Common use of ADDITIONAL SERVICES OF ENGINEER Clause in Contracts

ADDITIONAL SERVICES OF ENGINEER. If authorized in writing by OWNER, ENGINEER shall provide, or obtain from other qualified persons or firms, Additional Services which are not included as part of the Basic Services specified in Section 1. Additional Services shall include, but are not limited to, the following: 2.1. Services resulting from significant changes in the general scope, extent or character of the Project designed or specified by ENGINEER or its design including, but not limited to, changes in size, complexity, OWNER's schedule, character of construction or method of financing; and revising previously accepted studies, reports, design documents or Contract Documents when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to the preparation of such studies, reports or documents, or are due to any other causes beyond ENGINEER’s control. 2.2. Preparing documents for alternate bids requested by OWNER for Contractor's work which is not executed or documents for out-of-sequence work. 2.3. Services resulting from the award of more than one separate prime contract for construction, materials or equipment for the Project unless multiple awards were contemplated and included as part of Basic Services in Section 1. 2.4. Assistance in connection with rebidding or renegotiating contracts for construction which involve modifying the Contract Documents to revise the Project's general scope, extent or character as necessary to reduce or increase the Construction Cost to bring it within the cost limit. 2.5. Preparing to serve or serving as a consultant or witness for OWNER in any litigation, arbitration or other legal or administrative proceeding involving the Project. 2.6. Services in making revisions to Contract Documents occasioned by the acceptance of substitutions proposed by Contractor; and services after the award of the construction contract in evaluating and determining the acceptability of an unreasonable or excessive number of substitutions proposed by Contractor. 2.7. Services resulting from significant delays in Project schedule which occurred through no fault of ENGINEER. 2.8. Additional or extended services during construction made necessary by (a) work damaged by fire or other cause during construction; (b) a significant amount of defective, neglected or delayed work of Contractor or supplier; (c) protracted or extensive assistance in the startup or utilization of any equipment or system; (d) acceleration of the progress schedule involving services beyond normal working hours; and

ADDITIONAL SERVICES OF ENGINEER. If authorized in writing by OWNER, ENGINEER shall provide, or obtain from other qualified persons or firms, Additional Services which are not included as part of the Basic Services specified in Section 1. Additional Services shall include, but are not limited to, the following: 2.1. Services resulting from significant material changes in the general scope, extent or character of the Project designed or specified by ENGINEER or its design including, but not limited to, changes in size, complexity, OWNER's schedule, character of construction or method of financing; and revising previously accepted studies, reports, design documents or Contract Documents when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to the preparation of such studies, reports or documents, or are due to any other causes beyond ENGINEER’s control. 2.2. Preparing documents for alternate bids requested by OWNER for Contractor's work which is not executed or documents for out-of-sequence work. 2.3. Services resulting from the award of more than one separate prime contract for construction, materials or equipment for the Project unless multiple awards were contemplated and included as part of Basic Services in Section 1. 2.4. Assistance in connection with rebidding or renegotiating contracts for construction which involve modifying the Contract Documents to revise the Project's general scope, extent or character as necessary to reduce or increase the Construction Cost to bring it within the cost limit. 2.5. Preparing to serve or serving as a consultant or witness for OWNER in any litigation, arbitration or other legal or administrative proceeding involving the Project. 2.6. Services in making revisions to Contract Documents occasioned by the acceptance of substitutions proposed by Contractor; and services after the award of the construction contract in evaluating and determining the acceptability of an unreasonable or excessive number of substitutions proposed by Contractor. 2.7. Services resulting from significant delays in Project schedule which occurred through no fault of ENGINEER.of 2.8. Additional or extended services during construction made necessary by (a) work damaged by fire or other cause during construction; (b) a significant amount of defective, neglected or delayed work of Contractor or supplier; (c) protracted or extensive assistance in the startup or utilization of any equipment or system; (d) acceleration of the progress schedule involving services beyond normal working hours; and