Unit Completion definition

Unit Completion means the mechanical and electrical completion of the Unit in accordance with the Codes, the Connection Agreement and the standards of a Reasonable and Prudent Operator, and where applicable the issue of the relevant Unit Completion Form in accordance with clause 4.4.1 (Early Operating Period);
View Source
Unit Completion has the meaning given in Clause 7.4.2(g); "Unit SPAs" has the meaning given in Clause 7.4.2(e); "Unused Call" has the meaning given in Clause 15.5.3;
View Source
Unit Completion has the meaning set forth in the Construction Contract. “Unit Owner” means the residential owner or purchaser of a Unit.
View Source

Examples of Unit Completion in a sentence

  • Agent agrees to effect Substantial Completion of any Unit Improvements on or before the applicable Unit Completion Date.

  • If any Unit Improvements are partially or totally damaged or destroyed by fire or any other cause and the restoration thereof cannot reasonably be expected to be completed so that the Unit Improvements will be completed on or before the applicable Unit Completion Date, subject to any Force Majeure Delay.

  • The Agency shall give notice to the Trustee, in accordance with Section 7.3, when Construction Unit Completion for each Construction Unit and Final Completion, respectively, has been achieved.

  • If a Service or Deliverable is not complete for any reason, Customer shall provide written notification to Subcontractor and document that fact on the WAN Unit Completion Certificate.

  • If a Service of Deliverable is not complete for any reason, Predictive Systems shall have Customer provide written notification to Cisco and document that fact on the WAN Unit Completion Certificate.

  • Predictive Systems shall have Customer indicate its acceptance of the Service or Deliverable by signing the WAN Unit Completion Certificate within five (5) business days from presentation of the completed Service or Deliverable.

  • Promptly after receipt of such notice, the Construction Supervisor shall determine, by whatever means it deems appropriate, whether it agrees that such Mechanical Completion has occurred, and if the Construction Supervisor so agrees, then the Construction Supervisor shall provide prompt written notice of such Mechanical Completion (a "Coking Unit Completion Notice") to the Disbursement Agent and TEC.

  • The completion of the C-410/C-420 Complex in FY 2016 marks the completion of the D&D OU Pre-GDP shutdown scope (“Paducah Federal Facility Agreement—Decontamination and Decommissioning Operable Unit Completion Notification Letter,” PPPO-02-3334049-16, dated April 11, 2016).

  • Customer shall indicate its acceptance of the Service or Deliverable by signing the WAN Unit Completion Certificate within fifteen (15) days from presentation of the completed Service or Deliverable.

  • The Contractor shall use the critical path method to monitor and analyze the factors that are delaying or could delay achieving Construction Unit Completion of any Construction Unit.


More Definitions of Unit Completion

Unit Completion means, with respect to a Unit:
View Source

Related to Unit Completion

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Construction Completion Date or “Completion Date” means the date by which the overall Development of the Project is completed in accordance with the provisions of this Agreement and when the Completion Certificate is issued by the Authority as per Article 14.1.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity