Exhibit 10.22
SECOND AMENDMENT TO LEASE
THIS SECOND AMENDMENT TO LEASE (this "Amendment") is entered into as of the
30th day of December, 1998, by and between B.O. III, LTD., a Texas limited
partnership ("Landlord") and VIGNETTE, INC., a Delaware corporation ("Tenant").
WHEREAS, Landlord and Tenant executed that certain Office Lease Agreement
(the "Lease Agreement") dated August 4, 1998 covering 66,900 square feet of
Agreed Rentable Area in the building known as Barton Oaks Plaza III (the
"Building"), as more particularly described therein;
WHEREAS the Lease Agreement has been amended pursuant to that certain First
Amendment to Lease dated as of October 31, 1998 by and between Landlord and
Tenant (the Lease Agreement, as amended, the "Lease");
WHEREAS, pursuant to Rider 3 to the Lease, Tenant has exercised the
Expansion Option to lease 5,049 square feet of Agreed Rentable Area on the first
(1st) floor of the Building shown on Exhibit A attached hereto (the "First Floor
---------
Expansion Premises"); and
WHEREAS, Landlord and Tenant desire to amend the Lease to reflect their
agreements as to the terms and conditions governing Tenant's lease of the First
Floor Expansion Premises.
NOW, THEREFORE, in consideration of the premises and the mutual covenants
between the parties herein contained, Landlord and Tenant hereby agree as
follows:
1. Premises.
--------
(a) Effective on the earlier to occur of (i) April 1, 1999, with such date
being adjusted to a later date for each day of Landlord Delay (hereinafter
defined) or (ii) the date Tenant occupies the First Floor Expansion Premises for
the conduct of business, (such earlier date, the "First Floor Expansion Premises
Commencement Date"), Item 2 of the Basic Lease Provisions shall be amended in
its entirety to read as follows:
Premises:
a. Suite #: 500; Floors: The entire first floor, a portion of the third
floor and the entire fourth and fifth floors.
b. Agreed Rentable Area: 83,958 square feet.
(b) For purposes of determining the First Floor Expansion Premises
Commencement Date, "Landlord Delay" shall be defined as each day that Landlord
fails to make a submittal or take any other action required by Landlord within
the time period provided for such action under the Work Letter attached hereto
as Exhibit B.
---------
2. Basic Rent. Effective on the First Floor Expansion Premises Commencement
----------
Date, Item 3.a of the Basic Lease Provisions shall be amended to read as
follows:
a. Basic Rent (See Article 2, Supplemental Lease Provisions):
With respect to that portion of the Premises located on the first floor,
the fourth floor and the fifth floor and consisting of 71,949 square feet
of Agreed Rentable Area:
Rate Per Square Basic Basic
Rental Foot of Agreed Annual Monthly
Period Rentable Area Rent Rent
------ -------------- ---- ----
*First Floor
Expansion Premises
Commencement
Date - 36 $16.50 $1,187,158.50 $ 98,929.88
Months 37 - 60 $17.50 $1,259,107.50 $104,925.62
*The First Floor Expansion Premises Commencement Date is hereby defined to
mean the date which is the earlier to occur of (i) April 1, 1999, with such
date being adjusted to a later date for each day of Landlord Delay
(hereinafter defined) or (ii) the date Tenant occupies that portion of the
Premises located on the first floor of the Building and containing 5,049
square feet of Agreed Rentable Area for the conduct of business. For
purposes of determining the First Floor Expansion Premises Commencement
Date, "Landlord Delay" shall be defined as each day that Landlord fails to
make a submittal or take any other action required by Landlord within the
time period provided for such action under the work letter applicable to
the First Floor Expansion Premises.
With respect to the 12,009 square feet of the Premises located on the third
(3rd) floor of the Building:
Rate Per Square Basic Basic
Rental Foot of Agreed Annual Monthly
Period Rentable Area Rent Rent
------ -------------- ---- ----
*Expansion Premises
Commencement
Date - 12/31/99 $17.00 $204,153.00 $17,012.75
1/1/00 - 12/31/00 $17.25 $207,155.25 $17,262.93
1/1/01 - 12/31/01 $17.50 $210,157.50 $17,513.12
1/1/02 - 12/02/03 $17.75 $213,159.75 $17,763.31
*The Expansion Premises Commencement Date is hereby defined to mean the
date on which Tenant's Improvements are Substantially Complete in that
portion of the Premises located on the third floor of the Building
containing 12,009 square feet of Agreed Rentable Area.
3. Tenant's Pro Rata Share Percentage. Effective on the First Floor Expansion
----------------------------------
Premises Commencement Date, Item 4 of the Basic Lease Provisions shall be
amended in its entirety to read as follows:
a. Tenant's Pro Rata Share Percentage: 69.15% (the Agreed Rentable Area
of the Premises divided by the Agreed Rentable Area of the Building,
expressed in a percentage).
b. Tenant's Initial Monthly Payment of Additional Rent: $8.00 per square
foot of Agreed Rentable Area; $55,972.00 per month.
4. Term. Item 5 of the Basic Lease Provisions is hereby amended in its
----
entirety to read as follows:
Five (5) years and zero (0) months (see Article 1, Supplemental Lease
Provisions).
5. Expiration Date. Item 7 of the Basic Lease Provisions is hereby amended in
---------------
its entirety to read as follows:
December 2, 2003 (as adjusted pursuant to Article 1, Supplemental Lease
Provisions).
6. Amendment of Exhibit A. Effective on the First Floor Expansion Premises
----------------------
Commencement Date, Exhibit A attached hereto shall be added to and made a part
---------
of Exhibit A attached to the Lease.
---------
7. Security Deposit. Concurrently with the execution hereof, Tenant shall pay
----------------
to Landlord the sum of $23,679.81, representing the Security Deposit for the
First Floor Expansion Premises.
8. No Representations. EXCEPT AS PROVIDED IN THE LEASE, LANDLORD HAS NOT MADE
------------------
AND DOES NOT HEREBY MAKE AND HEREBY SPECIFICALLY DISCLAIMS ANY REPRESENTATIONS
OR WARRANTIES OF ANY KIND OR CHARACTER WHATSOEVER, EXPRESS OR IMPLIED, WITH
RESPECT TO THE FIRST FLOOR EXPANSION PREMISES, ITS CONDITION (INCLUDING WITHOUT
LIMITATION ANY REPRESENTATION OR WARRANTY REGARDING QUALITY OF CONSTRUCTION,
STATE OF REPAIR, WORKMANSHIP, MERCHANTABILITY, SUITABILITY OR FITNESS FOR ANY
PARTICULAR PURPOSE).
9. Tenant's Improvements. Landlord shall construct improvements in the First
---------------------
Floor Expansion Premises subject to and in accordance with the terms and
conditions of the Work Letter attached hereto as Exhibit B.
---------
10. Acceptance of First Floor Expansion Premises. Tenant hereby accepts the
--------------------------------------------
First Floor Expansion Premises for all purposes. Upon Substantial Completion of
the improvements in the First Floor Expansion Premises, Landlord and Tenant
shall execute the Acceptance of Premises Memorandum substantially in the form of
the Acceptance of Premises Memorandum executed in connection with the Lease.
11. No Brokers. Tenant warrants that it has had no dealings with any real
----------
estate broker or agent in connection with the negotiation of this Amendment,
excepting only the broker named in Item 9 of the Basic Lease Provisions (The
Alexander Company) and that it knows of no other real estate brokers or agents
who are or might be entitled to a commission in connection with this Amendment
or otherwise in connection with the Lease. Tenant agrees to indemnify and hold
harmless Landlord from and against any liability or claim arising in respect to
brokers or agents other than the broker named in Item 9 of the Basic Lease
Provisions.
12. Authority. Tenant and each person signing this Amendment on behalf of
---------
Tenant represents to Landlord as follows: (i) Tenant is a duly incorporated and
validly existing under the laws of the State of Delaware, (ii) Tenant has and is
qualified to do business in Texas, (iii) Tenant has the full right and authority
to enter into this Amendment, and (iv) each person signing on behalf of Tenant
was and continues to be authorized to do so.
13. Defined Terms. All terms not otherwise defined herein shall have the same
-------------
meaning as assigned to them in the Lease. Except as amended hereby, the Lease
shall remain in full force and effect in accordance with its terms and is hereby
ratified. In the event of a conflict between the Lease and this Amendment, this
Amendment shall control.
14. Exhibits. Each Exhibit attached hereto is made a part hereof for all
--------
purposes.
15. Entire Agreement. This Amendment, together with the Lease, contains all of
----------------
the agreements of the parties hereto with respect to any matter covered or
mentioned in this Amendment or the Lease, and no prior agreement, understanding
or representation pertaining to any such matter shall be effective for any
purpose.
IN WITNESS WHEREOF, the parties have executed this Amendment as of the date
first above written.
LANDLORD
B.O. III , LTD., a Texas limited partnership
By: Office/Industrial, Inc., General Partner
By: /s/ ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇
------------------------------------
Name: ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇
Title: Vice President
TENANT:
VIGNETTE, INC., Delaware corporation
By: /s/ ▇▇▇▇ ▇. ▇▇▇▇▇
------------------------------------------
Name: ▇▇▇▇ ▇. ▇▇▇▇▇
Title: Vice President
EXHIBIT A
---------
THE FIRST FLOOR EXPANSION PREMISES
EXHIBIT B
---------
WORK LETTER
PLANS TO BE AGREED UPON/FINISH ALLOWANCE
This Exhibit is attached to and a part of that certain First Amendment to
Lease Agreement (the "Amendment") dated as of December ___, 1998, executed by
and between B.0. III, LTD.("Landlord"), and VIGNETTE, INC. ("Tenant"). Any
capitalized term used but not defined herein shall have the meaning assigned to
it in the Lease (as defined in the Amendment). Landlord and Tenant mutually
agree as follows:
1. Space Plan. On or before January 4, 1999, a space planner engaged by
----------
Tenant and approved by Landlord shall, at Tenant's expense, prepare and deliver
to Landlord a space plan for the First Floor Expansion Premises showing,
regardless of the quantities of such items, the location of all partitions and
doors and the lay-out of the First Floor Expansion Premises. Landlord will at
all times cooperate with Tenant's space planner (who shall be subject to the
reasonable approval of Landlord) to efficiently and expeditiously arrive at an
acceptable lay-out of the First Floor Expansion Premises. Landlord will approve
or disapprove in writing the space plan within three (3) business days after
receipt from Tenant and if disapproved, Landlord shall provide Tenant's space
planner with specific reasons for disapproval. If Landlord fails to approve or
disapprove the space plan on or before the end of such three (3) business day
period, Landlord shall be deemed to have approved the last submitted space plan.
The foregoing process shall be repeated until Landlord has approved (which shall
include deemed approval) the space plan (such space plan, when approved by
Landlord and Tenant, is herein referred to as the "Space Plan").
1.2 Compliance With Disability Acts. Tenant has provided Tenant's space
-------------------------------
planner with all information needed to cause the construction of Tenant's
Improvements to be completed such that Tenant, the First Floor Expansion
Premises and Tenant's Improvements (as constructed) will be in compliance with
the Disability Acts. TENANT SHALL BE RESPONSIBLE FOR AND SHALL INDEMNIFY AND
HOLD HARMLESS LANDLORD FROM AND AGAINST ANY AND ALL CLAIMS, LIABILITIES AND
EXPENSES (INCLUDING, WITHOUT LIMITATION REASONABLE ATTORNEYS' FEES AND EXPENSES)
INCURRED BY OR ASSERTED AGAINST LANDLORD BY REASON OF OR IN CONNECTION WITH ANY
VIOLATION OF THE DISABILITY ACTS ARISING FROM OR OUT OF (i) Tenant's employer-
employee obligations, or (ii) violations by Tenant and/or Tenant's Improvements
or the First Floor Expansion Premises not being in compliance with the
Disability Acts. The foregoing indemnity shall not include any claims,
liabilities or expenses (including reasonable attorneys' fees and expenses)
arising out of the negligence or gross negligence of Landlord or Landlord's
employees, agents or contractors.
1.3 Construction Plans. On or before fifteen (15) days after approval of the
------------------
Space Plan by Landlord and Tenant, a licensed architect reasonably acceptable to
Landlord (which architect may be the approved space planner if the space planner
is a licensed architect), at Tenant's expense, will prepare construction plans
and specifications (such construction plans and specifications, when approved by
Landlord and Tenant, and all changes and amendments thereto agreed to by
Landlord and Tenant in writing, are herein called the "Construction Plans") for
all of Tenant's improvements requested pursuant to the Space Plan (all
improvements required by the Construction Plans are herein called "Tenant's
Improvements"), including color and design schemes, detail and finish drawings
for partitions, doors, reflected ceiling, telephone outlets, electrical switches
and outlets and Building standard heating, ventilation and air conditioning
equipment and controls. Within five (5) business days after construction plans
and specifications are delivered to Landlord, Landlord shall approve or
disapprove same in writing and if disapproved, Landlord shall provide Tenant's
architect specific reasons for disapproval. The foregoing process shall
continue until the construction plans and specifications are approved by
Landlord; provided that if Landlord fails to respond in any five (5) business
day period, Landlord shall be deemed to have approved the last submitted
construction plans. Landlord hereby agrees that Landlord shall not be entitled
to disapprove construction plans except for the following reasons: (i) the
construction plans do not conform to applicable laws, rules and regulations,
(ii) the construction plans or specifications will not accommodate Building
standard heating, cooling, mechanical, electrical or plumbing improvements,
(iii) the construction plans or specifications do not conform to the Space Plan,
(iv) the construction required by the construction plans could in Landlord's
judgment affect the structural integrity or any structural member of the
Building or any part thereof or requires
a floor of the Building to be cut through or in Landlord's judgment will
adversely affect existing Building standard heating, cooling, mechanical,
electrical or plumbing improvements in any part of the Building, (v) the design
and/or color of the improvements which can been seen from the Common Areas do
not conform to the design and/or color scheme generally found in other parts of
the Building, (vi) the work required by the construction plans affects the
exterior of the First Floor Expansion Premises or the Building, or (vii) the
construction plans are incomplete or contain material errors or omissions
(collectively, "Permitted Objections"). Tenant shall reimburse Landlord for the
cost of Landlord's architectural review of the Space Plan and the Construction
Plans within thirty (30) days of receipt of an invoice therefor.
1.4 Changes to Approved Plans. If any re-drawing or re-drafting of either the
-------------------------
approved Space Plan or the approved Construction Plans is necessitated by
changes (all of which shall be subject to Landlord's written approval) requested
by Tenant after approval by Landlord and Tenant, the expense of any such re-
drawing, re-drafting or re-reviewing by Landlord's architect required in
connection therewith and the expense of any work and improvements necessitated
by such re-drawing or re-drafting will be charged to Tenant.
1.5 Coordination of Planners and Designers. If Tenant shall arrange for
--------------------------------------
interior design services, whether with Landlord's space planner or any other
planner or designer, it shall be Tenant's responsibility to cause necessary
coordination of its agents' efforts with Landlord's agents to ensure that no
delays are caused to either the planning or construction of the Tenant's
Improvements.
1.6. Building Standard Materials. Tenant shall use Building standard materials
---------------------------
in connection the design and construction of the Tenant's Improvements,
including without limitation, Building standard doors, frames, hardware,
lighting, ceiling tile and occupancy sensors.
2. Construction and Costs of Tenant's Improvements.
-----------------------------------------------
2.1 Selection of Contractor.
-----------------------
(a) Landlord agrees to bid the construction of Tenant's Improvements to at
least three (3) mutually acceptable general contractors (unless a
lesser number is approved by Tenant) within two (2) business days
after Landlord's approval of the Construction Plans. Landlord shall
request that all contractors submit their respective bids within two
(2) weeks after receipt of the bid package. Landlord shall also
submit the Construction Plans for permit within two (2) business days
after Landlord's approval of the Construction Plans.
(b) Landlord and Tenant shall jointly review any bids, and make
adjustments in the bids, if necessary, for inconsistent assumptions in
order to reflect an equitable comparison. Tenant shall select a
contractor within two (2) business days after Landlord's receipt of
all bids. Within three (3) business days after Tenant's selection of
the Contractor, Landlord shall enter into a construction contract with
the Contractor consistent with the terms of the bid to construct the
Tenant's Improvements (the "Construction Contract").
2.2 Construction Obligation and Finish Allowance.
--------------------------------------------
(a) Landlord agrees to construct Tenant's Improvements, at Tenant's cost
and expense; provided, however, Landlord shall provide Tenant with an
allowance up to $1,493.66 per full calendar month remaining in the
initial term of the Lease on the First Floor Expansion Premises
Commencement Date (the "First Floor Expansion Premises Finish
Allowance"), which allowance shall be disbursed by Landlord, from time
to time, for payment of (in the following priority) (i) the contract
sum required to be paid to the general contractor engaged to construct
Tenant's Improvements, which contract sum shall include without
limitation, the costs of any and all payment and performance bonds
required by Landlord in connection with the construction of Tenant's
Improvements and any other costs incurred by such general contractor
to comply with the construction requirements applicable to the
Building (the "Contract Sum"), (ii) the
fees of the preparer of the Space Plan and the Construction Plans,
(iii) payment of the Construction Management Fee (hereinafter
defined), and (iv) such other costs related to the leasehold
improvements (such as equipment, appliances and furnishings) as
Landlord specifically approves in writing, it being understood that
Landlord shall have no obligation whatsoever to fund any portion of
the Finish Allowance for such other costs. Upon completion of Tenant's
Improvements and in consideration of Landlord administering the
construction of Tenant's Improvements, Tenant agrees to pay Landlord a
fee equal to five percent (5%) of the Contract Sum to construct
Tenant's Improvements (the "Construction Management Fee") (the
foregoing costs are collectively referred to as the "Permitted
Costs").
(b) Title to any equipment, appliances, furnishings or personalty
installed in the First Floor Expansion Premises and purchased with any
portion of the First Floor Expansion Premises Finish Allowance shall
pass to Landlord upon payment of the invoice cost thereof and Tenant
shall not remove any such equipment, appliances, furnishings or
personalty from the First Floor Expansion Premises without Landlord's
express, prior written consent or unless requested by Landlord in
connection with the expiration or earlier termination of the Lease.
2.3 Excess Costs. If the sum of the Permitted Costs exceeds the First Floor
------------
Expansion Premises Finish Allowance, then Tenant shall pay all such excess costs
("Excess Costs"). Tenant agrees to keep the First Floor Expansion Premises
free from any liens arising out of nonpayment of Excess Costs. In the event
that any such lien is filed and Tenant, within ten (10) days following such
filing fails to cause same to be released of record by payment or posting of a
proper bond, Landlord shall have, in addition to all other remedies provided
herein and by law, the right, but not the obligation, to cause the same to be
released by such means as it in its sole discretion deems proper, including
payment of or defense against the claim giving rise to such lien. All sums paid
by Landlord in connection therewith shall constitute Rent under the Lease and a
demand obligation of Tenant to Landlord and such obligation shall bear interest
at the rate provided for in Section 15.10 of the Supplemental Lease Provisions
from the date of payment by Landlord until the date paid by Tenant.
2.4 Construction Deposit. Tenant shall remit to Landlord an amount (the
--------------------
"Prepayment") equal to the projected Excess Costs, if any, within five (5)
working days after commencement of construction by Landlord. Upon Substantial
Completion of the Tenant's Improvements in the First Floor Expansion Premises,
Tenant shall deliver to Landlord the actual Excess Costs, minus the Prepayment
previously paid. Failure by Tenant to timely tender to Landlord the full
Prepayment shall permit Landlord to stop all work until the Prepayment is
received. All sums due Landlord under this Section 2.4 shall be considered Rent
under the terms of the Lease and nonpayment shall constitute a default under the
Lease and entitle Landlord to any and all remedies specified in the Lease.
3. Substantial Completion and Punch List. The terms "Substantial Completion"
-------------------------------------
and "Substantially Complete," as applicable, shall mean when Tenant's
Improvements are sufficiently completed in accordance with the Construction
Plans so that Tenant can reasonably use the First Floor Expansion Premises for
the Permitted Use (as described in Item 10 of the Basic Lease Provisions). When
Landlord considers Tenant's Improvements to be Substantially Complete, Landlord
will notify Tenant and within two (2) business days thereafter, Landlord's
representative and Tenant's representative shall conduct a walk-through of the
First Floor Expansion Premises and identify any necessary touch-up work, repairs
and minor completion items as are necessary for final completion of Tenant's
Improvements. Neither Landlord's representative nor Tenant's representative
shall unreasonably withhold his agreement on punch list items. Landlord will
use reasonable efforts to cause the contractor to complete all punch list items
within thirty (30) days after agreement thereon.
4. Tenant's Contractors. If Tenant should desire to enter the First Floor
--------------------
Expansion Premises or authorize its agent to do so prior to Substantial
Completion of the Tenant's Improvements in the First Floor Expansion Premises,
to perform approved work not requested of the Landlord, Landlord shall permit
such entry if:
(a) Tenant shall use only such contractors which Landlord shall approve in
its reasonable discretion and Landlord shall have approved the plans
to be utilized by Tenant, which approval will not be unreasonably
withheld; and
(b) Tenant, its contractors, workmen, mechanics, engineers, space planners
or such others as may enter the First Floor Expansion Premises
(collectively, "Tenant's Contractors"), work in harmony with and do
not in any way disturb or interfere with Landlord's space planners,
architects, engineers, contractors, workmen, mechanics or other agents
or independent contractors in the performance of their work
(collectively, "Landlord's Contractors"), it being understood and
agreed that if entry of Tenant or Tenant's Contractors would cause,
has caused or is causing a material disturbance to Landlord or
Landlord's Contractors, then Landlord may, with notice, refuse
admittance to Tenant or Tenant's Contractors causing such disturbance;
and
(c) Tenant (notwithstanding the first sentence of subsection 7.201 of the
Supplemental Lease Provisions), Tenant's Contractors and other agents
shall provide Landlord sufficient evidence that each is covered under
such Worker's Compensation, public liability and property damage
insurance as Landlord may reasonably request for its protection.
Landlord shall not be liable for any injury, loss or damage to any of Tenant's
installations or decorations made prior to the First Floor Expansion Premises
Commencement Date and not installed by Landlord. Tenant shall indemnify and
hold harmless Landlord and Landlord's Contractors from and against any and all
costs, expenses, claims, liabilities and causes of action arising out of or in
connection with work performed in the First Floor Expansion Premises by or on
behalf of Tenant (but excluding work performed by Landlord or Landlord's
Contractors). Landlord is not responsible for the function and maintenance of
Tenant's Improvements which are different than Landlord's standard improvements
at the Property or improvements, equipment, cabinets or fixtures not installed
by Landlord. Such entry by Tenant and Tenant's Contractors pursuant to this
Section 4 shall be deemed to be under all of the terms, covenants, provisions
and conditions of the Lease except the covenant to pay Rent.
5. Construction Representatives. Landlord's and Tenant's representatives for
----------------------------
coordination of construction and approval of change orders will be as follows,
provided that either party may change its representative upon written notice to
the other:
LANDLORD'S REPRESENTATIVE:
NAME ▇▇▇ Houston or ▇▇▇ ▇▇▇▇▇▇▇
ADDRESS ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇
▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
PHONE (▇▇▇) ▇▇▇-▇▇▇▇
TENANT'S REPRESENTATIVE:
NAME ▇▇▇▇▇ ▇▇▇▇▇▇
ADDRESS ▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇
▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇
PHONE (▇▇▇) ▇▇▇-▇▇▇▇
6. Building Shell. Landlord shall perform the following Building shell work
--------------
in connection the First Floor Expansion Premises at Landlord's sole cost and
expense:
(a) Building standard VAV system, rigid duct work, perimeter slot
diffusers (excluding internal zone flex duct and supply grills).
(b) Building standard window treatments.
(c) Building standard ceiling grid installed with 2 x 4 ceiling tile
stacked on the floor and 2 x 4 parabolic light fixtures at a ratio of
1 per 90 usable square feet stacked on the floor.
(d) Sprinkler heads installed at 1 per 225 usable square feet.
(e) All Building common areas installed.