Exhibit 10.18
STATE OF MAINE
DEPARTMENT OF HUMAN SERVICES
11 STATE HOUSE STATION
AUGUSTA, MAINE
04333-0011
▇▇▇▇▇ ▇. ▇▇▇▇, ▇▇. ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇▇
GOVERNOR COMMISSIONER
February 24, 1997
▇▇. ▇▇▇▇▇▇ ▇▇▇▇▇▇
Network Six, Inc.
▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇
▇▇▇▇▇▇▇, ▇.▇. 02886
RE: MACWIS Contract
Dear ▇▇. ▇▇▇▇▇▇:
Enclosed please find the final version of the MACWIS Contract. It is my
determination that this version is reasonable in accommodating the issues raised
in the past.
The State of Maine has dedicated significant resources to the initiation of this
contract and the enclosed version is the final iteration. Please notify ▇▇▇▇▇
▇▇▇▇▇ of your final decision on this matter within twenty four hours of the
receipt of this document.
As you are aware, prior to a final signing of this document the following
documents will need to be received:
* A copy of the required performance bond
* Certification that any required insurance polices have been issued.
I acknowledge that this has been a long process for all involved and the State
of Maine is very eager to begin this exciting project. We await your response.
Sincerely,
▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇▇
Commissioner
Maine Department of Human Services
cc: ▇▇▇▇▇ ▇▇▇▇▇: Deputy Commissioner of Programs
▇▇▇▇ ▇▇▇▇▇▇: Deputy Commissioner of OMB
▇▇▇▇▇ ▇▇▇▇▇▇▇: Director of the Bureau of Child and Family Services
▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇: Director of the Division of Data Processing
▇▇▇▇▇▇ ▇▇▇▇▇▇: MACWIS Project Manager
STATE OF MAINE
CONTRACT FOR SPECIAL SERVICES
Commencement Date April 1, 1997
-------------
Dollar Amount $6,265,738.00 Termination Date March 1, 1999
--------------- -------------
THIS AGREEMENT, made this 1st day of April, 1997, is by and between the State of
Maine, Department of Human Services, hereinafter called "Department," and
Network Six, Inc., hereinafter called "Contractor."
The type of organization of the Contractor is:
_____1. An individual doing business as__________________________
_____2. A partnership.
__X__3. A corporation of the State of Rhode Island
---------------------------
_____4. Other: __________________________________________________
The principal office of the Contractor is located
at (street, city, state, zip):
▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇
The Employer Identification Number (Federal tax identification number) of
the Contractor is ▇▇-▇▇▇-▇▇▇▇
-----------
WITNESSETH, that for and in consideration of the payments and agreements
hereinafter mentioned, to be made and performed by the Department, the
Contractor hereby agrees with the Department to furnish all qualified personnel,
facilities, materials and services and in consultation with the Department, to
perform the services, study or projects described in Rider B. The following
riders are hereby incorporated into this contract:
Rider A - Payment and Other Provisions
Rider B - Specifications of Work to be Performed
IN WITNESS WHEREOF, the Department and the Contractor, by their representatives
duly authorized, have executed this agreement in three original copies.
CONTRACTOR: DEPARTMENT:
Network Six, Inc. Maine Department of Human Services
-------------------------- ----------------------------------
Contractor Name Department Name
By: /s/ ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇ By:
----------------------- --------------------------------
Authorized Signature Authorized Signature
▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇, President/CEO ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇▇, Commissioner
-------------------------------- ----------------------------------
Typed Name and Title Typed Name and Title
APPROVED, CONTRACT REVIEW COMMITTEE: APPROVED, ATTORNEY GENERAL
(if applicable):
Date: ______________________, 1997 Date: ___________________________, 1997
Chairman Attorney General
*By Bureau of Purchases
STATE OF MAINE
MAINE AUTOMATED CHILD WELFARE
INFORMATION SYSTEM
CONTRACT FOR SPECIAL SERVICES
TABLE OF CONTENTS
INTRODUCTION AND RECITALS............................................. 1
RIDER A: PAYMENT AND OTHER PROVISIONS................................. 3
1.0 General Provisions........................................... 3
1.1 Definitions.................................................. 3
1.2 Contract Defined; Order of Priority.......................... 7
1.2.1 Deviations From The RFP............................... 7
1.3 Modification................................................. 7
1.4 Contract Approval............................................ 7
1.5 Updated Detailed Project Plan................................ 8
1.6 Beginning Of Work............................................ 8
1.7 Contract Price............................................... 8
1.8 Invoices and Payments....................................... 8
1.9 Benefits and Deductions...................................... 8
1.10 Independent Capacity......................................... 8
1.11 Contract Administrator...................................... 9
1.12 Project Manager.............................................. 9
1.13 Subletting, Assignment or Transfer........................... 9
1.14 Equal Employment Opportunity Assurances...................... 9
1.14.1 Non-Discrimination in Employment Assurances........... 9
1.14.2 Non-Discrimination in Advertising Assurances.......... 10
1.14.3 Labor Union Assurances................................ 10
1.14.4 Subcontractor Assurances.............................. 10
1.14.5 Civil Rights Act and Rehabilitation Act Assurances.... 10
1.15 Employment and Personnel..................................... 10
1.16 State Employees Not to Benefit............................... 11
1.17 Warranty..................................................... 11
1.18 Access to Records............................................ 11
1.19 Governmental Requirements.................................... 11
1.20 Interpretation and Performance............................... 11
1.20.1 Governing Law......................................... 11
1.20.2 Severability.......................................... 11
1.20.3 Reliance on Policy Determinations..................... 11
1.20.4 Titles Not Controlling................................ 12
1.20.5 Gender and Number..................................... 12
1.20.6 No Rule of Construction............................... 12
1.21 State Held Harmless.......................................... 12
1.22 Entire Agreement............................................. 13
1.23 Advertising Award............................................ 13
1.24 Notices...................................................... 13
2.0 Type Of Contract............................................. 13
2.1 Term Of The Contract......................................... 13
2.2 Limitation................................................... 14
2.3 Fiscal Year.................................................. 14
3.0 Termination Of Contract...................................... 14
3.1 Termination Claims........................................... 15
3.2 Default By Contractor........................................ 15
3.3 Assurances Before Breach..................................... 16
3.4 State Options At Termination................................. 16
4.0 Contractor Freedom From Liability (Force Majeure)............ 16
5.0 Liquidated Damages Failure To Meet Performance Standards..... 17
5.1 Documentation................................................ 18
5.2 Timeliness of the Project.................................... 18
5.3 Deliverables and Report Production........................... 19
5.4 Performance Standard Measurements............................ 19
5.5 Systems User Documentation................................... 19
6.0 Failure To Perform........................................... 20
7.0 Contractor Personnel......................................... 20
8.0 Changes In Scope............................................. 21
8.1 Changes In Scope (CIS)....................................... 21
8.2 Impact of CIS................................................ 21
8.3 Negotiations of CIS.......................................... 22
8.4 Failure to Negotiate CIS..................................... 22
8.5 Change Orders Within Scope................................... 22
8.6 Events Constituting CIS...................................... 22
8.7 Final Decisions Regarding CIS................................ 23
8.8 Restrictions of CIS.......................................... 23
8.9 Claims for Compensation for CIS.............................. 24
8.10 Authority to Issue Change Orders............................. 24
8.11 Modifications Which Do Not Constitute CIS.................... 24
8.12 Change Rates for CIS......................................... 24
9.0 Disputes..................................................... 24
10.0 Confidentiality Of Information............................... 25
11.0 Prime Contractor Responsibilities............................ 25
11.1 Subcontracts................................................. 25
12.0 Ownership Of Information..................................... 26
12.1 Custom Software.............................................. 26
12.2 COTS Software................................................ 28
13.0 Liability.................................................... 29
14.0 Waiver....................................................... 29
15.0 Warranty..................................................... 29
16.0 Insurance....................................................... 30
16.1 Minimum Insurance............................................... 30
16.2 Certificates.................................................... 30
16.3 Notice Of Change................................................ 31
16.4 Liability Not Limited........................................... 31
16.5 Insurance Of Assumed Contractual Risk........................... 31
17.0 Payment......................................................... 31
17.1 Invoices........................................................ 32
17.2 Method Of Charging.............................................. 32
18.0 Inspection And Approval......................................... 32
19.0 Conflict Of Interest............................................ 32
20.0 State Property.................................................. 33
21.0 Federal Inspections............................................. 33
22.0 Copies Of Reports............................................... 33
23.0 Copyright Of Data............................................... 33
24.0 Training........................................................ 34
25.0 Patent, Copyright And Other Proprietary Indemnification......... 34
26.0 Application Program Source Code................................. 34
27.0 Accounting Requirements......................................... 34
28.0 Audit Requirements.............................................. 34
29.0 Records Retention Requirements.................................. 35
30.0 Audit Liabilities............................................... 35
31.0 Taxes........................................................... 35
32.0 Price Protection................................................ 36
33.0 Lobbying Certification.......................................... 36
34.0 Pricing And Discount............................................ 36
35.0 Cover........................................................... 36
36.0 Additional Defaults............................................. 37
37.0 Performance Assurance........................................... 37
RIDER B: SPECIFICATIONS OF THE WORK TO BE PERFORMED...................... 39
INTRODUCTION AND RECITALS
This Contract is entered into as of __________________________ by and between
the State ofMaine, Department of Human Services (hereinafter referred to as
"State", "DHS" or "Department") and Network Six, Incorporated (hereinafter
referred to as the "Contractor").
WHEREAS, the Department desires to implement a Maine Automated Child Welfare
Information System (hereinafter referred to as "MACWIS"); and
WHEREAS, the Department is authorized by the laws of the State of Maine to
contract with organizations for the implementation of such a system; and
WHEREAS, the Department solicited proposals for such implementation by issuing a
Request for Proposals issued by the Department on December 4, 1995; and
WHEREAS, the Department evaluated all proposals received in response to the
Request for Proposals in a fair and unbiased manner; and
WHEREAS, the Department reviewed the proposed systems of all responding vendors
at system demonstrations and presentations by the key contractor employees
proposed for the project; and
WHEREAS, the Department further interviewed the key employees of the two highest
scoring responding vendors; and
WHEREAS, the Department selected the Contractor as the successful vendor for the
transfer, design, development, implementation and testing of MACWIS after
evaluating its proposal, reviewing its proposed system, conducting key employee
interviews and determining that the Contractor's and Subcontractor's key
employees to be assigned to the design, development and implementation of the
proposed system possessed abilities and could deliver a level of service not
available from other proponents; and
WHEREAS, the State's Contract Review Committee approved the selection of the
Contractor; and
WHEREAS, the Contractor is qualified and willing to perform its duties as set
out herein subject to the terms and conditions stated below; and
WHEREAS, the Contractor has agreed to supplement its personnel with the
appropriate technical consultants and subcontractors as necessary to
satisfactorily complete its duties and responsibilities; and
WHEREAS, the Contractor acknowledges that the Department may use Consultant
assistance to help it monitor the Contractor's performance under this Contract
and the Contractor agrees that it will cooperate with and provide State
Consultants with any information that is reasonably needed to monitor the
Contractor's work under this Contract;
NOW, THEREFORE, in consideration of the foregoing recitals and of the mutual
promises contained herein, the Department and the Contractor agree as follows:
RIDER A
PAYMENT AND OTHER PROVISIONS
1.0 GENERAL PROVISIONS
1.1 DEFINITIONS
The following terms used in this Contract shall be defined as follows, unless
the context clearly indicates otherwise:
ACF: (Federal) Administration for Children and Families (DHHS)
AFDC: Aid to Families with Dependent Children
APD: Advance Planning Document. The MACWIS APD was submitted in
separate Planning (PAPD) and Implementation (IAPD) versions.
ASPIRE: Additional Support for People in Retraining and Education
BCFS: (State) Bureau of Child and Family Services (DHS)
BFI: (State) Bureau of Family Independence (formerly Bureau of Income
Maintenance) (DHS)
BIS: (State) Bureau of Information Services (DOAFS)
CONTRACTOR: Network Six, Incorporated (NSI) and any of its subsidiaries,
affiliated entities, or successors.
CONTRACTOR'S ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇, President of NSI, or his successor
DISPUTE
RESOLUTION
AUTHORITY:
CSE: Child Support Enforcement
DAY: A calendar day, unless otherwise specified in this Contract
DELIVERABLE: The work products produced by the Contractor for submission to
DHS for its review and approval in accordance with the provisions
of this Contract
DEPARTMENT: (State) Department of Human Services
DHHS: (Federal) Department of Health and Human Services
DHS: (State) Department of Human Services
DHS-DDP: (State) Department of Human Services - Division of Data
Processing
DHS-DP: DHS-DDP
DISPUTE
RESOLUTION ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇▇, Commissioner of DHS, or his successor, and
AUTHORITIES: ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇, President of NSI, or his successor
DOAFS: (State) Department of Administrative and Financial Services
DSER: (State) Division of Support Enforcement and Recovery (BFI)
EFFECTIVE The effective date of this Contract is the date the Contract is
DATE: fully executed by the State and the Contractor, subsequent to
the contract's approval by both the U.S. Department of Health
and Human Services and the State's Contract Review Committee
EFFP: Enhanced Federal Financial Participation
EVENT: Any written or oral communication, direction, instruction,
interpretation or determination by or from the State's Contract
Administrator, Project Manager, or any duly designated and
authorized representative thereof, or any omission of the State's
Contract Adiministrator, Project Manager, or any duly designated
and authorized representative thereof.
FAMIS: Family Assistance Management Information System
FFP: Federal Financial Participation
FNS: (Federal) Food and Nutrition Service
HCFA: (Federal) Health Care Financing Administration
IAPD: Implementation Advance Planning Document
ICWIS: Indiana Child Welfare Information System
IDRT: The Interim Dispute Review Team, consisting of the following
persons or their successors: ▇▇▇▇▇ ▇▇▇▇▇, Deputy Commissioner for
Programs, DHS, and ▇▇▇▇▇ ▇▇▇▇▇, Vice President, NSI. If a dispute
involves the Subcontractor, then the IDRT shall also include
▇▇▇▇▇▇▇ ▇▇▇▇▇▇, Deputy Commissioner, Office of Management and
Budget, DHS, and ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇, MACWIS Engagement Principal,
Unisys
IV-A: Medicaid Eligibility Program/Title IV-A of the Social Security
Act Administered in Maine by the Bureau of Family Independence
(BFI)
IV-D: Child Support Enforcement Program/Title IV-D of the Social
Security Act Administered in Maine by the Division of Support
Enforcement and Recovery (DSER)
IV-E: Child Welfare Program/Title IV-E of the Social Security Act
Administered in Maine by the Bureau of Child and Family Services
(BCFS)
JET: Job Exploration and Training
JOBS: Job Opportunities and Basic Skills training
KEY PERSONNEL: Key Personnel are defined as the following individuals:
the Contractor's Project Manager: ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇, NSI;
the Deputy Project Manager/Implementation Manager:
▇▇▇▇ ▇'▇▇▇▇▇▇▇, NSI;
the Application Development Manager/Lead Analyst:
▇▇▇▇▇ ▇'▇▇▇▇▇,▇▇▇▇▇▇;
the two (2) Policy Specialists (part time, to the extent that
their time is allocated to the project per the RFP or the
latest mutually agreed upon version of the Project
Plan): ▇▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇▇▇▇, and ▇▇▇▇▇▇ ▇▇▇▇▇▇, NSI;
the Lead Programmer: J. R. ▇▇▇▇▇▇▇, ▇▇▇▇▇▇;
the Intake Team Leader: ▇▇▇▇ ▇▇▇▇▇, Unisys;
the Case Management Team Leader: ▇▇▇▇▇ ▇▇▇, Unisys;
the Resource Management Team Leader: ▇▇▇▇ ▇▇▇▇▇, Unisys;
the Financial Management/Interfaces Team Leader: ▇▇▇▇▇ ▇▇▇▇▇▇▇,
NSI;
the Technical Team Leader/Database Specialist: ▇▇▇▇▇ ▇▇▇▇▇, NSI;
the Training Team Leader/Help Desk: ▇▇▇▇▇▇ ▇▇▇▇▇▇, NSI;
the Conversion Team Leader: ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇, NSI;
and the Development Tool Specialist: ▇▇▇▇▇ ▇▇▇▇▇▇, NSI.
This definition of key personnel supersedes and replaces any and all earlier
----------------------------------------------------------------------------
such definitions in the Request for Proposal and the Contractor's proposals
-------------------------------------------------------------------------
submitted in response to the Request for Proposal.
--------------------------------------------------
MACWIS: Maine Automated Child Welfare Information System
MFASIS: Maine Financial and Administration Services Information System
MMIS: Medicaid Management Information System
NECSES: New England Child Support Enforcement System
PAPD: Planning Advance Planning Document
PRIME
CONTRACTOR: Contractor
PROPOSAL: The proposal submitted by the Contractor in response to the RFP.
REQUEST FOR The State's Request for Proposal for MACWIS, as amended and
PROPOSAL: supplemented by the MACWIS Bidders' Conference Questions and
Answers dated January 4, 1996 and the MACWIS Bidders' Conference
Additional Questions and Answers dated February 1, 1996
RFP: Request for Proposal
RIDERS: Written materials that are attached to this Contract and/or
incorporated by reference
SACWIS: Statewide Automated Child Welfare Information System
SIRU: (State) Special Investigations and Recovery Unit
SSA: (Federal) Social Security Administration
SSN: Social Security Number
STATE: The State of Maine
STATE'S ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇▇, Commissioner of DHS, or his successor
DISPUTE
RESOLUTION
AUTHORITY:
SUBCONTRACTOR: Any person not in the employ of the Contractor, or any
organization not owned by the Contractor including its officers,
employees or agents, performing work which is the responsibility
of the Contractor under this Contract, including any technical
consultant, firm, or corporation retained by the Contractor to
furnish or supply services, materials, equipment or supplies in
connection with this Contract
SUBCONTRACTOR: Unisys, Inc., and any of its subsidiaries, affiliated entities,
or successors and agents performing work that is the
responsibility of the Subcontractor under this Contract,
including any technical consultant, firm, or corporation
retained by the Subcontractor to furnish or supply services,
materials, equipment or supplies in connection with this
Contract
TRANSFER As specified in the Contractor's proposal the Transfer System
SYSTEM: is the State of Indiana SACWIS, known as ICWIS. The
transfer system includes any additional components developed and
implemented subsequent to the submission of the Contractor's
proposal.
USDA: (Federal) United States Department of Agriculture
1.2 CONTRACT DEFINED; ORDER OF PRIORITY
The contract between the State of Maine and the Contractor shall include the
terms set forth in: (i) this Rider A and any cover sheet attached hereto; (ii)
Rider B, which incorporates by reference both the Request for Proposal, as
amended and supplemented by the MACWIS Bidders' Conference Questions and Answers
dated January 4, 1996, and the MACWIS Bidders' Conference Additional Questions
and Answers dated February 1, 1996 (the "RFP"), and the Contractor's Proposal
submitted in response to the RFP (the "Proposal"), subject to the terms set
forth below in Section 1.2.1 of this Rider A; and (iii) any subsequent contract
amendments duly agreed to and signed by both parties (collectively, the
"Contract"). In the event of a conflict in language among the documents
referenced above, the provisions and requirements set forth and/or referenced in
this Rider A or any subsequent amendments shall govern, followed in priority by
the RFP and the Contractor's Proposal. In the event that an issue is addressed
in one document that is not addressed in the other documents, no conflict in
language shall be deemed to occur. However, the State reserves the right to
clarify any contractual relationship in writing with the agreement of the
Contractor, and such written clarification shall govern in case of conflict with
the applicable requirements stated in the RFP or the Contractor's proposal.
1.2.1 DEVIATIONS FROM THE RFP
The requirements appearing in the RFP are a part of the terms and conditions of
this Contract. The State has reviewed the Proposal and accepts as part of this
Contract those deviations from the specifications contained in Section 3 of the
RFP that pertain to the Contractor's scope of work with respect to the MACWIS
system and that have been specifically identified by the Contractor in Sections
III, IV, V, VI, VII, and 8.1.2 of the Proposal; provided, however, that in no
event shall anything contained in the Proposal be deemed to supersede or
contravene the terms and conditions set forth in this Rider A.
1.3 MODIFICATION
No modification or change of any provision in this Contract shall be made, or be
construed to have been made, unless such modification is mutually agreed to in
writing by the Contractor and the State. The contract modification will be
incorporated as a written amendment to this Contract. Memoranda of understanding
and correspondence shall not be construed as amendments to this Contract.
1.4 CONTRACT APPROVAL
In Maine, authority to approve contracts on behalf of the State is vested in the
initiating department, the State Contract Review Committee and the Attorney
General. The Contractor shall sign this Contract which shall then be forwarded
for approval and signature by all appropriate officials in the Maine State
government and approval by the federal funding agencies. Whenever the State is
required by terms of this Contract to provide written notice to the Contractor,
such notice must be signed by the State's Contract Administrator or Project
Manager, as appropriate under the applicable provisions of this Contract.
1.5 UPDATED DETAILED PROJECT PLAN
Within thirty (30) days of execution of this Contract, the State and the
Contractor shall prepare an Updated Detailed Project Plan which shall detail due
dates for each of the contract deliverables. The Updated Project Plan shall be
incorporated into this Contract and made a part thereof. All deliverables
approved by the Department shall be considered part of this Contract. In the
event any disagreement arises as to any term or provision to be included in the
Updated Project Plan, the State's Project Manager shall determine such term or
provision, subject to the dispute resolution procedures set forth in Section 9,
Disputes.
1.6 BEGINNING OF WORK
The Contractor must not commence any billable work until this Contract has been
fully executed by the parties and has been approved by the U.S. Administration
for Children and Families. Subsequent to federal approval, the Project Manager
will notify the Contractor in writing that work may commence.
1.7 CONTRACT PRICE
This is a fixed price.contract to provide the personal services, together with
supporting materials, as specified in Rider B for the amount of $6,265,738.00.
1.8 INVOICES AND PAYMENTS
Payment shall be made by the Department within 45 days after receipt
of an approved itemized invoice submitted by the Contractor upon its usual
billing forms or business letterhead.
1.9 BENEFITS AND DEDUCTIONS
The Contractor understands and agrees that at all times during the term of this
Contract it shall be acting in its capacity as an Independent Contractor for
whom no Federal or State Income Tax will be deducted by the Department, and for
whom no retirement benefits, survivor benefit insurance, group life insurance,
vacation and sick leave, and similar benefits available to State employees will
accrue. The Contractor further understands that annual information returns as
required by the Internal Revenue Code or State of Maine income tax law will be
filed by the State Controller with the Internal Revenue Service and the State of
Maine Bureau of Taxation, copies of which will be furnished to the Contractor
for its Income Tax records.
1.10 INDEPENDENT CAPACITY
The parties hereto agree that the Contractor, and any agents and employees of
the Contractor, in the performance of this agreement, shall act in an
independent capacity and not as officers or employees or agents of the State.
1.11 CONTRACT ADMINISTRATOR
All invoices, progress reports, correspondence, notices and related submissions
from the Contractor shall be directed to:
Name: ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇, Esq.
Title: Director, Bureau of Child and Family Services
Maine Department of Human Services
Address: ▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇
▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇-0011
who is designated as the Contract Administrator on behalf of the Department for
this Contract. The Contract Administrator shall be the Department's
representative during the period of this agreement. He or she has authority to
stop the work if necessary to ensure its proper execution. He or she shall
certify to the Department when payments under this Contract are due and the
amounts to be paid.
1.12 PROJECT MANAGER
The Contract Administrator may designate, in writing, a person or persons with
delegated authority to act on the Contract Administrator's behalf (the "Project
Manager"), and the Contractor may rely upon such designation until given notice
of its revocation; provided, however, that in no event shall any such
designation be effective to allow the Project Manager, without the approval of
the Contract Administrator, to (i) authorize the payment of invoices; (ii)
consent to any amendment or modification of this Contract, except as provided in
Section 8, Changes in Scope; or (iii) terminate this Contract.
1.13 SUBLETTING, ASSIGNMENT OR TRANSFER
The Contractor shall not sublet, sell, transfer or assign or otherwise dispose
of this Contract or any portion thereof, or of its right, title or interest
therein, without written request to and written consent of the Contract
Administrator, except to a bank. No subcontracts or transfer of this Contract
shall in any case release the Contractor of its liability under this Contract.
1.14 EQUAL EMPLOYMENT OPPORTUNITY ASSURANCES
During the performance of this Contract, Contractor agrees as follows:
1.14.1 NON-DISCRIMINATION IN EMPLOYMENT ASSURANCES
The Contractor will not discriminate against any employee or applicant for
employment relating to this Contract because of race, color, religious creed,
sex, sexual orientation, national origin, ancestry, age, or physical handicap,
unless related to a bona-fide occupational qualification. Contractor will take
affirmative action to ensure that applicants are employed and employees are
treated during employment, without regard to their race, color, religious creed,
sex, sexual orientation, national origin, ancestry, age or physical handicap.
Such action shall include, but not be limited to the following: employment,
upgrading, demotions, or transfers; recruitment or recruitment advertising;
layoffs or terminations; rates of pay or other forms of compensation; and
selection for training including apprenticeship. Contractor agrees to post in
conspicuous places available to employees and applicants for employment notices
setting forth the provisions of this non-discrimination clause.
1.14.2 NON-DISCRIMINATION IN ADVERTISING ASSURANCES
Contractor will, in all solicitations or advertising for employees placed by or
on behalf of Contractor relating to this Contract, state that all qualified
applicants will receive consideration for employment without regard to race,
color, religious creed, sex, sexual orientation, national origin, ancestry, age,
or physical handicap.
1.14.3 LABOR UNION ASSURANCES
Contractor will send to each labor union or representative of the workers with
which Contractor has a collective bargaining agreement, or other contract or
understanding, whereby Contractor is furnished with labor for the performance of
this Contract, a notice, to be provided by the contracting department or agency,
advising the said labor union or workers' representative of Contractor's
commitment under this section and shall post copies of the notice in conspicuous
places available to employees and the applicants for employment.
1.14.4 SUBCONTRACTOR ASSURANCES
Contractor will cause the foregoing provisions to be inserted in any
subcontracts for any work covered by this Contract so that such provisions shall
be binding upon each subcontractor, provided that the foregoing provisions shall
not apply to contracts or subcontracts for standard commercial supplies or raw
materials. The Contractor, or any subcontractor holding a contract directly
under
the Contractor, shall, to the maximum feasible extent, list all suitable
employment openings with the Maine Employment Security Commission. This
provision shall not apply to employment openings which the Contractor, or any
subcontractor holding a contract under the Contractor, proposes to fill from
within its own organization. Listing of such openings with the Employment
Services Division of the Maine Employment Security Commission shall involve only
the normal obligations attached to such listings.
1.14.5 CIVIL RIGHTS ACT AND REHABILITATION ACT ASSURANCES
Compliance with Title VI of Civil Rights Act of 1964 (42 U.S.C. & 2000d et
seq.); section 504 of the Rehabilitation Act of 1973, as amended (29 U.S.C. &
794); and the United States Administration for Children and Families Regulations
found in 45 C.F.R., parts 80 and 84, is required of the Contractor and all
subcontractors.
1.15 EMPLOYMENT AND PERSONNEL
The Contractor shall not engage on a full-time, part-time or other basis during
the term of this Contract any professional or technical personnel who are or
have been at any time during the term of this Contract in the employ of any
State Department or Agency, except regularly retired employees, without the
written consent of the public employer of such person. Further, the Contractor
shall not engage on this project on a full-time, part-time or other basis during
the term of this Contract any retired employee of the Department who has not
been retired for at least one year, without the written consent of the Contract
Review Committee.
1.16 STATE EMPLOYEES NOT TO BENEFIT
No individual employed by the State at the time this Contract is executed or any
time thereafter shall be admitted to any share or part of this Contract or to
any benefit that may arise therefrom directly or indirectly due to his or her
employment by or financial interest in the Contractor or any affiliate of the
Contractor.
1.17 WARRANTY
The Contractor warrants that it has not employed or written any company or
person, other than a bona fide employee working solely for the Contractor, to
solicit or secure this Contract, and that it has not paid, or agreed to pay any
company or person, other than a bona fide employee working solely for the
Contractor any fee, commission, percentage, brokerage fee, gifts, or any other
consideration, contingent upon, or resulting from the award for making this
Contract. For breach or violation of this warranty, the Department shall have
the right to annul this Contract without liability or, in its discretion, to
deduct from the contract price or consideration, or otherwise recover the full
amount of such fee, commission, percentage, brokerage fee, gifts, or contingent
fee.
1.18 ACCESS TO RECORDS
The Contractor shall maintain all books, documents, payrolls, papers, accounting
records and other evidence pertaining to costs incurred under this agreement and
to make such materials available at the Contractor's offices at all reasonable
times during the term of this Contract and for three years from the date of the
expiration of this Contract, for inspection by the Department or any authorized
representative of the State of Maine and copies thereof shall be furnished, if
requested.
1.19 GOVERNMENTAL REQUIREMENTS
The Contractor warrants and represents that all governmental ordinances, laws
and regulations shall be complied with, subject to the provisions of Section
8.5, Change Orders Within Scope.
1.20 INTERPRETATION AND PERFORMANCE
1.20.1 GOVERNING LAW
This agreement shall be governed by the laws of the State of Maine as to
interpretation and performance.
1.20.2 SEVERABILITY
Whenever possible, each provision of this Contract shall be interpreted in such
a manner as to be effective and valid under applicable law, but if any provision
of this Contract or the application thereof to any person(s) or circumstances
shall be deemed to be prohibited or invalid under such applicable law, such
provision shall be ineffective only to the extent of such prohibition or
invalidity, and such prohibition or invalidity shall not invalidate the
remainder of such provision or the other provisions of this Contract.
1.20.3 RELIANCE ON POLICY DETERMINATIONS
The State shall determine all program policy. The Contractor may from time to
time request the State to make policy determinations or to issue operating
guidelines required for proper performance of this Contract, and the State's
Project Manager shall respond in writing in a timely manner. The Contractor
shall be entitled to rely upon and act in accordance with such written policy
determinations and operating guidelines, unless subsequently amended, modified
or changed in writing by the Department, and shall incur no liability in doing
so unless the Contractor acts negligently, maliciously, fraudulent, or in bad
faith. Nothing contained in this Contract or in any agreement, determination,
operating guideline, or other communication from the Department shall relieve
the Contractor of its obligation to keep itself informed of applicable State and
federal laws, regulations, policies, procedures and guidelines, and, subject to
the provisions of Section 8.5, Change Orders Within Scope, to be in complete
compliance and conformity therewith.
1.20.4 TITLES NOT CONTROLLING
Titles of paragraphs used herein are for the purpose of facilitating ease of
reference only and shall not be construed to imply a contractual construction of
language.
1.20.5 GENDER AND NUMBER
The use of the masculine, feminine, or neuter gender, or of the singular or
plural number, from time to time herein shall not be so construed as to require
a particular implication therefrom, and any such gender or number may be implied
as the context may require.
1.20.6 NO RULE OF CONSTRUCTION
The parties acknowledge that this Contract was initially prepared by the State
solely as a convenience and that all parties hereto, and their counsel, have
read and fully negotiated all the language used in this Contract. The parties
acknowledge that, because all parties and their counsel participated in
negotiating and drafting this Contract, no rule of construction shall apply to
this Contract that construes ambiguous or unclear language in favor of or
against any party because such party drafted this Contract.
1.21 STATE HELD HARMLESS
The Contractor agrees to indemnify, defend and hold harmless the State, its
officers, agents and employees front any and all claims and losses accruing or
resulting to any and all contractors, subcontractors, material-persons, laborers
and any other person, firm or corporation furnishing or supplying work,
services, materials or supplies in connection with the performance of this
Contract and from any and all claims and losses accruing or resulting to any
person, firm or corporation who may be injured or damaged by the Contractor or
any subcontractor in connection with the performance of this Contract and
against any liability, including costs and expenses for violation of proprietary
rights, copyrights, or rights of privacy, arising out of publication,
translation, reproduction, delivery, performance, use or disposition of any data
furnished under this Contract or based on any libelous or other unlawful matter
contained in such data.
The Contractor further agrees to procure liability insurance, naming the State
as an insured, for the purpose of insuring against potential liabilities of the
Contractor pursuant to this Section 1.21. Said insurance shall be subject to the
approval of the State and shall remain in effect for the full term of this
Contract. Failure to maintain such insurance shall constitute a default,
subject to an applicable remedies set forth in Section 3 of this Rider A.
The State shall give the Contractor prompt written notice of each such claim or
suit and full right and opportunity (subject to the approval of the Attorney
General) to conduct the Contractor's own defense thereof, together with full
information and all reasonable cooperation.
1.22 ENTIRE AGREEMENT
This Contract contains the entire agreement of the parties, and neither party
shall be bound by any statement or representation not contained herein.
1.23 ADVERTISING AWARD
The Contractor shall not refer to awards in commercial advertising in such a
manner as to state or imply that the Contractor or its services are endorsed or
preferred by the State of Maine. News releases pertaining to this project will
not be made without prior approval from the State of Maine.
1.24 NOTICES
After contract award, all notices under this Contract shall be deemed duly
given:
. upon delivery, if delivered by hand against receipt; or
. three (3) business days after posting if sent by registered or certified
mail, return receipt required.
All notices to the State are to be delivered concurrently to the State's
Contract Administrator and Project Manager at the address given in Section 1.11
of this Rider A or to such other address or party as is designated.
All notices to the Contractor are to be delivered to the following address:
▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇
Network Six, Inc.
▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇
▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇
Either party may change its address for notification purposes by giving written
notice of the change and setting forth the new address and an effective date.
2.0 TYPE OF CONTRACT
This Contract is a contact for personal services on the basis of a firm fixed
price for the design, development, implementation and warranty support of
MACWIS.
2.1 TERM OF THE CONTRACT
The term of this Contract shall begin on the first day after this Contract has
been approved by the U.S. Administration for Children and Families and has been
fully executed by the parties, and shall expire twenty four (24) months later,
or at the completion of all specified tasks and delivery of all contracted
products, goods, and services as defined in this Contract including performance
of any warranty and/or maintenance agreements, whichever is the later date,
unless earlier terminated pursuant to the terms of this Contract.
2.2 LIMITATION
This Contract is subject to available budgetary appropriations and shall not
create any obligation on behalf of the Department in excess of such
appropriations. Subject to this limitation, and to the extent possible, the
Contractor shall be paid for work performed prior to termination in accordance
with Sections 3 and 3.1 of this Rider A. In the event that the amount of funds
appropriated is such that the Department must restrict or terminate funding for
this Contract, the Department will provide the Contractor with immediate written
notice of said restriction or termination of funding. The State may, in its sole
discretion, also terminate this Contract upon thirty (30) days notice to the
Contractor as a result of said restriction or termination of funding.
It is understood by the parties that the termination clause regarding non-
appropriation of funds by the Legislature is a requirement of both State law and
the Maine Constitution. Within this requirement, however, the Department
warrants that it will include a request to the Governor for each biennium during
the contract period.
2.3 FISCAL YEAR
For the purposes of this Contract, "state fiscal year" will be defined as the
state fiscal year: July 1 through June 30. "Federal fiscal year" will be
defined as October 1 through September 30.
3.0 TERMINATION OF CONTRACT
Notwithstanding any other provision of this Contract, the performance of work
under this Contract may be terminated by the Department in whole or in part
whenever, for any reason, the Contract Administrator shall determine that such
termination is in the best interest of the Department. Any such termination
shall be effected by delivery to the Contractor of a Notice of Termination
specifying the extent to which performance of the work under this Contract is
terminated and the date on which such termination becomes effective.
In the event of any such termination, the Contractor shall be entitled to
receive just and equitable compensation for all accepted deliverables and
satisfactory authorized work performed as of the termination date, subject to
the terms of this Section 3 of this Rider A. In no event, however, shall the
Contractor be paid for loss of anticipated profit.
Upon delivery to the Contractor of a Notice of Termination, pursuant to section
1.24, Notices, of this Rider A specifying the nature of the termination, the
extent to which performance of work under this Contract is terminated, and the
date upon which such termination becomes effective, the Contractor shall:
(i) stop work under this Contract on the date and to the extent specified
in the Notice of Termination;
(ii) take such action as may be necessary, or as the State's Project
Manager may direct, for the protection and preservation of the
property related to this Contract which is in the possession of the
Contractor and in which the State has or may acquire an interest;
(iii) terminate all orders to the extent that they relate to the performance
of work terminated by the Notice of Termination;
(iv) assign to the State in the manner and to the extent directed by the
State's Project Manager all of the rights, title, and interest of the
Contractor under the orders so terminated, in which case the State
shall have the right, at its discretion, to settle or pay any or all
claims arising out of the terminations of such orders, however,
notwithstanding this provision, the Contractor will not be obligated
to assign any such rights, title or interest in the absence of payment
therefor by the State;
(v) with the approval or ratification of the State's Project Manager,
settle all outstanding
liabilities and all claims, arising out of such termination of orders,
the cost of which would be reimbursable in whole or in part, in
accordance with the provision of this Contract;
(vi) transfer title to the State (to the extent that title has not already
been transferred) and deliver in the manner, at the times, and to the
extent directed by the State's Project Manager all files, processing
systems, data manuals, or other documentation, in any form, that
relate to all the work completed or in progress prior to the Notice of
Termination; and
(vii) complete the performance of such part of the work as shall not have
been terminated by the Notice of Termination.
The Contractor shall proceed immediately with the performance of the above
obligations notwithstanding any delay in determining or adjusting the amount of
any item of reimbursable price under this clause.
In any event, this Contract shall terminate at the time specified in Section 2.1
of this Rider A.
3.1 TERMINATION CLAIMS
Pursuant to Section 3, Termination of Contract, the State shall determine, on
the basis of information available, including information provided by the
Contractor, the amount, if any, due to the Contractor by reason of the
termination and shall thereupon pay to the Contractor the amount so determined.
Acceptance of said payment shall not constitute a waiver by the Contractor of
the right to dispute the State's determination of the amount due, pursuant to
the dispute resolution mechanism contained in Section 9 of this Rider A.
3.2 DEFAULT BY CONTRACTOR
If the Contractor fails to fulfill in a timely and proper manner its obligations
under this Contract, or if the Contractor shall violate any of the material
terms of this Contract, the State shall have the right, after the expiration of
any applicable notice and cure period(s), to terminate this Contract, said
termination to be effective upon the date notice of termination is given, and
the State may thereafter withhold payment of any amount in excess of fair
compensation for the work actually completed by the Contractor prior to
termination of this Contract and will be entitled to pursue all of its other
available legal remedies against the Contractor.
Notwithstanding the above, the Contractor shall not be relieved of liability to
the State for damages sustained by virtue of any breach of this Contract by the
Contractor. In addition to any other liabilities provided for in this Contract,
such Contractor liability may include, but is not limited to, all incidental and
consequential damages arising or resulting from any breach of this Contract.
The State may, by written notice of default to the Contractor, provide that the
Contractor may cure a failure or breach of this Contract within a period of
thirty (30) days (or such longer period as the State's Contract Administrator or
Project Manager may authorize in writing), said period to commence upon receipt
of the notice of default specifying such failure or breach. The State's
exercise of this provision allowing the Contractor time to cure a failure or
breach of this Contract does not constitute a waiver of the State's right to
terminate this Contract, without providing a cure period, for any other failure
or breach of this Contract.
3.3 ASSURANCES BEFORE BREACH
If documentation or any other deliverables due under this Contract are not to
the satisfaction of the Project Manager, the Contractor is to be prepared to
deliver additional Contractor resources to the project in order to complete the
deliverable to the satisfaction of DHS and to demonstrate that other project
schedules will not be affected. Upon written notice by the State's Project
Manager of the State's concerns regarding the quality or timeliness of an
upcoming deliverable, the Contractor shall, within five (5) business days of
receipt of said notice, submit a corrective action plan
documenting the Contractor's approach to completing the deliverable to the
satisfaction of the State's Project Manager without affecting other project
schedules. At his or her sole discretion, the State's Project Manager, within
five (5) business days of receipt of the corrective action plan, shall either
approve the plan, reject the plan, or return the plan to the Contractor with
specific instructions as to how the plan can be modified to merit approval and a
specific time period in which the revised plan must be resubmitted. Said
determination, approving, rejecting or returning the plan, shall not be subject
to the dispute resolution mechanism set forth in Section 9 of this Rider A.
Failure to submit, within the time period set forth herein, a corrective action
plan that is approved by the State's Project
Manager, or failure to comply with such an approved plan, shall constitute a
material breach of this Contract, and is subject to the provisions of
termination as specified in section 3.2, Default by Contractor.
3.4 STATE OPTIONS AT TERMINATION
In the event the State terminates this Contract pursuant to section 3,
Termination of Contract, the State may at its option:
(i) retain all or a portion of such hardware, equipment, software, and
documentation as has been provided, obtaining clear title to the same,
and procure upon such terms and in such manner as the State's Project
Manager may deem appropriate, hardware, equipment, software, and
documentation, or services as are necessary to complete the project;
or
(ii) to the extent that the termination is pursuant to Section 3.2 of this
Rider A, return, as is, all or a portion of hardware, equipment,
software, and documentation to Contractor at Contractor's expense in
which instance the Contractor must remit all moneys previously paid by
the State within five (5) business days of receipt of such hardware,
equipment, software, and documentation.
Notwithstanding the above, nothing herein shall limit the right of the State to
pursue any other legal remedies against the Contractor.
4.0 CONTRACTOR FREEDOM FROM LIABILITY (FORCE MAJEURE)
The Contractor shall not be liable for any damages if the failure to perform
this Contract arises out of causes beyond the control and without the fault or
negligence of the Contractor. Such causes may include, but are not restricted
to, acts of God, acts of the State of Maine solely in its sovereign or
contractual capacity, fires, floods, epidemics, quarantine restrictions,
strikes, freight embargoes, and unusually severe weather; but in every case the
failure to perform must be beyond the control and without the fault or
negligence of either the Contractor or is subcontractor(s). When such a cause
arises, the Contractor shall notify the State of Maine immediately in writing of
its failure to perform, describing the cause of failure and how it affects
performance, and the anticipated duration of the inability to perform. The
State of Maine shall review the information provided and may, at its option,
terminate this Contract.
5.0 LIQUIDATED DAMAGES FAILURE TO MEET PERFORMANCE STANDARDS
The Contractor agrees that time is of the essence in the performance of this
Contract. The State and the Contractor agree that in the event of a failure to
meet the milestones and project deliverable dates or any standard of performance
within the time set forth in the Contractor's Project Workplan contained within
the Contractor's proposal included in this Contract, damage shall be sustained
by the State and that it may be impractical and extremely difficult to ascertain
and determine the actual damages which the State will sustain by reason of such
failure. It is therefore agreed that the State, at its sole option, and subject
to the provisions of Section 3.2 of this Rider A, may require the Contractor to
pay liquidated damages for such failures according to the following Sections 5.1
through 5.5 and with the following provisions:
(i) Where the failure is the sole and exclusive fault of the State, no
liquidated damages shall be imposed.
(ii) Where responsibility for the failure is shared by the State and the
Contractor, one-half of the liquidated damages stated in the
appropriate subsection below shall be imposed.
(iii) Where the failure is the sole and exclusive fault of the Contractor,
the full amount of the liquidated damages stated in the appropriate
subsection below shall be imposed.
The imposition of liquidated damages shall not limit the State's right to pursue
any other remedies available to it, including but not limited to the right to
seek damages pursuant to Section 3.2 of this Rider A.
For any failure by the Contractor to meet any performance standard, milestone or
project deliverable date that is not specifically outlined below, the State of
Maine may require the Contractor to pay liquidated damages in the amount of five
hundred dollars ($500) (subject to the provisions of shared responsibility
stated above) per business day per deliverable, milestone, or performance
standard for each and every business day thereafter (not to exceed 180 business
days) until such deliverable, milestone, or performance standard is completed
and accepted by the State of Maine. The State at its option may begin default
proceedings at any point during this period.
Written notification of failure to meet a performance requirement shall be given
by the State's Project Manager to the Contractor. The Contractor shall have
five (5) business days or other mutually agreed period from the date of receipt
of written notification of a failure to perform the specifications to cure the
failure set forth in the written notification. If the failure is not resolved
within this period, liquidated damages may be imposed retroactively to the date
of expected delivery.
In the event that liquidated damages have been imposed and retained by the
State, any such damages shall be refunded, provided that the entire system
turnover to the State has been accomplished and approved by the State according
to the original schedule in the Project Workplan contained within the
Contractor's Proposal included in this Contract, as modified by mutually agreed
upon change orders.
5.1 DOCUMENTATION
Requirement: The Contractor is responsible for providing to DHS complete,
accurate, and timely documentation for MACWIS. Such documentation shall be
according to the specifications described in Section 3 of the RFP. The
Contractor shall also be responsible for providing any copies of documentation
required by applicable Federal authorities.
Any changes which occur to the system shall be documented according to the
standards described in Section 3 of the RFP and documentation of those changes
shall be provided to DHS within thirty (30) days of State approval of
implementation of the change.
LIQUIDATED DAMAGES: The Contractor shall pay five hundred dollars ($500) for
each business day (or any part thereof) from the date documentation was due
until the date following its acceptance as to format and completeness of
contents based on State reviews conducted in accordance with RFP requirements or
the latest mutually agreed upon version of the Updated Project Workplan.
5.2 TIMELINESS OF THE PROJECT
REQUIREMENT: The State intends to accomplish this project within the time
frames outlined in Section 3 of the RFP. The Contractor shall finalize and
submit the updated project workplan to DHS for approval within thirty (30) days
of contract signing. The Contractor shall also be required to update and submit
an updated project workplan to DHS on a monthly basis. If, for any reason, the
Contractor is delayed in meeting the approved schedule by neglect of the State
or by any cause beyond the Contractor's control, then the contract schedule may
be extended by change order for such reasonable time as the State may determine.
Any claim for extension of time shall be made in
writing to the Project Manager not more than ten (10) business days after the
Contractor reasonably would have become aware of the delay; otherwise, it shall
be waived.
If the State determines that delays in meeting the approved schedule were caused
by Contractor error or neglect, then the State may assess damages as prescribed
below.
LIQUIDATED DAMAGES: Five hundred dollars ($500) shall be paid by the Contractor
for each business day or any part thereof from the date the approved project
workplan or its monthly update was due until the date it is provided to DHS in
an acceptable form.
For delay in meeting key dates identified in the approved project workplan, five
hundred dollars ($500) shall be paid by the Contractor for each business day, or
part thereof, until the Contractor returns to the approved schedule. Damages
shall be deferred if a change order is approved by the Department.
The Contractor shall pay the full amount of any fiscal penalties imposed by
federal agencies for failure to meet the approved schedule if the Department
determines that Contractor errors or performance are the cause of delay.
5.3 DELIVERABLES AND REPORT PRODUCTION
REQUIREMENT: Unless the number of copies is otherwise specified, five (5)
copies of each deliverable described in Section 3 of the RFP shall be delivered
to the Project Manager in final form on the date specified in the approved
project workplan. All deliverables described in Section 3 of the RFP shall be
delivered in a format approved by DHS and shall meet the minimum requirements.
All MACWIS reports shall be produced in a format approved by DHS during design
and development or as later required because of changes in federal and/or state
reporting requirements specified in Section 3 of the RFP.
All MACWIS reports shall be delivered to locations according to a schedule to be
agreed upon by DHS and the Contractor.
LIQUIDATED DAMAGES: Five hundred dollars ($500) shall be paid by the Contractor
for each business day, per report or per deliverable, that the report or
deliverable is late, includes less than the required copies, or is found
unacceptable by state review teams in meeting the requirements of this Contract.
5.4 PERFORMANCE STANDARD MEASUREMENTS
REQUIREMENT: The Contractor shall provide the necessary equipment and/or
methodology for measuring performance as described in Section 3 of the RFP and
shall certify its accuracy in performing those measurements. Such equipment
and/or methodology is subject to approval by DHS.
Measurements shall be taken on a schedule to be provided by DHS. Additional
measurement periods shall be required, at the option of DHS, on demand and
unannounced.
LIQUIDATED DAMAGES: The Contractor shall be assessed one thousand dollars
($1,000) for each business day or any part thereof for which scheduled or
unannounced measurements are not taken.
5.5 SYSTEMS USER DOCUMENTATION
REQUIREMENT: The Contractor is responsible for providing to DHS complete,
accurate and timely systems user documentation. Such documentation shall be
according to the specification described in Section 3 of the RFP. Five (5)
copies of such documentation shall be provided to DHS in draft form during the
Pilot Test Task. Additional copies of the user documentation (training
materials, trainer guides and user guides) shall be provided by the Contractor
according to the schedule identified in the approved project workplan.
Any changes which occur to the system shall be documented according to the
standards described in Section 3 of the RFP. Documentation of those changes
shall be provided to DHS within thirty (30) days of State approval of
implementation of the change.
LIQUIDATED DAMAGES: The Contractor shall be assessed one thousand dollars
($1,000) for each business day, or any part thereof, from the date documentation
was due following state approval of implementation of the change until the date
it is provided and found to be acceptable as to format and completeness of
contents based an RFP requirements and State reviews.
6.0 FAILURE TO PERFORM
In the event the Contractor has failed to perform any substantial obligation
under this agreement, or has otherwise committed a failure or breach of this
Contract under Section 3.2, Default by Contractor, DHS may withhold all moneys
due and payable to the Contractor, without penalty, until such failure is cured
or otherwise adjudicated.
7.0 CONTRACTOR PERSONNEL
The State will provide office space in Augusta, Maine, for Contractor and
subcontractor staff, the prototype development and testing LAN, and JAD/RAD
sessions. The facilities and furnishings provided by the State are detailed in
Appendix H of the RFP, Contractor Facilities. BCFS requires that all Contractor
staff be located at this site during their participation in the project. To the
extent possible, BCFS prefers that the State's MACWIS staff also be housed in
this facility.
The parties recognize that the primary value of the Contractor to the State
derives directly from the Key Personnel assigned to the project. Therefore, the
parties agree that Key Personnel shall be assigned to the MACWIS project in
accordance with the time frames in the most recent mutually agreed upon project
schedule and work plan, and that no re-deployment or replacement of any Key
Personnel may be made without prior written consent of the State. Replacement
of such personnel, if approved, shall be with personnel of equal or greater
ability and qualifications.
The State shall retain the right to reject any of the Contractors and/or
Subcontractor,s employees whose qualifications, in the State's judgment, do not
meet the standards established by the State as necessary for the performance of
the services. In considering the Contractor's and the Subcontractor's
employee's qualifications, the State will act reasonably and in good faith.
Notwithstanding anything herein to the contrary, and without limitation of any
other remedies herein contained, in the event that any of the Contractor's or
the Subcontractor's Key Personnel as previously defined is/are redeployed or
shall cease to be employed on a full-time basis by the Contractor or the
Subcontractor, the State shall have the option, at its sole discretion, to
declare a default and terminate this Contract pursuant to Section 3.2, unless
the State determines, acting reasonably and in good faith, that the Contractor
has provided replacement personnel with equal or greater ability and
qualifications.
The Contractor may not propose individuals for this project that are employees
of a State agency. Federal regulations prohibit the federal government from
paying twice for any employee. For
example, a person who is an employee of one state could not be employed to work
on a project in a second state and be paid in any way by that state (including
paid leave status) as long as any part of his state compensation is reimbursed
by the federal government.
During the course of this Contract, the State reserves the right to require the
Contractor to reassign or otherwise remove from the project any Contractor or
subcontractor employees found unacceptable by the State. In considering the
Contractor's and subcontractor's 'employee's acceptability, the State shall act
reasonably and in good faith.
8.0 CHANGES IN SCOPE
The State may, at any time by written order, make changes within the general
scope of this Contract. No changes in scope are to be conducted except at the
approval of the State. This section establishes the-only procedures by which the
Contractor may obtain any compensation or reimbursement in excess of the amounts
specifically provided for elsewhere in this Contract for any services rendered
or property delivered or expense incurred in the performance of this Contract.
During the Project Planning and Initiation phase, the State and the Contractor
agree to jointly develop change control management procedures covering Change
Order requests.
8.1 CHANGES IN SCOPE (CIS)
From time to time, the DHS may request modifications to MACWIS not required by
any provision of this Contract. The DHS shall make any such request in writing
signed by the Project Manager and plainly labeled or titled a "Change Order."
The Change Order shall specify whether the requested change is to be implemented
on a certain date, or placed into effect only after approval of the Contractor's
price proposal as described in Section 8.2 below. The Contractor shall not be
penalized for any delays or change in the project schedule resulting from a DHS
initiated Change Order.
8.2 IMPACT OF CIS
The Contractor shall promptly, and in no event more than ten (10) business days
after receipt of such Change Order, furnish to the Project Manager a written
statement whether the change has a price or schedule impact. If there is a
price or schedule impact, the statement shall include a description of the
estimated price increase or decrease involved in implementing the change and any
impact on the schedule. Any statement of price increase shall be accompanied by
substantiation sufficient to show that the estimated increase meets all of the
following criteria:
(i) The charge for Contractor staff is based solely upon the categories
and change order rates identified in the proposal.
(ii) Allowance was made for any increase or decrease in the cost of the
Contractor's performance of the remainder of the contract, as a
result of implementing the Change Order.
(iii) Allowance was made for any economies to the Contractor resulting from
the duplication or overlapping of similar work which has been or will
be performed in any other site.
In the event that the State issues a Change Order and subsequently decides not
to implement the change, the Contractor shall be entitled to compensation for
the time and effort expended by Contractor staff in analysis of the price and
schedule impact of the change. Upon written notification by the State's Project
Manager that the State does not intend to proceed with the change, the
Contractor's Project Manager shall furnish to the State's Project Manager an
invoice detailing the number of hours expended on the analysis of price and
schedule impact, by category of personnel involved and their associated change
order rates as identified in the Contractor's proposal.
8.3 NEGOTIATIONS OF CIS
The parties shall then negotiate and attempt in good faith to agree upon a plan
and schedule for implementation of the Change Order, and the time, manner, and
amount of payment or price increase or decrease or change to schedule consistent
with the criteria in Section 8.2 above.
8.4 FAILURE TO NEGOTIATE CIS
If the parties are unable to reach an agreement under Section 8.3 above, and the
Change Order is intended to implement or address Federal or State law or
regulation or Departmental or Bureau policy, the State's Project Manager may
make a determination of the revised price or schedule, and, upon written
instruction from the Project Manager, the Contractor shall proceed forthwith to
implement the Change Order, subject to the Contractor's right to appeal the
Project Manager's determination of the price or schedule. In the event the
Project Manager fails to make a price or schedule determination and instruct the
Contractor in writing, or the Change Order is not intended to implement or
address Federal or State law or regulation or Departmental or Bureau policy, the
Contractor shall not be obligated to implement the Change Order.
8.5 CHANGE ORDERS WITHIN SCOPE
If in the sole judgment of the State's Project Manager any modification
described in a Change Order is within the scope of this Contract or is otherwise
necessary to achieve compliance with Maine or Federal law or regulation or
Departmental or Bureau policy, and the modification is to the functional
requirements specification and the Requirements Specification Document has not
been approved by the State at the time of the Change Order, or the modification
is to the design specification and the State has not approved the Detailed
Design Document at the time of the Change Order, the State's Project Manager may
so inform the Contractor, in which event the Contractor shall proceed forthwith
to implement the Change Order without initial resort or recourse to the
provisions of Sections 8.2 and 8.3 above. At its option, the Contractor may
also initiate dispute resolution procedures pursuant to Section 9, Disputes.
The procedures established in Sections 8.2 and 8.3 or 8.4, as appropriate, shall
be followed as soon as practicable after the Contractor has begun implementation
of the Change Order. Any Change Orders for functional requirements
specification changes issued after the State's approval of the Requirements
Specification Document, or any Change Orders for design specification changes
issued after the State's approval of the Detailed System Design Document, shall
be considered changes in scope and are subject to Sections 8.0, 8. 1, 8.2 and
8.3.
8.6 EVENTS CONSTITUTING CIS
If the Contractor considers that an Event constitutes a Change Order, but is not
plainly identified, labeled, or titled as such, the Contractor shall so advise
the State's Project Manager in writing within five (5) business days of such
Event, and shall request the Project Manager's written confirmation thereof.
Such notice to the Project Manager shall state the following:
(i) the nature and pertinent circumstances of the communication, act, or
omission regarded as a Change Order;
(ii) the date of the communication, act, or omission, and the identification
of each individual involved in such communication, act, or omission,
listing his or her name and function;
(iii) the identification of any documents involved;
(iv) the substance of any oral communications;
(v) the particular technical requirements or contract requirements regarded
as changed;
(vi) the direct and foreseeable consequential effects of the communication,
act, or omission regarded as a Change Order upon the contracted price,
manner, and sequence of performance, and delivery of supplies or
services, identifying which supplies or services are or will be
affected; and
(vii) the Contractor's best estimate as to the extent to which each such price
and performance schedule element of this Contract should be adjusted.
The State's Project Manager shall respond within ten (10) business days of
receipt of the Contractor's notice as required above:
(i) to countermand the action or communication regarded as an Event;
(ii) to deny that the Event is a Change Order under this Section 8, or to
confirm that the Event is a Change Order by issuance of a written change
notice designated a Change Order; or
(iii) if the information in the Contractor's notice is inadequate to permit a
decision to be made, advise the Contractor as to what additional
information is required and establish the date by which said information
should be furnished.
If the Contractor complies with any order, direction, interpretation or
determination, written or oral, from someone other than the Project Manager
without providing the notice in the manner and within the time specified in this
Section 8.6, then DHS shall not be liable for any increased price, delay in
performance or contract non-conformance by the Contractor.
8.7 FINAL DECISIONS REGARDING CIS
If the State's Project Manager denies that the Event constitutes a basis for an
adjustment in price or performance schedule, the Project Manager shall, within
ten (10) business days of receipt of the Contractor's notice, specifically set
forth in writing the reasons upon which the Project Manager relied in denying
that the Event constituted a basis for an adjustment in the price or performance
schedule. Upon receipt of such notice, the Contractor's Project Manager shall,
within ten (10) business days of receipt of such notice, send the State's
Project Manager written notice of his or her assent to the denial or initiate
dispute resolution procedures pursuant to Section 9, Disputes.
8.8 RESTRICTIONS OF CIS
Except as provided in this Section 8, no order, statement, or conduct of the
Project Manager, the DHS or any agent or representative thereof, shall be
treated as a Change Order under this Section 8, or entitle the Contractor to an
equitable adjustment hereunder, and the Contractor will not be required to
implement the Change Order if the Change Order procedures are not followed by
the State.
The parties will incorporate in the Project Plan a specific period for review
and acceptance of the specifications for each scheduled deliverable. Upon
acceptance of said specifications by the State, the specifications will be
frozen. Any subsequent change request will be considered after acceptance of
the deliverable by the State.
8.9 CLAIMS FOR COMPENSATION FOR CIS
Any claim by the Contractor for adjustment under this Section 8 must be asserted
within thirty (30) days from the date of receipt by the Contractor of a written
Change Order under Section 8.1, a written instruction under Section 8.4 or the
Contractor's furnishing of a written notice or the Project Manager's
acknowledgment of a Change Order under Section 8.6.
8.10 AUTHORITY TO ISSUE CHANGE ORDERS
For the purpose of issuing Change Orders under this Contract, the term "Project
Manager" shall not include any representative of the Project Manager whether or
not such representative is acting within the scope of his or her authority
except only in those instances where the Project Manager is unavailable,
immediate action is required and the Project Manager has notified the Contractor
in writing, citing the authority of this Section 8.10, that a specified
individual has the authority to issue Change Orders, including a description of
the exact scope and duration of the individual's authority.
8.11 MODIFICATIONS WHICH DO NOT CONSTITUTE CIS
In no event shall the correction of any deliverable to obtain its approval, nor
any services required to satisfy conditions on certification, nor performance of
any other work required under this Contract be deemed a modification permitting
or requiring treatment as a Change Order.
8.12 CHANGE RATES FOR CIS
All work for which the Contractor is entitled to any compensation for Contractor
staff in accordance with the provisions of this Section 8 shall be compensated
solely in accordance with the change order rates set forth in the Contractor's
proposal.
9.0 DISPUTES
In the event of any dispute arising during the term of this Contract concerning
performance of this Contract, either party shall serve written notice of such
dispute on the other party, and the dispute shall initially be decided by the
State's Project Manager who shall, within five (5) business days, reduce such
decision to writing and serve a copy on the Contractor. Should the Contractor
be dissatisfied with this decision, the Contractor may, within five (5) business
days of receipt of the decision, submit the dispute to the Interim Dispute
Review Team (IDRT).
The State's Project Manager and the Contractor's Project Manager will forward to
the IDRT whatever materials or information are necessary for consideration of
the dispute. Within five (5) business days, the IDRT shall either: (i) in the
event that the IDRT is in agreement as to how the dispute should be resolved,
issue a joint opinion that shall be binding on both parties; or (ii) in the
event that the IDRT does not reach agreement as to how the dispute should be
resolved, submit the dispute to the State's and Contractor's Dispute Resolution
Authorities.
In the event that the State's and Contractor's Dispute Resolution Authorities
are in agreement as to how the dispute should be resolved, they shall issue a
joint opinion, within five (5) business days, that shall be binding on both
parties. If the State's and Contractor's Dispute Resolution Authorities fail to
issue a joint opinion within the time period specified herein, the parties shall
proceed in accordance with the written decision of the State's Dispute
Resolution Authority.
In the event that the Contractor remains aggrieved, the Contractor may, while
implementing the decision, pursue whatever legal or equitable remedies are
available. Any legal proceedings against the State regarding this Contractor
shall be brought in State of Maine administrative or judicial forums.
In the event of any litigation, appeal, or other legal action to enforce any
provision of this Contract, the Contractor agrees to pay all expenses of such
action, including attorney's fees and costs at all stages of litigation, if the
State is the prevailing party.
10.0 CONFIDENTIALITY OF INFORMATION
All materials and information provided to the Contractor and/or any
subcontractors by the State or acquired by the Contractor and/or any
subcontractors on behalf of the State whether verbal, written, magnetic media,
cards or otherwise shall be regarded as confidential information in accordance
with the provisions of federal and state law and ethical standards, and all
necessary steps shall be taken by the Contractor to safeguard the
confidentiality of such material or information in conformance with federal and
state law and ethical standards.
11.0 PRIME CONTRACTOR RESPONSIBILITIES
The Contractor is solely responsible for fulfillment of this Contract with the
State. The Contractor assumes responsibility for all services offered and
products to be delivered whether or not the Contractor is the manufacturer or
producer of said services. The Contractor will be responsible for the entire
contract performance whether or not subcontractors are used.
The Contractor acknowledges that it was selected by the State due to the
determination that the Contractor's and Subcontractor's Key Personnel assigned
to the project displayed abilities and a proposed level of personal services not
available, to the same degree, from other proponents. Accordingly, no portion
of this Contract or the services required under this Contract may be assigned,
delegated or subcontracted without prior written consent of the State.
11.1 SUBCONTRACTS
Unless provided for in this Contract, no contract shall be made by the
Contractor with any other party for furnishing any of the work or services
herein contracted for without the consent, guidance, and approval of the State.
Any subcontract hereunder entered into, subsequent to the execution of this
Contract, must be approved by the State. This provision will not be taken as
requiring the approval of contracts of employment between the Contractor and
personnel assigned for services thereunder. All references in the Contract to
the Contractor should be construed to encompass both the Contractor and any
subcontractor(s). All subcontract agreements must contain the following
requirements:
(i) all subcontractors must contain the Assurances enumerated in Section
1.14 of this Rider A; and
(ii) all subcontracting agreements must be signed and delivered to the
State's Project Manager within five (5) business days following the
subcontract execution date.
The Contractor shall be wholly responsible for performance of the entire
contract whether or not subcontractors are used. Any subcontract into which the
Contractor enters with respect to performance under this Contract shall not
relieve the Contractor in any way of responsibility for performance of its
duties. Further, the State will consider the Contractor to be the sole point of
contact with regard to contractual matters, including payment of any and all
charges resulting from this Contract. The State shall bear no liability for
paying the claims of any subcontractors, whether or not those claims are valid.
The Contractor shall give the State immediate notice in writing of any legal
action or suit filed, and prompt notice of any claim made against the Contractor
by any subcontractor or vendor which may result in litigation related in any way
to this Contract or which may affect the performance of duties under this
Contract. The requirement of prior approval of any subcontract under this
Contract shall not make the State a party to any subcontract or create any
right, claim or interest in the subcontractor or proposed subcontractor against
the State. The Contractor agrees to defend (subject to the approval of the
Attorney General) and indemnify and hold harmless the State against any claim,
loss, damage, or liability against the State based upon the prior approval
requirements of this Section 11, Prime Contractor Responsibilities. No
subcontract or delegation shall relieve or discharge the Contractor from any
obligations or liability under this Contract.
12.0 OWNERSHIP OF INFORMATION
Al1 notebooks, plans, working papers, or other work produced in the performance
of this Contract are the joint property of the Department and upon request shall
be turned over to the Department. The State and the Federal government shall
have unlimited rights to use, disclose, duplicate, or publish for any purpose
whatsoever all information, and data developed, derived, documented, or
furnished by the Contractor under this Contract. The Contractor shall furnish
such information and data, upon the request of the State, in accordance with
applicable federal and state law.
In accordance with the term of this Contract, the Contractor shall furnish to
the State two types of software: customized software developed by the Contractor
specifically to design, develop, implement, test and administer MACWIS and its
predecessor system ("custom software"); and
commercial, off-the-shelf commodity software developed by the Contractor or
other third parties for generic applications ("COTS software").
12.1 CUSTOM SOFTWARE
For custom software furnished by the Contractor, the following terms and
conditions shall apply.
The State and all appropriate federal agencies must receive a royalty-free,
nonexclusive, and irrevocable license to reproduce, publish or otherwise use and
to authorize others to do so, all application software including, but not
limited to, all source, object and executable code, instructions, files, and
documentation composing the statewide MACWIS, its predecessor system, and all
associated custom administrative, maintenance and test software which is
installed as a result of this Contract.
Specifically, the State will be granted
:
(i) all of the rights described above in and to the executable code;
(ii) all of the rights described above in and to all source and object
codes;
(iii) the right to compile the source and create new object / executable
code;
(iv) the right to modify the source code;
(v) the right to duplicate the source, object, and executable codes;
(vi) the right to distribute the source, object, and executable codes
to others; and
(vii) the right to transfer these rights to others.
The license shall include all components of MACWIS, including but not limited to
the following:
(i) all MACWIS application programs in the most current version;
(ii) all system instructions or scripting language for operating MACWIS
in the most current version;
(iii) all data files in the most current versions and prior versions kept
according to operating instructions;
(iv) user and operational manuals and other documentation;
(v) system and program documentation describing the most current version
of MACWIS;
(vi) network configuration and control documentation;
(vii) training programs and material in the operation and maintenance of
the system for DHS
(viii) staff, DHS's agents, or designated representatives;
(ix) any and all performance enhancing operational plans and products
developed for MACWIS; and
(x) all specialized or specially modified operating system software and
specially developed programs, including utilities, software, and
documentation which are required for or used in the operation of
MACWIS, but which may not be considered as being developed or
modified under this Contract.
A fundamental obligation of the Contractor is the delivery to DHS of a non-
exclusive license to all rights to the complete system, including any and all
performance-enhancing software and operational plans whether developed under
this Contract or before it. This obligation to provide a license to all rights
on the part of the Contractor is not subject to limitation in any respect.
The State will be granted unlimited non-exclusive rights in and to all
application software, documentation and plans associated with this project.
These rights reserve the license to reproduce, publish or otherwise use such
application software, documentation, and plans and to authorize their use by
others.
In addition to the license rights described above, the Contractor agrees to
furnish the State with any and all additional rights in and to the MACWIS system
which may be required by federal law or regulation.
The Contractor agrees to furnish to the State a copy of all documentation
created at any time during the period of this Contract and for this Contract,
brought up-to-date as of the date of delivery. Licenses for any application
software and/or documentation will convey upon DHS's approval of
deliverables and payment to the Contractor for the deliverables within the task,
less retainage.
When the State shall come into possession of the application software,
documentation, and plans
developed for this Contract in accordance with this Contract, the State shall
thereafter have the absolute right to modify them for any function which the
State deems desirable.
In addition, if the Contractor purchases any software products as a part of this
agreement, that software will become the property of the State at the completion
of the project without further costs being incurred.
12.2 COTS SOFTWARE
For COTS software furnished by the Contractor, the following terms and
conditions shall apply.
The contractor grants to the State a personal, non-exclusive and nontransferable
license to use COTS software and related documentation according to the terms
and conditions of this Agreement, solely for the State's internal data
processing requirements on the CPU in the United States on which COTS software
is initially installed. The State's use of COTS software will also be governed
by any additional conditions which the Contractor may provide on or prior to
delivery of COTS software. The State agrees that the Contractor may, at its own
expense, periodically inspect the computer site in order to audit COTS software
supplied by the Contractor installed at the State's site at mutually agreed upon
times. In the event that a separate license agreement accompanies non-
Contractor commodity COTS software, then the separate license agreement terms
supercede the above license grant for that COTS software.
The State may develop application programs, may modify any Contractor
application COTS software and may combine such with other programs or materials
to form an updated work, provided that upon discontinuance or termination of the
license, the Contractor application COTS software will be removed from the
updated work and returned to the Contractor.
The State will not decompile or disassemble any COTS software provided under
this Agreement or modify COTS software which bears a copyright notice of any
third party. The State will make and maintain no more than one archival copy
(for backup purpose) of each item of COTS software, and each copy will contain
all legends and notices and will be subject to the same conditions and
restrictions as the original.
If the CPU on which any item of COTS software is licensed becomes temporarily
unavailable, use of such COTS software may be temporarily transferred to an
alternative CPU until the original CPU becomes available.
No license is granted to the State to use any Contractor proprietary operating
system COTS software to assess, test or develop any hardware products or COTS
software programs that will be marketed by the State or others for compensation.
This license does not apply to MS/DOS, UNIX and CTOS/BTOS operating systems or
the development of application programs. Application programs mean programs for
performing specific automatic data processing tasks such as payroll,
inventory control, information retrieval, or repetitive arithmetic operations,
but excludes programs such as environmental programs, handlers, operating
systems, and data base management programs.
If the State desires to: (a) use COTS software in a service bureau mode, (b)
use COTS software at another location, (c) use COTS software as restricted in
the preceding paragraph, or (d) transfer operational use of the COTS software to
a third party; then the State shall request prior permission in writing from the
Contractor. The Contractor will then advise the State whether, and under what
terms and conditions, the Contractor will license the COTS software as
requested. All restrictions applicable to the State will also apply to any
permitted service bureau or third party users.
This Agreement does not transfer to the State title to any intellectual property
contained in any COTS software, documentation or Proprietary Information.
No party shall be entitled to use any COTS software unless the party has a valid
written license to use such COTS software and all applicable charges for the use
of such COTS software have been paid.
13.0 LIABILITY
In addition to any other liabilities provided for in this Contract, the
Contractor's liability may include, but is not limited to, all incidential and
consequential damages arising from or resulting from any breach of this
Contract, including breach of any express or implied warranties.
In no event shall the State be liable to the Contractor for any incidental or
consequential damages arising from or resulting from either the performance of
this Contract, or the termination of this Contract.
14.0 WAIVER
This contract may be modified only by written amendment executed by all parties
hereto, and approved by the appropriate State officials and federal agencies,
with the exception of terms outlined in Section 8, Changes in Scope. Waiver of
any breach of any term or condition of this Contract shall not be deemed a
waiver of any prior or subsequent breach.
15.0 WARRANTY
The Contractor shall be required to expressly warrant deliverables as being
correct and compliant with the terms of this Contract. The Contractor hereby
warrants that all application software shall:
(i) operate as described in the Contractor's Proposal and as detailed in
the RFP;
(ii) operate and conform to the detailed system specifications described in
the Contractor's most recent General and Detailed System Design
documents, which must be approved by the State in accordance with the
criteria set forth in the RFP or the latest mutually agreed version of
the project plan; and
(iii) conform to standards of this Contract and those generally observed in
the industry.
This warranty encompasses correction of defective deliverables and revision of
the same as necessary, including deficiencies found during testing,
implementation, or post-implementation for a period of one year. At the
direction of the State, the Contractor must immediately work to correct any
deviations from specifications and all software related and performance
deficiencies of MACWIS and must completely correct such deficiencies within five
(5) days (or longer with written notification from the State's Project Manager).
This may require emergency maintenance to correct code problems on a 24-hour,
seven days a week basis. The State shall only invoke its right to require
emergency maintenance in the event that the defect is material and impairs the
operation of the system.
The Contractor will also be responsible for correcting and/or updating any
documentation affected by any operations support performed under this warranty
provision.
Contractor shall correct deficiencies in the deliverables on a timely basis as
requested by the State and replace incorrect or defective deliverables within
one week of notification by the State of such deficiencies, or such longer
period as may be necessary using all diligence and dispatch as agreed between
the Contractor and the State. If the Contractor fails to repair a deficiency or
defect within the warranty period, the State may, at its option, act to repair
the deficiency, and the Contractor shall be required to reimburse the State for
all costs incurred, provided Contractor was afforded an opportunity to correct
such deficiency or defect, pursuant to Section 3.2, Default by Contractor, and
failed to do so.
Failure of the Contractor to fulfill any written commitment within the scope of
this Contract shall render the Contractor liable for services due to the State
of Maine under the terms of this Contract.
16.0 INSURANCE
On or before beginning performance under this Contract, the Contractor shall
obtain from an insurance company duly authorized to do business in Maine,
insurance as follows.
16.1 MINIMUM INSURANCE
The Contractor shall obtain, pay for, and keep in force the following minimum
insurance and shall furnish a certificate or certificates evidencing that such
insurance is in effect:
(i) disability, ▇▇▇▇▇▇▇'▇ compensation, and unemployment compensation in
accordance with the statutory requirements of the state where the work
is performed;
(ii) general liability insurance (including automobile and broad form
contractual coverage) against bodily injury or death of any person in
the amount of one million dollars ($1,000,000) for any one occurrence;
and
(iii) insurance against liability for property damages as well as first-party
fire insurance, including contents coverage for all records maintained
pursuant to this Contract, in the amount of one million dollars
($1,000,000).
16.2 CERTIFICATES
The Contractor shall furnish to the State a certificate(s) evidencing that
required insurance is in effect, for the policy amounts, and applicable policy
numbers and expiration dates, within ten (10) business days of contract signing.
In the event of cancellation of any insurance coverage, the Contractor shall
immediately notify the State of such cancellation. The Contractor will be
required to obtain suitable replacement coverage within fourteen (14) days of
the cancellation. The State, at its option, may impose a stop work order on the
Contract until such replacement coverage is secured and approved by the State.
If a stop work order is imposed, the State shall not be liable for any costs or
lost profits incurred by the Contractor.
16.3 NOTICE OF CHANGE
The Contractor shall provide the State with written notice at least ten (IO)
business days prior to any change in the insurance coverage obtained to comply
with this section.
16.4 LIABILITY NOT LIMITED
The provisions of this clause shall not be deemed to limit the liability or
responsibility of the Contractor or any of its subcontractors hereunder.
16.5 INSURANCE OF ASSUMED CONTRACTUAL RISK
The Contractor may insure any portion of the risk assumed under the provisions
of this Contract based upon the Contractor's ability (size and financial
reserves included) to survive a series of adverse experiences, including
withholding of payment by the State, or imposition of penalties by DHS. Express
prior written approval of the Contract Administrator is required for any
proposed program of self-insurance.
17.0 PAYMENT
The State and Contractor have identified certain deliverables on which payment
will be based. Payment deliverables are those that represent the completion of
major phases of the project. The MACWIS project payment deliverables are
detailed in Cost Table 7 of the Contractor's Cost Proposal submitted in response
to the RFP.
Payment deliverables are predicated upon successful completion and written
approval by the State of the described tasks and deliverables. Payments will be
made to the Contractor after written approval of the payment deliverable. The
State will make payments to the Contractor within fortyfive (45) business days
after approval of the invoice by the Contract Administrator.
The amount of the payment will be determined in the following manner.
(i) The allowable payment amount from each payment deliverable will be
multiplied by ten (10) percent, giving the amount that will be withheld
from the payment. The remaining ninety (90) percent of the deliverable
payment will be made after written acceptance of the deliverable by the
State.
(ii) The retained amount from each of the payment deliverables that consist
entirely of COTSsoftware and/or non-custom hardware will be held by the
State until the successful turnover and acceptance of MACWIS by the
State.
(iii) The retained amount from each of the payment deliverables that do not
consist entirely of COTS software and/or non-custom hardware will be
held by the State until the successful conclusion of the warranty
phase; provided, however, that the State shall release the following
amounts to the Contractor prior to the successful conclusion of the
warranty phase:
Three months after acceptance of MACWIS: $114,000
Six months after acceptance of MACWIS: $114,000
End of warranty period: Remaining balance.
17.1 INVOICES
Invoices for payment, submitted on approved State invoice forms, shall be
submitted to the State's Contract Administrator at the address given in Section
1.11 of this Rider A. No invoices will be processed for payment until approved
by the State's Contract Administrator.
17.2 METHOD OF CHARGING
The charges described in this Contract are the only charges now or hereafter to
be levied by the Contractor for the services to be performed by it. There are no
other charges to be made by the Contractor to the State, unless they are
approved in accordance with the provisions of Section 1.2, Contract Defined;
Order of Priority, Section 1.3, Modification, or Section 8, Changes in Scope.
The Contractor shall maintain documentation for all charges against the State
under this Contract. The books, records and documents of the Contractor,
insofar as they relate to work performed or money received under this Contract,
shall be maintained for a period of five full years from the date
of the final payment, and shall be subject to audit at any reasonable time and
upon reasonable notice, by the State, or any appropriate federal agency, or
their duty appointed representatives. The records shall be maintained in
accordance with Generally Accepted Accounting Principles (GAAP).
18.0 INSPECTION AND APPROVAL
Final inspection and approval of all work required under this Contract shall be
performed by the State's Contract Administrator and other officials that the
State of Maine may so designate.
The State of Maine or its authorized representatives shall at all reasonable
times have the right to enter the premises or such other places where duties
under this Contract are being performed, to inspect, monitor or otherwise
evaluate the work being performed. All inspections and evaluations shall be
performed in such a manner that will not unreasonably delay work.
19.0 CONFLICT OF INTEREST
No official or employee of the State and no other public official of the State
of Maine or the federal government who exercises any functions or
responsibilities in the review or approval of the undertaking or carrying out of
the project shall, prior to the completion of the project, voluntarily acquire
any personal interest, direct or indirect, in this Contract.
The Contractor covenants that it presently has no interest and shall not acquire
any interest, direct or indirect, which would conflict in any manner or degree
with the performance of its services hereunder. The Contractor further
covenants that in the performance of this Contract, no person having any such
known interests shall be employed.
20.0 STATE PROPERTY
The Contractor shall be responsible for the proper custody and care of any State
owned property furnished for Contractor's use in connection with the performance
of this Contract, and the Contractor will reimburse the State for its loss or
damage, normal wear and tear excepted.
21.0 FEDERAL INSPECTIONS
During and after this project, the U.S. Administration for Children and Families
or their authorized representatives shall be allowed access to inspect all
Contractor materials, documents, work papers, deliverables, or any such other
items which pertain to this project. The Contractor shall cooperate with any
federal reviews and shall supply copies of any requested materials. This
requirement also applies to any subcontractor(s) who may be engaged in the
project. Any subcontract permitted by the State must contain a provision which
sets forth the subcontractor's agreement with the terms set forth in this
paragraph.
22.0 COPIES OF REPORTS
Upon completion of the project, the Contractor shall convey to the State copies
of all interim reports, cost records, data collection forms, and any other
working papers that support final system approval. These items shall also be
made available, upon request, to officials from the U.S. Administration for
Children and Families and other authorized officials from the federal government
23.0 COPYRIGHT OF DATA
The Contractor may not publish or copyright any data without prior approval,
unless otherwise stated herein; provided, however, that the Contractor may
publish source and object code without obtaining such prior approval. Unless
otherwise stated herein, the State and the federal government shall have the
right to publish, duplicate, use and disclose all such data in any manner, and
for any purpose whatsoever, and may authorize others to do so.
"Data" shall mean all results, technical information and materials developed
and/or obtained in the performance of the services hereunder, including but not
limited to, all reports, surveys, plans, charts, recordings (video and/or
sound), pictures, drawings, analyses, source and object code, graphic
representations, computer programs and printouts, notes and memoranda, and
documents whether finished or unfinished, which result from or are prepared in
connection with the services performed hereunder.
24.0 TRAINING
The Contractor shall provide, in accordance with the specified in this Contract,
quality instruction on all technical and user aspects of the system. The
Contractor shall also develop a post-training proficiency examination. This
examination is to be given to the students immediately upon completion of the
training, and additional training must be provided to the students not
demonstrating competency in the required skills. The Project Manager and
Training Coordinator must provide in advance all training materials including
proficiency examinations that are provided by the Contractor.
25.0 PATENT, COPYRIGHT AND OTHER PROPRIETARY INDEMNIFICATION
The Contractor warrants that all equipment, software, supplies, and other
products provided hereunder and all services do not and will not infringe upon
or violate any patent, copyright, trade secret, or any other proprietary right
of any third party. In the event of any claim by a third party against the
State, the State shall promptly notify the Contractor and the Contractor shall
cooperate in the defense of such claim at the Contractor's expense and shall
indemnify the State against any loss, cost, expense, or liability arising out of
such claim, including reasonable attorney's fees.
26.0 APPLICATION PROGRAM SOURCE
CODEConcurrent with the delivery of the software pursuant to this Contract, the
Contractor shall provide the Project Manager with one copy of the source code
for each custom software application program provided. The Contractor shall
update, improve, add to, and otherwise modify the source code consistent with
any modifications or enhancements made pursuant to this Contract. One hard copy
and one copy on magnetic medium must be provided at no cost to the state within
five (5) business days of the State's request. Up to twenty (20) requests must
be accommodated at no cost to the State. The hard copy requirement for any
request may be waived by written notification by the State's Project
Manager.
27.0 ACCOUNTING REQUIREMENTS
The Contractor shall establish and maintain an accounting system in accordance
with Generally Accepted Accounting Principles (GAAP). The accounting system
shall maintain records pertaining to the tasks defined in this Contract and all
other costs and expenditures made under this Contract
Specific accounting records and procedures are subject to State and federal
approval. Accounting procedures, policies, and records shall be completely open
to state and federal audit at any time during the contract period and for five
yews thereafter.
28.0 AUDIT REQUIREMENTS
The Contractor shall maintain books, records, documents, and other evidence
pertaining to the administrative costs and expenses of this Contract to the
extent and in such detail as shall properly reflect all revenues, all net costs,
direct and apportioned, and other costs and expenses of whatever nature as
relating to performance of contractual duties under the provisions of this
Contract. The Contractor's accounting procedures and practices shall conform to
Generally Accepted Accounting Principles (GAAP) and the costs properly
applicable to this Contract shall be readily ascertainable therefrom.
For work to be performed on an hourly reimbursement rate or cost reimbursement
basis, the allowability of direct and indirect costs shall be governed by 41
C.F.R., Subpart 1-15.
29.0 RECORDS RETENTION REQUIREMENTS
The Contractor hereby to the conditions of 45 C.F.R., Part 74.24 (a), (b), and
(d) regarding retention and access requirements relating to all financial and
programmatic records, supporting documents, statistical records, and other
records of this Contract. In addition, the Contractor shall agree to the
following terms regarding retention of contract records and access for
government officials.Unless the State specifies in writing a shorter period of
time, the Contractor agrees to preserve and make available all other pertinent
books, documents, papers, and records of the Contractor involving transactions
related to this Contract for a period of five years from the date of expiration
or termination of this Contract.Records involving matters in litigation shall be
kept for one year following the termination of litigation, including all appeals
if the litigation has not terminated within five years.
The Contractor hereby agrees that authorized federal and State representatives
shall have access to and the right to examine the items listed above during the
contract period and during the five year post-contract period or until
resolution. During the contract period, the access to these items will be
provided at the Contractor's office in Augusta, Maine at all reasonable times.
During the five year post-contract period, delivery of and access to the listed
items will be at no cost to the State.
The provision of this section shall be incorporated in any subcontract of
$10,000 or more.
30.0 AUDIT LIABILITIES
In addition to, and not in any way in limitation of the obligation of this
Contract, it is understood and agreed by the Contractor that the Contractor
shall be held liable for any State or federal audit exceptions that are the
fault of the Contractor or that arise out of any action, inaction or negligence
by the Contractor. In the event of an audit exception for which the Contractor
is liable as defined in this section, the Contractor shall have thirty (30) days
to remedy the exception. If the Contractor fails to remedy the exception within
this time period, the Contractor shall immediately return to the State all
payments made under this Contract which have been disallowed because of such an
exception.31.0 TAXES The State is not required to pay taxes of any nature;
however, if Contractor is required to pay sales, use, value-added, or other
federal, state, or local taxes based on the licenses or services provided in
this Contract, except taxes based on Contractor's income or property tax for
software, then such taxes shall be billed to and paid by the State upon evidence
of payment by Contractor.
31.0 TAXES
The State is not required to pay taxes of any nature; however, if Contractor is
required to pay sales, use, value-added, or other federal, state, or local taxes
based on the licenses or services provided in this Contract, except taxes based
on Contractor's income or property tax for software, then such taxes shall be
billed to and paid by the State upon evidence of payment by Contractor.
32.0 PRICE PROTECTION
The Contractor hereby warrants and represents that all the prices, terms,
warranties, and benefits granted by the Contractor are comparable to or better
than the equivalent terms being offered by the Contractor to any present
customer meeting the same qualifications or requirements as DHS. Except as
otherwise provided herein, if the Contractor shall, during the term of this
Contract, enter into arrangements with any other said customer providing greater
benefits or more favorable terms for like services, the Contractor shall be
obligated to provide the same to DHS.
33.0 LOBBYING CERTIFICATION
Section 1352 of Title 31 of the U.S. Code requires that funds appropriated to a
Federal agency be subject to a requirement that any Federal Contractor or
grantee (such as the State) certify that no Federal funds will be used to lobby
or influence a federal officer or member of Congress. The certification the
State has been required to sign provides that the language of this certification
shall be included in the award documents for all sub-awards at all tiers
(including subcontracts, subgrants, and contracts under grants, loans, and
cooperative agreements) and that all sub-recipients shall verify and disclose
accordingly, The certification also requires the completion of Federal lobbying
reports and the imposition of a civil penalty of $10,000 to $100,000 for failing
to make a required report. As a sub-recipient, the Contractor understands and
agrees to the Federal requirements for certification and disclosure.
34.0 PRICING AND DISCOUNT
The Contractor warrants that any element of recurring or nonrecurring
cost which must be borne by the State has been identified by Contractor in its
Proposal. This includes, but is not limited to hardware, maintenance, cabling,
system engineering, manuals and documentation, training, demonstration,
consultation, shipping charges, installation costs, testing, and manufactured
supplied programs, and that all items of cost to achieve compliance with the
State's requirements have been shown in the Contractor's Cost Proposal, which is
attached by reference to this Contract.
Federal funding is being used for acquisition of products and/or services, under
this Contract.Consequently, interest cannot be paid under any installment
purchase or lease/purchase agreement entered into as a part of this Contract.
Contractor agrees to convey to the State good title to purchased items free and
clear of all liens, pledges, mortgages, encumbrances or other security interest.
35.0 COVER
If, in the reasonable judgment of the State, a default by the Contractor is not
so substantial as to require termination reasonable efforts to induce the
Contractor to cure the default are unavailing, and the default is capable of
being cured by the State or by another contractor without unduly interfering
with continued performance by the Contractor, the State may provide or procure
the services reasonably necessary to cure the default, in which event the
Contractor shall reimburse the State for the reasonable cost of those services.
36.0 ADDITIONAL DEFAULTS
In the event Contractor shall be the subject of an order for relief purusant to
Title 11, United States Code and/or entered by any United States Bankruptcy
Court; or shall make an assignment for the benefit of creditors; or shall apply
for or consent to the appointment of a receiver, trustee, custodian, or similar
officer for him or it or for all or any substantial part of his or its property;
or such receiver, trustee, custodial or similar officer shall be appointed
without the application or consent of the Contractor; or if the Contractor shall
institute (by petition, application, answer, consent, or otherwise) any
bankruptcy, insolvency, reorganization, arrangement, readjustment or debt,
dissolution, liquidation or similar proceeding relating to it under the laws of
any jurisdiction; or any such proceeding shall be instituted (by petition,
application or otherwise) against the Contractor, or where the petition is filed
against the Contractor by creditors and is not dismissed within thirty (30)
days, then, in any such event, the State may terminate this Contract pursuant to
Section 3.2. The Contractor agrees that this Contract is a contract for personal
services pursuant to 11 U.S.C. && 365(c)(1) and (e)(2)(A).
37.0 PERFORMANCE ASSURANCE
A Performance Bond in the amount of twenty-five percent (25%) of the total
amount of this Contract is required by the State to ensure the vendor's faithful
performance to the specifications and conditions of this Contract. The amount of
the bond required by the State shall be reduced over the course of the project
as certain deliverables are accepted and approved by the State according to the
following schedule. Each such reduction shall only be made upon written
confirmation by the State that all associated deliverables, as enumerated below,
have been accepted and approved by the State. Such confirmation shall not be
unreasonably withheld by the State. The bond reduction schedule is as
follows:
Upon the State's acceptance and approval of the following deliverables,
the required performance bond may be reduced from 25% to 20% of the total
project cost:
. all deliverables associated with Task 3, Project Planning and Initiation, as
detailed in Cost Table 7 of the Vendor's Proposal;
. the Training Needs Analysis Questionnaire;
. the Draft Comprehensive Training Plan and Schedule;
. the Prototype Detailed System Design Document;
. the Prototype Design Analysis Report;
. the Prototype User and Technical Manuals;
. the Prototype Development Analysis Report;
. the Prototype Detailed Implementation Plan;
. the Prototype Implementation Analysis Report;
. the Prototype Acceptance Test Plan;
. the MACWIS Central Server Hardware, Peripherals, and Software;
. the Prototype, Draft and Final versions of the Requirements
Specification Document;
. the Draft and Final versions of the Detailed Conversion Test Plan;
. the Prototype and Draft versions of the Data Model; and
. the Prototype and Draft versions of the General System Design Document
Upon the State's acceptance and approval of the following deliverables, the
required performancebond may be reduced from 20% to 15% of the total project
cost:
. the Final Data Model;
. the Final General System Design Document;
. the Draft and Final versions of the Detailed System Design Document;
. the Draft and Final versions of the Comparative Analysis Report;
. the Draft and Final versions of the System Development Test Plan;
. the Draft and Final versions of the Conversion Specification Document; and
. the physical implementation of the MACWIS Central Server Hardware,
Peripherals and Software.
Upon the State's acceptance and approval of the following deliverables, the
required performance bond may be reduced from 15% to 10% of the total project
cost:
. MACWIS operational on the Development/Prototype LAN;
. the Draft versions of all System and User Documentation;
. the Draft and Final versions of the Development Test Analysis Report;
. the Draft and Final versions of the Detailed Implementation Plan;
. all deliverables associated with Task 5, System Development, as detailed in
cost Table 7 of the Vendor's Proposal contained in this Contract;
. all deliverables associated with Task 6, System Implementation, as detailed
in Cost Table 7 of the Vendor's Proposal contained in this Contract;
. the Draft and Final versions of the Data Conversion Test Results Report; and
. all Data Conversion Documentation for Users and Software Maintenance.
Should the amount of the required performance bond be reduced according to the
above schedule, then the vendor shall be required to maintain a performance bond
in the amount of ten percent (10%) of the total amount of this Contract. This
bond will only be released upon satisfactory completion of the entire project
plan as set forth in this Contract and the written acceptance by the State of
all deliverables related to this Contract.
The vendor will be required to furnish the bond to the Department of Human
Services. No contract will be executed until the bond is received. The bond will
be procured at the expense of the vendor, naming the Department of Human
Services as the obligee.
The bond shall be forfeited in whole or in part, as appropriate, under the
following circumstances:
. if this Contract is terminated during the Contract life for cause;
. if this Contract is terminated during the contract life for breach of
contract; or
. the vendor becomes insolvent during the term of this Contract.
The Purchasing Division of the Department of Administration and the State
Attorney General reserve the right to require the vendor to substitute an
acceptable performance assurance mechanism in such form as they may require.
RIDER B
SPECIFICATIONS OF THE WORK TO BE PERFORMED
The specifications of the work to be performed pursuant to this Contract
are set forth in the following:
1. The State's Request for Proposal, as amended and supplemented by the
MACWIS Bidders' Conference Questions and Answers dated January 4, 1996, and
the MACWIS Bidders' Conference Additional Questions and Answers dated
February 1, 1996, all of which together constitute the RFP and all of which
are attached hereto as Exhibit A and expressly incorporated by reference
herein; and
2. The Contractor's Proposal submitted in response to the RFP, which
Proposal is attached hereto as Exhibit B and expressly incorporated by
reference herein; subject, however, to the provisions of Rider A, Section
1.2.1, Deviations from the RFP.
CONFIDENTIAL
Cost Table 7 - MACWIS PAYMENT SCHEDULE BY DELIVERABLE
----------------------------------------------------------------------------------------------------------------------------------
Deliver- Deliverable Deliver- GROSS PAYMENT
able able
Number Due Date
------------------------------------------------------------------------------------------------------------------------------------
TASK 1 - PROJECT MANAGEMENT 4/7/97 - 3/31/98
Regular Updates to the Project Plan (Updated
Monthly at a Minimum)
Weekly Status Reports
TOTAL PAYMENT TASK 1
----------------------------------------------------------------------------------------------------------------------------
TASK 2 - QUALITY ASSURANCE 4/14/97 - 2/27/98
--------------------------------------------
Quality Review Meetings
--------------------------------------------
TOTAL PAYMENT TASK 2
----------------------------------------------------------------------------------------------------------------------------
3.. TASK 3 - PROJECT PLANNING & INITIATION 4/7/97 - 5/7/98
----------------------------------------------------------------------------------------------------------------------------
3.1. Establish Augusta Project Office 35,527 267,893
----------------------------------------------------------------------------------------------------------------------------
3.2. Install Develop. Server, Workstations, Develop Prototype LAN 35,530 194,153
----------------------------------------------------------------------------------------------------------------------------
3.3. Install Donor System 35,535 89,745
----------------------------------------------------------------------------------------------------------------------------
3.4. Install Project Management HW/SW 35,535 38,195
----------------------------------------------------------------------------------------------------------------------------
3.5. Project Kick-Off Meeting 35,537 97,076
---------------------------------------------------------------------------------------------------------------------------
3.6.1 First Update to Project Workplan DRAFT 35,548 68,398
----------------------------------------------------------------------------------------------------------------------------
3.6.2 First Update to Project Workplan FINAL 35,557 138,871
----------------------------------------------------------------------------------------------------------------------------
3.7. Project Management Manual 35,548 38,700
----------------------------------------------------------------------------------------------------------------------------
3.8. MACWIS Standards and Procedures Manual 35,550 27,390
----------------------------------------------------------------------------------------------------------------------------
3.9. MACWIS Communications Plan 35,550 48,538
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 3 1,008,959
----------------------------------------------------------------------------------------------------------------------------
----------------------------------------------------------------------------------------------------------------------------
4.. TASK 4 - SYSTEM DESIGN 4/7/97 - 7/28/97
----------------------------------------------------------------------------------------------------------------------------
4.1. Develop Training Needs Analysis Questionnaire 35,541 2,930
----------------------------------------------------------------------------------------------------------------------------
4.2.1 Comprehensive Training Plan and Schedule DRAFT (Final in Task 6) 35,548 11,720
----------------------------------------------------------------------------------------------------------------------------
4.3. Prototype Deliverables Format and Content
----------------------------------------------------------------------------------------------------------------------------
4.3.1 Requirements Specifications Document RSD) 35,541 44,118
----------------------------------------------------------------------------------------------------------------------------
4.3.2 Data Model 35,541 27,731
----------------------------------------------------------------------------------------------------------------------------
4.3.3 General System Design (GSD) 35,548 25,210
----------------------------------------------------------------------------------------------------------------------------
4.3.4 Detailed System Design (DSD) 35,548 6,303
----------------------------------------------------------------------------------------------------------------------------
4.3.5 Design Analysis Report (DesAR) 35,548 12,605
----------------------------------------------------------------------------------------------------------------------------
4.3.6 User and Technical Manuals 35,555 99,273
----------------------------------------------------------------------------------------------------------------------------
4.3.7 Development Analysis Report (DevAR) 35,555 26,473
----------------------------------------------------------------------------------------------------------------------------
4.3.8 Detailed Implementation Plan (DIP) 35,561 18,200
----------------------------------------------------------------------------------------------------------------------------
4.3.9 Implementation Analysis Report (ImpAR) 35,569 1,382
----------------------------------------------------------------------------------------------------------------------------
4.3.10 Acceptance Test Plan (ATP) 35,569 2,763
----------------------------------------------------------------------------------------------------------------------------
4.4. Deliver Central Server, Peripherals, Software 35,576 860,601
----------------------------------------------------------------------------------------------------------------------------
4.5.1 Requirements Specifications Document (RSD) DRAFT 35,576 131,031
----------------------------------------------------------------------------------------------------------------------------
4.5.1 Requirements Specifications Document (RSD) FINAL 35,597 262,062
----------------------------------------------------------------------------------------------------------------------------
4.6.1 Data Model DRAFT 35,569 83,111
----------------------------------------------------------------------------------------------------------------------------
4.6.2 Data Model FINAL 35,590 168,471
----------------------------------------------------------------------------------------------------------------------------
4.7.1 General System Design Document DRAFT 35,569 75,555
----------------------------------------------------------------------------------------------------------------------------
4.7.2 General System Design Document FINAL 35,590 151,338
----------------------------------------------------------------------------------------------------------------------------
4.8.1 Detailed System Design Document DRAFT 35,618 99,880
----------------------------------------------------------------------------------------------------------------------------
4.8.2 Detailed System Design Document FINAL 35,639 199,760
----------------------------------------------------------------------------------------------------------------------------
4.9.1 Comparative Analysis Report DRAFT 35,583 37,778
----------------------------------------------------------------------------------------------------------------------------
4.9.2 Comparative Analysis Report FINAL 35,604 75,669
----------------------------------------------------------------------------------------------------------------------------
4.10.1 System Development Test Plan DRAFT 35,576 18,889
----------------------------------------------------------------------------------------------------------------------------
4.10.2 System Development Test Plan FINAL 35,597 37,834
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 4 2,480,687
----------------------------------------------------------------------------------------------------------------------------
5.. TASK 5 - SYSTEM DEVELOPMENT 6/2/97 - 10/10/97
----------------------------------------------------------------------------------------------------------------------------
5.1. Physical Implementation of MACWIS Central Server HW & DB SW 35,597 89,753
----------------------------------------------------------------------------------------------------------------------------
5.2. Operational MACWIS Developed on Dev./Prototype LAN 35,713 695,641
----------------------------------------------------------------------------------------------------------------------------
5.3.1 System and System User Documentation DRAFT (Final in Task 11) 35,713 37,743
----------------------------------------------------------------------------------------------------------------------------
5.4.1 Development Test Analysis Report DRAFT 35,692 79,339
----------------------------------------------------------------------------------------------------------------------------
5.4.2 Development Test Analysis Report FINAL 35,713 158,917
----------------------------------------------------------------------------------------------------------------------------
5.5.1 Detailed Implementation Plan DRAFT 35,681 54,545
----------------------------------------------------------------------------------------------------------------------------
5.5.2 Detailed Implementation Plan FINAL 35,702 109,255
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENTS TASK 5 1,225,193
----------------------------------------------------------------------------------------------------------------------------
6.. TASK 6 - SYSTEM IMPLEMENTATION 10/13/97 - 11/28/97
----------------------------------------------------------------------------------------------------------------------------
6.1. Initial Load of the MACWIS Database 35,720 82,904
----------------------------------------------------------------------------------------------------------------------------
6.2. Implementation of all MACWIS functionality on Central Server 35,737 113,639
----------------------------------------------------------------------------------------------------------------------------
6.3. Completion of Training for BCFS Trainers 35,737 61,538
---------------------------------------------------------------------------------------------------------------------------------
Deliver- Deliverable
able
Number 10% HOLDBACK NET PAYMENT
--------------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
TASK 1 - PROJECT MANAGEMENT 4/7/97 - 3/31/98 No Payment for these deliverables
Regular Updates to the Project Plan (Updated
Monthly at a Minimum)
Weekly Status Reports
TOTAL PAYMENT TASK 1
--------------------------------------------------------------------------------------------------------------------------------
TASK 2 - QUALITY ASSURANCE 4/14/97 - 2/27/98 No Payment for these deliverables
----------------------------------------------------------------------------------------------------------------------
Quality Review Meetings
----------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 2
--------------------------------------------------------------------------------------------------------------------------------
3.. TASK 3 - PROJECT PLANNING & INITIATION 4/7/97 - 5/7/98
--------------------------------------------------------------------------------------------------------------------------------
3.1. Establish Augusta Project Office 26,789 241,104
--------------------------------------------------------------------------------------------------------------------------------
3.2. Install Develop. Server, Workstations, Develop Prototype LAN 19,415 174,738
--------------------------------------------------------------------------------------------------------------------------------
3.3. Install Donor System 8,975 80,771
--------------------------------------------------------------------------------------------------------------------------------
3.4. Install Project Management HW/SW 3,820 34,376
--------------------------------------------------------------------------------------------------------------------------------
3.5. Project Kick-Off Meeting 9,708 87,368
--------------------------------------------------------------------------------------------------------------------------------
3.6.1 First Update to Project Workplan DRAFT 6,840 61,558
--------------------------------------------------------------------------------------------------------------------------------
3.6.2 First Update to Project Workplan FINAL 13,887 124,984
--------------------------------------------------------------------------------------------------------------------------------
3.7. Project Management Manual 3,870 34,830
--------------------------------------------------------------------------------------------------------------------------------
3.8. MACWIS Standards and Procedures Manual 2,739 24,651
--------------------------------------------------------------------------------------------------------------------------------
3.9. MACWIS Communications Plan 4,854 43,684
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 3 100,897 908,064
--------------------------------------------------------------------------------------------------------------------------------
4.. TASK 4 - SYSTEM DESIGN 4/7/97 - 7/28/97
--------------------------------------------------------------------------------------------------------------------------------
4.1. Develop Training Needs Analysis Questionnaire 293 2,637
--------------------------------------------------------------------------------------------------------------------------------
4.2.1 Comprehensive Training Plan and Schedule DRAFT (Final in Task 6) 1,172 10,548
--------------------------------------------------------------------------------------------------------------------------------
4.3. Prototype Deliverables Format and Content
--------------------------------------------------------------------------------------------------------------------------------
4.3.1 Requirements Specifications Document RSD) 4,412 39,706
--------------------------------------------------------------------------------------------------------------------------------
4.3.2 Data Model 2,773 24,958
--------------------------------------------------------------------------------------------------------------------------------
4.3.3 General System Design (GSD) 2,521 22,689
--------------------------------------------------------------------------------------------------------------------------------
4.3.4 Detailed System Design (DSD) 630 5,673
--------------------------------------------------------------------------------------------------------------------------------
4.3.5 Design Analysis Report (DesAR) 1,261 11,345
--------------------------------------------------------------------------------------------------------------------------------
4.3.6 User and Technical Manuals 9,927 89,346
--------------------------------------------------------------------------------------------------------------------------------
4.3.7 Development Analysis Report (DevAR) 2,647 23,826
--------------------------------------------------------------------------------------------------------------------------------
4.3.8 Detailed Implementation Plan (DIP) 1,820 16,380
--------------------------------------------------------------------------------------------------------------------------------
4.3.9 Implementation Analysis Report (ImpAR) 138 1,244
--------------------------------------------------------------------------------------------------------------------------------
4.3.10 Acceptance Test Plan (ATP) 276 2,487
--------------------------------------------------------------------------------------------------------------------------------
4.4. Deliver Central Server, Peripherals, Software 86,060 774,541
--------------------------------------------------------------------------------------------------------------------------------
4.5.1 Requirements Specifications Document (RSD) DRAFT 13,103 117,928
--------------------------------------------------------------------------------------------------------------------------------
4.5.2 Requirements Specifications Document (RSD) FINAL 26,206 235,856
--------------------------------------------------------------------------------------------------------------------------------
4.6.1 Data Model DRAFT 8,311 74,800
--------------------------------------------------------------------------------------------------------------------------------
4.6.2 Data Model FINAL 16,647 149,824
--------------------------------------------------------------------------------------------------------------------------------
4.7.1 General System Design Document DRAFT 7,556 68,000
--------------------------------------------------------------------------------------------------------------------------------
4.7.2 General System Design Document FINAL 15,134 136,204
--------------------------------------------------------------------------------------------------------------------------------
4.8.1 Detailed System Design Document DRAFT 9,988 89,892
--------------------------------------------------------------------------------------------------------------------------------
4.8.2 Detailed System Design Document FINAL 19,976 179,784
--------------------------------------------------------------------------------------------------------------------------------
4.9.1 Comparative Analysis Report DRAFT 3,778 34,000
--------------------------------------------------------------------------------------------------------------------------------
4.9.2 Comparative Analysis Report FINAL 7,567 68,102
--------------------------------------------------------------------------------------------------------------------------------
4.10.1 System Development Test Plan DRAFT 1,889 17,000
--------------------------------------------------------------------------------------------------------------------------------
4.10.2 System Development Test Plan FINAL 3,783 34,051
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 4 247,868 2,230,821
--------------------------------------------------------------------------------------------------------------------------------
5.. TASK 5 - SYSTEM DEVELOPMENT 6/2/97 - 10/10/97
--------------------------------------------------------------------------------------------------------------------------------
5.1. Physical Implementation of MACWIS Central Server HW & DB SW 8,975 80,778
--------------------------------------------------------------------------------------------------------------------------------
5.2. Operational MACWIS Developed on Dev./Prototype LAN 69,564 626,077
--------------------------------------------------------------------------------------------------------------------------------
5.3.1 System and System User Documentation DRAFT (Final in Task 11) 3,774 33,969
--------------------------------------------------------------------------------------------------------------------------------
5.4.1 Development Test Analysis Report DRAFT 7,934 71,405
--------------------------------------------------------------------------------------------------------------------------------
5.4.2 Development Test Analysis Report FINAL 15,892 143,025
--------------------------------------------------------------------------------------------------------------------------------
5.5.1 Detailed Implementation Plan DRAFT 5,455 49,091
--------------------------------------------------------------------------------------------------------------------------------
5.5.2 Detailed Implementation Plan FINAL 10,926 98,330
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENTS TASK 5 122,520 1,102,675
--------------------------------------------------------------------------------------------------------------------------------
6.. TASK 6 - SYSTEM IMPLEMENTATION 10/13/97 - 11/28/97
--------------------------------------------------------------------------------------------------------------------------------
6.1. Initial Load of the MACWIS Database 8,290 74,614
--------------------------------------------------------------------------------------------------------------------------------
6.2. Implementation of all MACWIS functionality on Central Server 11,364 102,275
--------------------------------------------------------------------------------------------------------------------------------
6.3. Completion of Training for BCFS Trainers 6,154 55,384
--------------------------------------------------------------------------------------------------------------------------------
----------------------------------------------------------------------------------------------------------------------------
Deliver- Deliverable Deliver-
able able GROSS
Number Due Date PAYMENT
----------------------------------------------------------------------------------------------------------------------------
----------------------------------------------------------------------------------------------------------------------------
4.2.2 Comprehensive Training Plan and Schedule FINAL 35,758 39,714
----------------------------------------------------------------------------------------------------------------------------
6.4.1 Implementation Analysis Report DRAFT 35,744 4,141
----------------------------------------------------------------------------------------------------------------------------
6.4.2 Implementation Analysis Report FINAL 35,762 8,295
----------------------------------------------------------------------------------------------------------------------------
6.5.2 Detailed Acceptance Test Plan, Inc. Benchmark Test Cases FINAL 35,762 16,590
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 6 335,104
----------------------------------------------------------------------------------------------------------------------------
7.. TASK 7 - ACCEPTANCE TESTING 11/10/97 - 2/9/98
----------------------------------------------------------------------------------------------------------------------------
7.1. Acceptance Test Team Trained 35,751 94,923
----------------------------------------------------------------------------------------------------------------------------
7.2. Errors Identified During Testing & Retesting Documented & Resolved 35,793 221,192
----------------------------------------------------------------------------------------------------------------------------
7.3.1 Acceptance Test Result Report DRAFT 35,793 31,918
----------------------------------------------------------------------------------------------------------------------------
7.3.2 Acceptance Test Results Report FINAL 35,811 63,932
----------------------------------------------------------------------------------------------------------------------------
7.4.1 Detailed Pilot Test Plan DRAFT 35,751 41,739
----------------------------------------------------------------------------------------------------------------------------
7.4.2 Detailed Pilot Test Plan FINAL 35,772 83,603
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 7 537,307
----------------------------------------------------------------------------------------------------------------------------
8.. TASK 8 - PILOT SITE IMPLEMENTATION 1/5/98 - 2/20/98
----------------------------------------------------------------------------------------------------------------------------
8.1. Full Installation of Operational MACWIS in Selected Pilot Office 35,807 71,500
----------------------------------------------------------------------------------------------------------------------------
8.2. MACWIS Help Desk Procedures Documented 35,807 50,315
----------------------------------------------------------------------------------------------------------------------------
8.3. Errors Identified During Testing & Retesting Documented & Resolved 35,804 55,611
----------------------------------------------------------------------------------------------------------------------------
8.4.1 Pilot Test Analysis Report DRAFT 35,804 13,108
----------------------------------------------------------------------------------------------------------------------------
8.4.2 Pilot Test Analysis Report FINAL 35,825 26,614
----------------------------------------------------------------------------------------------------------------------------
8.4.1 Detailed Statewide Implementation Test Plan DRAFT 35,825 15,873
----------------------------------------------------------------------------------------------------------------------------
8.4.2 Detailed Statewide Implementation Test Plan FINAL 35,846 31,793
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENTS TASK 8 264,814
----------------------------------------------------------------------------------------------------------------------------
9.. TASK 9 - STATEWIDE IMPLEMENTATION 2/9/98 - 3/6/98
----------------------------------------------------------------------------------------------------------------------------
9.1. Full Statewide Implementation of MACWIS Satisfying RFP Requirements 35,853 67,168
----------------------------------------------------------------------------------------------------------------------------
9.2. Benchmark Test Performance Report 35,853 9,872
----------------------------------------------------------------------------------------------------------------------------
9.3.1 Statewide Implementation Analysis Report DRAFT 35,846 2,430
----------------------------------------------------------------------------------------------------------------------------
9.3.2 Statewide Implementation Analysis Report FINAL 35,860 4,867
----------------------------------------------------------------------------------------------------------------------------
9.4.1 System Turnover Plan DRAFT 35,832 27,953
----------------------------------------------------------------------------------------------------------------------------
9.4.2 System Turnover Plan FINAL 35,853 55,906
----------------------------------------------------------------------------------------------------------------------------
10.. TASK 10 - LEGACY DATA CONVERSION 4/7/97 - 2/6/98
----------------------------------------------------------------------------------------------------------------------------
10.1.1 Detailed Conversion Test Plan DRAFT 35,548 2,858
----------------------------------------------------------------------------------------------------------------------------
10.1.2 Detailed Conversion Test Plan FINAL 35,566 5,725
----------------------------------------------------------------------------------------------------------------------------
10.2.1 Conversion Specification Document DRAFT 35,569 8,767
----------------------------------------------------------------------------------------------------------------------------
10.2.2 Conversion Specification Document FINAL 35,587 19,555
----------------------------------------------------------------------------------------------------------------------------
10.3. Conversion Programs 35,701 28,548
----------------------------------------------------------------------------------------------------------------------------
10.4.1 Conversion Test Results Report DRAFT 35,688 3,834
----------------------------------------------------------------------------------------------------------------------------
10.4.2 Conversion Test Results Report FINAL 35,709 7,681
----------------------------------------------------------------------------------------------------------------------------
10.5. Data Conversion - Pilot Office 35,800 19,397
----------------------------------------------------------------------------------------------------------------------------
10.6. Conversion Documentation for Users and Software Maintenance 35,713 3,730
----------------------------------------------------------------------------------------------------------------------------
10.7. Data Conversion - Central and Regional Offices 35,832 30,540
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 10 130,635
----------------------------------------------------------------------------------------------------------------------------
11.. TASK 11 - OPERATIONS SUPPORT/WARRANTY 3/1/98 - 2/26/99
----------------------------------------------------------------------------------------------------------------------------
11.1. Completion of Training or State MIS Operations Staff 35,881 27,535
----------------------------------------------------------------------------------------------------------------------------
5.3.2 System and System User Documentation FINAL 35,881 11,563
----------------------------------------------------------------------------------------------------------------------------
11.2. Successful Turnover of MACWIS to State Technical Personnel 35,881 23,951
----------------------------------------------------------------------------------------------------------------------------
Release of Equipment Holdback to Unisys 35,886
----------------------------------------------------------------------------------------------------------------------------
11.3.1 System Turnover Results Report DRAFT 35,895 1,495
----------------------------------------------------------------------------------------------------------------------------
11.3.2 System Turnover Results Report FINAL 35,909 2,995
----------------------------------------------------------------------------------------------------------------------------
11.4. Warranty - Month 1 35,885 4,192
----------------------------------------------------------------------------------------------------------------------------
11.5. Warranty - Month 2 35,915 4,192
----------------------------------------------------------------------------------------------------------------------------
11.6. Warranty - Month 3 35,946 4,192
----------------------------------------------------------------------------------------------------------------------------
Release of Holdback to Unisys 35,947
----------------------------------------------------------------------------------------------------------------------------
11.7. Warranty - Month 4 35,976 4,192
----------------------------------------------------------------------------------------------------------------------------
11.8. Warranty - Month 5 36,007 4,192
----------------------------------------------------------------------------------------------------------------------------
11.9. Warranty - Month 6 36,038 4,192
----------------------------------------------------------------------------------------------------------------------------
Release of Holdback to Unisys 36,039
----------------------------------------------------------------------------------------------------------------------------
11.1. Warranty - Month 7 36,068 4,192
----------------------------------------------------------------------------------------------------------------------------
11.11. Warranty - Month 8 36,099 4,192
----------------------------------------------------------------------------------------------------------------------------
11.12. Warranty - Month 9 36,129 4,192
----------------------------------------------------------------------------------------------------------------------------
11.13. Warranty - Month 10 36,160 4,192
----------------------------------------------------------------------------------------------------------------------------
11.14. Warranty - Month 11 36,191 4,192
----------------------------------------------------------------------------------------------------------------------------
11.15. Warranty - Month 12 36,217 4,192
----------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 11 117,843
----------------------------------------------------------------------------------------------------------------------------
Release of Unisys Holdback to Network Six for $100,00 in Task 3 36,220
----------------------------------------------------------------------------------------------------------------------------
Release of Holdback to Network Six 36,220
----------------------------------------------------------------------------------------------------------------------------
Totals 6,268,738
----------------------------------------------------------------------------------------------------------------------------
---------------------------------------------------------------------------------------------------------------------------------
Deliver- Deliverable
able
Number 10% HOLDBACK NET PAYMENT
--------------------------------------------------------------------------------------------------------------------------------
4.2.2 Comprehensive Training Plan and Schedule FINAL 3,971 35,743
--------------------------------------------------------------------------------------------------------------------------------
6.4.1 Implementation Analysis Report DRAFT 414 3,727
--------------------------------------------------------------------------------------------------------------------------------
6.4.2 Implementation Analysis Report FINAL 830 7,466
--------------------------------------------------------------------------------------------------------------------------------
6.5.1 Detailed Acceptance Test Plan, Inc. Benchmark Test Cases DRAFT 828 7,455
--------------------------------------------------------------------------------------------------------------------------------
6.5.2 Detailed Acceptance Test Plan, Inc. Benchmark Test Cases FINAL 1,659 14,931
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 6 33,510 301,595
--------------------------------------------------------------------------------------------------------------------------------
7.. TASK 7 - ACCEPTANCE TESTING 11/10/97 - 2/9/98
--------------------------------------------------------------------------------------------------------------------------------
7.1. Acceptance Test Team Trained 9,492 85,431
--------------------------------------------------------------------------------------------------------------------------------
7.2. Errors Identified During Testing & Retesting Documented & Resolved 22,119 199,073
--------------------------------------------------------------------------------------------------------------------------------
7.3.1 Acceptance Test Result Report DRAFT 3,192 28,726
--------------------------------------------------------------------------------------------------------------------------------
7.3.2 Acceptance Test Results Report FINAL 6,393 57,539
--------------------------------------------------------------------------------------------------------------------------------
7.4.1 Detailed Pilot Test Plan DRAFT 4,174 37,565
--------------------------------------------------------------------------------------------------------------------------------
7.4.2 Detailed Pilot Test Plan FINAL 8,360 75,243
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 7 53,730 483,577
--------------------------------------------------------------------------------------------------------------------------------
8.. TASK 8 - PILOT SITE IMPLEMENTATION 1/5/98 - 2/20/98
--------------------------------------------------------------------------------------------------------------------------------
8.1. Full Installation of Operational MACWIS in Selected Pilot Office 7,150 64,350
--------------------------------------------------------------------------------------------------------------------------------
8.2. MACWIS Help Desk Procedures Documented 5,032 45,284
--------------------------------------------------------------------------------------------------------------------------------
8.3. Errors Identified During Testing & Retesting Documented & Resolved 5,561 50,050
--------------------------------------------------------------------------------------------------------------------------------
8.4.1 Pilot Test Analysis Report DRAFT 1,311 11,797
--------------------------------------------------------------------------------------------------------------------------------
8.4.2 Pilot Test Analysis Report FINAL 2,661 23,953
--------------------------------------------------------------------------------------------------------------------------------
8.4.1 Detailed Statewide Implementation Test Plan DRAFT 1,587 14,286
--------------------------------------------------------------------------------------------------------------------------------
8.4.2 Detailed Statewide Implementation Test Plan FINAL 3,179 28,614
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENTS TASK 8 26,481 238,334
--------------------------------------------------------------------------------------------------------------------------------
9.. TASK 9 - STATEWIDE IMPLEMENTATION 2/9/98 - 3/6/98
--------------------------------------------------------------------------------------------------------------------------------
9.1. Full Statewide Implementation of MACWIS Satisfying RFP Requirements 6,717 60,451
--------------------------------------------------------------------------------------------------------------------------------
9.2. Benchmark Test Performance Report 987 8,885
--------------------------------------------------------------------------------------------------------------------------------
9.3.1 Statewide Implementation Analysis Report DRAFT 243 2,187
--------------------------------------------------------------------------------------------------------------------------------
9.3.2 Statewide Implementation Analysis Report FINAL 487 4,380
--------------------------------------------------------------------------------------------------------------------------------
9.4.1 System Turnover Plan DRAFT 2,795 25,158
--------------------------------------------------------------------------------------------------------------------------------
9.4.2 System Turnover Plan FINAL 5,591 50,315
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENTS TASK 9 16,820 151,376
--------------------------------------------------------------------------------------------------------------------------------
10.. TASK 10 - LEGACY DATA CONVERSION 4/7/97 - 2/6/98
--------------------------------------------------------------------------------------------------------------------------------
10.1.1 Detailed Conversion Test Plan DRAFT 286 2,572
--------------------------------------------------------------------------------------------------------------------------------
10.1.2 Detailed Conversion Test Plan FINAL 573 5,153
--------------------------------------------------------------------------------------------------------------------------------
10.2.1 Conversion Specification Document DRAFT 877 7,890
--------------------------------------------------------------------------------------------------------------------------------
10.2.2 Conversion Specification Document FINAL 1,958 17,600
--------------------------------------------------------------------------------------------------------------------------------
10.3. Conversion Programs 2,855 25,693
--------------------------------------------------------------------------------------------------------------------------------
10.4.1 Conversion Test Results Report DRAFT 383 3,451
--------------------------------------------------------------------------------------------------------------------------------
10.4.2 Conversion Test Results Report FINAL 768 6,913
--------------------------------------------------------------------------------------------------------------------------------
10.5. Data Conversion - Pilot Office 1,940 17,457
--------------------------------------------------------------------------------------------------------------------------------
10.6. Conversion Documentation for Users and Software Maintenance 273 2,457
--------------------------------------------------------------------------------------------------------------------------------
10.7. Data Conversion - Central and Regional Offices 3,054 27,486
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 10 12,967 116,672
--------------------------------------------------------------------------------------------------------------------------------
11.. TASK 11 - OPERATIONS SUPPORT/WARRANTY 3/1/98 - 2/26/99
--------------------------------------------------------------------------------------------------------------------------------
11.1. Completion of Training or State MIS Operations Staff 2,754 24,782
--------------------------------------------------------------------------------------------------------------------------------
5.3.2 System and System User Documentation FINAL 1,156 10,407
--------------------------------------------------------------------------------------------------------------------------------
11.2. Successful Turnover of MACWIS to State Technical Personnel 2,395 21,556
--------------------------------------------------------------------------------------------------------------------------------
Release of Equipment Holdback to Unisys 97,776
--------------------------------------------------------------------------------------------------------------------------------
11.3.1 System Turnover Results Report DRAFT 150 1,346
--------------------------------------------------------------------------------------------------------------------------------
11.3.2 System Turnover Results Report FINAL 300 2,696
--------------------------------------------------------------------------------------------------------------------------------
11.4. Warranty - Month 1 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.5. Warranty - Month 2 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.6. Warranty - Month 3 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
Release of Holdback to Unisys 114,058
--------------------------------------------------------------------------------------------------------------------------------
11.7. Warranty - Month 4 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.8. Warranty - Month 5 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.9. Warranty - Month 6 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
Release of Holdback to Unisys 114,058
--------------------------------------------------------------------------------------------------------------------------------
11.1. Warranty - Month 7 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.11. Warranty - Month 8 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.12. Warranty - Month 9 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.13. Warranty - Month 10 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.14. Warranty - Month 11 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
11.15. Warranty - Month 12 419 3,773
--------------------------------------------------------------------------------------------------------------------------------
TOTAL PAYMENT TASK 11 11,783 431,955
--------------------------------------------------------------------------------------------------------------------------------
Release of Unisys Holdback to Network Six for $100,00 in Task 3 100,000
--------------------------------------------------------------------------------------------------------------------------------
Release of Holdback to Network Six 200,000
--------------------------------------------------------------------------------------------------------------------------------
626,576 6,265,751
--------------------------------------------------------------------------------------------------------------------------------
--------------------------------------------------------------------------------
Bond No. 6996
ACSTAR
INSURANCE COMPANY
▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ *P.O. BOX 2350 PERFORMANCE
NEW BRITAIN, CT 06050-22350 BOND
(▇▇▇) ▇▇▇-▇▇▇▇
KNOW ALL MEN BY THESE PRESENTS, that We Network Six, Inc. ▇▇▇ ▇▇▇▇▇▇▇
-----------------------------
Street, Warwick, RI 02886, as Principal, and ACSTAR INSURANCE COMPANY, 233 Main
--------------------------
Street, P.O. Box 2350, New Britain, CT 06050-2350, as Surety, are held and
firmly bound unto
State of Maine, Dept. of Human Services, Augusta, ME 04333
As Obligee, hereinafter called the Obligee, in the penal sum of One million five
----------------
hundred sixty six thousand four hundred thirty five and 00/100------------------
-------------------------------------------------------------------------------
Dollars ($1,566,435.00) for which payment well and truly to be made we do bind
-----------------------
ourselves, our heirs, executors, administrators and assigns, firmly by these
presents.
THE CONDITION OF THIS OBLIGATION IS SUCH, that:
WHEREAS, the Principal entered into a certain contract with the Obligee,
dated 2/5/97 for to build an automated child welfare information system for the
------ ---------------------------------------------------------------
State of Maine.
---------------
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
--------------------------------------------------------------------------------
which contract and the specifications therefore shall be deemed a part hereof as
fully as if set out herein.
NOW, THEREFORE, if the said Princial shall well and truly perform all the
work specified in said contract, then this obligation to be void; otherwise to
remain in full force and effect.
The foregoing obligation is subject to the condition that no suit or action
shall be commenced hereunder after the expiration date of one year following the
date on which Principal ceased work on said contract or the date on which final
payment under the contract falls due, or the date on which goods or services
were received by principal, whichever occurs first. The Surety shall have no
obligation to claimants who do not have a direct contract with the Principal.
IN WITNESS WHEREOF, the above bounden parties have executed this instrument
under their several seals this 3rd day of February, 1997 the name and corporate
-------------------------
seal of each corporate party being affixed hereto and these presents duly signed
by its undersigned representatives, pursuant to authority of its governing body.
ATTEST: NETWORK SIX, INC.
------------------------------------
Principal (Seal)
/s/ ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ By: /s/ ▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇
----------------------------------- ------------------------------------
▇▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇
President & CEO
ATTEST: ACSTAR INSURANCE COMPANY
/s/ By: /s/ ▇▇▇▇▇ ▇. ▇▇▇▇▇, ▇▇.
----------------------------------- ------------------------------------
Name ▇▇▇▇▇ ▇. ▇▇▇▇▇, ▇▇.
Title President
--------------------------------------------------------------------------------