Substantial Completion Guaranteed Date definition

Substantial Completion Guaranteed Date means January 1, 2014 as the same may be extended pursuant to Articles XVI, and Sections 8.04, 22.02 and 23.07, provided a Full Notice to Proceed is issued by Owner no later than April 1, 2012.
View Source
Substantial Completion Guaranteed Date means the Phase 1 Substantial Completion Guaranteed Date, the Phase 2 Substantial Completion Guaranteed Date, the Phase 3 Substantial Completion Guaranteed Date, the Phase 4 Substantial Completion Guaranteed Date, or the PV Power Plant Substantial Completion Guaranteed Date, as applicable.
View Source
Substantial Completion Guaranteed Date means the date of August 31, 2009, as such date may be modified in accordance with the terms hereof.
View Source

Examples of Substantial Completion Guaranteed Date in a sentence

  • If the Project fails to achieve the Substantial Completion Date on or prior to close of business on the Substantial Completion Guaranteed Date, then Developer shall pay to PacifiCorp liquidated damages for each day until the Project achieves the Substantial Completion Date, in an amount equal to [ ($ )] per day for the first thirty-one (31) days following the Substantial Completion Guaranteed Date and [ (collectively, the “Delay Liquidated Damages”).

  • The CPM Schedule shall represent Contractor's best judgment as to how it shall complete the Work in compliance with the Schedule Milestones including the Phase Substantial Completion Guaranteed Dates, the PV Power Plant Substantial Completion Guaranteed Date, and the Final Completion Guaranteed Date.

  • In the event the negotiation and execution of any such Agency Subcontracts is delayed and the Project Schedule is adversely impacted (provided that Contractor is not acting in a commercially unreasonable manner), Contractor shall be entitled to a Change In Work to the extent such delay actually and demonstrably impacts the Substantial Completion Guaranteed Date for the applicable Unit or the Separated Contract Price.

  • On the Full Notice to Proceed Date, Contractor shall commence with the performance of the remainder of the Work in accordance with the Project Schedule and shall thereafter diligently pursue the Work assigning to it a priority as necessary for each Unit to achieve Substantial Completion on or before the Substantial Completion Guaranteed Date for such Unit.

  • Contractor shall prosecute the Work in accordance with the Project Schedule and shall cause Substantial Completion of the Project to occur on or before the Substantial Completion Guaranteed Date (as such date may be extended pursuant to Article 17, Article 22 or any other provision hereof).

  • Contractor shall cause Substantial Completion to occur on or before the Substantial Completion Guaranteed Date (as such dates may be extended pursuant to this Contract, including Articles XXIII, XVII, XXII, Section 25.01, Section 36.01 or any other provision hereof).

  • Approval by Owner of an Acceleration Plan shall not be deemed in any way to relieve Contractor of its obligations under this Agreement relating to the failure to achieve Substantial Completion by the Substantial Completion Guaranteed Date, shall not be a basis for an increase in the Contract Price, and shall not limit the rights of Owner under Section 15.1.

  • Design and prepare a written narrative description of the training program (in accordance with the provisions of Exhibit “A”) and the proposed written materials to be used in the training program, and submit such description to Owner by no later than the date that is one hundred eighty (180) days before the Substantial Completion Guaranteed Date or, if sooner, the then-anticipated Substantial Completion Date.

  • Owner agrees that if Contractor achieves Phase Substantial Completion for a Phase prior to with respect to ▇▇▇▇▇ ▇, ***, with respect to Phase 2 or Phase 4, ***, with respect to ▇▇▇▇▇ ▇, ***, or achieves the PV Power Plant Substantial Completion prior to the PV Power Plant Substantial Completion Guaranteed Date, Contractor shall be entitled to a bonus payment (“Bonus Payment”) from Owner in the amount of $***.

  • Subject to Contractor’s obligation to pay Delay Liquidated Damages to the extent set forth herein, Contractor shall have the period (the “Performance Testing Period”) through and including the ninetieth (90th) day following the Substantial Completion Guaranteed Date during which Contractor shall run, and, if necessary, re-run each of the Performance Tests necessary to demonstrate compliance with Performance Guarantees.


More Definitions of Substantial Completion Guaranteed Date

Substantial Completion Guaranteed Date means [___________].
View Source
Substantial Completion Guaranteed Date means the date that is no later than twenty (20) months after the Starting Date of Construction as extended (if applicable) for so long as necessary (i) for the Gas Purchaser to connect the Plant to the grid; (ii) to account for extreme weather conditions during construction and/or due to other Events of Force Majeure; or (iii) to account for or delays due to Principal including Principal’s delay in providing the Plant with Sufficient Substrates. This date coincides with the start of the liquidated damages if the Contractor is late meeting this guaranteed date.
View Source
Substantial Completion Guaranteed Date means the date that is no later than thirteen (13) months after the Starting Date of Construction as extended (if applicable) for so long as necessary (i) for the Power Purchaser to connect the Plant to the grid, so long as delay is not caused by Contractor’s default of its obligations under this Agreement; (ii) to account for extreme weather conditions during construction and/or due to Events of Force Majeure; (iii) to account for or delays due to any actions or omissions of Principal in breach of this Agreement, including Principal’s delay in providing the Plant with Sufficient Substrates; or (iv) as required due to changes to the Workflow Plan agreed to by Principal;
View Source
Substantial Completion Guaranteed Date means, with respect to the first Unit, the date of ***, and, with respect to the second Unit, the date of ***, as such dates may be modified in accordance with the terms hereof.
View Source

Related to Substantial Completion Guaranteed Date

  • Guaranteed Substantial Completion Date means [ ], as may be adjusted by Change Order according to Article VIII.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Completion Guaranty means the Completion Guaranty of even date herewith executed by Guarantor in favor of Lender in connection with the Capital Improvement Work and the Loan, as amended from time to time.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Completion Date or “Completion Date” means the date by which the overall Development of the Project is completed in accordance with the provisions of this Agreement and when the Completion Certificate is issued by the Authority as per Article 14.1.