Change Order Confirmation definition

Change Order Confirmation means a written confirmation provided by the Province of the Estimate, and, if applicable, of an adjustment to the Contractor’s Construction Schedule or the O&M Payments in Schedule 14 (Payment Schedule);
View Source
Change Order Confirmation has the meaning indicated in Schedule 1 (Change Orders);
View Source
Change Order Confirmation means confirmation provided by the City of a Change Estimate pursuant to Section 2.4 [Change Order Confirmation] of Schedule 13 [Changes].
View Source

Examples of Change Order Confirmation in a sentence

  • For certainty, the Change Order Confirmation shall not include any Direct Losses referenced in or payable pursuant to Section 1.7 [Effect on Schedule] of this Schedule 13 [Changes].

  • An Innovation Proposal that is Accepted by the City shall be implemented as a Change and Design-Builder shall not implement an Innovation Proposal prior to the issuance of a Change Order Confirmation.

  • For certainty, the Change Order Confirmation shall not include any Direct Losses referenced in or payable pursuant to Section 1.7 [Effect on Schedule].

  • An Innovation Proposal that is Accepted by the City shall be implemented as a Change and Project Co shall not implement an Innovation Proposal prior to the issuance of a Change Order Confirmation.

  • Design-Builder shall use all reasonable efforts and Good Industry Practice to minimize the effect of a Change on the Construction Schedule and Key Dates and, subject to the foregoing and Sections 1.1 [Changes] and 2.3(b)(ii), the Target PICO Completion Date, Target Construction Completion Date and the Long Stop Date shall be adjusted by such time as is reasonable in the circumstances to take account of the effect of the delay caused by the Change, as confirmed in the applicable Change Order Confirmation.

  • Date of Change Order Confirmation or notice from City not to accept Innovation Proposal Yes 15.

  • Within 30 days following the Construction Completion Date, the City shall prepare and deliver to Project Co a consolidated Change Order Confirmation encompassing all of the agreed Design Development Changes, as set out in the applicable Design Development Change Registers.

  • The City will issue, on an annual basis a Change Order Confirmation covering Design Development Change Record Confirmations issued in the prior year.

  • Within 30 days following the Construction Completion Date, the City shall prepare and deliver to Design-Builder a Change Order Confirmation encompassing all of the remaining Design Development Change Record Confirmations.


More Definitions of Change Order Confirmation

Change Order Confirmation means a written confirmation issued by the City of the Estimate, including any agreed modifications thereto, and, if applicable, of any adjustments to Project Co’s Construction Schedule and/or any payments due to Project Co hereunder;
View Source
Change Order Confirmation means a Confirmation (as described in Schedule 5 – Review Procedure) provided by the City of:
View Source
Change Order Confirmation has the meaning given in section 2.5; “Estimate” has the meaning given in section 2.3;
View Source
Change Order Confirmation has the meaning as set out in Schedule 17 – Change Orders;
View Source
Change Order Confirmation means the confirmation provided by the City of:
View Source
Change Order Confirmation has the meaning given in section 2.5;
View Source

Related to Change Order Confirmation

  • Order Confirmation All TIPS Member Agreement orders are approved daily by TIPS and sent to vendor. The Vendor should confirm receipt of orders to the TIPS Member (customer) within 3 business days. • Vendor custom website for TIPS: If Vendor is hosting a custom TIPS website, updated pricing when effective. TIPS shall be notified when prices change in accordance with the award.

  • Firm Order Confirmation or "FOC" means the notice CenturyLink provides to CLEC to confirm that CLEC's Local Service Order (LSR) has been received and has been successfully processed. The FOC confirms the schedule of dates committed to by CenturyLink for the Provisioning of the service requested.

  • Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.

  • Change Orders mean changes or modifications to any Construction Contract or any other contract with labor or material suppliers.

  • Change Order Request means a written request or proposal for a Change Order submitted by either Company or Contractor and including: