EPC Agreement No. 1004 between Monongahela Power Company and Washington Group International covering Balance of Plant for Flue Gas Desulphurization Project at Ft. Martin Units 1 and 2 Principal Document

ARTICLE

TITLE

PAGE

ARTICLE 1 -

AGREEMENT SCOPE

1

ARTICLE 2 -

TERM AND SURVIVORSHIP

1

ARTICLE 3 -

DEFINITIONS

1

ARTICLE 4 -

CONTRATOR’S GENERAL OBLIGATIONS

3

ARTICLE 5 -

COST AND SCHEDULE PERFORMANCE

4

ARTICLE 6 -

WARRANTIES

4

ARTICLE 7 -

PROCUREMENT AND SUBCONTRACTING

6

ARTICLE 8 -

ALLEGHENY

6

ARTICLE 9 -

CHANGE ORDER

8

ARTICLE 10 -

INDEPENDENT CONTRACTOR

9

ARTICLE 11 -

PAYMENT AND INVOICING

9

ARTICLE 12 -

CLAIMS AND LIENS

11

ARTICLE 13

TAXES AND DUTIES

12

ARTICLE 14 -

INSPECTION OF WORK

14

ARTICLE 15 -

DEFICIENT WORK

14

ARTICLE 16 -

SUSPENSION

15

ARTICLE 17 -

TERMINATION

15

ARTICLE 18 -

COMPLETION AND ACCEPTANCE

16

ARTICLE 19 -

TITLE

16

ARTICLE 20 -

DISTRIBUTION OF RISK, RELEASE AND INDEMNITY

16

ARTICLE 21 -

INSURANCE

17

ARTICLE 22 -

TOOLS AND EQUIPMENT

19

ARTICLE 23 -

RESPONSIBILITY FOR CONSEQUENTIAL DAMAGES

19

ARTICLE 24 -

GOVERNING LAW AND DISPUTE RESOLUTION

20

ARTICLE 25 -

OWNERSHIP OF INVENTIONS AND DOCUMENTS

20

ARTICLE 26 -

CONFIDENTIAL INFORMATION

22

ARTICLE 27 -

USE OF TRADEMARK AND PUBLICITY

22

ARTICLE 28 -

AUDIT

23

ARTICLE 29 -

BUSINESS STANDARDS

23

ARTICLE 30 -

NO INFORMATION BROKERING

24

ARTICLE 31 -

MANAGEMENT OF WASTE AND HAZARDOUS MATERIALS

25

ARTICLE 32 -

ASSIGNMENT OF AGREEMENT

25

ARTICLE 33 -

DESIGNATED REPRESENTATIVE AND NOTICES

26

ARTICLE 34 -

ALCOHOL AND DRUGS

26

ARTICLE 35 -

HEALTH AND SAFETY

26

ARTICLE 36 -

RIGHT OF REMOVAL

26

ARTICLE 37 -

FORCE MAJEURE

27

ARTICLE 38 -

AMENDMENTS

27

ARTICLE 39 -

PRECEDENCE

27

ARTICLE 40 -

MISCELLANEOUS

28

ARTICLE 41 -

SURVIVING OBLIGATIONS

28

ARTICLE 42 -

LIMITATION OF LIABILITY

28

ARTICLE 43 -

ENTIRE AGREEMENT

29

EXHIBIT

A

REIMBURSABLE COSTS

B

FIXED RATES

C

FEE

D

CONTRACTOR’S PERSONNEL POLICIES

E

WGI 5 YEAR ACCOUNTING PERIOD CUT-OFF CALENDAR

F

FORM of LETTER OF CREDIT

G

OWNER’S CONTROLLED INSURANCE PROGRAM (OCIP)

H

DISPUTE RESOLUTION PROCEDURE

I

LIST OF KEY WGI PERSONNEL

J

TRUST ACCOUNT AGREEMENT

K

AUDIT DATA FIELD REQUIREMENTS

L

AGREEMENT PRICE BUDGET

M

BONUSES

2.1

TERM. THE TERM OF THIS AGREEMENT BEGINS AND IS EFFECTIVE FROM THE DATE FIRST WRITTEN ABOVE AND SHALL TERMINATE UPON FINAL ACCEPTANCE PURSUANT TO ARTICLE 18, UNLESS TERMINATED EARLIER AS PERMITTED BY THIS AGREEMENT.

2.2

SURVIVORSHIP. THE PROVISIONS OF THIS AGREEMENT AS STIPULATED IN ARTICLE 41 SHALL SURVIVE ANY EXPIRATION OR TERMINATION OF THIS AGREEMENT.

3.1

“Agreement” means Principal Document, Job Specification, and the Exhibits listed in the Table of Contents.

a)

“Principal Document” means this document, executed by Allegheny and Contractor and comprising Articles 1 through 43.

b)

“Job Specification” means the documents issued by Allegheny to Contractor, dated February 23, 2007, which contain the detailed description of the Work, including technical and other requirements pertaining thereto. The Parties agree that the following documents are for information only in the Job Specification and are not part of this Agreement: Design Bases Fort ▇▇▇▇▇▇; Result of Limestone Analysis and Its Reactivity, dated March 2006, prepared by Mitsubishi Heavy Industries, Lts.; Technical Specification for Wet Flue Gas Desulfurization System prepared by ▇▇▇▇▇▇▇ & ▇▇▇▇▇; Continuous Emissions Monitoring Systems Specification; Fort ▇▇▇▇▇▇ Lagoon Water; Geotechnical Investigation; and Fort ▇▇▇▇▇▇ Unit 1 and 2 Mass Balance Diagrams prepared by ▇▇▇▇▇▇▇ & ▇▇▇▇▇▇.

3.2

“Agreement Price” means the total of Costs and Fee relating to compensation as specified in Exhibits A, B &C to be paid by Allegheny to Contractor.

(a)

“Costs” means the sum of Reimbursable Costs and costs resulting from application of Fixed Rates.

(b)

“Reimbursable Costs” means costs set forth in Exhibit A for which Contractor is compensated at actual costs incurred and paid.

(c)

“Fixed Rates” means unit prices listed in Exhibit B.

(d)

“Fee” means the part of Agreement Price as provided in Exhibit C by which Contractor is compensated for: (i) its profit related to the Work; and (ii) expenses not recovered by Contractor in Costs.

3.3

“Agreement Price Budget” means the budget for the Work and Allegheny Acquired Materials prepared by Contractor and approved by Allegheny, which may be modified or adjusted by Change Orders. The Agreement Price Budget, dated January 19, 2007, is attached hereto as Exhibit L.

3.4

“Allegheny Acquired Materials” means those items of equipment and materials purchased under Allegheny purchase order, paid for by Allegheny and received at the Work Site by Allegheny.

3.5

“Change Order” means the document issued by Allegheny, which sets forth adjustments to the Agreement Price Budget and/or the Scheduled Completion Date.

3.6

“Competence” means the expertise, experience, capability and specialized knowledge to perform the Work in a good and workmanlike manner and within all accepted standards for the engineering and construction industry serving the utility industry.

3.7

“Completion Notice” means the document issued by Allegheny upon agreeing that Contractor has substantially met the criteria set forth in the Job Specification for completion of the Work, for each flue gas desulphurization unit and/or the common systems.

3.8

“Consequential Damages” means any loss or anticipated loss of profit, loss or anticipated loss of revenue, business interruption, loss of use of any equipment, loss of any Agreement or other business opportunity and any other indirect damage of a similar nature as further defined in Article 23.

3.9

“Contractor” means: (1) the legal entity identified in the Principal Document and, where the context so permits; (2) any company in which that legal entity now or hereafter (a) owns directly or indirectly or (b) controls, directly or indirectly, more

3.10

“Facility” means the existing power generation facility and all property at Ft. ▇▇▇▇▇▇ in Maidsville, West Virginia.

3.11

“Law” means all applicable laws of the jurisdiction in its broadest sense including without limitation the following: constitutional law, civil law, common law, international law, equity, treaties, statutes, decrees, edicts, codes, orders, rules, ordinances and regulations of any federal, state, local, municipal or any other duly constituted governmental authority or agency.

3.14

“Subcontractor” means any subcontractor, supplier, agent or materialman providing services or work to Contractor for the purpose of performing the Work under this Agreement.

3.15

“Vendor” means any supplier, agent or materialman providing equipment, materials, and/or specialty services to Contractor pursuant to the Work under this Agreement.

3.16

“Work” means the engineering, procurement and construction of the balance of plant work for flue gas desulphurization systems, by Contractor under this Agreement, including providing as necessary therefor supervision, construction work, consultations, any specified materials, labor, construction tools, equipment, and supplies at the Work Site, as well as certain site management of the entire flue gas desulphurization project pursuant to the Job Specification.

3.17

“Work Site” means the site indicated in the Job Specification at the Ft. ▇▇▇▇▇▇ Facility in Maidsville, West Virginia.

4.1

Contractor shall engineer, procure and construct flue gas desulphurization systems and shall perform the Work in accordance with the terms and conditions of this Agreement.

4.2

No documentation, including Contractor’s proposal and bid clarification correspondence, shall constitute a part of this Agreement unless included in Exhibit E - Supplemental Documentation.

4.3

Contractor represents that it knows:

(a)

the nature, requirements and scope of the Work,

(b)

the location and peculiarities of the Work Site,

(c)

the type and magnitude of detailed engineering, procurement, construction and construction management services and labor required,

(d)

the character of equipment, materials and facili­ties required, and

(e)

the general and local conditions and other matters which could affect the Work.

4.4

After entering into this Agreement, Contractor shall commence the Work promptly upon being notified by Allegheny, and shall perform the Work in a professional manner to the satisfaction of Allegheny: (i) with diligence until its obligations pursuant to this Agreement have been completed; and (ii) meeting or exceeding the standards prevailing in the industry pertaining to such Work including standards of the appropriate construction code and revisions thereto applicable to the jurisdiction, where the Work is to be performed, in effect as of the effective date of this Agreement, as well as such other requirements as set forth in this Agreement. Allegheny shall have the right to reject any deficient Work performed by Contractor in accordance with the provisions of Article 15.     

4.5

Contractor shall provide sufficient supervisory and other personnel to perform the Work and Contractor shall continuously furnish such personnel and control the progress of the Work until Contractor’s performance under this Agreement has been completed. Contractor’s project manager and other key personnel as approved by Allegheny and identified in Exhibit I shall not be reassigned or removed from the Work by Contractor without the approval of Allegheny, except to the extent there are circumstances beyond Contractor’s control, such as but not limited to, death, incapacity due to disease or injury, or the employee leaving the Contractor’s employment. Contractor may use third party agency personnel for any position with Allegheny’s prior approval, and Contractor shall maintain a list of such approved personnel. Contractor further agrees that Allegheny shall have the right to direct Contractor to remove any member of Contractor’s project team from those performing Work under this Agreement.

4.6

Contractor shall perform the Work under the National Maintenance Agreement, providing for a wage modifier at ninety percent (90%) and one hundred percent (100%) of the fringe benefits found in the local collective bargaining agreement. Contractor shall take all necessary steps to minimize and/or eliminate labor disputes with respect to this Agreement.

4.7

Contractor shall develop with governmental authorities customs procedures for: (i) importing to the Work Site equipment, materials, supplies and construction tools required for the Work; and (ii) exporting Contractor-owned or rented construction tools and construction equipment. Contractor shall be responsible for obtaining and maintaining all licenses, visas, clearances, certifications and governmental or administrative authorizations, necessary for the performance of its obligations hereunder, including entry visas, residence and work permits and any applicable licenses for its employees, agents and representatives. Allegheny shall have no liability whatsoever in respect thereof.

4.8

Except for the permits and licenses that Allegheny is required to obtain pursuant to the Job Specification, Contractor shall procure all necessary permits and licenses required to be in Contractor’s name, including licenses or registrations issued by any professional boards pursuant to Law, and shall obtain approval of plans and specifications, and observe and abide by all applicable Law relating to the Work. Without releasing Contractor from its obligation hereunder, if any drawings or specifications are known by Contractor to be at variance with any applicable Law, Contractor shall give notice to Allegheny thereof before performing such Work. Applications for such permits, licenses or approvals shall be submitted to Allegheny for approval prior to being filed with any relevant authority involved. Contractor shall give a copy of each permit to Allegheny promptly after receipt thereof by Contractor.

4.9

Contractor shall have custody and control of: equipment, materials and supplies for performing the Work furnished by it or delivered to it by Allegheny; parts of the Work Site under construction or completed; temporary structures; and construction facilities, except for: (i) partially completed parts of the Work for which Allegheny has taken temporary possession by Change Order, (ii) parts (units, systems or areas of equipment) of the Work for which Allegheny has accepted custody and control pursuant to Completion Notices, and (iii) parts of the Work included in any part of the Work which has been terminated pursuant to Article 17. Contractor shall protect and care for items and parts of the Facility in its custody and control.

4.10

Contractor’s proposed schedule for work hours shall be submitted to Allegheny for its approval prior to Contractor beginning any Work at the Work Site. Once approved, such work schedule shall not be revised without further approval by Allegheny. Contractor shall not permit its employees or Subcontractors’ employees to work overtime or more than the approved work schedule, unless approved in advance by Allegheny.

4.11

Contractor shall schedule, report, forecast and control progress of the Work, and use best efforts to achieve completion of the Work on or before the Scheduled Completion Date, as set forth in the Job Specification.

4.14

Contractor agrees, unless exempt, to comply with the Federal Acquisition Regulations System (FAR) including, but not limited to, solicitation provisions and contract clauses in the following implementation provisions which are hereby incorporated by reference: Equal Employment Opportunity (48 C.F.R. §22.8), Special Disabled and Vietnam Era Veterans (48 C.F.R. §22.13, 41 C.F.R. 60-250.4(m)), Employment of the Handicapped (48 C.F.R. §22.14, 41 C.F.R. 60-741.4(f)), Small Business and Small Disadvantaged Business Concerns (48 C.F.R. §19.000-19.902). Pollution Control and Clean Air and Water (48 C.F.R. §23.1).

4.15

Contractor’s project manager named in the Job Specification shall have the authority to act for Contractor with respect to all matters pertaining to the Work and Contractor’s performance. Communications concerning these matters received by Contractor’s project manager from Allegheny shall be deemed to have been received by Contractor.

4.16

Contractor shall respond promptly to Allegheny’s request for assurances concerning the financial condition of Contractor and any Subcontractor or Vendor and their respective ability to perform all of their respective obligations under this Agreement. Upon the request of Allegheny, Contractor shall submit financial statements for its most recent fiscal quarter, as well as the most recent three years or the period of existence, if shorter, and will submit such other documents as are permitted by Law and, in Allegheny’s discretion, necessary to substantiate Contractor’s financial ability to complete the Work in accordance with the terms hereof. In the event that Contractor fails to provide such financial information, then a deficiency will be deemed to have occurred under Sub-Article 15.1. Contractor shall include in all subcontracts and purchase orders a similar provision requiring all Subcontractors and Vendors to provide such financial information upon request of either Allegheny or Contractor.

4.17

Without diminishing the importance of other portions of the Job Specification, Contractor shall ensure satisfactory pursuance of the requirements in the following portions of that document:

a)

furnishing and maintaining, in an up-to-date condition, the project control documents and giving notice to Allegheny, if any condition exists that Contractor forecasts may prevent Contractor from obtaining results that are in full compliance with this Agreement;

b)

operating a quality assurance system that complies with Allegheny’s requirements in the Job Specification and allows Allegheny full access to audit the system, and further undertakes to make such modifications to the system as may be required for the applicable quality assurance standards to be met; and

c)

during the course of manufacture and fabrication of equipment and materials, the making of inspections and tests required by the Job Specification, including Allegheny’s right to attend such inspections and tests and Contractor’s giving Allegheny proper notice therefore.

4.18

Contractor shall provide as specified in the Job Specification, office space, furnishings, clerical and secretarial assistance, communication services and other facilities and services required for Allegheny’s use at Contractor’s home and branch offices and at the Work Site.

5.1

Contractor shall estimate, budget, report, forecast and control Costs, and shall schedule, report, forecast and control progress of the Work.

5.2

Contractor shall keep the forecasted Agreement Price for all phases of the Work within the Agreement Price Budget, complete elements of the Work by the time specified in the agreed upon detailed work schedule, and use best efforts to achieve completion of the Work and other deliverables to be provided as part of the Work on or before the Scheduled Completion Date.

5.3

Contractor shall achieve completion of each part of the Work and other deliverables in the time sequence speci­fied in the Job Specification or as mutually agreed to by the parties. If the time sequence is revised by Allegheny, a Change Order shall be issued if appropriate pursuant to the criteria of Sub-Article 9.2. If such revision is required because of Contractor’s deficient performance, no adjustment to any fixed component of Fee shall be allowed and no adjustment to the Scheduled Completion Date shall be allowed unless the delay was excusable under force majeure pursuant to Article 37.

5.4

After issuance of the final Completion Notice, and at Allegheny’s request, Contractor shall prepare an estimated breakdown of the Agreement Price into accounting classifica­tions specified by Allegheny.

6.1

Representations and Warranties

(a)

has the Competence to perform the Work;

(b)

has or shall obtain and maintain the necessary personnel and supervision possessing appropriate skills to perform the Work to meet or exceed its obligations under this Agreement;

(c)

shall obtain, maintain and use all tools and equipment in accordance with manufacturer’s specifications and recommendations and good engineering and operational practices;

(d)

has or shall obtain, at its expense, before performing any work connected with the Work, all the necessary registrations, certificates, permits, licenses and authorizations to conduct business and perform the Work;

(e)

shall perform all Work in accordance with Law;

(f)

shall perform all Work promptly, with due diligence and Competence;

(g)

shall conduct itself with ethical and professional standards; and

(h)

fully comprehends the requirements and contingencies for performing the Work and that it has examined the Work Site for any additional or special requirements and contingencies.

6.2

Contractor’s Duty for Compliance while Performing Work under this Agreement

6.3

Additional Warranty

6.4

Warranties of Others

7.1

Contractor shall obtain Allegheny’s agreement with (i) procurement procedure, (ii) subcontract procedure (iii) purchase order and subcontract documents and (iv) Subcontractor and Vendor selection.

7.2

No home, branch office or construction management services shall be performed by Subcontractor(s), Vendor(s) and/or consultants without Allegheny’s prior approval.

7.3

Contractor shall include terms, conditions, provisions, obligations, warranties, and guaranties no less stringent than those imposed on Contractor under this Agreement in all purchase orders and subcontracts, except for non-material purchase orders with Vendors as agreed to by Allegheny.

7.4

In purchase orders and subcontracts involving the supply of equipment, supplies, structures and/or materials, whether permanent or temporary, Contractor shall:

7.4.1

specify that the equipment, supplies, structures and/or materials are being procured on behalf of Allegheny, and that Allegheny is the legal and equitable owner thereof at the time of payment, and

7.4.2

require that Allegheny be a recipient of manufacturer’s notices related to the equipment, supplies, structures and/or materials to be supplied including, but not limited to, any and all health and safety advisories and notices.

7.5

At regular intervals and as requested by Allegheny, Contractor shall review with Allegheny each Subcontractor’s progress and performance. Subcontract administration matters of a non-routine nature including, but not limited to, claims or potential claims shall be reviewed with Allegheny prior to any action or response by Contractor.

7.6

Contractor shall be responsible to Allegheny for work performed by Subcontractors to the same extent it is for work performed by Contractor’s employees.

7.7

Reviews or approvals of purchase orders, subcontracts, Subcontractors or Vendors by Allegheny shall not create any Contractual relation between Allegheny and any Subcontractor or Vendor.

7.8

Pursuant to Public Law 95-507, the Small Business Investment Act, 15 U.S.C. 637(d), Contractor agrees to perform to a mutually agreed plan so that small business concerns and those concerns owned and controlled by socially and economically disadvantaged individuals, as defined in the Act, have the opportunity to compete for purchase orders and subcontracts to the fullest extent consistent with the efficient performance under this Agreement, and make certifications and periodic reports required by the plan.

7.9

Contractor shall provide the necessary services to support the procurement of the Allegheny Acquired Materials, including specifications, quantities, expediting, inspection and the handling of such items subsequent to delivery to the Work Site.

8.1

Specific Obligations

8.1.1

Allegheny shall provide Contractor with the Job Specification, revisions thereto, and upon request, copies of specifications, drawings, instructions and other documents referred to in the Job Specification and not readily avail­able to Contractor.

(a)

Job Specification will be identified by its Table of Contents date.

(b)

At any time Allegheny may issue revision(s) to the Job Specification and shall issue Change Order(s) thereto.

8.1.2

Allegheny shall obtain from governmental authorities the licenses and permits that it must possess to locate, construct, maintain and operate the Facility.

8.1.3

Allegheny shall fulfill its obligations under Sub-Articles 8.1.1 through 8.1.2 above, and shall provide those items specified in the Job Specification as being provided by Allegheny in time to avoid delaying Contractor in the perform­ance of the Work.

8.1.4

Allegheny shall coordinate activities conducted by Allegheny or by other Contractors employed by Allegheny on or contiguous to the Work Site with the activities of Contractor.

8.1.5

Allegheny shall use its best efforts to provide certificates, upon reasonable and timely request, as it is empowered to issue in support of Contractor.

8.1.6

Allegheny shall maintain the insurance coverages set forth in the OCIP under Exhibit G and, if any such coverages are terminated, provide at least ten (10) days notice under a Change Order for Contractor to obtain replacement insurance pursuant to Exhibit G.

8.1.7

Allegheny shall designate certain items of the equipment and materials specified by Contractor as being Allegheny Acquired Materials. For each such item, purchase orders shall be placed using Allegheny documentation and authorization.

8.1.8

Allegheny shall make payments to Vendors for items of Allegheny Acquired Materials under the terms of the Allegheny purchase orders.

8.1.9

Allegheny personnel shall receive and sign at the Work Site for acceptable items of Allegheny Acquired Materials.

8.1.10

Allegheny shall deliver to Contractor items of Allegheny Acquired Materials, accepted pursuant to Sub-Article 8.1.9 above, for purposes of

8.2

Allegheny’s Project Manager

8.3

Access to and Use of Premises

8.3.1

Allegheny may use any portion of its property for its own purpose and may employ workers or other contractors of its own choosing for constructing other facilities or maintaining or changing any of the existing facilities. Work performed in accordance with the Job Specification at the Work Site by Allegheny and its contractors shall be coordinated with Contractor.

8.3.2

Allegheny may refuse any person admission to the Facility or exclude any person from performing Work under this Agreement, and Contractor shall cooperate with Allegheny with respect thereto.

8.3.3

Allegheny may take temporary possession of and use partially completed parts of the Work by notifying Contractor thereof and shall coordinate with Contractor to minimize any impacts on the Work.

(a)

Such possession by Allegheny shall not be deemed an acknowledgement of completion of said parts of the Work and shall not limit Contractor’s responsibility for custody and control of said parts of the Work pursuant to Sub-Article 4.10, after possession is returned to Contractor.

(b)

A Change Order shall be issued with respect to such temporary possession. If taking possession or use is required because Contractor’s performance has fallen behind the agreed upon detailed work schedule, Allegheny shall provide notice thereof, but no Change Order shall be allowed unless the delay was excusable under force majeure pursuant to Article 37.

(c)

Allegheny shall elect at the time of such taking of possession either to accept such part of the Work or to delay acceptance thereof until the time set forth in Sub-Article 18.2.

8.3.4

Contractor is responsible for ensuring that its employees, Subcontractors, Vendors and all others permitted by Contractor to enter the Facility and other sites made available by Allegheny for construction-related activities shall comply with Allegheny’s regulations and requirements. Contractor also shall require said persons to go to and from the Work Site and within

8.4

Approvals, Authorizations, Agreements and Reviews

8.5

Bonuses

9.1

Changes

9.2

Change Orders

(a)

Unless this Agreement provides otherwise, Allegheny shall issue a Change Order when it revises the Job Specification or elements of the Work already completed or being performed in accordance with the Job Specification, requires additional Work of Contractor or directs omission of part of the Work previously authorized, provided that any of the following Change Order criteria is satisfied: (i) Contractor’s costs for performing the Work are affected thereby; or (ii) the time required for performing the Work is affected thereby; or (iii) the scope of the Work or execution approach is affected thereby. If any of the foregoing criteria is satisfied, Allegheny shall authorize Contractor to prepare and Contractor shall prepare an estimate of the effects on costs and/or completion of the Work. After Contractor and Allegheny agree on the effects, Contractor shall proceed with the additional Work and Allegheny shall issue a Change Order adjusting one or more aforesaid items. In the event of a significant addition in the scope of Job Specification, Contractor shall have the right to propose an adjustment to the Agreement Price Budget, a modification to the Fee (fixed at 6.7% for Change Orders totaling up to 15% of the amount of the Agreement Price Budget) and revisions to the Schedule Completion Date to reflect the changes made by Allegheny. In the event of a significant deletion from the scope of the Job Specification, Allegheny shall have the right to propose an adjustment to the Agreement Price Budget, the Fee (at the rate of 6.7%) and the Schedule Completion Date. If there are any

(b)

A Change Order shall not be issued, when: (i) Contractor is required to remediate deficient Work under Sub-Article 15.1; or (ii) to correct errors, omissions or work not in accordance with the requirements of Sub-Articles 4.3 and 4.5; or (iii) Contractor has not complied with a requirement of this Agreement.

11.1.1

On or before the fifteenth day of each month, Contractor shall render to Allegheny an invoice for the actual, payable portion of the Agreement Price incurred for: the Work performed by Contractor during the first seven days of Contractor’s accounting period month, as set forth in Exhibit E, and an estimate of the payable portion of the Agreement Price forecasted to be earned for Work performed by Contractor during the balance of Contractor’s accounting period for that month; and the Work by Subcontractors and Vendors not previously invoiced by Contractor to Allegheny. The invoice shall specify, document and be adjusted for the difference between the estimate paid to Contractor during the prior month and the actual Costs incurred by Contractor in the prior month. Invoices shall include supporting documentation required by the Job Specification detailing:

11.1.3

Costs and Fee shall be certified by Contractor as being allowable under this Agreement before payment by Allegheny shall be made hereunder.

11.1.4

Invoicing for Costs shall be kept current and Allegheny shall have the right to not pay for undisputed Costs incurred in excess of ninety (90) days from the date such Costs should have been invoiced by Contractor to Allegheny.

11.1.5

Each invoice shall be specified net of taxes, with applicable taxes (e.g., sales tax) identified separately.

11.1.6

Allegheny shall review each such invoice provided by Contractor and within 15 calendar days after receipt of a correct and valid invoice with full supporting documentation Allegheny: will advise Contractor of any amount rejected, together with the reason for the rejection; and on the last Wednesday of Contractor’s accounting period, as set forth in Exhibit E, of the month of the invoice, shall deposit into the Trust Account the undisputed amount of the invoice to then be paid under the Trust Agreement to Contractor, Subcontractors and Vendors.

11.1.7

Retainage, at the rate of two and one half percent (2.5%) of the amount of each invoice submitted by Contractor, shall be capped at five million dollars ($5 million). Contractor, at its own expense, shall provide an ascending, irrevocable, on demand, stand-by letter of credit in form and substance as Exhibit F attached hereto, issued by a financial institution approved by Allegheny (“Letter of Credit”), in lieu of Allegheny retaining funds from invoices presented by Contractor. The Letter of Credit shall be used to cover contract and warranty claims not honored by Contractor and, after providing Contractor with seven days notice to cure such claims and if Contractor has not diligently pursued such cure, may be partially or wholly drawn upon demand by Allegheny with notification to the financial institution in accordance with the terms of the Letter of Credit. Upon expiration of the base warranty period (eighteen (18) months from the date of the Completion Notice) as noted in Sub-Article 6.3 herein, to the extent it has not been drawn upon, Allegheny shall, promptly after receipt of written request from Contractor, return the Letter of Credit to Contractor.

12.1

Contractor agrees to waive all rights to mechanics’, materialmen’s or similar liens with respect to every aspect of this Agreement. Contractor shall include enforceable language waiving all rights to any mechanics’ lien, materialmen’s lien or similar lien in all Subcontract and Vendor agreements related to Work under this Agreement, and will require that all Subcontractors, Vendors, or other persons supplying labor, material, services or any other potentially lienable product for the Work will include such language in all Agreements with any lower tier Subcontractor or Vendor of such products.

12.2

Contractor agrees that it will indemnify, defend and hold Allegheny harmless from any fines, penalties, assessments, attorneys fees, expenses or costs of any kind incurred by Allegheny or assessed against Allegheny in connection with any violation or alleged violation by Contractor or any Subcontractor or Vendor of any Occupational Safety and Health statutes, regulations or requirements.

12.3

In the event any Subcontractor, Vendor or third party asserts any claim that would, if successful, cause an increase in the Agreement Price, become a cost, or cause an extension of the Scheduled Completion Date, Contractor shall immediately notify Allegheny of the receipt of such claim, and shall immediately provide to Allegheny all claim documentation received from such claimant. Allegheny shall have the right to monitor the progress and handling of such claim in every respect, and may, at Allegheny’s sole option, undertake the handling and defense of any such claim with counsel of its own choosing and at its sole cost. Contractor agrees to fully cooperate with Allegheny in the negotiation, handling and/or defense of any such claim, including but not limited to the provision of documentary and witness support, and shall not settle or make payment on any such claim without the written consent of Allegheny.

12.4

Contractor agrees that it will continue performance under this Agreement during the pendency of any dispute or claim, and Allegheny agrees to continue paying undisputed amounts due during the pendency of any dispute or claim.

13.1

Contractor shall pay when due:

13.1.1

Taxes and fees imposed by reason of the performance of the Work by Contractor including, but not limited to, sales, excise, storage, consumption and use taxes; licenses, permit and registration fees; and income, profit, franchise, and personal property taxes, but excluding fees for licenses and permits obtained by Allegheny pursuant to Sub-Article 8.1.2.

13.1.2

Employment taxes and contributions imposed by applicable Law, or trade union Agreements or regulations, with respect to or measured by compensation (wages, salaries or other) paid to employees of Contractor including, but not limited to taxes and contributions for unemployment compensation insurance, old age benefits, welfare funds, pensions and annuities, and disability insurance, and

13.1.3

Import/export license fees and import/export taxes and duties on services, equipment and materials, and construction tools, equipment and supplies imported or exported by Contractor.

13.2

Except to the extent due to Allegheny’s non-payment of undisputed invoices, Contractor shall defend, indemnify and hold Allegheny harmless from liability resulting from Contractor’s or Subcontractors’ or Vendors’ failure to (i) make timely payment of or to pay any of the items in Sub-Article 13.1 above, or (ii) comply with the reporting, filing or other procedural requirements with respect to their payment. Interest, penalties or other liabilities arising from such failures shall not be allowed as Costs and shall be for Contractor’s account.

13.3

Contractor shall develop procedures and minimize the sales and use tax or value added tax burden on purchases of equipment, materials, and services under this Agreement. Prior to Contractor’s initiation of procurement activities hereunder, it shall obtain Allegheny’s approval of the aforesaid procedures.

13.4

If Contractor fails to obtain immunity or exemption from taxes or duties from which Contractor or Subcontractors are exempt under applicable Law, or fails to obtain a refund or credit, including interest, applicable for any such taxes or duties paid, such taxes and duties shall not be allowed as Costs and shall be for Contractor’s account.

13.5

Contractor shall promptly notify Allegheny of matters pertaining to nonpayment or payment under protest of, claim for immunity or exemption from, or claim for refund of or credit against any taxes or duties that are applicable to the Work.

13.6

Without liability to Contractor, Allegheny shall withhold income and other taxes from payments due to Contractor under this Agreement to the extent that such withholding is required by Law. Payment by Allegheny to the appropriate governmental office of the amount of money so withheld will be deemed to have

13.7

Sales and Use Tax Responsibilities

13.7.1

Except as expressly provided in Sub-Article 13.7.2 below, all permanent equipment and materials purchased by Contractor for incorporation as a permanent part of the Work shall be purchased by Contractor. Contractor shall pay sales and/or accrue and pay use tax as appropriate. Allegheny shall have the option to purchase Allegheny Acquired Materials directly in order to utilize its public utility sales tax exemption.

13.7.2

Contractor shall pay applicable sales or use tax on: (i) equipment, materials and supplies (including but not limited to consumable supplies and small tools) that will not become a permanent part of the Work; (ii) third party rentals including construction equipment; and (iii) permanent equipment and materials purchased by Contractor.

13.7.3

Contractor shall, in its accounting of the Agreement Price Budget, distinguish between (i) permanent equipment and materials purchased for incorporation as a permanent part of the Work and (ii) those equipment, materials and supplies which Contractor shall have paid sales and use tax in accordance with Sub-Article 13.7.2 above.

13.7.4

The Contractor agrees to assign and transfer to Allegheny all its rights to sales and use tax which may be refunded as a result of a claim for refund for materials purchased in connection with this Agreement. The Contractor further agrees that it will not file a claim for refund for any sales or use tax which is the subject of this assignment.

14.1

Allegheny or its representative shall at all times have access to the Work whether it is in preparation or in progress and Contractor shall provide proper facilities for such access and for inspection. If the Job Specification, Allegheny’s instructions, any Law or any public authority require any Work to be specifically inspected, tested or approved, Contractor shall give Allegheny timely notice of: (i) readiness for inspection; and (ii) the date fixed for any inspection to be performed by a public authority.

14.2

Inspections by Allegheny shall be promptly made. If any part of the Work requiring Allegheny’s inspection or witnessing is closed or covered before such inspection or witnessing has been performed, Allegheny may require said Work to be opened or uncovered for inspection or witnessing and reclosed or recovered. Costs associated therewith shall be for Contractor’s account.

15.1

Any or all of the following, at Allegheny’s option, shall be deemed deficient Work hereunder: (i) any Work performed or equipment and/or materials furnished by Contractor or Subcontractors that does not conform with requirements as set forth in this Agreement, or (ii) Contractor has at any time failed to remedy any imperfections in the Work, or (iii) Contractor has failed to supply a sufficient number of properly skilled workmen or satisfactory equipment and/or materials, or (iv) Contractor, or any Subcontractor or Vendor, fails upon request to demonstrate financial ability to complete the Work in accordance with the terms of this Agreement, or (v) Contractor has failed to execute the Work with promptness and diligence satisfactory to Allegheny, or (vi) Contractor has failed to comply with any of the provisions of this Agreement. Upon receipt of notice from Allegheny that any such deficiency exists, Contractor shall promptly undertake and proceed with due diligence to remedy such deficiency to meet the requirements of the Job Specification or to the satisfaction of Allegheny.

15.2

For Contractor’s remediation pursuant to the foregoing Sub-Article, Allegheny shall pay Contractor in accordance with Exhibit A, costs incurred by Contractor in correcting deficiencies in the Work, except for: (i) amounts recoverable from Subcontractors, Vendors or others; and (ii) costs incurred as a result of Contractor’s failure to substantially meet or exceed the standards prevailing in the industry pertaining to such Work.

15.3

If Contractor does not within ten (10) days after receipt of such notice undertake and proceed with due diligence to remedy such deficiencies, Allegheny may declare Contractor in material breach of this Agreement, and by written notice setting forth the effective date of removal, may remove Contractor from all or any part of the Work and use or dispose of all materials, supplies, tools and equipment in connection therewith. Allegheny may then complete all or any part of the Work from which Contractor has been removed.

15.4

In the event that Allegheny does remove Contractor and take possession as aforesaid, then notwithstanding Article 11, Contractor shall only be entitled to payment for the part of the Work performed by it and acceptable to Allegheny under the terms and conditions of this Agreement up to the effective date of such removal, reduced by: (i) costs recoverable under Subcontractors’ or Vendors’ guarantees; (ii) costs recoverable under insurance policies; and (iii) Allegheny’s retainage out of moneys owing to Contractor of an amount sufficient to indemnify Allegheny against extra costs incurred by Allegheny to remedy deficiencies. The rights and remedies of Allegheny provided by this Article are in addition to any other rights and remedies provided by Law or this Agreement.

16.1

Suspension of Work

16.2

Compensation

(a)

Contractor’s employees whose retention on the Work during the suspension has been authorized in advance by Allegheny; and

(b)

Other items directly related to the suspended part of the Work if authorized in advance by Allegheny,

16.3

Resumption

16.4

Liability

17.1

Termination for Convenience

17.2

Termination for Material Breach

17.3

Termination by Contractor

17.3.1

In the event that all of the Work was suspended pursuant to Sub-Article 16.1 and Allegheny has not authorized resumption within three months of such suspension, Contractor may give notice to Allegheny of its intention to terminate this Agreement. If, within thirty (30) days of said notice Allegheny does not authorize resumption of the Work, or any part thereof, Contractor may terminate this Agreement with immediate effect, and Allegheny will compensate Contractor pursuant to Sub-Article 17.4 below.

17.3.2

In the event Allegheny fails to pay Contractor undisputed amounts required to be paid hereunder when such amounts are due, Contractor may, at its sole discretion and upon the provision of written notice to Allegheny, immediately suspend its performance of the Work. Contractor shall not be required to resume performance of suspended Work until such time as undisputed past due amounts have been paid by Allegheny.

17.4

Compensation

(a)

for non-lump sum and non-unit cost agreements, according to Exhibit A;

(b)

for lump sum and unit-cost agreements, the percentage of any lump sum or unit cost price (as the case may be) which represents the percentage of the Work completed by Contractor; and

(c)

for direct costs that Contractor incurs in terminating the Work under this Agreement, including unpaid legally enforceable obligations to Subcontractors and Vendors and others as well as transportation costs for return of employees, construction tools and equipment, provided those costs were authorized in advance by Allegheny and are properly supported by time sheets, invoices and the like.

17.5

No Compensation

17.6

Liability

18.1

Completion

18.2

Acceptance

20.1

Contractor’s Responsibilities

20.1.1

Contractor agrees, to the extent not prohibited by Law, to defend, indemnify and hold Allegheny and its agents, officers and employees harmless from (i) all third party claims, obligations and liabilities (and all costs and expenses including attorneys’ fees incurred in connection there­with) to the proportionate extent caused by the negligence, gross negligence, recklessness or willful misconduct of Contractor and (ii) all claims for death, disease, bodily injury and/or property damage including, without limitation, claims from Contractor’s employees, Subcontractors’ employees and/or Vendors’ employees (other than property damage to the Work itself) that may arise in connection with the Work or that occur during Contractor’s performance of the Work, including all costs and expenses including attorneys’ fees incurred in connection therewith.

20.1.2

Contractor shall also cause any Subcontractor, to the extent not prohibited by Law, to indemnify, defend and hold Allegheny and Contractor and their respective principals, officers, partners, agents and employees harmless from all third party claims for death, disease, bodily injury and/or property

20.1.3

Contractor’s and all Subcontractor’s obligations to indemnify and hold Allegheny harmless shall not be limited by a limitation on the amount or type of damages, compensation or benefits payable by or for the Contractor or Subcontractor under workers’ compensation acts, disability benefit acts or other employee benefit acts. Where personal injury, death, disease or loss of or damage to property arises from a cause or causes attributable jointly to the negligence of one or more of Allegheny, Contractor and/or any Subcontractor, each indemnitor’s duty of indemnification shall be in proportion to its allocable share of such negligence.

20.1.4

(a) Contractor hereby waives all rights of subrogation against Allegheny, and against all Contractors and Subcontractors enrolled in the OCIP, in connection with any and all events, occurrences, claims, losses and/or payments arising from or in connection with the performance of the Work.

20.2

Allegheny’s Responsibilities

20.2.1

Allegheny agrees to indemnify and save Contractor harmless from any and all damages, claims, causes of action, liabilities, loss, cost fines, penalties or expense claimed by third parties for property damage and or bodily injury, including death, to the proportionate extent caused by the negligence, gross negligence or willful misconduct of Allegheny, its agents, employees, or affiliates.

20.2.2

Allegheny shall be responsible for and hold Contractor harmless for loss of or damage howsoever caused to Allegheny’s property intended to be incorporated into or used in the Work and located at the Work Site, even if the loss or damage results from Contractor’s negligence, except that Contractor shall be responsible for the first $5,000 of any such loss.

20.2.3

Allegheny will indemnify Contractor for loss of or damage howsoever caused to Contractor’s property intended to be incorporated into the Work and located at the Work Site, even if the loss or damage results from

20.2.4

Notwithstanding the provisions of Sub-Articles 20.2.1 and 20.2.2, Contractor shall also be responsible, and not compensated by Allegheny, for:

(a)

any loss of money or securities in the care, custody or control of Contractor, which are used or intended for use in paying for or performing the Work;

(b)

unexplained or mysterious disappearance of any property in Contractor’s care, custody or control, or shortage of any property disclosed on taking inventory; or

(c)

theft of property on the part of Contractor, Subcontractors or their employees.

21.1

Contractor shall participate, and require Subcontractors to participate, in Allegheny’s Controlled Insurance Program (OCIP) pursuant to Exhibit G and meet the other insurance coverage requirements set forth in ▇▇▇▇▇▇▇ ▇.

▇▇.▇

▇▇▇▇ ▇▇▇▇▇▇▇▇▇’s request, Contractor agrees to participate in a project-wide bonding program, subguard, primeguard or other insurance programs, and Contractor shall not bond Subcontractors, unless requested by Allegheny.

22.1

to inspect the tools and equipment and make its own determination, before commencing the Work, that they are adequate for the safe and efficient performance of the Work by Contractor.

22.2

that the tools and equipment will be loaned or furnished by Allegheny and accepted by Contractor without warranty or representation by Allegheny as to their condition or fitness for Contractor purpose.

22.3

to return the tools and equipment to Allegheny at the conclusion of use in good condition as when received, ordinary wear and tear excepted.

24.1

Governing Law

24.2

Dispute Resolution

25.1

Ownership of Documents

25.2

Contractor shall cause provisions substantially similar to Sub-Article 25.1 to be included with all of Contractor’s agreements with its consultants and shall require all of Contractor’s consultants to grant the licenses to Allegheny as described in Sub-Article 25.1.  

25.3

Contractor shall provide to Allegheny, in a medium (e.g., disk, magnetic tape, network direct transfer, etc.) approved by Allegheny, a digital copy of the most recent design drawings, specifications and other documents, including those which were produced or created by Contractor’s consultants and/or others.

25.4

In the case of products, materials, systems, etc., protected by patent, Contractor and its consultants shall not specify or cause to be specified any infringing use of a patent. Should Contractor become aware of or receive notice of potential infringement of any intellectual property right related to the Work or other work for Allegheny, regardless of the source of that awareness or notice, Contractor shall (i) immediately cease the copying and any other activity which is the potential source of infringement; and within seven (7) calendar days (ii) investigate the potential infringement; (iii) submit to Allegheny copies of all documents relating to that awareness, the notice, or the object thereof; and (iv) issue to Allegheny a complete written response and analysis of the potential infringement and the course of action recommended by Contractor. Contractor shall submit to Allegheny a supplement of the initial report within seven (7) calendar days of Contractor’s receipt of, or awareness of, additional related information. Nothing in this Agreement shall be deemed to relieve Contractor of its obligations under this Sub-Article, nor shall Allegheny’s receipt of the information indicated in this Sub-Article give rise to any duty or obligation on the part of Allegheny.

25.5

Ownership of Inventions

25.6

Infringement Notice and Indemnification

26.1

Contractor’s Duty of Confidentiality

(a)

information, which is or becomes, without fault of Contractor, part of the public domain;

(b)

information, which Contractor can show, was received by Contractor from an independent third party that is under no obligation to Allegheny regarding the information;

(c)

information, which Contractor can show was already in Contractor’s possession at the time the information, was made available to Contractor, directly or indirectly, from Allegheny.

26.2

Contractor’s Use of Confidential Information

26.3

Contractor’s Information

28.1

Contractor shall maintain and preserve, and shall require Subcontractors to maintain and preserve, in accordance with generally accepted accounting practices, accurate documentation and data (including but not limited to written and electronic records, books of account, correspondence, plans, permits, licenses, drawings, payroll records, memoranda, invoices including all back-up details, receipts, records relating to air freight and ground transportation and documentation of related systems and controls) pertaining to the performance of the Work under this Agreement, as well as any gift or entertainment expenses incurred by Contractor or Subcontractors pertaining to the Work under this Agreement. A listing of the minimum data field requirements for audit purposes to be maintained by Contractor and Subcontractors is attached hereto as Exhibit K.

28.2

At all reasonable times, Contractor shall permit and shall require Subcontractors to permit, employees and agents of Allegheny, and its insurers, to have access to its and their offices and work locations to examine, reproduce and retain copies of such documentation and data and discuss with Contractor’s and Subcontractors’ personnel in connection therewith, as necessary for Allegheny to verify and monitor: (i) that Reimbursable Costs are actually incurred and paid; (ii) the existence and effectiveness of Contractor’s and Subcontractors’ business practices; and (iii) Contractor’s compliance with the terms of this Agreement. Where Work is billable under Fixed Rates, Allegheny shall have sufficient access to those rates to satisfy themselves that the Work provided thereunder have not also been separately billed on some other basis (e.g., a reimbursable basis).

28.3

The provisions of this Article shall be applicable during the term of this Agreement and for a period of three (3) years thereafter. If errors or deficiencies are identified by an audit or otherwise, Contractor shall take prompt corrective action and advise Allegheny thereof.

29.1

Business Standards

29.2

Accuracy of Records

29.3

Compliance With Law

29.4

Notice of Non-Compliance

30.1

Warranty and Representation

30.2

Notification

31.1

Contractor and its Subcontractors shall have the responsibility and liability for the proper management of non-hazardous wastes resulting from their Work, as well as for the proper disposal of non-hazardous wastes at the Work Site, pursuant to the Job Specification and according to Law. In particular, but without limitation, Contractor and Subcontractors shall implement procedures to minimize the generation of non-hazardous waste. These procedures shall include, at a minimum, process substitution, materials recovery, and continued product use.

31.2

Contractor and Subcontractors shall, in performing the Work, have the responsibility and liability for all hazardous materials brought onto or generated at the Work Site by Contractor and Subcontractors, including the proper permitting, removal and disposal of all such hazardous materials according to Law. In particular, but without limitation, Contractor and Subcontractors shall implement procedures to minimize the generation of hazardous materials. These procedures shall include, at a minimum, process substitution, materials recovery, and continued product use. When possible, Contractor shall select less toxic alternatives to minimize the generation of hazardous materials. Contractor shall maintain a log of all hazardous materials, including their quantity, locations and place of disposal, and provide copies of such log regularly to Allegheny. Contractor in performing the Work shall remove all Contractor and Subcontractor hazardous materials from the Work Site as soon as practicable, but in no event later than acceptance of the Work.

31.3

In the event pre-existing hazardous materials, including asbestos or asbestos containing materials, are identified at the Work Site, Contractor shall provide notice of such existence and Allegheny shall remove and dispose of such materials.

31.4

Contractor shall defend, indemnify and hold harmless Allegheny, and Allegheny’s parents, subsidiaries, contractors, subcontractors and suppliers of any tier, affiliates and the officers, directors, employees, successors and assigns of each of them, from and against all Losses (as defined in Sub-Article 31.5 below) resulting from or related to: (i) any hazardous material that has been brought onto the Work Site by Contractor or any Subcontractors or any person acting on behalf of, or under the direction or supervision of Contractor or Subcontractors; (ii) Contractor’s failure to timely notify Allegheny of the presence of any hazardous material on, or the release of any hazardous material on or from, the Work Site, (iii) Contractor’s failure to remove or properly dispose of any such hazardous materials or waste generated by Contractor or Subcontractors at the Work Site; or (iv) Contractor’s or a Subcontractor’s failure to comply with Law with respect to any such hazardous materials or waste. Contractor’s obligations hereunder shall not be limited by the provisions of any Workers’ Compensation act or similar statute or otherwise.

31.5

Allegheny shall protect, defend, indemnify and hold harmless Contractor and its affiliates, consultants, agents, Subcontractors and Vendors of any tier, and any and all employees, officers, or directors of any of the foregoing (the “Contractor’s Indemnified Parties”), from and against any and all claims (including all penalties, attorney’s fees, fines, or administrative or civil sanctions related directly to such claims), losses, costs, judgments, damages, (but excluding incidental, consequential, indirect and special damages), penalties, and liabilities (the “Losses”) suffered as a result of or arising out of or in connection with the performance of the Work and relating to any hazardous material not introduced to the Work Site by Contractor or Contractor’s Indemnified Parties.

33.1

Executive Sponsor

33.1.1

Allegheny’s Executive Sponsor, ▇▇▇▇▇▇ ▇. ▇▇▇▇▇, or other such person as may be subsequently designated in writing by Allegheny, shall be the primary contact with Contractor’s corporate management and shall have authority to act for Allegheny with respect to all matters pertaining to this Agreement.

33.1.2

Contractor’s Executive Sponsor, ▇▇▇▇▇ ▇. ▇▇▇▇▇, ▇▇., an officer of Contractor or some other officer as may be subsequently designated in writing by Contractor, shall have authority to act for Contractor with respect to all matters pertaining to this Agreement. The Executive Sponsor shall be available to Allegheny’s representatives at any reasonable time, regarding among other things, communications to Contractor’s corporate management of its performance of the Work. It is agreed that the Executive Sponsor shall maintain a detailed knowledge of the progress of the Work and of significant or anticipated problems and shall ensure that Contractor fulfils its obligations under this Agreement. In particular, the Executive Sponsor shall attend regular project review meetings and shall receive copies of Contractor’s regular progress reports and other significant correspondence. If Contractor’s Project Manager and Allegheny’s Project Manager cannot reach agreement on any material matter related to the Work, the matter will be decided by Contractor’s Executive Sponsor and Allegheny’s Executive Sponsor.

33.2

Notices

33.2.1

Notices required by this Agreement shall be in writing and shall be sent by hand or certified mail or overnight delivery services to Contractor or Allegheny at the respective party’s office address set forth below, to the attention of the respective Designated Representative:

Allegheny:

Contractor:

ATTN:

▇▇▇▇▇▇ ▇. ▇▇▇▇▇

ATTN: ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇

Allegheny Energy

Washington Group International

▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇

▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇

▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇

▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇-▇▇▇▇

With a copy to:

Allegheny:

Contractor:

ATTN:

General Counsel

ATTN: ▇▇▇▇▇▇▇ ▇. ▇▇▇▇, ▇▇.

Allegheny Energy

Washington Group International

▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇

▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇

▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇

▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇-▇▇▇▇

33.2.2

The effective date of notice shall be the date the notice is received by the addressee or it reaches the office of the addressee, whichever is earlier.

34.1

Contractor certifies that to the best of its knowledge and belief, none of its personnel or those of Subcontractors shall perform any Work for Allegheny while under the influence of alcohol and/or drugs. Contractor’s and Subcontractor’s personnel performing the Work for Allegheny shall be informed about its alcohol and drug policy.

34.2

Contractor’s and Subcontractors’ personnel shall be advised to neither abuse medications nor use, possess, distribute or sell alcohol and/or drugs when performing the Work for Allegheny or on premises owned or controlled by Allegheny. Upon for cause suspicion that so happens, Contractor’s or Subcontractors’ personnel shall be suspended from performing Work for Allegheny. In such instances, Allegheny also has the right to instruct the Contractor to remove subject personnel from performing the Work for Allegheny. In those instances where personnel have been removed from performing the Work caused by possible alcohol and drug abuse, such personnel shall be allowed to resume performing the Work only if the Contractor can document that such personnel have passed an alcohol and drug test.

34.3

The Contractor shall introduce guidelines and implement procedures to ensure an alcohol and drug free working place when performing the Work for Allegheny. Allegheny has the right to request documentation to ensure that the guidelines and procedures are in compliance with Allegheny’s requirements.

37.1

No delay or failure of performance by either party shall constitute default hereunder or give rise to any claim for damages if, and to the extent, such delay or failure is caused by force majeure. Force majeure means an unforeseeable, irresistible occurrence beyond the control and without the fault or negligence of the party affected and which said party is unable to prevent or provide against by the exercise of reasonable diligence including, but not limited to: acts of God or the public enemy; expropriation or confiscation of facilities; war, rebellion, sabotage or riot, floods, unusually severe weather that could not reasonably have been anticipated; fires, explosions, or other catastrophes; changes in Law; strikes or any other concerted acts of workers; and other similar occurrences; but lack of finances shall in no event be deemed to be a cause beyond a party’s control.

37.2

The following are specifically excluded as force majeure occurrences unless: (i) they were caused by force majeure of the type set forth in the preceding clause; and (ii) an acceptable alternate source of work or materials is unavailable:

(a)

late performance by a Subcontractor caused by a shortage of supervisors or labor, inefficiencies, or similar occurrences.

(b)

late delivery of equipment or materials caused by congestion at a manufacturer’s plant or elsewhere, an oversold condition of the market, inefficiencies, or similar occurrences.

37.3

The party invoking the force majeure will: (i) immediately notify the other party; (ii) make every effort to remedy the cause of non-performance; and (iii) perform the entirety of its obligations as soon as this cause has gone, the other party being released from its Contractual obligations until such time as the cause has gone. Contractor shall not have the right to terminate the Work by reason of Allegheny having invoked force majeure.

37.4

WHEN THE EFFECT OF SAID OCCURRENCE IS ESTABLISHED, ALLEGHENY SHALL ISSUE A CHANGE ORDER.

40.1

Severability

40.2

Waiver

40.3

Remedies Cumulative

40.4

Sole Benefit

40.5

Counter Parts

Washington Group International

Allegheny Energy Service Corporation
(as agent for Monongahela Power Company)

By:

/s/ ▇▇▇▇▇ ▇▇▇▇▇

By:

/s/ ▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇▇▇

Name:

▇▇▇▇▇ ▇▇▇▇▇

Name

▇▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇▇▇

(Typed or Printed)

(Typed or Printed)

Title:

Executive Vice President -

Title:

Chief Operating Officer, Generation

Operations – Power

Date:

March 12, 2007

Date:

March 15, 2007