thereto ("S&P") or the equivalent rating by ▇▇▇▇▇'▇ Investors Service,
Inc. and any successor thereto ("Moody's"), naming Ranchcorp as the
beneficiary thereof, shall be deemed to be reasonably satisfactory to
Ranchcorp.
(vi) Business automobile liability insurance covering all owned and
non-owned and hired vehicles in limits of not less than $1 million per
occurrence combined single limit for bodily injury and property
damage, including all statutory coverage for all states of operation.
(vii) "All-risk" property insurance insuring all real and personal property
at full replacement cost value, together with rent coverage/business
interruption insurance in an amount necessary to satisfy PEF's rent
obligations under this Lease or, if PEF does not maintain such rent
coverage insurance with Ranchcorp as the loss payee thereof, PEF shall
cause to be issued a Calpine Guaranty guaranteeing the payment of the
Fixed Rent during the duration of any business interruption event (as
defined below) with respect to PEF, up to a maximum amount of two (2)
years of Fixed Rent with respect to each such occurrence of a business
interruption event, in each case, to the extent such Fixed Rent is due
and payable pursuant to Section 3.2 hereof and is not otherwise paid
from any other source. For purposes of this Section 8.4(a)(vii), a
"business interruption event" shall mean an event which results in the
necessary interruption or reduction of business operations that are
conducted by PEF with respect to the Project and are caused by any
loss, damage or destruction by any of the perils that are not excluded
under the property casualty insurance then maintained by or on behalf
of PEF with respect to the Project.
(b) The coverages obtained by PEF pursuant to this Section shall be with
insurance companies with Best's Insurance Guide Rating of A:VIII or better
(or an equivalent rating by another nationally recognized insurance rating
agency of similar standing if Best's Insurance Guide and Key Ratings shall
no longer be published).
(c) PEF shall ensure that each subcontractor shall procure and maintain at all
times during the period of its performance of work with respect to the
Project such insurance as shall be reasonable and in accordance with
industry practices in relation to the work being performed or services
provided and as is customary for companies of similar size engaged in
similar businesses. Despite any conflicting provision in PEF's or any
subcontractor's insurance policies to the contrary, any comparable
insurance carried by Ranchcorp which may be applicable shall be deemed to
be excess insurance. All insurance required pursuant to this Section shall
be primary for all purposes under this Agreement and all of the insurance
to be carried by PEF or any subcontractor pursuant to this Section shall so
provide.
(d) All liability insurance coverage required under this Lease (except for
workers' compensation coverages) shall, to the extent available and on
reasonable commercial terms, include Ranchcorp and its directors, officers,
agents and employees and Covered
Lenders as additional insureds and provide coverage on an occurrence basis
or another basis substantially equivalent to that. "Covered Lenders" means
lenders having as security for the obligations owed to them all or any part
of the Premises or the Easement Parcels (as defined in the Option
Agreement). All such policies shall contain "cross-liability" or
"severability of interest" clauses or endorsements. Notwithstanding any
other provision of such policies, the insurance afforded shall apply
separately to each insured, named insured, or additional insured with
respect to any claim, suit, or judgment made or brought by or for any other
insured, named insured, or additional insured as though a separate policy
had been issued to each, except the insurer's liability shall not be
increased beyond the amount or amounts for which the insurer would have
been liable had only one insured been named. Ranchcorp shall not, by reason
of its inclusion under any of these policies, incur liability to the
insurance carrier for the payment of any premium.
(e) PEF and Ranchcorp shall require their insurance carriers, with respect to
all insurance policies to be carried with respect to the Project, to waive
all rights of subrogation against each other and, in the case of PEF, such
waivers shall include Ranchcorp and Ranchcorp's directors, officers, agents
and employees. PEF agrees to exercise its reasonable efforts to obtain from
any subcontractor waivers of subrogation against Ranchcorp and Ranchcorp's
directors, officers, agents and employees.
(f) Any insurance required to be obtained and maintained by PEF shall be
subject to either (A) a deductible not exceeding $100,000 (the "Maximum
Deductible Amount") per policy period, or (B) a deductible amount per
policy period satisfactory to PEF that exceeds the Maximum Deductible
Amount (a "PEF Deductible Amount"); provided, that, in the event that
--------
Ranchcorp has incurred any loss or has any claim for which insurance
proceeds would have been payable under the insurance then required to be
maintained by PEF under Section 8.4(a) but for the fact that the deductible
amount exceeded the Maximum Deductible Amount, PEF shall pay to Ranchcorp
an amount (the "PEF Deductible Payment") equal to the additional amount of
the insurance proceeds which would have been paid to Ranchcorp pursuant to
such loss or claim under such insurance policy then required to be
maintained by PEF under Section 8.4(a), but for the fact that such
insurance policy was subject to the PEF Deductible Amount and not the
Maximum Deductible Amount.
If PEF elects to maintain any insurance policy required pursuant to Section
8.4(a) which is subject to a PEF Deductible Amount rather than a Maximum
Deductible Amount, PEF shall cause a Calpine Guaranty, guaranteeing payment
to Ranchcorp of any PEF Deductible Payment, if and to the extent that such
PEF Deductible Payment becomes due and payable under this Section 8.4(f),
to be issued in favor of Ranchcorp. If during any period that a Calpine
Guaranty is required to be maintained hereunder, either the tangible net
worth (as such term is defined under GAAP) of Calpine shall be less than
Four Hundred Fifty Million Dollars ($450,000,000), or any voluntary or
involuntary bankruptcy proceeding has been commenced against Calpine, then
PEF shall promptly, and in any event within the number of days specified
below, obtain or cause to be obtained either (1) insurance satisfying the
requirements of Section 8.4(a) which is subject to the Maximum Deductible
Amount within 45 days after PEF acquires actual knowledge of the decrease
in net worth or the commencing of bankruptcy proceedings as contemplated
above, or (2) replacement security for such Calpine Guaranty provided
pursuant to this Section 8.4(f) within 15 business days after PEF acquires
actual knowledge of the decrease in net worth or the commencing of
bankruptcy proceedings
as contemplated above, which replacement security shall be reasonably
satisfactory to Ranchcorp, it being acknowledged and agreed by Ranchcorp
that either (x) a replacement guaranty issued by an affiliate of Calpine
which maintains a tangible net worth (as defined under GAAP) of not less
than Four Hundred Fifty Million Dollars ($450,000,000) in form and
substance substantially equivalent to the Calpine Guaranty being replaced,
(y) cash or cash-equivalents of not less than the excess of the PEF
Deductible Amount over the Maximum Deductible Amount, which are pledged as
collateral security for PEF's obligations for any PEF Deductible Payment,
pursuant to a security agreement in form and substance reasonably
satisfactory to Ranchcorp which, together with any additional documents or
instruments provided by or on behalf of PEF, provide a perfected,
first-priority security interest in and to such collateral to Ranchcorp, or
(z) a letter of credit to be drawable in the United States in form and
substance reasonably satisfactory to Ranchcorp and in a stated amount of
not less than the excess of the PEF Deductible Amount over the Maximum
Deductible Amount issued by an LOC Bank, naming Ranchcorp as the
beneficiary thereof, shall be deemed to be reasonably satisfactory to
Ranchcorp.
(g) In the event any insurance hereby required to be maintained by PEF, other
than insurance required by law to be maintained, shall not be available and
commercially feasible in the commercial insurance market, Ranchcorp shall
not unreasonably withhold its agreement to waive such requirement to the
extent maintenance thereof is not so available; provided, however, that (i)
PEF shall first request any such waiver in writing, which request shall be
accompanied by a letter from a licensed insurance advisor of recognized
national standing certifying that such insurance is not reasonably
available and commercially feasible in the commercial insurance market for
electric generating plants of similar type and capacity as the Project and
explaining in detail the basis for such conclusions, such insurance advisor
and the form and substance of such reports to be reasonably acceptable to
Ranchcorp; (ii) at any time after the granting of any such waiver,
Ranchcorp may request, and PEF shall furnish to Ranchcorp within thirty
(30) days after such request, supplemental reports reasonably acceptable to
Ranchcorp from such insurance advisor updating its prior report and
reaffirming such conclusion; and (iii) any such waiver shall be effective
only so long as such insurance shall not be available and commercially
feasible in the commercial insurance market, it being understood that
failure of PEF to timely furnish any requested supplemental report shall be
conclusive evidence that such waiver is no longer effective because such
condition no longer exists, but that such failure is not the only way to
establish such nonexistence. Failure at any time to satisfy the conditions
to any waiver of an insurance requirement set forth in the proviso to the
preceding sentence shall not impair or be construed as a relinquishment of
PEF's ability to obtain a waiver of an insurance requirement pursuant to
the preceding sentence at any other time upon satisfaction of such
conditions.
(h) PEF shall furnish Ranchcorp with certificates of insurance on forms
acceptable to Ranchcorp to evidence that policies providing the required
coverage and limits of insurance for PEF are in full force and effect. The
certificates shall provide that any company issuing an insurance policy
under this Agreement shall provide not less than thirty (30) days' advance
notice in writing to Ranchcorp prior to cancellation, termination, or
material change of any policy of insurance and ten (10) days' advance
notice in writing to Ranchcorp prior to cancellation for non-payment. In
addition, PEF shall immediately provide written notice to Ranchcorp upon
receipt of notice of cancellation of an insurance policy or decision to
terminate or materially change an insurance policy. All certificates of
insurance shall clearly state that all applicable requirements of this
Section have been satisfied. Certificates of insurance for insurance to be
furnished by PEF pursuant to this Section and notices of any cancellations,
terminations, or alterations of such policies shall be mailed to Ranchcorp
at the address set forth for notices to Ranchcorp in this Lease.
(i) The coverage requirements set forth in this Section shall be adjusted every
five years, commencing in 2004, by an amount reflecting the annual
percentage increase (if any) in the CPI, during the twelve-month period
from the date that is fifteen (15) months prior to the date of the
escalation to the date that is three (3) months prior to the date of the
escalation. In the event the CPI is ever discontinued, the parties shall
substitute any generally recognized successor or substitute index published
by a governmental agency and reflecting changes in consumer prices in the
greater Los Angeles area.
8.5 General Construction Requirements.
(a) PEF shall construct the Project and any Alterations in strict
accordance with all Applicable Laws, and with all other provisions of this
Lease.
(b) Prior to the commencement of construction, Ranchcorp shall have
the right to post in a conspicuous location on the Premises as well as to record
in the Official Records of ▇▇▇▇ and Los Angeles Counties, a Notice of
Ranchcorp's Nonresponsibility. PEF covenants and agrees to give Ranchcorp at
least ten (20) days prior written notice of the commencement of any
construction.
(c) PEF shall take all necessary safety precautions during any
construction.
8.6 Construction Completion Procedures.
(a) On completion of the construction of the Project or any
Alterations during the Term, PEF shall file for recordation, or cause to be
filed for recordation, a notice of completion. PEF hereby appoints Ranchcorp as
PEF's attorney-in-fact to file the notice of completion on PEF's failure to do
so after the work of improvement has been substantially completed.
(b) On completion of construction of the Project or any Alterations,
PEF shall deliver to Ranchcorp evidence satisfactory to Ranchcorp of payment of
all costs, expenses, liabilities and liens arising out of or in any way
connected with such construction (except for liens that are contested in the
manner provided in this Lease).
8.7 Mitigation Measures. PEF will incorporate into the design, construction
and operation of the Project the environmental mitigation measures and pollution
and waste (including waste water and/or solid waste) control technologies
described in Schedule 8.7.
8.8 Laydown License Area. During the construction of the Project, Ranchcorp
shall allow PEF an exclusive license to enter upon and use such adjacent
property belonging to Ranchcorp in the Site Selection Area as shall be
reasonably needed (currently thought to be 75 contiguous acres) for the storage
of equipment and materials for the Project, for staging of construction work on
the Project, and for construction of the Project (the "Laydown License Area").
8.9 Permits. Ranchcorp shall, upon written request of PEF, execute and
deliver all applications for permits, licenses or other authorizations relating
to the construction, use and occupancy of the Premises and the Improvements
required by any municipal, county, state or federal authorities, or required in
connection with any repair or Alteration of the Improvements, provided that such
permits, licenses or other authorizations are consistent with the terms of this
Lease and the other Project Agreements.
8.10 Personal Property. All equipment, furniture and other personal
property installed by PEF on the Premises shall remain the property of PEF. At
any time during the Term, PEF may remove any and all such equipment, furniture
and personal property. Any removal shall be performed in a good and workmanlike
manner and PEF shall repair any damage or injury to the Premises resulting from
the removal. PEF shall be entitled to all depreciation or amortization
deductions attributable to all such equipment, furniture and personal property.
8.11 Easements. Upon request by PEF, Ranchcorp shall grant to public
entities and public utilities, for the sole purpose of providing operating
utilities to the Project, rights of way or easements on, in or over the Premises
for poles or conduits or both for telephone, electricity, water, sanitary sewers
and storm sewers and for other utility, municipal and district services
reasonably required for the Project or any Alterations, in locations and on
alignments subject to Ranchcorp's reasonable review and approval. Ranchcorp
agrees to execute and acknowledge all required documentation to create the
required easements or rights of way. This Section 8.11 shall not apply to any
easement or right of way that is included in the Easement Deed and Agreement
between the parties of even date with this Lease.
8.12 Ownership of Improvements. The Improvements shall be owned in fee by
PEF or a permitted sublessee of the Premises. At any time during the Term, PEF
may remove any and all of the Improvements. Any removal shall be performed in a
good and workmanlike manner consistent with the requirements of this Section 8.
PEF shall repair any damage or injury to the Premises resulting from the
removal. PEF shall be entitled to all depreciation or amortization deductions
attributable to the Improvements.
8.13 Surrender. Before the end of the Term, PEF shall decommission the
Project by removing all buildings, equipment, and personal property from the
Premises and shall return the Premises to their pre-construction condition. For
purposes of this section and Section 8.14, the "Project" refers to the original
generating plant, as well as any Alterations, subsequent expansions,
re-powering, or other modifications thereof, and any then-existing above-ground
power lines. PEF may abandon buried pipelines in place after decommissioning
them in accordance with applicable state and/or federal regulations.
8.14 Decommissioning Security. Concurrently with the execution of this
Lease, PEF has furnished Ranchcorp with security for its obligations under
Section 8.13 in the form required under Section 4.2(e) of the Option Agreement.
8.15 Material Environmental Conditions. In the event that during
construction of the Project PEF discovers any Hazardous Substance on the
Property which will prevent or materially interfere with or make materially more
costly the construction, operation or financing of the Project, Ranchcorp shall
within 25 days after request therefor by PEF identify alternative property
adjacent to or in the vicinity of the Project site which will enable PEF to
avoid the Hazardous Substance (and any other Hazardous Substance) without making
access to the WRM and DWR electric loads less feasible physically or
economically than the property affected by the Hazardous Substance and which is
not affected by any Hazardous Substance but is
otherwise generally as suitable for the Project as the property affected by the
Hazardous Substance (the "Alternative Property"). If PEF approves the
Alternative Property (which approval shall not be unreasonably withheld or
delayed), this Agreement shall be amended to substitute the Alternative Property
for the portion of the Property affected by the Hazardous Substance and this
Lease shall be amended, and the memorandum hereof recorded to reflect the
substitution. Notwithstanding the foregoing, in the event no Alternative
Property is or can be supplied and a governmental authority requires cleanup of
the Hazardous Substance, then Ranchcorp will at its option either (A) clean up
or remediate the Hazardous Substance when and to the extent required by the
governmental authority, or (B) reimburse PEF for its costs incurred in cleaning
up or remediating the Hazardous Substance when and to the extent required by the
governmental authority. PEF's rights under this Section shall not be impaired by
its failure to exercise any of its rights under Section 1.5(c) or 11.3 of the
Option Agreement.
Section 9. Maintenance; Repairs; Reconstruction.
9.1 Maintenance. PEF shall keep the Premises and the Improvements in good
order, condition and repair, including without limitation, all repairs to the
exterior or interior of the Improvements and all repairs of a structural nature.
All repairs shall be at the expense of PEF, except repairs caused by the
negligence or willful conduct of Ranchcorp or Ranchcorp's agents. Ranchcorp
shall not be obligated to make any repairs, replacements or renewals of any
kind, nature or description whatsoever (including but not limited to repairs or
restoration) required due to flooding of Pastoria Creek, and PEF hereby
expressly waives any right to terminate this Lease and any right to make repairs
at Ranchcorp's expense under Sections 1932, 1933, 1941 and/or 1942 of the
California Civil Code, or any amendments thereof or any similar law, statute or
ordinance now or hereafter in effect on account of any such flooding or any
failure to make any such repairs.
9.2 Obligation to Repair. PEF shall have the right to contest by
appropriate judicial or administrative proceedings, without cost or expense to
Ranchcorp, the validity or application of any Applicable Law or other
requirement that PEF repair, maintain, alter or replace the Improvements in
whole or in part or that would affect PEF's use of the Premises or the
Improvements. In the event that any such contest is finally determined in a
manner adverse to PEF, PEF shall either undertake the required repairs,
maintenance, alterations or replacements to the Premises and the Improvements,
or modify its use of the Premises and the Improvements so that no repair,
maintenance, alteration or replacement is required.
9.3 Damage or Destruction. If the Improvements are totally or partially
destroyed or damaged at any time, PEF may repair or reconstruct the
Improvements.
Section 10. Hazardous Substances
PEF shall provide to Ranchcorp prior to commencing construction of the
Project, and shall thereafter periodically update, a list of Hazardous
Substances that PEF requires on the Premises for the construction, operation,
maintenance and/or decommissioning of the Project or any Alterations. PEF shall
not cause or permit possession or storage on the Premises of any Hazardous
Substance other than those named on the then-most recent list of Hazardous
Substances provided to Ranchcorp. PEF shall not cause or permit to occur during
the Term any unlawful Release of a Hazardous Substance on, about or beneath the
Premises, whether affecting surface water or groundwater, air, the surface or
subsurface environment. In the event any unlawful Release of a Hazardous
Substance to the environment occurs on or about or beneath the Premises during
the Term as a result of any act or omission of PEF or any of PEF's
Agents, PEF shall promptly undertake all remedial measures required to clean up
and ▇▇▇▇▇ or otherwise respond to the unlawful Release in accordance with
applicable Environmental Laws at PEF's sole cost, and PEF shall, subject to
Section 12.8 of the Transaction Agreement, indemnify, defend, protect and hold
Ranchcorp harmless from and against any and all claims, losses, first and third
party damages, liabilities and costs, including without limitation reasonable
consultants' and attorneys' fees and costs, arising out of or relating to the
presence of Hazardous Substances on or about the Premises as a result of any act
or omission of PEF or PEF's Agents. If any unlawful Release of a Hazardous
Substance which is used on the Premises by PEF or any of PEF's Agents comes to
be located on or beneath the Premises or within 50 feet of the property line of
the Premises, unless the source of such release is readily identifiable at the
time the Release becomes known, such release shall be presumed (subject to the
following sentence) to be the result of an act or omission of PEF or PEF's
Agents and shall trigger PEF's remedial and indemnity obligations under this
section. Those obligations shall continue in effect until and unless a different
source of the Release is identified with a reasonable degree of certainty, as
evidenced either by Ranchcorp's written concurrence with identification of a
different source or a decision concurring with identification of a different
source by an arbitrator engaged pursuant to the following sentence. Any dispute
between the parties regarding the source of a Release shall be resolved by
arbitration as provided under Section 12 of the Transaction Agreement. Nothing
in this Lease is intended to release any party from any liability it may have
under the Comprehensive Environmental Response Compensation and Liability Act.
The prior sentence is not intended to modify any indemnity or other undertaking
of any party under any of the Project Agreements.
Section 11. Sublease.
PEF shall have the right from time to time or at any time to sublet the
Premises (a) to any Project Financing Entity as may be necessary or convenient
in connection with any financing of the Project, and (b) to any Person who or
which is a Qualified Person at the date of the sublease; provided that any
subtenant must be an owner of the Project and must have assumed PEF's
obligations under the Transaction Agreement and the Easement Agreement. Upon the
execution of any permitted sublease of the Premises by PEF, Ranchcorp shall
execute a non-disturbance agreement in form satisfactory to both Ranchcorp and
PEF in their reasonable discretion. Any such sublease shall be subject in all
respects to this Lease.
Section 12. Assignments and Pledges of Collateral.
Subject to and only in accordance with the terms of Section 11 and Schedule
11.4 of the Transaction Agreement, PEF shall have the right, at any time and
from time to time, to enter into any leasehold mortgage or other security
agreement regarding, or to assign all or portions of, its rights and interests
under this Lease. All other assignments, pledges, mortgages, or other transfers
of PEF's rights or interests under this Lease, except for those permitted under
Section 11 and Schedule 11.4 of the Transaction Agreement, are prohibited.
Section 13. Indemnity.
13.1 Indemnity.
Subject to Section 12.8 of the Transaction Agreement:
(a) With respect to claims by PEF or by any of PEF's Agents or by third
parties (other than any of the Tejon Interests) arising or claimed to arise out
of the presence or activities of
PEF or any of PEF's Agents on the Tejon Ranch, and to claims by PEF or by any of
PEF's Agents for work performed on the Project or for materials supplied to the
Project, PEF will defend, indemnify and hold Ranchcorp harmless from all actual
losses, damages, liabilities, claims, expenses, causes of action, judgments and
liens filed against the Premises or against any other land or land rights owned
by Ranchcorp in ▇▇▇▇ County, California, arising directly from the actions of
PEF or any of PEF's Agents, except to the extent arising (i) from active
negligence, recklessness, willful misconduct or breach of contract or law by
Ranchcorp or any of Ranchcorp's Agents, (ii) as a consequence of strict
liability imposed upon Ranchcorp or any of Ranchcorp's Agents as a matter of
law, or (iii) from the discovery or disclosure of any Hazardous Substance or
other substance in, under or about the Tejon Ranch unless the presence thereof
is due to any act or omission of PEF or any of PEF's Agents.
(b) With respect to claims by Ranchcorp for physical damage to its property
or for personal injury to Ranchcorp or Ranchcorp's Agents arising out of the
presence of PEF or any of PEF's Agents on the Tejon Ranch, PEF will defend,
indemnify and hold Ranchcorp harmless from all actual losses, damages, liens,
liabilities, claims, expenses, causes of action and judgments arising directly
from the actions of PEF or any of PEF's Agents, except to the extent arising (i)
from negligence, recklessness, willful misconduct or breach of contract or law
by Ranchcorp or any of Ranchcorp's Agents, (ii) as a consequence of strict
liability imposed upon Ranchcorp or any of Ranchcorp's Agents as a matter of
law, or (iii) from the discovery or disclosure of any Hazardous Substance or
other substance in, under or about the Tejon Ranch unless the presence thereof
is due to any act or omission of PEF or any of PEF's Agents.
Section 14. Mechanics and Other Liens.
PEF shall keep the Premises free and clear of all mechanics', materialmen's
and other liens for work done, services performed or materials used in or about
the Premises or the Improvements or in connection with any operations of PEF
("Mechanics' Liens"). PEF shall have the right to contest the amount or validity
of any Mechanics' Lien by giving Ranchcorp written notice of PEF's intention to
do so within twenty (20) days after the recording of a Mechanics' Lien. During
the period of the contest, provided that PEF properly records the bond
permitted, in the amount provided, by California Civil Code Section 3143,
Ranchcorp shall not satisfy and discharge the Mechanics' Lien and PEF shall not
be in default so long as such bond remains valid and effective. PEF shall
satisfy and discharge any Mechanics' Lien within twenty (20) days after the
final determination of its amount or validity to the extent held valid and all
penalties, interest and costs related to the Lien; provided, however, that the
satisfaction and discharge of the Mechanics' Lien shall not, in any case, be
delayed until execution is levied upon any judgment. PEF shall indemnify and
hold Ranchcorp harmless against all loss, cost, expense and damage (including
reasonable attorneys' fees) arising out of the contest. Ranchcorp shall not be
required to join in any proceeding to contest the amount or validity of any
Mechanics' Lien, except that if any law shall require that the proceeding be
brought by Ranchcorp, Ranchcorp agrees to join in the proceeding, or permit it
to be brought in its name. Ranchcorp shall cooperate with PEF in any contest.
PEF's obligations under this Section with regard to Mechanic's Liens arising
prior to the Commercial Operation Date are guaranteed by Calpine under Section
2.2 of the Transaction Agreement.
Section 15. Eminent Domain.
15.1 Taking of Premises. If at any time during the Term, all or any portion
of the Project or the Premises are taken as a result of the exercise of the
right of eminent domain, the rights of Ranchcorp and PEF to the compensation for
the taking shall be determined in
accordance with this Section 15. The terms "taken" or "taking" shall mean an
acquisition and/or damaging, including severance damage, by eminent domain, or
by inverse condemnation, or by voluntary deed or transfer in contemplation of a
taking or under threat of a taking, or for any public or quasi-public use under
any statute or law. The "date of taking" shall be the earliest of (a) the date
actual physical possession is taken by the condemnor; (b) the date on which the
right to compensation and damages accrues under Applicable Laws; or (c) the date
on which title vests in the condemnor. "Entire Taking" means a taking as the
result of which operating the Project, even at reduced capacity, to produce
electric energy and/or to provide Ancillary Services is not, and is not
reasonably likely to become again, commercially viable. "Partial Taking" means a
taking other than an Entire Taking.
15.2 Effect on Rent. In the event of a Partial Taking as a result of which
the capacity of the Project is reduced, this Lease shall continue in full force
and effect for the remainder of the Term and : (a) Fixed Rent shall be adjusted
as set forth in the same manner as for changes in "C" under Section 3.2(c), and
(b) Variable Rent shall be adjusted by adjusting the factor "C" in the formula
stated in Section 3.4(c) for calculating the Spark Spread to conform with the
reduced capacity of the Project. During any period of a temporary taking, or
during any period after the date of a Partial Taking, during which the Project
necessarily ceases to operate, no portion of Rent shall be abated.
15.3 Notice. The party receiving any notice of an intended taking, service
of legal process relating to a taking, notice regarding any proceedings or
negotiations with respect to a taking, or notice of intent to negotiate a
transfer in lieu of a taking shall promptly give the other party notice of the
receipt, contents and date of the notice received. PEF shall provide any Project
Financing Entity with a copy of any notice of any threatened or pending taking.
15.4 Compensation. The rights of Ranchcorp and PEF to any award,
compensation or damages for a taking shall be separately determined by the
condemning authority or the court having jurisdiction over any proceedings as
follows:
(a) Entire Taking. In the event of an Entire Taking, this Lease shall
terminate on the date of taking and each party shall have the right to make its
own claim for any and all awards, compensation and damages for the taking. The
parties agree that an element of Ranchcorp's claim will be the present value of
its rental stream under this Lease.
(b) Partial Taking. In the event of a Partial Taking, all awards,
compensation and damages shall first be used for replacement and restoration of
the Project and the Premises, and then the remainder shall be allocated between
Ranchcorp and PEF as provided in Section 15.4(a).
(c) Temporary Taking. If the Project or the Premises are temporarily taken,
PEF shall receive the entire amount of any awards, compensation and damages for
the temporary taking, and Ranchcorp hereby assigns such awards, compensation and
damages to PEF to the extent that the taking does not extend beyond the
expiration of the Term.
15.5 Representation in Proceedings or Negotiations. Subject to the
allocation provisions of Section 15.4, Ranchcorp, PEF and any Project Finance
Entities shall have the right to participate as their interests may appear in
any proceeding, negotiation or settlement of awards, compensation and damages
and may contest and appeal any awards, compensation and damages. Neither
Ranchcorp nor PEF shall enter into any agreement or settlement with or sale or
transfer to the condemning authority without the consent of the other. Ranchcorp
and
PEF each agree to execute and deliver to the other any instruments which may be
required to effectuate or facilitate the provisions of this Section 15. In the
event the condemning authority or court having jurisdiction over any takings
proceedings does not make the allocation and distribution of the award,
compensation and damages in accordance with this Section 15, and the parties
cannot mutually agree upon the appropriate allocation, the allocation shall be
determined pursuant to the dispute resolution provisions set forth in Section 12
of the Transaction Agreement.
Section 16. Ranchcorp's Right of Inspection.
Ranchcorp may, at reasonable times during the Term and upon reasonable
prior written notice to PEF, enter upon the Premises during regular business
hours for the purpose of inspecting the Premises and the Improvements and for
such other purposes as the reasonable protection of its interests requires,
subject, however, to PEF's reasonable requirements regarding security on the
Premises and the confidentiality of its business affairs, which shall not bar
Ranchcorp's right to make reasonable inspections.
Section 17. Default.
The occurrence of any one of the following shall constitute a default and
breach of this Lease by PEF. Notices given under this Section 17 shall specify
the alleged default and the applicable Lease provisions, and shall demand that
PEF perform the provisions of this Lease or pay the rent that is in arrears, as
the case may be, within the applicable time period. Ranchcorp need not elect its
remedy or remedies for an uncured default at the time it gives notice of a
default.
17.1 Failure to Pay Rent. Any failure of PEF to pay Rent or any other
required payments, where the failure continues for a period of ten (10) days
after written notice from Ranchcorp to PEF. Such notice shall not be deemed to
be the notice required under California Code of Civil Procedure Section 1161;
Ranchcorp must separately provide such Section 1161 notice.
17.2 Failure to Observe Other Provisions. Any failure by PEF to observe or
perform any other provision of this Lease to be observed or performed by PEF,
where the failure continues for thirty (30) days after written notice by
Ranchcorp to PEF. Such notice shall not be deemed to be the notice required
under California Code of Civil Procedure Section 1161; Ranchcorp must separately
provide such Section 1161 notice. However, if the nature of PEF's default is
such that it cannot reasonably be cured within the thirty (30) day period, PEF
shall not be in default if PEF commences the cure within the thirty (30) day
period and thereafter diligently prosecutes the cure to completion.
17.3 Abandonment. The abandonment of the Premises.
17.4 Insolvency. Should PEF admit in writing its inability to pay its debts
generally as they become due, file a petition in bankruptcy, insolvency,
reorganization, readjustment of debt, dissolution or liquidation under any law
or statute of any government or any subdivision thereof either now or hereafter
in effect, make an assignment for the benefit of its creditors, consent to or
acquiesce in the appointment of a receiver of itself or of the whole or any
substantial part of the Premises.
17.5 Receivership. Should a court of competent jurisdiction enter an order,
judgment or decree appointing a receiver of PEF or of the whole or any
substantial part of the Premises or of the Project and should such order,
judgment or decree not be vacated, set aside or stayed within ninety (90) days
after the date of entry of such order, judgment, or decree, or should a stay
thereof be thereafter set aside.
17.6 Involuntary Bankruptcy. Should a court of competent jurisdiction enter
an order, judgment or decree approving a petition filed against PEF under any
bankruptcy, insolvency, reorganization, readjustment of debt, dissolution or
liquidation law or statute of the federal government or any state government or
any subdivision of either now or hereafter in effect, and should such order,
judgment or decree not be vacated, set aside or stayed within sixty (60) days
from the date of entry of such order, judgment or decree, or should a stay
thereof be thereafter set aside.
Section 18. Remedies.
In the event of a default by PEF, Ranchcorp shall have the following
remedies. These remedies are not exclusive; they are cumulative and are in
addition to any other right or remedy available to Ranchcorp at law or in
equity. Ranchcorp may initiate an action for damages or injunctive relief
without terminating this Lease or PEF's right to possession.
18.1 Termination of Right to Possession. If the default is in the
observance or performance of any material obligation of PEF under this Lease,
Ranchcorp may terminate PEF's right to possession of Premises. The parties agree
that a "material obligation" shall be any obligation of PEF which is material to
the realization by Ranchcorp of any of the material benefits intended to be
conferred on Ranchcorp by this Lease and includes without limitation any default
under Section 17.1. No act by Ranchcorp, other than giving specific notice of
termination to PEF, shall terminate this Lease. Acts of maintenance, or efforts
to relet the Premises, shall not constitute a termination of PEF's right to
possession. On termination, Ranchcorp has the right to recover from PEF: (a) the
worth, at the time of the award, of the unpaid Rent that had been earned at the
time of termination of this Lease; (b) the worth, at the time of the award, of
the amount by which the unpaid Rent that would have been earned after the date
of termination of this Lease until the time of the award exceeds the amount of
loss of rent that PEF proves could have reasonably been avoided; and (c) the
worth, at the time of the award, of the amount by which the unpaid Rent for the
balance of the Term after the time of the award exceeds the amount of the loss
of Rent that PEF proves could have been reasonably avoided;
"The worth, at the time of the award," as used in (a) and (b) of this
Section 18.1 is to be computed by allowing interest at the rate of 10% per
annum. "The worth, at the time of the award," as referred to in (c) of this
Section 18.1, is to be computed by discounting the amount by the discount rate
of the Federal Reserve Bank of San Francisco at the time of the award, plus 1%.
18.2 Civil Code Section 1951.4. Ranchcorp shall have the remedy described
in California Civil Code Section 1951.4 (lessor may continue lease in effect
after lessee's breach and abandonment and recover rent as it becomes due, if
lessee has right to sublet or assign, subject only to reasonable limitations).
18.3 Self-Cure; Costs Thereof. In the event of a default arising from PEF's
failure to perform work required to be performed by PEF under this Lease within
the time required by the Lease and/or by Ranchcorp's related notice of default,
unless Ranchcorp is expressly prohibited from performing such work by this
Lease, Ranchcorp may elect, but shall not be required, to perform such work
after delivery of thirty (30) days prior written notice to PEF of such election
(except that no such prior notice shall be required in the event of an
emergency). If Ranchcorp so elects, PEF shall pay all of Ranchcorp's costs and
expenses of such work, plus an overhead and management fee of ten percent (10%)
of such costs and expenses, within twenty (20) days after PEF receives
Ranchcorp's itemized invoice for such work. If PEF does not pay such an invoice
within such 20-day period, (i) the obligation shall accrue interest at the rate
of 10% per annum without compounding from the twentieth day after PEF received
the invoice until it is fully paid, and (ii) without further notice to PEF,
shall constitute a default under Section 17.1.
Section 19. Waiver.
No waiver of any default under this Lease shall constitute or operate as a
waiver of any subsequent default, and no delay, failure or omission in
exercising or enforcing any right, privilege, or option under this Lease shall
constitute waiver, abandonment or relinquishment of, or prohibit or prevent any
election under or enforcement or exercise of, any right, privilege or option
under this Lease. Any waiver of any provisions of this Lease by Ranchcorp or PEF
must be in writing and signed by the party against whom it is sought to be
enforced. The receipt by Ranchcorp of Rent with knowledge of any default under
this Lease, or after having provided notice of a default, or after having
commenced an action to enforce this Lease shall not constitute or operate as a
waiver of the default, unless the payment of such Rent cures the monetary
default.
Section 20. No Merger.
There shall he no merger of the leasehold estate created by this Lease with
the fee estate in the Premises by reason of the fact that the same person may
own or hold (i) the leasehold estate created by this Lease or any interest in
the leasehold estate and (ii) the fee estate in the Premises or any interest in
the fee estate unless and until Ranchcorp shall execute, acknowledge and record
a written instrument effecting the merger. Termination of this Lease shall not,
unless Ranchcorp elects, cause a merger of the estates of Ranchcorp and PEF.
Termination shall, at the option of Ranchcorp, either cause a termination of any
sublease in effect or act as an assignment to Ranchcorp of PEF's interest in any
sublease.
Section 21. Reserved
Section 22. General Provisions.
22.1 Covenants Running With the Land. The agreements, covenants and
conditions contained in this Lease are and shall be deemed to be covenants
running with the land and the reversion and shall be binding upon and shall
inure to the benefit of Ranchcorp and PEF and their respective permitted
successors and assigns. All references in this Lease to "PEF" or "Ranchcorp"
shall be deemed to refer to and include permitted successors and assigns of PEF
or Ranchcorp, respectively, without specific mention of such successors or
assigns.
22.2 Estoppel Certificates. PEF or Ranchcorp, as the case may be, shall
execute, acknowledge and deliver to the other or any Person specified by the
other, promptly upon request, its certificate certifying: (a) that this Lease is
unmodified and in full force and effect (or,
if there have been modifications, that this Lease is in full force and effect,
as modified, and stating the modifications); (b) the dates, if any, to which all
Rent has been paid; (c) whether there are then existing charges, offsets or
defenses against the enforcement by Ranchcorp of any agreement, covenant or
condition on the part of PEF (and, if so, specifying the same); and (d) whether
there are then existing any defaults by PEF under the Lease and whether any
notice has been given to PEF of any default which has not been cured (and, if
so, specifying the same). Any certificate may be relied upon by the Person to
whom the certificate is delivered.
22.3 Holding Over. This Lease shall terminate without further notice upon
the expiration of the Term, and any holding over by PEF after the expiration of
the Term shall not constitute a renewal or give PEF any rights to the Premises.
PEF shall pay Rent as provided under Section 3 of this Lease during any holdover
period. If PEF holds over with the consent of Ranchcorp, PEF shall be a tenant
from month-to-month during the holdover period. If PEF holds over without
Ranchcorp's consent, PEF shall be a tenant at sufferance during the holdover
period.
22.4 Miscellaneous.
(a) Time is of the essence in each of the provisions of this Lease.
(b) All Exhibits referred to are attached to this Lease and
incorporated by reference.
(c) Contemporaneously with the execution of this Lease, Ranchcorp and
PEF will execute, acknowledge and record in the Official Records of ▇▇▇▇ County
a memorandum of lease in the form of attached Schedule 22.4(c).
(d) The provisions of Section 14 of the Transaction Agreement apply to
this Lease.
(e) This Agreement may be executed in one or more counterparts, all of
which shall be considered one and the same agreement, and shall become effective
when one or more counterparts have been signed by each of the parties hereto and
delivered to the other party.
22.5 Authority of PEF. PEF warrants to Ranchcorp that PEF is a validly
existing limited liability company under the laws of the State of Delaware, that
it is duly qualified to do business in the State of California, that its entry
into and performance of this Lease has been duly authorized, that the
officer(s), director(s), or employee(s), as applicable, executing this Lease on
PEF's behalf are duly authorized to do so, and that this Lease is binding upon
PEF.
22.6 Authority of Ranchcorp. Ranchcorp warrants to PEF that Ranchcorp is a
validly existing corporation under the laws of the State of California, that its
entry into and performance of this Lease has been duly authorized, that the
officer(s), director(s), or employee(s), as applicable, executing this Lease on
Ranchcorp's behalf are duly authorized to do so, and that this Lease is binding
upon Ranchcorp.
22.7 Labor Issues. The parties will consult with one another, and consider
each other's views, regarding labor issues of concern to either party
22.8 Consent. Without prejudice to its other rights and remedies under this
Lease and the other Project Agreements, either party shall have the right to
institute an arbitration for declaratory relief under Section 12 of the
Transaction Agreement to determine whether any proposed withholding or delay of
any consent or approval by the party would be unreasonable.
Section 23. Glossary.
Additional Rent - Section 3.6.
Affiliate - Section 15 of the Transaction Agreement.
Alterations - Section 8.2.
Ancillary Services -- Section 3.4(d).
Applicable Laws - all applicable laws, codes, ordinances, orders, rules,
regulations and requirements, including, without limitation, all Environmental
Laws, of all federal, state, county, municipal and other governmental
authorities and the departments, commissions, boards, bureaus,
instrumentalities, and officers relating to or affecting the Premises, the
Improvements or the use, operation or occupancy of the Premises, whether now
existing or hereafter enacted.
C - Section 3.4(c).
Calpine - Section 8.4(a)(v).
Calpine Guaranty - Section 8.4(a)(v).
Commencement Date - Section 2.1.
Commercial Operation Date - Section 2.1.
Daily Gas Price - Section 3.4(d).
Developer Interests - Calpine and PEF.
Entire Taking - Section 15.1.
Environmental Laws - all present and future federal, state and local laws,
statutes, ordinances, regulations, rules, judicial and administrative orders and
decrees, permits, licenses, approvals, authorizations and similar requirements
pertaining to the protection of human health and safety or the environment.
Excepted Cause - Section 15 of the Transaction Agreement.
Extended Term - Section 2.2.
Final Project Decision - the CEC's final decision with respect to the
Project AFC.
Fixed Rent - Section 3.1.
GAAP - Section 8.4(a)(v).
Gas Daily - Section 3.4(d).
GP -- Section 3.4(c).
Hazardous Substance - any chemical, substance, medical or other waste,
living organism or combination thereof which is or may be hazardous to the
environment or human or animal health or safety due to its radioactivity,
ignitability, corrosivity, reactivity, explosivity, toxicity, carcinogenicity,
mutagenicity, phytotoxicity, infectiousness or other harmful or potentially
harmful properties or effects. "Hazardous Substances" shall include, without
limitation, petroleum hydrocarbons, including crude oil or any fraction thereof,
asbestos, radon, polychlorinated biphenyls (PCBs), methane and all substances
which now or in the future may be defined as "hazardous substances," "hazardous
wastes," "extremely hazardous wastes," "Hazardous Substance," "toxic
substances," "infectious wastes," "biohazardous wastes," "medical wastes,"
"radioactive wastes" or which are otherwise listed, defined or regulated in any
manner pursuant to any Environmental Laws.
HR -- Section 3.4(c).
Improvements - Section 3.6.
Initial Term - Section 2.1.
ISO -- Section 3.4(d).
ISO Controlled Grid - Section 3.4(d).
ISO Tariff -- Section 3.4(d).
Laydown License Area - Section 8.8.
Minimum Deductible Amount - Section 8.4(f).
Mechanics' Liens - Section 14.
▇▇▇▇▇'▇ - Section 8.4(a)(v).
Nominal COD - Section 2.1
Option Agreement - Recitals.
Partial Taking - Section 15.
Pastoria Substation - Section 3.4(d).
PEF - introductory paragraph.
PEF's Agents - any Affiliate of either of the Developer Interests and any
contractor, consultant, agent, employee, invitee or other Person acting at the
request and for the benefit of any of the Developer Interests or any of their
Affiliates.
PEF Deductible Amount - Section 8.4(f).
PEF Deductible Payment - Section 8.4(f).
Premises - Section 1.
Project - Recitals.
Project Financing Agreements - Section 11.5 of the Transaction Agreement.
Project Financing Entity - Section 11.5 of the Transaction Agreement.
Project Financing -- Section 11.5 of the Transaction Agreement.
Property Taxes - Section 3.6.
PX - Section 3.4(d).
PX Price -- Section 3.4(d).
Qualified - Section 11.3(c) of the Transaction Agreement.
Ranchcorp - introductory paragraph.
Ranchcorp's Agents - any Affiliate of any of the Tejon Interests and any
contractor, consultant, agent, employee, invitee or other Person acting at the
request and for the benefit of any of the Tejon Interests or any of their
Affiliates.
Release - any accidental or intentional spilling, leaking, pumping,
pouring, emitting, emptying, discharging, injection, escaping, leaching,
migrating, dumping or disposing into the air, land, surface water, ground water
or the environment.
Rent - Section 3.1.
Revenue Day -- Section 3.4(d).
Revenue Hour -- Section 3.4(d).
S&P - Section 8.4(a)(v).
Security Agreement - Section 1 of Schedule 11.4 of the Transaction
Agreement.
Site Selection Area - Section 1.1 of the Option Agreement.
Spark Spread - Section 3.4(c).
Taken or Taking - Section 15.1.
Tejon Interests - Ranchcorp, Tejon Ranch Co. and Pastoria Power Project
LLC.
Tejon Ranch - the approximately 270,000 acres of real property in ▇▇▇▇ and
Los Angeles counties currently owned by Ranchcorp and known as The Tejon Ranch.
Term - Section 2.2.
Transaction Agreement - Recitals.
Variable Rent - Section 3.1.
IN WITNESS WHEREOF, Ranchcorp and PEF have executed this Lease as of the
date first written above.
TEJON RANCHCORP, PASTORIA ENERGY FACILITY L.L.C.,
a California corporation a Delaware limited liability company
By: By:
--------------------------------- ---------------------------------
Name: Name:
Title: Title:
By:
-------------------------------
Name:
Title:
Schedule 8.7
Environmental Mitigation Measures
1. Before commencing construction of the Project or at such other, later time
specified by Ranchcorp, PEF will plant one or more windrow(s) of trees
totaling not more than five miles in length in such location(s) on
Ranchcorp's land as Ranchcorp shall designate. Ranchcorp will notify PEF of
the type(s), number and spacing of the trees to be planted. PEF will
acquire trees of approximately 15 gallons in size for this purpose.
2. If PEF decides that it will construct the Project with a closed loop (dry)
cooling system, it shall design, build and operate that system to ensure no
exceedances of applicable noise emission standards stated in the General
Plan of ▇▇▇▇ County, California, as of the date of execution of the Option
Agreement.
3. If PEF decides that it will construct the Project with a water cooling
system, it shall pursue that approach in accordance with the following
terms:
A. PEF may design, construct and operate the Project with once through
cooling, provided that, if the Project includes one or more cooling
towers, PEF complies with the "Cooling Tower Conditions."
B. PEF may design, construct and operate the Project with a semi-open
system with waste water reduction, which produces waste water
discharge at a flow rate, and with concentrations of total dissolved
solids (TDS), suitable to ensure no degradation of waters in the
injection zone into which the waste water will be injected, provided
that, (i) after the Project is constructed, PEF will adjust the volume
of, and the TDS concentrations in, the Project's wastewater as
necessary to ensure that the wastewater can be disposed of in the
planned number and size of injection ▇▇▇▇▇ without increasing the TDS
concentration of the receiving water; and (ii) PEF complies with the
Cooling Tower Conditions.
C. Should neither once through cooling nor a semi-open cooling system be
available to the Project under the terms and conditions of paragraphs
A and B above, then PEF shall design, construct and operate the
Project
with a zero-discharge cooling system, provided that PEF complies with
the Cooling Tower Conditions.
The "Cooling Tower Conditions" are (i) that PEF will install drift
eliminators on the Project's cooling tower(s) of the type representing best
available technology for the control of particulate emissions from the
towers; and (ii) that PEF will contain any solid waste "salt cake" created
by operation of the Project's cooling towers to avoid discharge of the
waste material to air or land at or adjacent to the Premises prior to
required shipping of the waste off of the Premises for disposal.
4. PEF will restore the Laydown License Area to its pre-construction state and
will take reasonable measures to achieve such restoration within 12 months
after it completes construction of the Project. PEF shall monitor the
progress of revegetation and other aspects of the restoration of the area
and shall perform any further work that is reasonably necessary to restore
the area to its pre-construction state.
5. Prior to commencement of construction of the Project, PEF shall obtain
incidental take authority from the U.S. Fish & Wildlife Service and an
incidental take permit from the California Department of Fish & Game
(except to the extent either agency provides PEF and Ranchcorp a letter
stating that such incidental take authority or permit is not required)
respecting any species listed under the Federal or California Endangered
Species Acts that are likely to be taken (as defined in each agency's
governing laws and regulations) by construction or operation of the Project
. If, as a condition to issuance of the incidental take authority or
permit, PEF is required to tender mitigation land to either agency, PEF
shall so notify Ranchcorp and Ranchcorp shall have thirty (30) days to
notify PEF that Ranchcorp has land suitable for mitigation purposes that it
is willing to provide to PEF. If Ranchcorp provides PEF with notice that it
has suitable land available, PEF shall seek the agencies' concurrence that
Ranchcorp's available land is suitable for mitigation purposes. If PEF
obtains the agencies' concurrence, Ranchcorp shall convey the land or
appropriate interests therein to the entity designated by the agencies.
Concurrent with such conveyance, PEF shall pay Ranchcorp $500 per acre for
the land, plus all fees and endowments required to be paid to the agencies
or the donee entity designated by the agencies, plus all of Ranchcorp's
costs incurred in parcelizing (if necessary) and conveying the land or
interest therein.
6. Except to the extent inconsistent with applicable safety or other
requirements, PEF will paint its above-ground facilities other than its
electric transmission towers in earth-tone colors to minimize the Project's
visual contrast with the surrounding landscape.
7. PEF will secure the Project site and buildings to protect public safety.
8. PEF will limit outdoor lighting on the Premises to the minimum required by
applicable public and occupational safety rules and regulations.
SCHEDULE 22.4(c)
Recording Requested By
and When Recorded Return. To:
▇▇▇▇▇▇ ▇▇▇▇▇
▇▇▇▇▇▇ ▇▇▇▇ & Priest, LLP
▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇
▇▇▇ ▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇-▇▇▇▇
--------------------------------------------------------------------------------
MEMORANDUM OF LEASE
THIS MEMORANDUM OF LEASE is entered into as of , (the
------------ ------
"Effective Date") by and between Tejon Ranchcorp, a California corporation
("Landlord") and Pastoria Energy Facility, LLC, a Delaware limited liability
company ("Tenant").
A. Landlord and Tenant entered in that certain Option Agreement, dated
April 30, 1999, as amended by that certain letter agreement, dated March 5, 2001
(the "Option Agreement") pursuant to which Landlord granted an option to Tenant
to lease the Premises (as defined below) pursuant to the Ground Lease (as
defined below), and for which a Memorandum of Option was recorded on May 30,
1999 as document number 0199063511 in the ▇▇▇▇ County Official Records.
B. Landlord and Tenant are the parties to that certain Ground Lease of even
date herewith (the "Lease") covering certain real property located in ▇▇▇▇
County, California and more particularly described in Exhibit A attached hereto
---------
(the "Premises"), on the terms and conditions set forth below.
C. Landlord and Tenant are recording this Memorandum so that third parties
shall have notice of the rights and obligations of Landlord and Tenant under the
Lease.
NOW THEREFORE, in consideration of the Lease and other good and valuable
consideration, receipt of which is hereby acknowledged, the parties agree as
follows:
1. Premises. Landlord hereby leases the Premises to Tenant and Tenant
hereby leases the Premises from Landlord, upon the terms and conditions of the
Lease, which terms are incorporated herein by this reference, including, without
limitation, that Landlord shall have no surface rights related to any minerals
or mineral rights, and shall not, in the exercise of any mineral rights, disturb
the surface of the Premises, interfere with or disturb the occupancy or
operations of Tenant on the Premises, or drill at a depth which is less than
five hundred (500) feet below the surface of the Premises.
2. Term. The term of the Lease commenced on the Effective Date and expires,
if not sooner terminated pursuant thereto, on the twenty-fifth (25th)
anniversary of the Commencement Date as defined in the Lease.
3. Option to Extend. Tenant has an option to extend the term of the Lease
for three additional five (5) year periods as more particularly described in the
Lease.
4. Controlling Document. This Memorandum of Lease is subject to all the
terms and conditions of the Lease. Should there be any inconsistency between the
terms of this instrument and the Lease, the terms of the Lease shall prevail.
IN WITNESS WHEREOF, the parties hereto, by their duly authorized
representatives, have executed this Memorandum of Lease as of the, date first
above written.
LANDLORD:
TEJON RANCHCORP,
a California corporation
By:
----------------------------------------
Its:
----------------------------------------
By:
----------------------------------------
Its:
----------------------------------------
TENANT:
PASTORIA ENERGY FACILITY L.L.C.
a Delaware limited liability company
By:
----------------------------------------
Its:
----------------------------------------
[ACKNOWLEDGEMENTS ATTACHED]
ACKNOWLEDGMENT
State of California )
)
County of )
On [date] before me, [name and title
---------------- -------------------------
"Notary Public"], personally appeared [name of
----------------------
signer(s)], personally known to me (or proved to me on the basis of satisfactory
evidence) to be the person(s) whose names(s) is/are subscribed to the within
instrument and acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her their signature(s)
in the instrument the person(s), or the entity upon behalf of which the
person(s) acted, executed the instrument.
WITNESS my hand and official seal.
(Signature of Notary) (Seal of Notary)
----------------------------
ACKNOWLEDGMENT
State of California )
)
County of )
On [date] before me, [name and title
---------------- -------------------------
"Notary Public"], personally appeared [name of
----------------------
signer(s)], personally known to me (or proved to me on the basis of satisfactory
evidence) to be the person(s) whose names(s) is/are subscribed to the within
instrument and acknowledged to me that he/she/they executed the same in
his/her/their authorized capacity(ies), and that by his/her their signature(s)
in the instrument the person(s), or the entity upon behalf of which the
person(s) acted, executed the instrument.
WITNESS my hand and official seal.
(Signature of Notary) (Seal of Notary)
----------------------------