EXHIBIT 10.19(A) PROMISSORY NOTE

EXHIBIT 10.19(A)

PROMISSORY NOTE

--------------------------------------------------------------------------------------------------
PRINCIPAL LOAN DATE MATURITY LOAN NO CALL COLLATERAL ACCOUNT OFFICER INITIALS
$3,400,000.00 04-13-2000 10-10-2000 0400706081 016 1111 120144 019
--------------------------------------------------------------------------------------------------
References in the shaded area are for Lender's use only and do not limit the applicability of this
document to any particular loan or item.
--------------------------------------------------------------------------------------------------

BORROWER: FAFCO, INC. LENDER: BUTTE COMMUNITY BANK
▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇
▇▇▇▇▇▇▇ ▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇
▇▇▇▇▇, ▇▇ ▇▇▇▇▇

--------------------------------------------------------------------------------
--------------------------------------------------------------------------------

PRINCIPAL AMOUNT: INTEREST RATE: DATE OF NOTE:
$3,400,000.00 9.050% APRIL 13, 2000

PROMISE TO PAY. FAFCO, INC. ("BORROWER") PROMISES TO PAY TO BUTTE COMMUNITY BANK
("LENDER"), OR ORDER, IN LAWFUL MONEY OF THE UNITED STATES OF AMERICA, THE
PRINCIPAL AMOUNT OF THREE MILLION FOUR HUNDRED THOUSAND & 00/100 DOLLARS
($3,400,000.00) OR SO MUCH AS MAY BE OUTSTANDING, TOGETHER WITH INTEREST AT THE
RATE OF 9.050% ON THE UNPAID OUTSTANDING PRINCIPAL BALANCE OF EACH ADVANCE.
INTEREST SHALL BE CALCULATED FROM THE DATE OF EACH ADVANCE UNTIL REPAYMENT OF
EACH ADVANCE.

PAYMENT. ▇▇▇▇▇▇▇▇ WILL PAY THIS LOAN IN ONE PAYMENT OF ALL OUTSTANDING PRINCIPAL
PLUS ALL ACCRUED UNPAID INTEREST ON OCTOBER 10, 2000. IN ADDITION, BORROWER WILL
PAY REGULAR MONTHLY PAYMENTS OF ACCRUED UNPAID INTEREST BEGINNING MAY 10, 2000,
AND ALL SUBSEQUENT INTEREST PAYMENTS ARE DUE ON THE SAME DAY OF EACH MONTH AFTER
THAT. The annual interest rate for this Note is computed on a 365/360 basis;
that is, by applying the ratio of the annual interest rate over a year of 360
days, multiplied by the outstanding principal balance, multiplied by the actual
number of days the principal balance is outstanding. Borrower will pay Lender at
▇▇▇▇▇▇'s address shown above or at such other place as Lender may designate in
writing. Unless otherwise agreed or required by applicable law, payments will be
applied first to any unpaid collection costs and any late charges, then to any
unpaid interest, and any remaining amount to principal.

PREPAYMENT; MINIMUM INTEREST CHARGE. In any event, even upon full prepayment of
this Note, Borrower understands that Lender is entitled to a minimum interest
charge of $50.00. Other than ▇▇▇▇▇▇▇▇'s obligation to pay any minimum interest
charge, Borrower may pay without penalty all or a portion of the amount owed
earlier than it is due. Early payments will not, unless agreed to by ▇▇▇▇▇▇ in
writing, relieve ▇▇▇▇▇▇▇▇ of ▇▇▇▇▇▇▇▇'s obligation to continue to make payments
of accrued unpaid interest. Rather, they will reduce the principal balance due.

LATE CHARGE. If a payment is 10 DAYS OR MORE LATE, Borrower will be charged
5.000% OF THE REGULARLY SCHEDULED PAYMENT OR $5.00, WHICHEVER IS GREATER.

DEFAULT. Borrower will be in default if any of the following happens: (a)
Borrower fails to make any payment when due. (b) Borrower breaks any promise
Borrower has made to Lender, or Borrower fails to comply with or to perform when
due any other term, obligation, covenant, or condition contained in this Note or
any agreement related to this Note, or in any other agreement or loan Borrower
has with Lender. (c) Borrower defaults under any loan, extension of credit,
security agreement, purchase or sales agreement, or any other agreement, in
favor of any other creditor or person that may materially affect any of
Borrower's property or Borrower's ability to repay this Note or perform
Borrower's obligations under this Note or any of the Related Documents. (d) Any
representation or statement made or furnished to Lender by Borrower or on
▇▇▇▇▇▇▇▇'s behalf is false or misleading in any material respect either now or
at the time made or furnished. (e) ▇▇▇▇▇▇▇▇ becomes insolvent, a receiver is
appointed for any part of ▇▇▇▇▇▇▇▇'s property, ▇▇▇▇▇▇▇▇ makes an assignment for
the benefit of creditors, or any proceeding is commenced either by Borrower or
against Borrower under any bankruptcy or insolvency laws. (f) Any creditor tries
to take any of ▇▇▇▇▇▇▇▇'s property on or in which ▇▇▇▇▇▇ has a lien or security
interest. This includes a garnishment of any of ▇▇▇▇▇▇▇▇'s accounts with ▇▇▇▇▇▇.
(g) Any guarantor dies or any of the other events described in this default
section occurs with respect to any guarantor of this Note. (h) A material
adverse change occurs in Borrower's financial condition, or ▇▇▇▇▇▇ believes the
prospect of payment or performance of the indebtedness is impaired.

If any default, other than a default in payment, is curable and if Borrower has
not been given a notice of a breach of the same provision of this Note within
the preceding twelve (12) months, it may be cured (and no event of default will
have occurred) if Borrower, after receiving written notice from Lender demanding
cure of such default: (a) cures the default within fifteen (15) days; or (b) if
the cure requires more than fifteen (15) days, immediately initiates steps which
Lender deems in ▇▇▇▇▇▇'s sole discretion to be sufficient to cure the default
and thereafter continues and completes all reasonable and necessary steps
sufficient to produce compliance as soon as reasonably practical.

LENDER'S RIGHTS. Upon default, ▇▇▇▇▇▇ may declare the entire unpaid principal
balance on this Note and all accrued unpaid interest immediately due, without
notice, and then Borrower will pay that amount. Lender may hire or pay someone
else to help collect this Note if Borrower does not pay. ▇▇▇▇▇▇▇▇ also will pay
Lender that amount. This includes, subject to any limits under applicable law,
▇▇▇▇▇▇'s attorneys' fees and ▇▇▇▇▇▇'s legal expenses whether or not there is a
lawsuit, including attorneys' fees and legal expenses for bankruptcy proceedings
(including efforts to modify or vacate any automatic stay or injunction),
appeals, and any anticipated post-judgment collection services. ▇▇▇▇▇▇▇▇ also
will pay any court costs, in addition to all other sums provided by law. THIS
NOTE HAS BEEN DELIVERED TO LENDER AND ACCEPTED BY ▇▇▇▇▇▇ IN THE STATE OF
CALIFORNIA. IF THERE IS A LAWSUIT, ▇▇▇▇▇▇▇▇ AGREES UPON ▇▇▇▇▇▇'S REQUEST TO
SUBMIT TO THE JURISDICTION OF THE COURTS OF BUTTE COUNTY, THE STATE OF
CALIFORNIA. THIS NOTE SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE
LAWS OF THE STATE OF CALIFORNIA.

DISHONORED ITEM FEE. Borrower will pay a fee to Lender of $10.00 if Borrower
makes a payment on Borrower's loan and the check or preauthorized charge with
which Borrower pays is later dishonored.

COLLATERAL. Borrower acknowledges this Note is secured by a Deed of Trust dated
April 13, 2000, to a trustee in favor of Lender on real property located in
BUTTE County, State of California. That agreement contains the following due on
sale provision: Lender may, at its option, declare immediately due and payable
all sums secured by this Note upon the sale or transfer, without the Lender's
prior written consent, of all or any part of the Real Property, or any interest
in the Real Property. A "sale or transfer" means the conveyance of Real Property
or any right, title or interest therein; whether legal, beneficial or equitable;
whether voluntary or involuntary; whether by outright sale, deed, installment
sale contract, land contract, contract for deed, leasehold interest with a term
greater than three (3) years, lease-option contract, or by sale, assignment, or
transfer of any beneficial interest in or to any land trust holding title to the
Real Property, or by any other method of conveyance of Real Property Interest.
If any Trustor is a corporation, partnership or limited liability company,
transfer also includes any change in ownership of more than twenty-five percent
(25%) of the voting stock, partnership interests or limited liability company
interests, as the case may be, of Trustor. However, this option shall not be
exercised by Lender if such exercise is prohibited by applicable law.

LINE OF CREDIT. This Note evidences a straight line of credit. Once the total
amount of principal has been advanced, Borrower is not entitled to further loan
advances. ▇▇▇▇▇▇▇▇ agrees to be liable for all sums either: (a) advanced in
accordance with the instructions of an authorized person or (b) credited to any
of ▇▇▇▇▇▇▇▇'s accounts with ▇▇▇▇▇▇. The unpaid principal balance owing on this
Note at any time may be evidenced by endorsements on this Note or by ▇▇▇▇▇▇'s
internal records, including daily computer print-outs.

GENERAL PROVISIONS. Lender may delay or forgo enforcing any of its rights or
remedies under this Note without losing them. Borrower and any other person who
signs, guarantees or endorses this Note, to the extent allowed by law, waive any
applicable statute of limitations, presentment, demand for payment, protest and
notice of dishonor. Upon any change in the terms of this Note, and unless
otherwise expressly stated in writing, no party who signs this Note, whether as
maker, guarantor, accommodation maker or endorser, shall be released from
liability. All such parties agree that Lender may renew or extend (repeatedly
and for any length of time) this loan, or release any party or guarantor or
collateral; or impair, fail to realize upon or perfect ▇▇▇▇▇▇'s security
interest in the collateral; and take any other action deemed necessary by Lender
without the consent of or notice to anyone. All such parties also agree that
▇▇▇▇▇▇ may modify this loan without the consent of or notice to anyone other
than the party with whom the modification is made.

PRIOR TO SIGNING THIS NOTE, ▇▇▇▇▇▇▇▇ READ AND UNDERSTOOD ALL THE PROVISIONS OF
THIS NOTE. ▇▇▇▇▇▇▇▇ AGREES TO THE TERMS OF THE NOTE AND ACKNOWLEDGES RECEIPT OF
A COMPLETED COPY OF THE NOTE.

BORROWER:

FAFCO, INC.

COPY

BY: ----------------------------------------
▇▇▇▇▇▇▇ ▇. ▇▇▇▇, PRESIDENT
2

CONSTRUCTION LOAN AGREEMENT

PRINCIPAL LOAN DATE MATURITY LOAN NO CALL COLLATERAL ACCOUNT OFFICER INITIALS

$3,400,000.00 04-13-2000 10-10-2000 0400706081 016 1111 120144 019

References in the shaded area are for Lender's use only and do not limit the applicability of this document to any particular loan
or item.

================================================================================

THIS CONSTRUCTION LOAN AGREEMENT BETWEEN FAFCO, INC. ("BORROWER") AND BUTTE
COMMUNITY BANK ("LENDER") IS MADE AND EXECUTED ON THE FOLLOWING TERMS AND
CONDITIONS. ▇▇▇▇▇▇▇▇ HAS APPLIED TO LENDER FOR LOANS IN THE TOTAL PRINCIPAL
AMOUNT OF U.S. $3,400,000.00 IN ORDER TO CONSTRUCT THE IMPROVEMENTS ON THE REAL
PROPERTY DESCRIBED BELOW. LENDER IS WILLING TO LEND THE LOAN AMOUNT TO BORROWER
SOLELY UNDER THE TERMS AND CONDITIONS SPECIFIED IN THIS AGREEMENT AND IN THE
RELATED DOCUMENTS, TO EACH OF WHICH ▇▇▇▇▇▇▇▇ AGREES. ▇▇▇▇▇▇▇▇ UNDERSTANDS AND
AGREES THAT: (a) IN GRANTING, RENEWING, OR EXTENDING ANY LOAN, LENDER IS
RELYING UPON BORROWER'S REPRESENTATIONS, WARRANTIES, AND AGREEMENTS AS SET FORTH
IN THIS AGREEMENT, AND (b) ALL SUCH LOANS SHALL BE AND REMAIN SUBJECT TO THE
TERMS AND CONDITIONS OF THIS AGREEMENT.

TERM. This Agreement shall be effective as of April 13, 2000 and shall continue
thereafter until all Indebtedness has been paid in full and all other
obligations of Borrower hereunder have been performed in full and the parties
terminate this Agreement in writing.

DEFINITIONS. The following words shall have the following meanings when used in
this Agreement. Terms not otherwise defined in this Agreement shall have the
meanings attributed to such terms in the Uniform Commercial Code. All references
to dollar amounts shall mean amounts in lawful money of the United States of
America.

AGREEMENT. The word "Agreement" means this Construction Loan Agreement, as
this Construction Loan Agreement may be amended or modified from time to
time, together with all exhibits and schedules attached to this
Construction Loan Agreement from time to time.

ARCHITECTURE CONTRACT. The words "Architecture Contract" mean the
architect's contract relating to the Project, if any.

BORROWER. The word "Borrower" means each and every person or entity
signing the Note, including without limitation FAFCO, INC.

COLLATERAL. The word "Collateral" means and includes without limitation
all property and assets granted as collateral security for a Loan, whether
real or personal property, whether granted directly or indirectly, whether
granted now or in the future, and whether granted in the form of a
security interest, mortgage, deed of trust, assignment, pledge, chattel
mortgage, chattel trust, factor's lien, equipment trust, conditional sale,
trust receipt, lien, charge, lien or title retention contract, lease or
consignment intended as a security device, or any other security or lien
interest whatsoever, whether created by law, contract, or otherwise.

COMMENCEMENT DATE. The words "Commencement Date" mean April 15, 2000.

COMPLETION DATE. The words "Completion Date" mean October 10, 2000.

COMPLETION GUARANTY. The words "Completion Guaranty" mean the Guaranty of
Completion and Performance of the construction of the Project executed and
delivered by CENTRAL DEVELOPMENT, INC. to and for the benefit of Lender.

CONSTRUCTION CONTRACT. The words "Construction Contract" mean and include
the contract between Borrower and CENTRAL DEVELOPMENT, INC., the general
contractor for the Project, (General Contractor), and any subcontracts
with subcontractors, materialmen, laborers, or any other person or entity
for performance of work on the Project or the delivery of materials to the
Project.

CONTRACTOR. The word "Contractor" means CENTRAL DEVELOPMENT, INC., the
General Contractor for the Project.

EVENT OF DEFAULT. The words "Event of Default" mean and include without
limitation any of the Events of Default set forth below in the section
titled "Events of Default."

GRANTOR. The word "Grantor" means and includes without limitation each and
all of the persons or entities granting a Security Interest in any
Collateral for the indebtedness, including without limitation all
Borrowers granting such a Security Interest.

GUARANTOR. The word "Guarantor" means and includes without limitation all
guarantors, sureties, and accommodation parties, including without
limitation all guarantors under the Completion Guaranty.

IMPROVEMENTS. The word "Improvements" means and includes without
limitation all existing and future buildings, structures, facilities,
fixtures, additions, and similar construction on the Property.

INDEBTEDNESS. The word "Indebtedness" means and includes without
limitation all Loans, together with all other obligations, debts and
liabilities of Borrower to Lender, or any one or more of them, as well as
all claims by Lender against Borrower, or any one or more of them; whether
now or hereafter existing, voluntary or involuntary, due or not due,
absolute or contingent, liquidated or unliquidated; whether Borrower may
be liable individually or jointly with others; whether Borrower may be
obligated as a guarantor, surety, or otherwise; whether recovery upon such
Indebtedness may be or hereafter may become barred by any statute of
limitations; and whether such Indebtedness may be or hereafter may become
otherwise unenforceable.

LENDER. The word "Lender" means BUTTE COMMUNITY BANK, its successors and
assigns.

LOAN. The word "Loan" means the loan made to Borrower under this Agreement
and the Related Documents as described below.

LOAN FUND. The words "Loan Fund" mean the undisbursed proceeds of the Loan
under this Agreement together with any equity funds or other deposits
required from Borrower under this Agreement.

NOTE. The word "Note" means the promissory note or credit agreement dated
April 13, 2000, IN THE ORIGINAL PRINCIPAL AMOUNT OF $3,400,000.00 from
Borrower to Lender, together with all renewals of, extensions of,
modifications of, refinancings of, consolidations of, and substitutions
for the promissory note or agreement.

PLANS AND SPECIFICATIONS. The words "Plans and Specifications" mean the
plans and specifications for the Project which have been submitted to and
initialed by ▇▇▇▇▇▇, together with such changes and additions as may be
approved by Lender in writing.

PROJECT. The word "Project" means the construction and completion of all
Improvements contemplated by this Agreement, including without limitation
the erection of the building or structure, installation of equipment and
fixtures, landscaping, and all other work necessary to make the Property
usable and complete for the intended purposes. The Project includes the
following work:

CONSTRUCT A 50,000 SQUARE FOOT COMMERCIAL BUILDING

PROJECT DOCUMENTS. The words "Project Documents" means the Plans and
Specifications, all studies, data and drawings relating to the Project,
whether prepared by or for Borrower, the Construction Contract, the
Architecture Contract, and all other contracts and agreements relating to
the Project or the construction of the Improvements.

PROPERTY. The word "Property" means the Real Property together with all
Improvements, all equipment, fixtures, and other articles of personal
property now or subsequently attached or affixed to the real property,
together with all accessions, parts, and additions to, all replacements
of, and all substitutions for any of such property, and all proceeds
(including insurance proceeds and refunds of premiums) from any sale or
other disposition of such property.

REAL PROPERTY. The words "Real Property" mean the real property located in
BUTTE COUNTY, STATE OF CALIFORNIA, and legally described as:

SEE EXHIBIT "A" ATTACHED HERETO AND MADE A PART HEREOF

The Real Property or its address is commonly known as ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇,
▇▇▇▇▇, ▇▇ ▇▇▇▇▇. The property tax identification number for the Real
Property is ▇▇▇-▇▇▇-▇▇▇.

RELATED DOCUMENTS. The words "Related Documents" mean and include without
limitation all promissory notes, credit agreements, loan agreements,
environmental agreements, guaranties, security agreements, mortgages,
deeds of trust, and all other instruments, agreements and documents,
whether now or hereafter existing, executed in connection with the
Indebtedness.

SECURITY AGREEMENT. The words "Security Agreement" mean and include
without limitation any agreements, promises, covenants, arrangements,
understandings or other agreements, whether created by law, contract, or
otherwise, evidencing, governing, representing, or creating a Security
Interest.

3
04-13-2000 CONSTRUCTION LOAN AGREEMENT PAGE 2
LOAN NO 0400706081 (CONTINUED)
================================================================================

VALUE. The word "value" means such amount or worth as defined and
determined by Lender in its sole discretion unless agreed to the contrary
by ▇▇▇▇▇▇ in writing.

LOAN. The Loan shall be in an amount not to exceed the principal sum of U.S.
$3,400,000.00 and shall bear interest on so much of the principal sum as shall
be advanced pursuant to the terms of this Agreement and the Related Documents.
The Loan shall bear interest on each Advance from the date of the Advance in
accordance with the terms of the Note. Borrower shall use the Loan Funds solely
for the following specific purposes: CONSTRUCTION OF NEW BUILDING. The Loan
amount shall be subject at all times to all maximum limits and conditions set
forth in this Agreement or in any of the Related Documents, including without
limitation, any limits relating to loan to value ratios and acquisition and
Project costs.

FEES AND EXPENSES. Whether or not the Project shall be consummated, Borrower
shall assume and pay upon demand all out-of-pocket expenses incurred by Lender
in connection with the preparation or loan documents and the making of the Loan,
including without limitation the following: (a) all closing costs, fees, and
disbursements; (b) all expenses of Lender's legal counsel; and (c) all title
examination fees, title insurance premiums, appraisal fees, survey costs,
required fees, and filing and recording fees.

NO CONSTRUCTION PRIOR TO RECORDING OF SECURITY DOCUMENT. Borrower will not
permit any work or materials to be furnished in connection with the Project
until (a) Borrower has signed the Related Documents; (b) ▇▇▇▇▇▇'s mortgage or
deed of trust and other Security Interests in the Property have been duly
recorded and perfected; and (c) Lender has been provided evidence, satisfactory
to Lender, that Borrower has obtained all insurance required under this
Agreement or any Related Agreement and that Lender's liens on the Property and
Improvements are valid perfected first liens, subject only to such exceptions,
if any, acceptable to Lender.

REPRESENTATIONS AND WARRANTIES. Borrower represents and warrants to Lender, as
of the date of this Agreement, as of the date of each disbursement of Loan
proceeds, as of the date of any renewal, extension or modification of any Loan,
and at all times any Indebtedness exists:

ORGANIZATION. Borrower is a corporation which is duly organized, validly
existing, and in good standing under the laws of the State of California
and is validly existing and in good standing in all states in which
Borrower is doing business. Borrower has the full power and authority to
own its properties and to transact the businesses in which it is presently
engaged or presently proposes to engage. Borrower also is duly qualified as
a foreign corporation and is in good standing in all states in which the
failure to so qualify would have a material adverse effect on its
businesses or financial condition.

AUTHORIZATION. The execution, delivery, and performance of this Agreement
by Borrower, to the extent to be executed, delivered or performed by
Borrower, have been duly authorized by all necessary action by Borrower; do
not require the consent or approval of any other person, regulatory
authority or governmental body; and do not conflict with, result in a
violation of, or constitute a default under (a) any provision of its
articles of incorporation or organization, or bylaws, or any agreement or
other instrument binding upon Borrower or (b) any law, governmental
regulation, court decree, or order applicable to Borrower.

FINANCIAL INFORMATION. Each financial statement of ▇▇▇▇▇▇▇▇ supplied to
Lender truly and completely disclosed ▇▇▇▇▇▇▇▇'s financial condition as of
the date of the statement, and there has been no material adverse change in
Borrower's financial condition subsequent to the date of the most recent
financial statement supplied to Lender. Borrower has no material contingent
obligations except as disclosed in such financial statements.

LITIGATION AND CLAIMS. No litigation, claim, investigation, administrative
proceeding or similar action (including those for unpaid taxes) against
Borrower is pending or threatened, and no other event has occurred which
may materially adversely affect Borrower's financial condition or
properties, other than litigation, claims, or other events, if any, that
have been disclosed to and acknowledged by ▇▇▇▇▇▇ in writing.

TITLE TO PROPERTY. Borrower has, or on the date of first disbursement of
Loan proceeds will have, good and marketable title to the Property free and
clear of all defects, liens, and encumbrances, excepting only liens for
taxes, assessments, or governmental charges or levies not yet delinquent or
payable without penalty or interest, and such liens and encumbrances as may
be approved in writing by the Lender.

HAZARDOUS SUBSTANCES. The terms "hazardous waste," "hazardous substance,"
"disposal," "release," and "threatened release," as used in this Agreement,
shall have the same meanings as set forth in the Comprehensive
Environmental Response, Compensation, and Liability Act of 1980, as
amended, 42 U.S.C. Section 9601, et seq. ("CERCLA"), the Superfund
Amendments and Reauthorization Act of 1986, Pub. L. No. 99-499 ("▇▇▇▇"),
the Hazardous Materials Transportation Act, 49 U.S.C. Section 1801, et
seq., the Resource Conservation and Recovery Act, 42 U.S.C. Section 6901,
et seq., Chapters 6.5 through 7.7 of Division 20 of the California Health
and Safety Code, Section 25100, et seq., or other applicable state or
Federal laws, rules, or regulations adopted pursuant to any of the
foregoing. Except as disclosed to and acknowledged by ▇▇▇▇▇▇ in writing,
▇▇▇▇▇▇▇▇ represents and warrants that: (a) During the period of Borrower's
ownership of the properties, there has been no use, generation,
manufacture, storage, treatment, disposal, release or threatened release of
any hazardous waste or substance by any person on, under, about or from
any of the properties. (b) Borrower has no knowledge of, or reason to
believe that there has been (i) any use, generation, manufacture, storage,
treatment, disposal, release, or threatened release of any hazardous waste
or substance on, under, about or from the properties by any prior owners or
occupants of any of the properties, or (ii) any actual or threatened
litigation or claims of any kind by any person relating to such matters.
(c) Neither Borrower nor any tenant, contractor, agent or other authorized
user of any of the properties shall use, generate, manufacture, store,
treat, dispose of, or release any hazardous waste or substance on, under,
about or from any of the properties; and any such activity shall be
conducted in compliance with all applicable federal, state, and local laws,
regulations, and ordinances, including without limitation those laws,
regulations and ordinances described above. Borrower authorizes Lender and
its agents to enter upon the properties to make such inspections and tests
as Lender may deem appropriate to determine compliance of the properties
with this section of the Agreement. Any inspections or tests made by Lender
shall be at Borrower's expense and for Lender's purposes only and shall not
be construed to create any responsibility or liability on the part of
Lender to Borrower or to any other person. The representations and
warranties contained herein are based on Borrower's due diligence in
investigating the properties for hazardous waste and hazardous substances.
Borrower hereby (a) releases and waives any future claims against Lender
for indemnity or contribution in the event Borrower becomes liable for
cleanup or other costs under any such laws, and (b) agrees to indemnify and
hold harmless Lender against any and all claims, losses, liabilities,
damages, penalties, and expenses which Lender may directly or indirectly
sustain or suffer resulting from a breach of this section of the Agreement
or as a consequence of any use, generation, manufacture, storage, disposal,
release or threatened release of a hazardous waste or substance on the
properties. The provisions of this section of the Agreement, including the
obligation to indemnify, shall survive the payment of the Indebtedness and
the satisfaction of this Agreement and shall not be affected by ▇▇▇▇▇▇'s
acquisition of any interest in any of the properties, whether by
foreclosure or otherwise.

PROJECT COSTS. The Project costs are true and accurate estimates of the
costs necessary to complete the Improvements in a good and workmanlike
manner according to the Plans and Specifications presented by Borrower to
Lender, and Borrower shall take all steps necessary to prevent the actual
cost of the Improvements from exceeding the Project costs.

UTILITY SERVICES. All utility services appropriate to the use of the
Project after completion of construction are available at the boundaries of
the Property.

ACCESS. The Property is contiguous to publicly dedicated streets, roads, or
highways providing access to the Property.

ASSESSMENT OF PROPERTY. The Property is and will continue to be assessed
and taxed as an independent parcel by all governmental authorities.

COMPLIANCE WITH GOVERNING AUTHORITIES. Borrower has examined and is
familiar with all the easements, covenants, conditions, restrictions,
reservations, building laws, regulations, zoning ordinances, and federal,
state, and local requirements affecting the Project. The Project will at
all times and in all respects conform to and comply with the requirements
of such easements, covenants, conditions, restrictions, reservations,
building laws, regulations, zoning ordinances, and federal, state, and
local requirements.

LEGAL EFFECT. This Agreement constitutes, and any instrument or agreement
required hereunder to be given by ▇▇▇▇▇▇▇▇ when delivered will constitute,
legal, valid and binding obligations of Borrower enforceable against
Borrower in accordance with their respective terms.

BINDING EFFECT. This Agreement, the Note and all Security Agreements
directly or indirectly securing repayment of Borrower's Loan and Note are
binding upon Borrower as well as upon ▇▇▇▇▇▇▇▇'s successors,
representatives and assigns, and are legally enforceable in accordance with
their respective terms.

SURVIVAL OF REPRESENTATION AND WARRANTIES. ▇▇▇▇▇▇▇▇ understands and agrees
that ▇▇▇▇▇▇ is relying upon the above representations and warranties in
extending Loan Advances to Borrower. ▇▇▇▇▇▇▇▇ further agrees that the
foregoing representations and warranties shall be continuing in nature and
shall remain in full force and effect until such time as Borrower's Loan
and Note shall be paid in full, or until this Agreement shall be terminated
in the manner provided above, whichever is the last to occur.

CONDITIONS PRECEDENT TO EACH ADVANCE. ▇▇▇▇▇▇'s obligation to make the Initial
Advance and each subsequent Advance under this Agreement shall be subject to the
fulfillment to ▇▇▇▇▇▇'s satisfaction of all of the conditions set forth in this
Agreement.

SPECIAL CONDITIONS TO INITIAL ADVANCE. DEED OF TRUST TO BE RECORDED IN
FIRST POSITION.

APPROVAL OF CONTRACTORS, SUBCONTRACTORS, AND MATERIALMEN. Lender shall have
approved a list of all contractors employed in connection with the
construction of the Improvements, showing the name, address, and telephone
number of each contractor, a general description of the nature of the work
to be done, the labor and materials to be supplied, the names of
materialmen, if known, and the approximate dollar value of the labor, work,
or materials with respect to each contractor or materialman. Lender shall
have the right to communicate with any person to verify the facts disclosed
by the list or by any application for any Advance, or for any other
purpose.

4
04-13-2000 CONSTRUCTION LOAN AGREEMENT PAGE 3
LOAN NO 0400706081 (CONTINUED)
================================================================================

necessary for the construction and use of the Project.

ARCHITECTURE AND CONSTRUCTION CONTRACTS. Borrower shall have furnished in
form and substance satisfactory to Lender an executed copy of the
Architecture Contract and an executed copy of the Construction Contract.

SUPPORT DOCUMENTS. Borrower shall provide to Lender in form satisfactory to
Lender the following support documents for the Loan: COMPLETION GUARANTY.

BUDGET AND SCHEDULE OF ESTIMATED ADVANCES. Lender shall have approved
detailed budget and cash flow projections of total Project costs and a
schedule of the estimated amount and time of disbursements of each Advances.

▇▇▇▇▇▇▇▇'S AUTHORIZATION. Borrower shall have provided in form and
substance satisfactory to Lender properly certified resolutions, duly
authorizing the execution and delivery of the Loan documents, and the
consummation of the Project, and such other authorizations and other
documents as Lender in its sole discretion may require.

BOND. If requested by ▇▇▇▇▇▇, Borrower shall have furnished a performance
and payment bond in an amount equal to 100% of the amount of the
Construction Contract, as well as a materialmen's and mechanics' payment
bond, with such riders and supplements as Lender may require each in form
and substance satisfactory to Lender, naming the General Contractor as
principal and Lender as an additional obligee. Any required bonds and the
contracts which they cover must be duly recorded or filed in accordance
with California Civil Code Section 3235, if required by Lender.

APPRAISAL. If required by Lender, an appraisal shall be prepared for the
Property, at Borrower's expense, which in form and substance shall be
satisfactory to Lender, in its sole discretion, including applicable
regulatory requirements.

PLANS AND SPECIFICATIONS. If requested by ▇▇▇▇▇▇, Borrower shall have
assigned to Lender on Lender's forms the Plans and Specifications for the
Project.

ENVIRONMENTAL REPORT. If requested by ▇▇▇▇▇▇, Borrower shall have furnished
to Lender, at Borrower's expense, an environmental report and certificate
on the Property in form and substance satisfactory to Lender, prepared by
an engineer or other expert satisfactory to Lender stating that the
Property complies with all applicable provisions and requirements of the
"Hazardous Substances" paragraph set forth below.

SOIL REPORT. If requested by ▇▇▇▇▇▇, Borrower shall have furnished to
Lender, at Borrower's expenses, a soil report for the Property in form and
substance satisfactory to Lender, prepared by a registered engineer
satisfactory to Lender stating that the Property is free from soil or other
geological conditions that would preclude its use or development as
contemplated without extra expense for precautionary, corrective or
remedial measures.

SURVEY. If requested by ▇▇▇▇▇▇, Borrower shall have furnished to Lender a
survey of recent date, prepared and certified by a qualified surveyor and
providing that the improvements, if constructed in accordance with the
Plans and Specifications, shall lie wholly within the boundaries of the
Property without encroachment or violation of any zoning ordinances,
building codes or regulations, or setback requirements, together with such
other information as Lender in its sole discretion may require.

ZONING. Borrower shall have furnished evidence satisfactory to Lender that
the Property is duly and validly zoned for the construction, maintenance,
and operation of the Project.

TITLE INSURANCE. Borrower shall have provided to Lender an ALTA Lender's
extended coverage policy of the title insurance with such endorsements as
Lender may require, issued by a title insurance company acceptable to
Lender and in a form, amount, and content satisfactory to Lender, insuring
or agreeing to insure that ▇▇▇▇▇▇'s Mortgage or Deed of Trust on the
Property is or will be upon recordation a valid first lien on the Property
free and clear of all defects, liens, encumbrances, and exceptions except
those as specifically accepted by Lender in writing. If requested by
▇▇▇▇▇▇, Borrower shall provide to Lender, at ▇▇▇▇▇▇▇▇'s expense, a
foundation endorsement (CLTA 102.5 or its equivalent) to the title policy
upon the completion of each foundation for the improvements, showing no
encroachments, and upon completion of the improvements (CLTA 101 series, as
required by Lender). Specifically, Borrower shall provide to Lender the
following title insurance endorsements: LP10 POLICY WITH A 102.5
ENDORSEMENT.

INSURANCE. Unless waived by ▇▇▇▇▇▇ in writing, Borrower shall have
delivered to Lender the following insurance policies or evidence thereof:
(a) an all risks course of construction insurance policy (builder's risk),
with extended coverage covering the improvements issued in an amount and by
a company acceptable to Lender, containing a loss payable or other
endorsement satisfactory to Lender insuring Lender as mortgagee, together
with such other endorsements as may be required by ▇▇▇▇▇▇, including
stipulations that coverages will not be cancelled or diminished without at
least ten (10) days' prior written notice to Lender; (b) owners and General
Contractor general liability insurance, public liability and workmen's
compensation insurance; (c) flood insurance if required by Lender or
applicable law; and (d) all other insurance required by this Agreement or
by the Related Documents.

WORKERS' COMPENSATION COVERAGE. Provide to Lender proof of the General
Contractors' compliance with all applicable workers' compensation laws and
regulations with regard to all work performed on the Project.

PAYMENT OF FEES AND EXPENSES. Borrower shall have paid to Lender all
expenses specified in this Agreement as are then due and payable.

SATISFACTORY CONSTRUCTION. All work usually done at the stage of
construction for which disbursement is requested shall have been done in a
good and workmanlike manner and all materials and fixtures usually
furnished and installed at that stage of construction shall have been
furnished and installed, all in compliance with the Plans and
Specifications. Borrower shall also have furnished to Lender such proofs as
Lender may require to establish the progress of the work, compliance with
applicable laws, freedom of the Property from liens, and the basis for the
requested disbursement.

CERTIFICATION. Borrower shall have furnished to Lender a certification by
an engineer, architect, or other qualified inspector acceptable to Lender
that the construction of the improvements has complied and will continue to
comply with all applicable statutes, ordinances, codes, regulations, and
similar requirements.

▇▇▇▇ ▇▇▇▇▇▇▇. Borrower shall have obtained and attached to each application
for an Advance, including the Advance to cover final payment to the General
Contractor, executed acknowledgments of payments of all sums due and
releases of mechanic's and materialmen's liens, satisfactory to Lender,
from any party having lien rights, which acknowledgments of payment and
releases of liens shall cover all work, labor, equipment, materials done,
supplied, performed, or furnished prior to such application for an Advance.

LACK OF DEFAULT. There shall not exist at the time of any Advance a
condition which would constitute an Event of Default under this Agreement.

DISBURSEMENT OF LOAN PROCEEDS. The following provisions relate to the
disbursement of funds from the Loan Fund.

APPLICATION FOR ADVANCES. Each application shall be stated on a standard
AIA payment request form or other form approved by Lender, executed by
▇▇▇▇▇▇▇▇, and supported by such evidence as Lender shall reasonably require.
Borrower shall apply only for disbursement with respect to work actually
done by the General Contractor and for materials and equipment actually
incorporated into the Project. Each application for an Advance shall be
deemed a certification of Borrower that as of the date of such application,
all representations and warranties contained in the Agreement are true and
correct, and that Borrower is in compliance with all of the provisions of
this Agreement.

LOAN TO VALUE. Unless waived by ▇▇▇▇▇▇ in writing, the ratio of the amount
of the Loan to the Value of the Property as completed shall not exceed
80.000%. The term "Value" as used herein shall be defined by Lender in its
sole discretion unless agreed to the contrary by ▇▇▇▇▇▇ in writing.

PAYMENTS. At the sole option of ▇▇▇▇▇▇, Advances may be paid in the joint
names of ▇▇▇▇▇▇▇▇ and the General Contractor, subcontractor(s), or
supplier(s) in payment of sums due under the Construction Contract. At its
sole option, Lender may directly pay the General Contractor and any
subcontractors or other parties the sums due under the Construction
Contract. Borrower appoints ▇▇▇▇▇▇ as its attorney-in-fact to make such
payments. This power shall be deemed to be coupled with all interest, shall
be irrevocable, and shall survive an Event of Default under this Agreement.

PROJECTED COST OVERRUNS. If Lender at any time determines in its sole
discretion that the amount in the Loan Fund is insufficient, or will be
insufficient, to complete fully and to pay for the Project, then within ten
(10) days after receipt of a written request from ▇▇▇▇▇▇, Borrower shall
deposit in the Loan Fund an amount equal to the deficiency as determined by
Lender. The judgment and determination of Lender under this section shall
be final and conclusive. Any such amounts deposited by Borrower shall be
disbursed prior to any Loan proceeds.

FINAL PAYMENT TO GENERAL CONTRACTOR Upon completion of the Project and
fulfillment of the Construction Contract to the satisfaction of Lender and
provided sufficient Loan Funds are available, Lender shall make an Advance
to cover the final payment due to the General Contractor upon delivery to
Lender of endorsements to the ALTA title insurance policy following the
posting of the completion notice, as provided under applicable law.
Construction shall not be deemed complete for purposes of final disbursement
unless and until Lender shall have received all of the following:

(a) Evidence satisfactory to Lender that all work under the
Construction Contract requiring inspection by any governmental
authority with jurisdiction has been duly inspected and approved by
such authority, that a certificate of occupancy has been issued, and
that all parties performing work have been paid, or will be paid, for
such work;

5
04-13-2000 CONSTRUCTION LOAN AGREEMENT PAGE 4
LOAN NO 0400706081 (CONTINUED)
===============================================================================

(b) A certification by an engineer, architect, or other qualified
inspector acceptable to Lender that the improvements have been completed
substantially in accordance with the Plans and Specifications and the
Construction Contract, that direct connection has been made to all
utilities set forth in the Plans and Specifications, and that the Project
is ready for occupancy; and

CONSTRUCTION DEFAULT. If Borrower fails in any respect to comply with the
provisions of this Agreement or if construction ceases before completion
regardless of the reason, Lender, at its option, may refuse to make further
Advances, may accelerate the indebtedness under the terms of the Note, and
without thereby impairing any of its rights, powers, or privileges, may
enter into possession of the construction site and perform or cause to be
performed any and all work and labor necessary to complete the improvements,
substantially in accordance with the Plans and Specifications.

DAMAGE OR DESTRUCTION. If any of the Property or Improvements is damaged or
destroyed by casualty of any nature, within sixty (60) days thereafter
Borrower shall restore the Property and Improvements to the condition in
which they were before such damage or destruction with funds other than
those in the Loan Fund. Lender shall not be obligated to make disbursements
under this Agreement until such restoration has been accomplished.

RIGHT TO ADVANCE FUNDS. When any event occurs that Lender determines may
endanger completion of the Project or the fulfillment of any condition or
covenant in this Agreement, Lender may require Borrower to furnish, with ten
(10) days after delivery of a written request, adequate security to
eliminate, reduce, or indemnify Lender against, such danger. In addition,
upon such occurrence, Lender in its sole discretion may advance funds or
agree to undertake to advance funds to any party to eliminate, reduce, or
indemnify Lender against, such danger or to complete the Project. All sums
paid by Lender pursuant to such agreements or undertakings shall be for
Borrower's account and shall be without prejudice to Borrower's rights, if
any, to receive such funds from the party to whom paid. All sums expended by
▇▇▇▇▇▇ in the exercise of its option to complete the Project or protect
▇▇▇▇▇▇'s interests shall be payable to Lender on demand together with
interest from the date of the Advance at the rate applicable to the Loan. In
addition, any Advance of funds under this Agreement, including without
limitation direct disbursements to the General Contractor or other parties
in payment of sums due under the Construction Contract, shall be deemed to
have been expended by or on behalf of Borrower and to have been secured by
▇▇▇▇▇▇'s Mortgage or Deed of Trust, if any, on the Property.

LIMITATION OF RESPONSIBILITY. The making of any Advance by Lender shall not
constitute or be interpreted as either (a) an approval or acceptance by Lender
of the work done through the date of the Advance, or (b) a representation or
indemnity by Lender to any party against any deficiency or defect in the work
or against any breach of any contract. Inspections and approvals of the Plans
and Specifications, the Improvements, the workmanship and materials used in the
Improvements, and exercise of any other right of inspection, approval, or
inquiry granted to Lender in this Agreement are acknowledged to be solely for
the protection of ▇▇▇▇▇▇'s interests, and under no circumstances shall they be
construed to impose any responsibility or liability of any nature whatsoever on
Lender to any party. Neither Borrower nor any contractor, subcontractor,
materialman, laborer, or any other person shall rely, or have any right to
rely, upon ▇▇▇▇▇▇'s determination of the appropriateness of any Advance. No
disbursement or approval by Lender shall constitute a representation by ▇▇▇▇▇▇
as to the nature of the Project, its construction, or its intended use for
Borrower or for any other person, nor shall it constitute an indemnity by
Lender to Borrower or to any other person against any deficiency or defects in
the Project or against any breach of any contract.

AFFIRMATIVE COVENANTS. Borrower covenants and agrees with ▇▇▇▇▇▇ that, while
this Agreement is in effect, Borrower will:

LITIGATION. Promptly inform ▇▇▇▇▇▇ in writing of (a) all material adverse
changes in Borrower's financial condition, and (b) all existing and all
threatened litigation, claims, investigations, administrative proceedings or
similar actions affecting Borrower or any Guarantor which could materially
affect the financial condition of Borrower or the financial condition of any
Guarantor.

FINANCIAL RECORDS. Maintain its books and records in accordance with
generally accepted accounting principles, applied on a consistent basis, and
permit ▇▇▇▇▇▇ to examine and audit ▇▇▇▇▇▇▇▇'s books and records at all
reasonable times.

FINANCIAL STATEMENTS. Furnish Lender with, as soon as available, but in no
event later than ninety (90) days after the end of each fiscal year,
▇▇▇▇▇▇▇▇'s balance sheet and income statement for the year ended, audited by
a certified public accountant satisfactory to Lender. All financial reports
required to be provided under this Agreement shall be prepared in accordance
with generally accepted accounting principles, applied on a consistent
basis, and certified by Borrower as being true and correct.

ADDITIONAL INFORMATION. Furnish such additional information and statements,
lists of assets and liabilities, agings of receivables and payables,
inventory schedules, budgets, forecasts, tax returns, and other reports with
respect to ▇▇▇▇▇▇▇▇'s financial condition and business operations as Lender
may request from time to time.

COMPLIANCE WITH GOVERNMENTAL REQUIREMENTS. Comply with all laws, ordinances,
and regulations, now or hereafter in effect, of all governmental authorities
applicable to the use or occupancy of the Property, including without
limitation, the Americans With Disabilities Act. Borrower may contest in
good faith any such law, ordinance, or regulation and withhold compliance
during any proceeding, including appropriate appeals, so long as Borrower
has notified Lender in writing prior to doing so and so long as, in ▇▇▇▇▇▇'s
sole opinion, ▇▇▇▇▇▇'s interests in the Property are not jeopardized. Lender
may require Borrower to post adequate security or a surety bond, reasonably
satisfactory to Lender, to protect ▇▇▇▇▇▇'s interest.

CONSTRUCTION OF THE PROJECT. Commence construction of the Project no later
than April 15, 2000, and cause the improvements to be constructed and
equipped in a diligent and orderly manner and in strict accordance with the
Plans and Specifications approved by Lender, the Construction Contract, and
all applicable laws, ordinances, codes, regulations, and rights of adjoining
or concurrent property owners. ▇▇▇▇▇▇▇▇ agrees to complete the Project for
purposes of final payment to the General Contractor on or before October 10,
2000, regardless of the reason for any delay.

LOAN PROCEEDS. Use the Loan Funds solely for payment of bills and expenses
directly related to the Project.

DEFECTS. Upon demand of Lender, promptly correct any defect in the
improvements or any departure from the Plans and Specifications not approved
by Lender before further work shall be done upon the portion of the
improvements affected.

PROJECT CLAIMS AND LITIGATION. Promptly inform ▇▇▇▇▇▇ of (a) all material
adverse changes in the financial condition of the General Contractor; (b)
any litigation and claims, actual or threatened, affecting the Project or
the General Contractor, which could materially affect the successful
completion of the Project or the ability of the General Contractor to
complete the Project as agreed; and (c) any condition or event which
constitutes a breach or default under any of the Related Documents or any
contract related to the Project.

PAYMENT OF CLAIMS AND REMOVAL OF LIENS. (a) Cause all claims for labor done
and materials and services furnished in connection with the Improvements to
be fully paid and discharged in a timely manner, (b) diligently file or
procure the filing of a valid notice of completion of the Improvements, or
such comparable document as may be permitted under applicable lien laws, (c)
diligently file or procure the filing of a notice of cessation, or such
comparable document as may be permitted under applicable lien laws, upon the
happening of cessation of labor on the Improvements for a continuous period
of thirty (30) days or more, and (d) take all reasonable steps necessary to
remove all claims of liens against the Property, the Improvements or any part
of the Property or Improvements, or any rights or interests appurtenant to
the Property or Improvements. Upon ▇▇▇▇▇▇'s request, ▇▇▇▇▇▇▇▇ shall make such
demands or claims upon or against laborers, materialmen, subcontractors, or
other persons who have furnished or claim to have furnished labor, services,
or materials in connection with the Improvements, which demands or claims
shall under the laws of the State of California require diligent assertions
of lien claims upon penalty of loss or waiver thereof. Borrower shall, within
ten (10) days after the filing of any claim of lien that is disputed or
contested by ▇▇▇▇▇▇▇▇, record or cause the General Contractor for the
construction of the Improvements to record in the Office of the BUTTE County
Recorder, a surety bond pursuant to California law sufficient to release the
claim of lien and, within five (5) days of Lender's demand, make suitable
provision by deposit of funds with Lender in an amount satisfactory to Lender
or by bond satisfactory to Lender for the possibility that the contest will
be unsuccessful. If Borrower fails to remove any lien on the Property or
Improvements or provide a bond or deposit pursuant to this provision, Lender
may pay such lien, or may contest the validity of the lien, and Borrower
shall pay all costs and expenses of such contest, including ▇▇▇▇▇▇'s
reasonable attorney's fees.

TAXES AND CLAIMS. Pay and discharge when due all of Borrower's indebtedness,
obligations, and claims that, if unpaid, might become a lien or charge upon
the Property or improvements; provided, however, that Borrower shall not be
required to pay and discharge any such indebtedness, obligation, or claim so
long as (a) its legality shall be contested in good faith by appropriate
proceedings, (b) the indebtedness, obligation, or claim does not become a
lien or charge upon the Property or Improvements, and (c) Borrower shall
have established on its books adequate reserves with respect to the amount
contested in accordance with generally accepted accounting practices. If the
indebtedness, obligation, or claim does become a lien or charge upon the
Property or Improvements, Borrower shall remove the lien or charge as
provided in the preceding paragraph.

PERFORMANCE. Perform and comply with all terms, conditions, and provisions
set forth in this Agreement and in all other instruments and agreements
between Borrower and Lender, and in all other loan agreements now or
hereafter existing between Borrower and any other party. Borrower shall
notify ▇▇▇▇▇▇ immediately in writing of any default in connection with any
agreement.

ADDITIONAL ASSURANCES. Make, execute, and deliver to Lender such Security
Agreements, instruments, documents, and other agreements reasonably
necessary to document and secure the Loan and to perfect Lender's Security
Interests in the Property and Improvements.

NEGATIVE COVENANTS. Borrower covenants and agrees with Lender that while this
Agreement is in effect, Borrower shall not, without the prior written consent of
Lender:
6
04-13-2000 CONSTRUCTION LOAN AGREEMENT Page 5
LOAN NO 0400706081 (CONTINUED)
===============================================================================

INDEBTEDNESS AND LIENS. (a) Except for trade debt incurred in the normal
course of business and indebtedness to Lender contemplated by this
Agreement, create, incur or assume indebtedness for borrowed money,
including capital leases, (b) sell, transfer, mortgage, assign, pledge,
lease, grant a security interest in, or encumber any of Borrower's assets,
or (c) sell with recourse any of Borrower's accounts, except to Lender.

CONTINUITY OF OPERATIONS. (a) Engage in any business activities
substantially different than those in which Borrower is presently engaged,
(b) cease operations, liquidate, merge, transfer, acquire or consolidate
with any other entity, change ownership, change its name, dissolve or
transfer or sell Collateral out of the ordinary course of business, (c) pay
any dividends on Borrower's stock (other than dividends payable in its
stock), provided, however that notwithstanding the foregoing, but only so
long as no Event of Default has occurred and is continuing or would result
from the payment of dividends, if Borrower is a "Subchapter S Corporation"
(as defined in the Internal Revenue Code of 1986, as amended), Borrower may
pay cash dividends on its stock to its shareholders from time to time in
amounts necessary to enable the shareholders to pay income taxes and make
estimated income tax payments to satisfy their liabilities under federal
and state law which arise solely from their status as Shareholders of a
Subchapter S Corporation because of their ownership of shares of stock of
Borrower, or (d) purchase or retire any of Borrower's outstanding shares or
alter or amend Borrower's capital structure.

LOANS, ACQUISITIONS AND GUARANTIES. (a) Loan, invest in or advance money or
assets, (b) purchase, create or acquire any interest in any other
enterprise or entity, or (c) incur any obligation as surety or guarantor
other than in the ordinary course of business.

MODIFICATION OF CONTRACT. Make or permit to be made any modification of the
Construction Contract.

LIENS. Create or allow to be created any lien or charge upon the Property
or the Improvements.

GENERAL PROJECT PROVISIONS. The following provisions relate to the construction
and completion of the Project:

CHANGE ORDERS. All requests for changes in the Plans and Specifications,
other than minor changes involving no extra cost, must be in writing,
signed by ▇▇▇▇▇▇▇▇ and the architect, and delivered to Lender for its
approval. Borrower will not permit the performance of any work pursuant to
any change order or modification of the Construction Contract or any
subcontract without the written approval of Lender. Borrower will obtain
any required permits or authorizations from governmental authorities
having jurisdiction before approving or requesting a new change order.

PURCHASE OF MATERIALS; CONDITIONAL SALES CONTRACTS. No materials,
equipment, fixtures, or articles of personal property placed in or
incorporated into the Project shall be purchased or installed under any
Security Agreement or other agreement whereby the seller reserves or
purports to reserve title or the right of removal or repossession, or the
right to consider such items as personal property after their
incorporation into the Project, unless otherwise authorized by ▇▇▇▇▇▇ in
writing.

▇▇▇▇▇▇'S RIGHT OF ENTRY AND INSPECTION. Lender and its agents shall have
at all times the right of entry and fee access to the Property and the
right to inspect all work done, labor performed, and materials furnished
with respect to the Project. Lender shall have unrestricted access to and
the right to copy all records, accounting books, contracts, subcontracts,
bills, statements, vouchers, and supporting documents of Borrower relating
in any way to the Project.

▇▇▇▇▇▇'S RIGHT TO STOP WORK. If Lender in good faith determines that any
work or materials do not conform to the approved Plans and Specifications
or sound building practices, or otherwise depart from any of the
requirements of this Agreement, Lender may require the work to be stopped
and withhold disbursements until the matter is corrected. In such event,
▇▇▇▇▇▇▇▇ will promptly correct the work to ▇▇▇▇▇▇'s satisfaction. No such
action by Lender will affect ▇▇▇▇▇▇▇▇'s obligation to complete the
Improvements on or before the Completion Date. ▇▇▇▇▇▇ is under no duty to
supervise or inspect the construction or examine any books and records.
Any inspection or examination by ▇▇▇▇▇▇ is for the sole purpose of
protecting ▇▇▇▇▇▇'s security and preserving Lender's rights under this
Agreement. No default of Borrower will be waived by any inspection by
▇▇▇▇▇▇. In no event will any inspection by Lender be a representation that
there has been or will be compliance with the Plans and Specifications or
that the construction is free from defective materials or workmanship.

INDEMNITY. Borrower shall indemnify and hold harmless from any and all
claims asserted against Lender or the Property by any person, entity, or
governmental body, or arising out of or in connection with the Property,
Improvements, or Project. Lender shall be entitled to appear in any action
or proceeding to defend itself against such claims, and all costs incurred
by ▇▇▇▇▇▇ in connection with such defense, including attorneys' fees,
shall be paid by Borrower to Lender. Lender shall, in its sole discretion,
be entitled to settle or compromise any asserted claims against it, and
such settlement shall be binding upon Borrower for purposes of this
indemnification. All amounts paid by ▇▇▇▇▇▇ under this paragraph shall be
secured by ▇▇▇▇▇▇'s Mortgage or Deed of Trust, if any, on the Property,
shall be deemed an additional principal Advance under the Loan, payable
upon demand, and shall bear interest at the rate applicable to the Loan.

PUBLICITY. Lender may display a sign at the construction site informing
the public that Lender is the construction lender for the Project. ▇▇▇▇▇▇
may obtain other publicity in connection with the Project through press
releases and participation in ground-breaking and opening ceremonies and
similar events.

ACTIONS. Lender shall have the right to commence, appear in, or defend
any action or proceeding purporting to affect the rights, duties, or
liabilities of the parties in this Agreement, or the disbursement of funds
from the Loan Fund. In connection with this right, ▇▇▇▇▇▇ may incur and
pay reasonable costs and expenses, including, but not limited to,
attorneys' fees, for both trial and appellate proceedings. Borrower
covenants to pay to Lender on demand all such expenses, together with
interest from the date Lender incurs the expense at the rate specified in
the Note, and Lender is authorized to disburse funds from the Loan Fund
for such purposes.

CONSTRUCTION LOAN COMMITMENT. ▇▇▇▇▇▇ has issued a construction loan commitment
letter for the Loan to Borrower.

RELATIONSHIP TO THIS AGREEMENT. The terms and provisions of this
Agreement, the Note and the Related Documents supersede any inconsistent
terms and conditions of ▇▇▇▇▇▇'s construction loan commitment letter to
Borrower, provided that all obligations of Borrower under the commitment
to pay any fees to Lender or any costs and expenses relating to the Loan
or the commitment shall survive the execution and delivery of this
Agreement, the Note and the Related Documents. Any failure of Borrower to
perform any such obligation shall constitute a default under this
Agreement.

PERMANENT LOAN REQUIREMENTS. THE CONSTRUCTION NEEDS TO BE COMPLETED WITH
ALL APPROVALS AND FINAL INSPECTIONS SIGNED OFF BY THE GOVERNING
AUTHORITIES INCLUDING A CERTIFICATE OF OCCUPANCY.

EVENTS OF DEFAULT. Each of the following shall constitute an Event of Default
under this Agreement:

DEFAULT OF INDEBTEDNESS. Failure of Borrower to make any payment when due
on the Loans.

OTHER DEFAULTS. Failure of Borrower or any Grantor to comply with or to
perform when due any other term, obligation, covenant or condition
contained in this Agreement or in any of the Related Documents, or failure
of Borrower to comply with or to perform any other term, obligation,
covenant or condition contained in any other agreement between Lender and
Borrower.

FALSE STATEMENTS. Any warranty, representation or statement made or
furnished to Lender by or on behalf of Borrower or any Grantor under this
Agreement or the Related Documents is false or misleading in any material
respect at the time made or furnished, or becomes false or misleading at
any time thereafter.

DEFECTIVE COLLATERALIZATION. This Agreement or any of the Related
Documents ceases to be in full force and effect (including failure of any
collateral document to create a valid and perfected security interest or
lien) at any time and for any reason.

INSOLVENCY. The dissolution or termination of ▇▇▇▇▇▇▇▇'s existence as a
going business, the insolvency of ▇▇▇▇▇▇▇▇, the appointment of a receiver
for any part of ▇▇▇▇▇▇▇▇'s property, any assignment for the benefit of
creditors, any type of creditor workout, or the commencement of any
proceeding under any bankruptcy or insolvency laws by or against Borrower.

CREDITOR OR FORFEITURE PROCEEDINGS. Commencement of foreclosure or
forfeiture proceedings, whether by judicial proceeding, self-help,
repossession or any other method, by any creditor of Borrower, any
creditor of any Grantor against any collateral securing the Indebtedness,
or by any governmental agency. This includes a garnishment, attachment, or
levy on or of any of Borrower's deposit accounts with Lender. However,
this Event of Default shall not apply if there is a good faith dispute by
Borrower or Grantor, as the case may be, as to the validity or
reasonableness of the claim which is the basis of the creditor or
forfeiture proceeding, and if Borrower or Grantor gives ▇▇▇▇▇▇ written
notice of the creditor or forfeiture proceeding and furnishes reserves or
a surety bond for the creditor or forfeiture proceeding satisfactory to
Lender.

EVENTS AFFECTING GUARANTOR. Any of the preceding events occurs with
respect to any Guarantor of any of the Indebtedness or any Guarantor dies
or becomes incompetent, or revokes or disputes the validity of, or
liability under, any Guaranty of the Indebtedness. Lender, at its option,
may, but shall not be required to, permit the Guarantor's estate to assume
unconditionally the obligations arising under the guaranty in a manner
satisfactory to Lender, and, in doing so, cure the Event of Default.

CHANGE IN OWNERSHIP. Any change in ownership of twenty-five percent (25%)
or more of the common stock of Borrower.

ADVERSE CHANGE. A material adverse change occurs in Borrower's financial
condition, or ▇▇▇▇▇▇ believes the prospect of payment or performance of
the Indebtedness is impaired.

RIGHT TO CURE. If any default, other than a Default on Indebtedness, is
curable and if Borrower or Grantor, as the case may be, has not been given
a notice of a similar default within the preceding twelve (12) months, it
may be cured (and no Event of Default will have occurred) if Borrower or
Grantor, as the case may be, after receiving written notice from Lender
demanding cure of such default: (a) cures the default within fifteen (15)
days; or (b) if the cure requires more than fifteen (15) days, immediately
initiates steps which Lender deems in ▇▇▇▇▇▇'s sole discretion to be

7
04-13-2000 CONSTRUCTION LOAN AGREEMENT PAGE 6
LOAN NO 0400706081 (CONTINUED)
================================================================================
sufficient to cure the default and thereafter continues and completes all
reasonable and necessary steps sufficient to produce compliance as soon as
reasonably practical.

BREACH OF CONSTRUCTION CONTRACT. The improvements are not constructed in
accordance with the Plans and Specifications or in accordance with the
terms of the Construction Contract.

CESSATION OF CONSTRUCTION. Prior to the completion of construction of the
Improvements and equipping of the Project, the construction of the
Improvements or the equipping of the Project is abandoned or work thereon
ceases for a period of more than ten (10) days for any reason, or the
Improvements are not completed for purposes of final payment to the
General Contractor prior to October 10, 2000, regardless of the reason for
the delay.

TRANSFER OF PROPERTY. Sale, transfer, hypothecation, assignment, or
conveyance of the Property or the Improvements or any portion thereof or
interest therein by Borrower or any Grantor without ▇▇▇▇▇▇'s prior written
consent.

CONDEMNATION. All or any material portion of the Property is condemned,
seized, or appropriated without compensation, and Borrower does not within
thirty (30) days after such condemnation, seizure, or appropriation,
initiate and diligently prosecute appropriate action to contest in good
faith the validity of such condemnation, seizure, or appropriation.

EFFECT OF AN EVENT OF DEFAULT; REMEDIES. Upon the occurrence of any Event of
Default and at any time thereafter, Lender may, at its option, but without any
obligation to do so, and in addition to any other right Lender may have, do any
one or more of the following without notice to Borrower: (a) Cancel this
Agreement; (b) Institute appropriate proceedings to enforce the performance of
this Agreement; (c) Withhold further disbursement of Loan Fund; (d) Expend
funds necessary to remedy the default; (e) Take possession of the Property and
continue construction of the Project; (f) Accelerate maturity of the Note
and/or Indebtedness and demand payment of all sums due under the Note and/or
Indebtedness; (g) Bring an action on the Note and/or Indebtedness; (h)
Foreclose Lender's Mortgage or Deed of Trust, if any, on the Property in any
manner available under law; and (i) Exercise any other right or remedy which it
has under the Notes or Related Documents, or which is otherwise available at
law or in equity or by statute.

COMPLETION OF IMPROVEMENTS BY LENDER. If ▇▇▇▇▇▇ takes possession of the
Property, it may take any and all action necessary in its judgment to complete
construction of the Improvements, including but not limited to making changes
in the Plans and Specifications, work, or materials and entering into,
modifying or terminating any contractual arrangements, subject to ▇▇▇▇▇▇'s
right at any time to discontinue any work without liability. If Lender elects
to complete the Improvements, it will not assume any liability to Borrower or
to any other person for completing the Improvements or for the manner or
quality of construction of the Improvements, and Borrower expressly waives any
such liability. Borrower irrevocably appoints ▇▇▇▇▇▇ as its attorney-in-fact,
with full power of substitution, to complete the Improvements, at ▇▇▇▇▇▇'s
option, either in Borrower's name or in its own name. In any event, all sums
expended by ▇▇▇▇▇▇ in completing the construction of the Improvements will be
considered to have been disbursed to Borrower and will be secured by the
collateral for the Loan. Any such sums that cause the principal amount of the
Loan to exceed the face amount of the Note will be considered to be an
additional Loan to Borrower, bearing interest at the Note rate and being
secured by the collateral. For these purposes, Borrower assigns to Lender all
of its right, title and interest in and to the Project Documents; however
Lender will not have any obligation under the Project Documents unless Lender
expressly hereafter agrees to assume such obligations in writing. Lender will
have the right to exercise any rights of Borrower under the Project Documents
upon the occurrence of an Event of Default. All rights, powers, and remedies of
Lender under this Agreement are cumulative and alternative, and are in addition
to all rights which Lender may have under applicable law.

MISCELLANEOUS PROVISIONS. The following miscellaneous provisions are a part of
this Agreement:

AGENCY. Nothing in this Agreement shall be construed to constitute the
creation of a partnership or joint venture between Lender and Borrower or
any contractor. ▇▇▇▇▇▇ is not an agent or representative of Borrower. This
Agreement does not create a contractual relationship with and shall not be
construed to benefit or bind Lender in any way with or create any
contractual duties by ▇▇▇▇▇▇ to any contractor, subcontractor, materialman,
laborer, or any other person.

AMENDMENTS. This Agreement, together with any Related Documents,
constitutes the entire understanding and agreement of the parties as to the
matters set forth in this Agreement. No alteration of or amendment to this
Agreement shall be effective unless given in writing and signed by the
party or parties sought to be charged or bound by the alteration or
amendment.

APPLICABLE LAW. THIS AGREEMENT HAS BEEN DELIVERED TO LENDER AND ACCEPTED
BY LENDER IN THE STATE OF CALIFORNIA. IF THERE IS A LAWSUIT, ▇▇▇▇▇▇▇▇
AGREES UPON ▇▇▇▇▇▇'S REQUEST TO SUBMIT TO THE JURISDICTION OF THE COURTS OF
BUTTE COUNTY, THE STATE OF CALIFORNIA. THIS AGREEMENT SHALL BE GOVERNED BY
AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF CALIFORNIA.

AUTHORITY TO FILE NOTICES. Borrower appoints and designates Lender as its
attorney-in-fact to file for record any notice than Lender deems necessary
to protect its interest under this Agreement. This power shall be deemed
coupled with an interest and shall be irrevocable while any sum or
performance remains due and owing under any of the Related Documents.

CAPTION HEADINGS. Caption headings in this Agreement are for convenience
purposes only and are not to be used to interpret or define the provisions
of this Agreement.

MULTIPLE PARTIES; CORPORATE AUTHORITY. All obligations of Borrower under
this Agreement shall be joint and several, and all references to Borrower
shall mean each and every Borrower. This means that each of the persons
signing below is responsible for all obligations in this Agreement.

CONSENT TO LOAN PARTICIPATION. ▇▇▇▇▇▇▇▇ agrees and consents to ▇▇▇▇▇▇'s
sale or transfer, whether now or later, of one or more participation
interests in the Loans to one or more purchasers, whether related or
unrelated to Lender. Lender may provide, without any limitation
whatsoever, to any one or more purchasers, or potential purchasers, any
information or knowledge Lender may have about Borrower or about any other
matter relating to the Loan, and Borrower hereby waives any rights to
privacy it may have with respect to such matters. Borrower additionally
waives any and all notices of sale of participation interests, as well as
all notices of any repurchase of such participation interest. ▇▇▇▇▇▇▇▇
also agrees that the purchasers of any such participation interests will
be considered as the absolute owners of such interests in the Loans and
will have all the rights granted under the participation agreement or
agreements governing the sale of such participation interests. Borrower
further waives all rights of offset or counterclaim that it may have now
or later against Lender or against any purchaser of such a participation
interest and unconditionally agrees that either Lender or such purchaser
may enforce ▇▇▇▇▇▇▇▇'s obligation under the Loans irrespective of the
failure or insolvency of any holder of any interest in the Loans. ▇▇▇▇▇▇▇▇
further agrees that the purchaser of any such participation interests may
enforce its interests irrespective of any personal claims or defenses that
Borrower may have against ▇▇▇▇▇▇.

COSTS AND EXPENSES. ▇▇▇▇▇▇▇▇ agrees to pay upon demand all of ▇▇▇▇▇▇'s
expenses, including without limitation attorneys' fees, incurred in
connection with the preparation, execution, enforcement, modification and
collection of this Agreement or in connection with the Loans made pursuant
to this Agreement. ▇▇▇▇▇▇ may pay someone else to help collect the Loans
and to enforce this Agreement, and Borrower will pay that amount. This
includes, subject to any limits under applicable law, ▇▇▇▇▇▇'s attorneys'
fees and ▇▇▇▇▇▇'s legal expenses, whether or not there is a lawsuit,
including attorneys' fees for bankruptcy proceedings (including efforts to
modify or vacate any automatic stay or injunction), appeals, and any
anticipated post-judgment collection services. ▇▇▇▇▇▇▇▇ also will pay any
court costs, in addition to all other sums provided by law.

ENTIRE AGREEMENT. This Agreement and the Related documents constitute all
of the agreements between the parties relating to the Project and
supersede all other prior or concurrent oral or written agreements or
understandings relating to the Project.

NOTICES. All notices required to be given under this Agreement shall be
given in writing, may be sent by telefacsimile (unless otherwise required
by law), and shall be effective when actually delivered or when deposited
with a nationally recognized courier or deposited in the United States
mail, first class, postage prepaid, addressed to the party to whom the
notice is to be given at the address shown above. Any party may change its
address for notices under this Agreement by giving formal written notice
to the other parties, specifying that the purpose of the notice is to
change the party's address. To the extent permitted by applicable law, if
these is more than one Borrower, notice to any Borrower will constitute
notice to all Borrowers. For notice purposes, Borrower will keep Lender
informed at all times of ▇▇▇▇▇▇▇▇'s current address(es).

SUCCESSORS AND ASSIGNS. All covenants and agreements contained by or on
behalf of Borrower shall bind its successors and assigns and shall inure to
the benefit of Lender, its successors and assigns. Borrower shall not,
however, have the right to assign its rights under this Agreement or any
interest therein, without the prior written consent of Lender.

SEVERABILITY. If a court of competent jurisdiction finds any provision of
this Agreement to be invalid or unenforceable as to any person or
circumstance, such finding shall not render that provision invalid or
unenforceable as to any other persons or circumstances. If feasible, any
such offending provision shall be deemed to be modified to be within the
limits of enforceability or validity; however, if the offending provision
cannot be so modified, it shall be stricken and all other provisions of
this Agreement in all other respects shall remain valid and enforceable.

SURVIVAL. All warranties, representations, and covenants made by Borrower
in this Agreement or in any certificate or other instrument delivered by
Borrower to Lender under this Agreement shall be considered to have been
relied upon by ▇▇▇▇▇▇ and will survive the making of the Loan and delivery
to Lender of the Related Documents, regardless of any investigation made
by ▇▇▇▇▇▇ or on ▇▇▇▇▇▇'s behalf.

TIME IS OF THE ESSENCE. Time is of the essence in the performance of this
Agreement.

8
04-13-2000 CONSTRUCTION LOAN AGREEMENT PAGE 7
LOAN NO 0400706081 (CONTINUED)
================================================================================

WAIVER. Lender shall not be deemed to have waived any rights under this
Agreement unless such waiver is given in writing and signed by ▇▇▇▇▇▇. No
delay or omission on the part of Lender in exercising any right shall
operate as a waiver of such right or any other right. A waiver by ▇▇▇▇▇▇ of
a provision of this Agreement shall not prejudice or constitute a waiver of
Lender's right otherwise to demand strict compliance with that provision or
any other provision of this Agreement. No prior waiver by ▇▇▇▇▇▇, nor any
course of dealing between ▇▇▇▇▇▇ and Borrower, or between Lender and any
Grantor, shall constitute a waiver of any of Lender's rights or of any
obligations of Borrower or of any Grantor as to any future transactions.
Whenever the consent of Lender is required under this Agreement, the
granting of such consent by Lender in any instance shall not constitute
continuing consent in subsequent instances where such consent is required,
and in all cases such consent may be granted or withheld in the sole
discretion of Lender.

ADDITIONAL PROVISIONS. 1) INITIAL LOAN TERM IS SIX MONTHS AT WHICH TIME,
ASSUMING CONSTRUCTION IS COMPLETED, THE LOAN WILL BE AMORTIZED OVER THE
REMAINING 29.5 YEARS OF THE COMMITMENT. 2) THE INTEREST RATE WILL BE 9.05% FOR
THE FIRST FIVE YEARS. THE INTEREST RATE WILL BE RESET FOR SUBSEQUENT FIVE YEAR
PERIODS AT THE WEST COAST PRIME LENDING RATE PLUS .05%. 3) THE INITIAL ADVANCE
RATE WILL BE 75% OF THE LOAN AMOUNT UNTIL THE APPRAISAL IS COMPLETED. AT THAT
TIME THE ADVANCE RATE WILL BE A MAXIMUM OF 80% OF THE APPRAISED VALUE OF THE
PROPERTY.

BORROWER ACKNOWLEDGES HAVING READ ALL THE PROVISIONS OF THIS CONSTRUCTION LOAN
AGREEMENT, AND ▇▇▇▇▇▇▇▇ AGREES TO ITS TERMS. THIS AGREEMENT IS DATED AS OF
APRIL 13, 2000.

BORROWER:

FAFCO, INC.

By:_______________________________
▇▇▇▇▇▇▇ ▇. ▇▇▇▇, President

LENDER:

BUTTE COMMUNITY BANK

By:_______________________________
Authorized Officer

================================================================================

9
GUARANTY OF COMPLETION AND PERFORMANCE

Principal Loan Date Maturity Loan No Call Collateral Account Officer Initials

$3,400,000.00 04-13-2000 10-10-2000 0400706081 016 1111 120144 019

References in the shaded area are for Lender's use only and do not limit the
applicability of this document to any particular loan or item.

GUARANTOR: CENTRAL DEVELOPMENT, INC.

================================================================================

THIS GUARANTY OF COMPLETION AND PERFORMANCE ("Guaranty") is made as of April 13,
2000, by CENTRAL DEVELOPMENT, INC. ("Guarantor") to and for the benefit of BUTTE
COMMUNITY BANK ("Lender").

DEFINITIONS. The following words shall have the following meanings when used in
this Guaranty:

BORROWER. The word "Borrower" means each and every person or entity signing
the Note, including without limitation FAFCO, INC.

CONSTRUCTION LOAN AGREEMENT. The words "Construction Loan Agreement" mean
the loan agreement for the construction of the Project dated April 13,
2000, between Borrower and Lender, together with all exhibits and schedules
attached to the Construction Loan Agreement from time to time.

GUARANTOR. The word "Guarantor" means each and every person or entity
signing this Guaranty, including without CENTRAL DEVELOPMENT, INC.

GUARANTY. The word "Guaranty" means this Guaranty of Completion and
Performance from Guarantor to Lender dated April 13, 2000.

IMPROVEMENTS. The word "Improvements" means and includes without limitation
all existing and future buildings, structures, facilities, fixtures,
additions, and similar construction on the Property.

LENDER. The word "Lender" means BUTTE COMMUNITY BANK, its successors and
assigns.

LOAN. The word "Loan" means the loan made to Borrower under the
Construction Loan Agreement and the Loan Documents as described below.

LOAN DOCUMENTS. The words "Loan Documents" mean the Note, the Construction
Loan Agreement, and all other notes, credit agreements, loan agreements,
guaranties, security agreements, mortgages, deeds of trust, and other
documents, whether now or hereafter existing, executed in connection with
the Loan.

NOTE. The word "Note" means the promissory note or credit agreement dated
April 13, 2000, in the original principal amount of $3,400,000.00 from
Borrower to Lender, together with all renewals of, extensions of,
modifications of, refinancings of, consolidations of, and substitutions
for the promissory note or agreement.

PLANS AND SPECIFICATIONS. The words "Plans and Specifications" mean the
plans and specifications for the Project which have been approved and
initialed by Lender, together with such changes and additions as may be
approved by ▇▇▇▇▇▇ in writing.

PROJECT. The word "Project" means the construction, renovation, or other
work on the Improvements on the Real Property as set forth in the Plans and
Specifications. The Project includes the following work:

CONSTRUCT A 50,000 SQUARE FOOT COMMERCIAL BUILDING

REAL PROPERTY. The words "Real Property" mean the real property located in
BUTTE County, State of California, and legally described as:

SEE EXHIBIT "A" ATTACHED HERETO AND MADE A PART HEREOF

THE LOAN. ▇▇▇▇▇▇▇▇ proposes to borrow from Lender the principal amount of Three
Million Four Hundred Thousand & 00/100 Dollars ($3,400,000.00) pursuant to the
terms and conditions of the Construction Loan Agreement. As a condition and
inducement to making the Loan, ▇▇▇▇▇▇▇▇ has requested that Guarantor duly
execute and deliver this Guaranty guaranteeing the lien-free completion of the
construction of the Project and the performance of other covenants, which are
all considered by ▇▇▇▇▇▇ to be material regarding ▇▇▇▇▇▇'s decision to make the
Loan.

GUARANTY. Guarantor hereby unconditionally and absolutely warrants and
guarantees to Lender that: (a) construction of the Project shall be commenced
and shall be substantially completed within the time limits set forth in the
Construction Loan Agreement; (b) the Project shall be constructed and
completed in accordance with the Loan Documents and the Plans and
Specifications, without substantial deviation therefrom unless approved by
Lender in writing; (c) except for Lender's security agreements, the Project
will be constructed and completed free and clear of all liens and encumbrances,
including without limitation all mechanics' liens, materialmen's liens, and
equitable liens; and (d) all costs of constructing the Project will be paid
when due, and no stop notices shall be served on Lender.

OBLIGATIONS OF GUARANTOR UPON EVENT OF DEFAULT. Should an Event of Default (as
defined in the Construction Loan Agreement) occur or if the Project shall not
be constructed and completed as provided above, Guarantor shall: (a) diligently
proceed to cure such default and procure completion of the Project at
Guarantor's sole cost and expense; (b) fully pay and discharge all claims for
labor performed and material and services furnished in connection with the
construction of the Project; and (c) pay such amounts as may be necessary to
release and discharge all claims of stop notices, mechanics' liens,
materialmen's liens, and equitable liens, if any, that may come into existence
in connection with the construction of the Project.

NATURE OF GUARANTY. This Guaranty is an original and independent obligation of
Guarantor, separate and distinct from Borrower's obligations to Lender under
the Loan Documents. The obligations of Guarantor to Lender under this Guaranty
are direct and primary, regardless of the validity or enforceability of the
Loan Documents. This Guaranty is for the benefit of Lender, and is not for the
benefit of any third party. This Guaranty shall continue until (a) the Project
has been completed, free and clear of all liens and encumbrances as provided
above, and (b) all obligations of Guarantor to Lender hereunder have been
performed in full.

GUARANTOR'S AUTHORIZATION TO LENDER. Guarantor authorizes Lender, without
notice or demand and without lessening Guarantor's liability under this
Guaranty, from time to time: (a) to make or approve changes to the Plans and
Specifications; (b) to make modifications to the Construction Loan Agreement
and the other Loan Documents; (c) to make one or more additional secured or
unsecured loans to Borrower; (d) to repeatedly alter, compromise, renew,
extend, accelerate, or otherwise change the time for payment or other terms of
the Loan or any part of the Loan, including increases and decreases of the rate
of interest on the Loan; extensions may be repeated and may be for longer than
the original loan term; (e) to take and hold security for the payment of the
Loan or this Guaranty, and exchange, enforce, waive, and release any such
security, with or without the substitution of new collateral; (f) to release,
substitute, agree not to use, or deal with any one or more of Borrower's
sureties, endorsers, or other guarantors on any terms or in any manner Lender
may choose; (g) to determine how, when, and what application of payments and
credits shall be made on the Loan; (h) to apply such security and direct the
order or manner of sale thereof, including without limitation, any nonjudicial
sale permitted by the terms of the controlling security agreement or deed of
trust, as Lender in its discretion may determine; (i) to sell, transfer,
assign, or grant participations in all or any part of the Loan; and (j) to
assign or transfer this Guaranty in whole or in part.

GUARANTOR'S REPRESENTATIONS AND WARRANTIES. Guarantor represents and warrants to
Lender that: (a) no representations or agreements of any kind have been made to
Guarantor which would limit or qualify in any way the terms of this Guaranty;
(b) this Guaranty is executed at Borrower's request and not at the request of
Lender to induce Lender to disburse the Loan to Borrower pursuant to the terms
of the Loan Documents and that Lender would not make and disburse the Loan to
Borrower pursuant to the Loan Documents were it not for the execution and
delivery of this Guaranty; (c) Guarantor has not and will not, without the prior
written consent of Lender, sell, lease, assign, encumber, hypothecate, transfer,
or otherwise dispose of all or substantially all of Guarantor's assets, or any
interest therein; (d) neither the execution nor the delivery of this Guaranty
nor compliance with the terms hereof will conflict with or result in the breach
of any law or statute, will constitute a breach or default under any agreement
or instrument to which Guarantor may be a party, or will result in the creation
or imposition of any charge or lien upon any property or assets of Guarantor;
(e) Lender has made no representation to Guarantor as to the creditworthiness of
Borrower; (f) the most recent financial statements of Guarantor heretofore
delivered to Lender are true and correct in all material respects and fairly
present the financial condition of Guarantor as of the respective dates thereof,
and no material adverse change has occurred in the financial condition of
Guarantor since the date of the most recent financial statements; and (g)
Guarantor has established adequate means of obtaining from Borrower on a
continuing basis information regarding

10
04-13-2000 GUARANTY OF COMPLETION AND PERFORMANCE PAGE 2
LOAN NO 0400706081 (CONTINUED)
================================================================================

obligations to disclose to Guarantor any information or documents acquired by
Lender in the course of its relationship with ▇▇▇▇▇▇▇▇.

GUARANTOR'S WAIVERS. Except as prohibited by applicable law, Guarantor waives
any right to require Lender to (a) make any presentment, protest, demand, or
notice of any kind, including notice of change of any terms of repayment of the
Indebtedness, default by Borrower or any other guarantor or surety, any action
or nonaction taken by Borrower, Lender, or any other guarantor or surety of
Borrower, or the creation of new or additional Indebtedness; (b) proceed against
any person, including Borrower, before proceeding against Guarantor; (c) proceed
against any collateral for the Indebtedness, including ▇▇▇▇▇▇▇▇'s collateral,
before proceeding against Guarantor; (d) apply any payments or proceeds received
against the Indebtedness in any order; (e) give notice of the terms, time, and
place of any sale of the collateral pursuant to the Uniform Commercial Code or
any other law governing such sale; (f) disclose any information about the
Indebtedness, the Borrower, the collateral, or any other guarantor or surety, or
about any action or nonaction of Lender; or (g) pursue any remedy or course of
action in ▇▇▇▇▇▇'s power whatsoever.

Guarantor also waives any and all rights or defenses arising by reason of (h)
any disability or other defense of Borrower, any other guarantor or surety or
any other person; (i) the cessation from any cause whatsoever, other than
payment in full, of the Indebtedness; (j) the application of proceeds of the
Indebtedness by Borrower for purposes other than the purposes understood and
intended by Guarantor and Lender; (k) any act of omission or commission by
Lender which directly or indirectly results in or contributes to the discharge
of Borrower or any other guarantor or surety, or the Indebtedness, or the loss
or release of any collateral by operation of law or otherwise; (l) any statute
of limitations in any action under this Guaranty or on the Indebtedness; or (m)
any modification or change in terms of the Indebtedness, whatsoever, including
without limitation, the renewal, extension, acceleration, or other change in the
time payment of the Indebtedness is due and any change in the interest rate.

Guarantor waives all rights and defenses arising out of an election of remedies
by ▇▇▇▇▇▇, even though that election of remedies, such as nonjudicial
foreclosure with respect to security for a guaranteed obligation, has destroyed
Guarantor's rights of subrogation and reimbursement against Borrower by the
operation of Section 580d of the California Code of Civil Procedure, or
otherwise.

This waiver includes, without limitation, any loss of rights Guarantor may
suffer by reason of any rights or protections of Borrower in connection with any
anti-deficiency laws, or other laws limiting or discharging the Indebtedness or
Borrower's obligations (including, without limitation, Section 726, 580a, 580b,
and 580d of the California Code of Civil Procedure). Guarantor waives all rights
and protections of any kind which Guarantor may have for any reason, which would
affect or limit the amount of any recovery by Lender from Guarantor following a
nonjudicial sale or judicial foreclosure of any real or personal property
security for the Indebtedness including, but not limited to, the right to any
fair market value hearing pursuant to California Code of Civil Procedure Section
580a.

▇▇▇▇▇▇▇▇▇ understands and agrees that the foregoing waivers are waivers of
substantive rights and defenses to which Guarantor might otherwise be entitled
under state and federal law. The rights and defenses waived include, without
limitation, those provided by California laws of suretyship and guaranty,
anti-deficiency laws, and the Uniform Commercial Code. Guarantor acknowledges
that Guarantor has provided these waivers of rights and defenses with the
intention that they be fully relied upon by ▇▇▇▇▇▇. Until all Indebtedness is
paid in full, Guarantor waives any right to enforce any remedy Lender may have
against Borrower or any other guarantor, surety, or other person, and further,
Guarantor waives any right to participate in any collateral for the Indebtedness
now or hereafter held by Lender.

GUARANTOR'S UNDERSTANDING WITH RESPECT TO WAIVERS. Guarantor warrants and agrees
that each of the waivers set forth above is made with Guarantor's full knowledge
of its significance and consequences and that, under the circumstances, the
waivers are reasonable and not contrary to public policy or law. If any such
waiver is determined to be contrary to any applicable law or public policy, such
waiver shall be effective only to the extent permitted by law.

RIGHTS AND REMEDIES. If Guarantor shall fail to perform promptly as provided in
this Guaranty, Lender shall have the following rights and remedies:

PERFORM WORK. Lender, at its option, but without any obligation to do so,
may proceed to perform on behalf of Guarantor any and all work on the
Project and to pay any costs incurred in connection with the work.
Guarantor, upon ▇▇▇▇▇▇'s demand, shall promptly pay to Lender all such sums
expended together with interest thereon at the interest rate set forth in
the Note.

CURE DEFAULTS. Lender, at its option, but without any obligation to do so,
may cure any defaults, including without limitation, paying any unpaid
bills and liens, including without limitation those for construction,
labor, and materials. Guarantor, upon ▇▇▇▇▇▇'s demand, shall promptly pay
to Lender all such sums expended together with interest thereon at the
interest rate set forth in the Note.

SPECIFIC PERFORMANCE. From time to time and without first requiring
performance on the part of Borrower and without being required to exhaust
any security held by Lender for the Loan, to require Guarantor specifically
to perform its obligations under this Guaranty, by action at law or in
equity or both, and further to collect in any such action compensation for
all loss, cost, damage, injury and expense sustained or incurred by ▇▇▇▇▇▇
as a direct or indirect consequence of such breach with interest thereon at
the interest rate set forth in the Note.

OTHER RIGHTS AND REMEDIES. In addition, Lender shall have and may exercise
any or all of the rights and remedies it may have available at law, in
equity, or otherwise.

SUBORDINATION OF ▇▇▇▇▇▇▇▇'S DEBTS TO GUARANTOR. Guarantor agrees that the Loan
Indebtedness of Borrower to Lender, whether now existing or hereafter created,
shall be prior to any claim that Guarantor may now have or hereafter acquire
against Borrower, whether or not Borrower becomes insolvent. Guarantor hereby
expressly subordinates any claim Guarantor may have against Borrower, upon any
account whatsoever, to any claim that Lender may now or hereafter have against
Borrower. In the event of insolvency and consequent liquidation of the assets of
Borrower, through bankruptcy, by an assignment for the benefit of creditors, by
voluntary liquidation, or otherwise, the assets of Borrower applicable to the
payment of the claims of both ▇▇▇▇▇▇ and Guarantor shall be paid to Lender and
shall be first applied by Lender to the Loan Indebtedness of Borrower to Lender.
Guarantor does hereby assign to Lender all claims which it may have or acquire
against Borrower or against any assignee or trustee in bankruptcy of Borrower;
provided however, that such assignment shall be effective only for the purpose
of assuring to Lender full payment in legal tender of the Loan Indebtedness. Any
notes or credit agreements now or hereafter evidencing any debts or obligations
of Borrower to Guarantor shall be marked with a legend that the same are subject
to this Guaranty and, if Lender so requests, shall be delivered to Lender.
▇▇▇▇▇▇▇▇▇ agrees, and ▇▇▇▇▇▇ hereby is authorized, in the name of Guarantor,
from time to time to execute and file financing statements and continuation
statements and to execute such other documents and to take such other actions as
Lender deems necessary or appropriate to perfect, preserve, and enforce its
rights under this Guaranty.

MISCELLANEOUS PROVISIONS. The following miscellaneous provisions are a part of
this Guaranty:

AMENDMENTS. This Guaranty constitutes the entire understanding and
agreement of the parties as to the matters set forth in this Guaranty. No
alteration of or amendment to this Guaranty shall be effective unless given
in writing and signed by the party or parties sought to be charged or bound
by the alteration or amendment.

APPLICABLE LAW. This Guaranty has been delivered to Lender and accepted by
▇▇▇▇▇▇ in the State of California. If there is a lawsuit, ▇▇▇▇▇▇▇▇▇ agrees
upon ▇▇▇▇▇▇'s request to submit to the jurisdiction of the courts of BUTTE
County, State of California. This Guaranty shall be governed by and
construed in accordance with the laws of the State of California.

ATTORNEYS' FEES; EXPENSES. ▇▇▇▇▇▇▇▇▇ agrees to pay upon demand all of
▇▇▇▇▇▇'s costs and expenses, including attorneys' fees and ▇▇▇▇▇▇'s legal
expenses, incurred in connection with the enforcement of this Guaranty.
Lender may pay someone else to help enforce this Guaranty, and Guarantor
shall pay the costs and expenses of such enforcement. Costs and expenses
include ▇▇▇▇▇▇'s attorneys' fees and legal expenses whether or not there is
a lawsuit, including attorneys' fees and legal expenses for bankruptcy
proceedings (and including efforts to modify or vacate any automatic stay
or injunction), appeals, and any anticipated post-judgment collection
services. Guarantor also shall pay all court costs and such additional fees
as may be directed by the court.

NOTICES. All notices required to be given by either party to the other
under this Guaranty shall be in writing, may be sent by telefacsimile
(unless otherwise required by law), and shall be effective when actually
delivered, or when deposited with a nationally recognized overnight
courier, or when deposited in the United States mail, first class postage
prepaid, addressed to the party to whom the notice is to be given at the
address shown above or to such other addresses as either party may
designate to the other in writing. If there is more than one Guarantor,
notice to any Guarantor will constitute notice to all Guarantors. For
notice purposes, ▇▇▇▇▇▇▇▇▇ agrees to keep ▇▇▇▇▇▇ informed at all times of
Guarantor's current address.

INTERPRETATION. In all cases where there is more than one Borrower or
Guarantor, then all words used in this Guaranty in the singular shall be
deemed to have been used in the plural where the context and construction
so require; and where there is more than one Borrower named in this
Guaranty or when this Guaranty is executed by more than one Guarantor, the
words "Borrower" and "Guarantor" respectively shall mean all and any one or
more of them. Caption headings in this Guaranty are for convenience
purposes only and are not to be used to interpret or define the provisions
of this Guaranty. If a court of competent jurisdiction finds any provision
of this Guaranty to be invalid or unenforceable as to any person or
circumstance, such finding shall not render that provision invalid or
unenforceable as to any other persons or circumstances, and all provisions
of this Guaranty in all other respects shall remain valid and enforceable.
If any one or more of Borrower or Guarantor are corporations or
partnerships, it is not necessary for Lender to inquire into the powers of
Borrower or Guarantor or of the officers, directors, partners, or agents
acting or purporting to act on their behalf, and any Loan Indebtedness made
or created in reliance upon the professed exercise of such powers shall be
guaranteed under this Guaranty.

WAIVER. Lender shall not be deemed to have waived any rights under this
Guaranty unless such waiver is given in writing and signed by ▇▇▇▇▇▇. No
delay or omission on the part of Lender in exercising any right shall
operate as a waiver of such right or any other right. A waiver by ▇▇▇▇▇▇
of a provision of this Guaranty shall not prejudice or constitute a waiver
of Lender's right otherwise to demand strict compliance with that
provision or
11
04-13-2000 GUARANTY OF COMPLETION AND PERFORMANCE PAGE 3
LOAN NO 0400706081 (CONTINUED)

================================================================================

any other provision of this Guaranty. No prior waiver by ▇▇▇▇▇▇, nor any
course of dealing between ▇▇▇▇▇▇ and Guarantor, shall constitute a waiver
of any of Lender's rights or of any Guarantor's obligations as to any
future transactions. Whenever the consent of Lender is required under this
Guaranty, the granting of such consent by Lender in any instance shall not
constitute continuing consent to subsequent instances where such consent is
required and in all cases such consent may be granted or withheld in the
sole discretion of Lender.

EACH UNDERSIGNED GUARANTOR ACKNOWLEDGES HAVING READ ALL THE PROVISIONS OF THIS
GUARANTY AND AGREES TO ITS TERMS. IN ADDITION, EACH GUARANTOR UNDERSTANDS THAT
THIS GUARANTY IS EFFECTIVE UPON GUARANTOR'S EXECUTION AND DELIVERY OF THIS
GUARANTY TO LENDER. NO FORMAL ACCEPTANCE BY ▇▇▇▇▇▇ IS NECESSARY TO MAKE THIS
GUARANTY EFFECTIVE. THIS GUARANTY IS DATED APRIL 13, 2000.

GUARANTOR: CENTRAL DEVELOPMENT, INC.

X_____________________________________
Guarantor's Signature

LENDER:

X_____________________________________
Authorized Signer

================================================================================

EXHIBIT 10.19(A) PROMISSORY NOTE

Document Metadata

Document Metadata

Table of Contents