Inexcusable Delay Event definition

Inexcusable Delay Event means a Delay Event caused by circumstances within the control of Contractor, its subcontractors or suppliers of any tier.
View Source

Related to Inexcusable Delay Event

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation: (1) acts of God or of the public enemy, (2) acts of the United States of America in either its sovereign or contractual capacity, (3) acts of another contractor in the performance of a contract with the Government, (4) fires, (5) floods, (6) epidemics, (7) quarantine restrictions, (8) strikes, (9) freight embargoes, (10) unusually severe weather, or (11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.

  • Delay Event means: (i) a tsunami, flood, cyclone, earthquake, bushfire or other act of nature; (ii) riot, civil commotion, war, invasion or a terrorist act; (iii) an imminent threat of an event in paragraphs (i) or (ii); or (iv) compliance with any lawful direction or order by a Government Agency; or (v) if clause 2.5 applies, the computer system operated by the ATO for the GST Withholding notifications referred to in clause 2.5(5)(c) is inoperative;

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.