After the Possession Date Sample Clauses

POPULAR SAMPLE Copied 1 times
After the Possession Date. Tenant shall defend, indemnify and hold harmless Landlord and the City from and against any and all liabilities, losses, damages, costs, expenses, claims, obligations, penalties, and causes of action (including without limitation, reasonable attorneys' fees and expenses) whether based upon negligence, strict liability, absolute liability, product liability, misrepresentation, contract, implied or express warranty or any other principle of 169 law or equity, that are imposed upon, incurred by or asserted against Landlord or the City or which Landlord or the City may suffer or be required to pay (except (A) to the extent caused by the intentional acts or omissions, or the sole negligence of Landlord or the City or their employees, agents, or contractors or (B) where Landlord or the City or their employees, agents or contractors are liable with a third party or parties other than Tenant or JCC Development or their respective employees, agents, or contractors) and which arise out of or relate in any manner to: (i) the ownership, possession, use, condition or occupancy of the Leased Premises or any part thereof or any Improvement thereon; (ii) the operation or management of the Development; (iii) any failure on the part of Tenant to perform or comply with any of the terms of this Lease, the Second Floor Non-Gaming Sublease, the GDA or any other agreement affecting the Casino or the Development to which Tenant is a party; (iv) any failure on the part of JCC Development to perform or comply with any of the terms of the Second Floor Non-Gaming Sublease; (v) the construction or remodeling of the Casino (including any Alterations) or the performance of any labor or services or the furnishing of any 170 material for or on the Development or any part thereof, any enforcement thereon after the Possession Date or the failure to pay for such labor, service or furnishing of material as and when required; (vi) any personal injury, death or property damage suffered or alleged to have been suffered by Tenant or JCC Development (including Tenant's or JCC Development's employees, agents or servants), the Casino Manager/Operator (including its employees, agents or servants), any Space Tenant or any third person on or about the Development after the Possession Date; (vii) any work or things whatsoever done in, on or about the Development or any portion thereof after the Possession Date; (viii) any act or omission of a design professional, contractor, subcontractor, equipment les...
View Source
After the Possession Date. Landlord or its employees, agents or contractors has Tenant's permission to enter the Premises as needed for testing shell and core construction and Building systems as required to obtain any necessary permits for the Building. Landlord will not be liable for any delay in opening of Tenant's Premises as a result of such testing. Landlord will use reasonable efforts to conduct such testing so as not to unreasonably interfere with the construction of the Tenant Improvements.
View Source

Related to After the Possession Date

  • Possession and Control The Grantor has exclusive possession and control of its Equipment and Inventory.

  • TERM; POSSESSION The Term shall commence on the Commencement Date and ---------------- shall expire, if not sooner terminated pursuant to the provisions of this Lease, on the Expiration Date. On the Commencement Date, the Premises and Equipment Space are accepted by Tenant in "as is" condition and configuration (subject to the completion of the Landlord Work). By taking possession of the Premises and Equipment Space, Tenant agrees that the Premises and Equipment Space are in good order and satisfactory condition, and that there are no representations or warranties by Landlord regarding the condition of the Premises, Equipment Space or the Building except as may be expressly set forth herein. If Landlord is delayed in delivering possession of the Premises and Equipment Space or any other space, Landlord shall use reasonable efforts to obtain possession of the space, but no such delay shall nullify this Lease or give rise to any claim for damages on the part of Tenant. If Tenant takes possession of the Premises or Equipment Space before the Commencement Date, such possession shall be subject to the terms and conditions of this Lease except that, prior to the Rent Commencement Date, Tenant will not be required to pay Rent hereunder. Notwithstanding the foregoing, if the Commencement Date does not occur by the date that is one hundred fifty (150) days following the mutual execution and delivery of this Lease (the "Outside Delivery Date"), Tenant, as its sole remedy, may terminate this Lease by giving Landlord written notice of termination after the Outside Delivery Date. In such event, and subject to the provisions set forth below in this Article 3, this Lease shall be deemed null and void and of no further force and effect and Landlord shall promptly refund any prepaid Rent and Security Deposit previously advanced by Tenant under this Lease and the parties hereto shall have no further responsibilities or obligations to each other with respect to this Lease. Landlord and Tenant acknowledge and agree that the Outside Delivery Date shall be postponed by the number of days the Commencement Date is delayed due to events of Force Majeure (as defined herein). Notwithstanding the foregoing to the contrary, if Tenant exercises its right to terminate this Lease as set forth above but Landlord delivers the Premises to Tenant in the condition required by this Lease within thirty (30) days after the date of Tenant's delivery of Tenant's termination notice, this Lease shall continue in full force and effect the same as if Tenant had not delivered its termination notice, and Tenant's termination notice will be null and void. Tenant's right to terminate as described herein shall be null and void as of the Commencement Date.

  • Happen After We Receive Your Letter When we receive your letter, we must do two things:

  • Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.

  • POSSESSION AND CLOSING If BUYERS timely perform all obligations, possession of the Property shall be delivered to Buyers on April 10, 2020, and any adjustments of rent, insurance, interest and all charges attributable to the SELLERS' possession shall be made as of the date of possession. Closing shall occur after the approval of title by BUYERS and vacation of the Property by ▇▇▇▇▇▇▇, but prior to possession by BUYERS. SELLERS agree to permit BUYERS to inspect the Property within 0 hours prior to closing to assure that the premises are in the condition required by this Agreement. If possession is given on a day other than closing, the parties shall make a separate agreement with adjustments as of the date of possession. This transaction shall be considered closed: Upon the delivery of the title transfer documents to BUYERS and receipt of all funds then due at closing from BUYERS under the Agreement.