Common use of Agreement Exceptions/Deviations Explanation Clause in Contracts

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Items

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Organization City State Contact Name Contact Phone Contact Email Dallas County Community Colleges Dallas TX ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ Dallas County Community Colleges Dallas TX ▇▇▇▇▇ ▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇@▇▇▇▇▇.▇▇▇ Cedar Valley College DCCCD Dallas TX ▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Due to character restrictions, the Agreement language, all such deviations must be listed on response to this Bid Attributes this attribute, with complete and detailed conditions and question is included in the form of a information included. TIPS will consider any deviations in Response Attachment. entitled its proposal award decisions, and TIPS reserves the right "AMERESCO_Attributes to accept or reject any proposal based upon any deviations Q84_Agreement indicated below. In the absence of any deviation entry on Exceptions-Deviations Explanation". this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone City of Casa Grande ▇▇▇▇▇ ▇▇▇▇▇▇, Management Analyst ▇▇▇▇▇▇_▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 520.421.8661 Arizona State University ▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇. Project Manager - Energy Innovations ▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇.▇▇▇.▇▇▇▇ Orange Unifed School ▇▇▇▇▇ ▇▇▇▇▇▇, Director of Maintenance & Operations ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 714.936.3738 New Mexico State University ▇▇▇▇ ▇▇▇▇▇▇▇, Associate VP for Facilities and Services ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ 575.646.2101 Bee County, Texas Judge ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇.▇▇▇.▇▇.▇▇ 361.621.1556 San ▇▇▇▇▇▇▇▇ County, Texas Judge ▇▇▇▇▇ ▇. Simpson ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇.▇▇▇-▇▇▇▇▇▇▇▇.tx.us 361.364.9301 City of Rockport, Texas ▇▇▇▇▇ ▇▇▇▇▇▇▇, City Manager ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 361.729.2213 City of Smithville, Texas ▇▇▇▇▇▇ ▇▇▇▇▇▇, City Manager ▇▇▇▇▇▇▇▇▇▇▇@▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇.▇▇ 512.237.3282 City of Wichita Falls, Texas ▇▇▇ ▇▇▇▇▇▇▇, Deputy City Manager ▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 940.761.7615 Prairie View A&M University ▇▇. ▇▇▇▇▇▇▇ ▇▇▇▇▇▇, Assistant Vice President for Business Services ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 936.261.2194 Texas A&M University - Corpus Christi ▇▇▇▇▇▇▇ ▇.▇. ▇▇▇▇▇▇▇▇, Contracts Manager, ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ 361.825.3918 ▇▇▇▇▇ County Water Reclamation District ▇▇▇▇ ▇▇▇▇▇▇, Assistant General Manager ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 702.668.8266 Part 1 – RFP 180203 Renewable Energy and Solar Solutions and Services Part 2 – RCSP 180203 Renewable Energy and Solar Solutions and Services The certificates provided herein are intended to highlight Ameresco’s good standing with industry accreditors, insurers, professional licensing agencies, and governmental bodies, particularly those within the State of Texas. • Texas Certificate of Authority • Texas Board of Professional Engineers Certificate of Registration • Certificates of Insurance • North American Board of Certified Energy Practitioners (NABCEP) Certifications (individual) Part 1 – RFP 180203 Renewable Energy and Solar Solutions and Services Part 2 – RCSP 180203 Renewable Energy and Solar Solutions and Services Ameresco, Inc. (NYSE: AMRC) is a leading, independent full-service provider of comprehensive energy and water services including energy efficiency, infrastructure upgrades and renewable energy solutions for clients throughout North America. Ameresco’s only business is energy and water, and the execution of comprehensive HVAC solutions and services is supported by our dedicated company of professionals. Our team of utility experts will develop and deliver custom solutions that meet the energy, economic, operational and sustainability goals of the TIPS Member. Since Ameresco’s inception, we have designed and implemented over $5 billion in energy projects. Over the past five years, we have completed over $2.4 billion in energy projects for government entities throughout North America, including cities and counties, the federal government, state agencies, higher education institutions, K-12 public and private schools, commercial and industrial clients, and non-profit organizations. With over 1,000 employees and 70 offices, Ameresco has a long and successful track record in the specialized areas of energy efficiency, water conservation and renewable energy with a national portfolio of comprehensive engineering services for mechanical and electrical upgrades and water infrastructure. Clients value our understanding of complex systems, accurate cost and savings projections, ability to coordinate with other ongoing site activities, quality assurances, and emphasis on client service and satisfaction. Energy and Water Efficiency Energy Supply Integrated Services Renewable Energy Energy Information Turnkey/Design Build Utility Budgeting Conservation Landfill Gas Utility ▇▇▇▇ Analysis, Processing & Payment ENERGY STAR Reporting Greenhouse Gas Reporting Automated Demand Response Asset Planner Facility Renewal Water and Energy Audits Commodity Procurement Asset Monetization Plant Rehabilitation Biogas Biomass Demand-Side Management Automated Meter Reading Rate Analysis Negotiation Facilities Management On-Site Cogeneration Solar Photovoltaic Solar Thermal Advanced Metering Infrastructure Performance-Based Contracting Utility Meter Replacements Price Risk Mitigation Greenhouse Gas Management Distributed Generation Geothermal Wind Utility Meter Radio Retrofits LED Streetlight and Smart City

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇▇ ISD ▇▇. ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ ISD ▇▇. ▇▇▇ ▇▇▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 817-297-5800 Lubbock ISD ▇▇. ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Lubbock ISD ▇▇. ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 806-219-0150 Cleburne ISD ▇▇. ▇▇▇▇▇ Hipp ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Frenship ISD ▇▇. ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Frenship ISD ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Abilene ISD ▇▇. ▇▇▇▇ Owens ▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 325-671-5000 Greenville ISD Mr. Shannon Fulp ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 903.408.4407 ▇▇▇▇ ▇▇▇▇ ISD Mr. ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ County Mr. ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇.▇▇▇▇▇▇▇.▇▇.us 903-813-4259 Wichita County ▇▇. ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇.▇▇▇▇▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Grand Prairie Police Department ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Parish Episcopal School ▇▇. ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Fort Worth Country Day School ▇▇. ▇▇▇▇▇ Slayton ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ U.S. Army Corps of Engineers Ms. ▇▇▇▇▇▇▇ Adidas ▇▇▇▇▇▇▇.▇.▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of Wolfforth ▇▇. ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇ 806-866-4215 X-Fab ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ 180204 Fire Safety and Security Solutions Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor We do not carry Agreement language, all such deviations must be listed on Products/Completed Operation this attribute, with complete and detailed conditions and insurance, we provide service not a information included. TIPS will consider any deviations in product. We do however cover the its proposal award decisions, and TIPS reserves the right $1,000,000.00 requirement as our to accept or reject any proposal based upon any deviations Umbrella policy is $5,000,000.00 indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Tarrant County ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of Fort Worth ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Dallas Independent School District ▇▇▇▇ Boston ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFP 180306 Technology Solutions Products and Services (2) Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone City of Dallas ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Dallas ▇▇▇ ▇▇▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Dallas ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Dallas ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Northwest ISD ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Family Medical Group ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Texas A&M Engineering Experiment Station ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ 180203 Renewable Energy and Solar Solutions and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ County Gregg Cannon ▇▇▇▇▇.▇▇▇▇▇▇@▇▇.▇▇▇▇▇▇.tx.us ▇▇▇-▇▇▇-▇▇▇▇ South Texas Nuclear Project ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of Friendswood ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Greater Houston Partnership ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Eagle Mountain-Saginaw ISD ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇-▇▇▇.▇▇▇ 817-232-0880 Avaya enterprise solutions solve key challenges like supporting users through a scattered and mobile workforce, managing personal devices in the office, or driving consistent customer experiences. Designed from the ground up to simplify phone system administration, ShoreTel’s PBX phone solutions run on our solid state appliances or virtualized on your servers, and is ideal for organizations that want hands-on control. From IP phones to desktop devices and applications, Mitel has the industry’s broadest portfolio of business phones. Customized solutions that provide easy access and feature rich. Alert Logic provides a managed Security-as- a-Service solution that integrates innovative security technology, human analytics, and responsive communication to deliver the highest- quality security outcome for companies that Fortinet’s security fabric can intelligently protect your entire network: from the endpoint to the cloud and everywhere in between, delivering industry-leading, end-to-end simplified security that won’t slow you down. WatchGuard solutions put IT security pros back in charge of their networks with widely deployable, enterprise-grade security and threat visibility tools suitable for any organization, regardless of budget, size, or complexity.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Homewood SD 153 Dr. ▇▇▇▇ ▇▇▇▇▇▇-CSBO ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of Chicago/Fleet and Facilities Mgt. ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Skokie SD 68 ▇▇▇▇ ▇▇▇▇▇- Asst. CSBO ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor none Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ Schools ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 501−860−5791 Greenbrier Schools ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 501−679−4808 Hamburg Schools ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 870−807−2111 ▇▇▇▇▇▇▇▇ Schools ▇▇. ▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇.▇▇▇.▇▇.▇▇ 870−741−7600 Hope Schools ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 870−722−2700 ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Shannon ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 870−349−2232 Malvern Schools ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 501−332−7500 Lake ▇▇▇▇▇▇▇▇ Schools ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 501−318−8322 ▇▇▇▇▇▇ Schools ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 501−268−6954 Batesville Schools ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 501−593−2861 Cave City Schools ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇▇.▇▇▇.▇▇.▇▇ 870−283−3330 Southside Bee Branch Schools ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 501−654−2633 ▇▇▇▇▇▇▇ Schools Gary Wayman ▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 479−637−3177 TaylorƒEmerson Schools ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 870−547−2218 ▇▇▇▇▇▇ Schools ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 870−226−8500 Hot Springs Schools ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 507−624−3372 Nemo Vista Schools ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇.▇▇▇.▇▇.▇▇ 501−893−2925 Sheridan Schools ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 870−942−3135 March 09, 2018 The Interlocal Purchasing System ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇ RE: TIPS Bid #180204 – Warranty Information Dear TIPS I am pleased to offer this warranty letter as part of our proposal for BID #180204. Our standard warranty period for TIPS purchases is 1 year from date of substantial completion for all installation projects. Services provided on a T&M basis carry a 1 year warranty from date of service. Manufacturer warranties on products that exceed our warranty period are passed through to the customer but do not cover any associated labor to facilitate the repair. Warranty is excluded for acts of God, failure to properly maintain the equipment, neglect, abuse or modifications not made by us. Sincerely

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Due to character restrictions, the Agreement language, all such deviations must be listed on response to this Bid Attributes this attribute, with complete and detailed conditions and question is included in the form of a information included. TIPS will consider any deviations in Response Attachment. Please find its proposal award decisions, and TIPS reserves the right Ameresco’s response in the file to accept or reject any proposal based upon any deviations named “AMERESCO_Attributes indicated below. In the absence of any deviation entry on Q84_Agreement this attribute, the proposer assures TIPS of their full Exceptions-Deviations”. compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Bee County, Texas Judge ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇.▇▇▇.▇▇.▇▇ 361.621.1556 San ▇▇▇▇▇▇▇▇ County, Texas Judge ▇▇▇▇▇ ▇. Simpson ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇.▇▇▇-▇▇▇▇▇▇▇▇.tx.us 361.364.9301 City of Rockport, Texas ▇▇▇▇▇ ▇▇▇▇▇▇▇, City Manager ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 361.729.2213 City of Smithville, Texas ▇▇▇▇▇▇ ▇▇▇▇▇▇, City Manager ▇▇▇▇▇▇▇▇▇▇▇@▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇.▇▇ 512.237.3282 City of Wichita Falls, Texas ▇▇▇ ▇▇▇▇▇▇▇, Deputy City Manager ▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 940.761.7615 Prairie View A&M University ▇▇. ▇▇▇▇▇▇▇ ▇▇▇▇▇▇, Assistant Vice President for Business Services ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 936.261.2194 Texas A&M University - Corpus Christi ▇▇▇▇▇▇▇ ▇.▇. ▇▇▇▇▇▇▇▇, Contracts Manager, CTCM ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ 361.825.3918 RCSP 180101 Comprehensive HVAC Solutions and Services Part 2 – Installation and Construction on Site Considered a Public Work – Job Order Contract (JOC) The certificates provided herein are intended to highlight Ameresco’s good standing with industry accreditors, insurers, professional licensing agencies, and governmental bodies, particularly those within the State of Texas. • Texas Certificate of Authority • Texas Board of Professional Engineers Certificate of Registration • Certificates of Insurance RCSP 180101 Comprehensive HVAC Solutions and Services Part 2 – Installation and Construction on Site Considered a Public Work – Job Order Contract (JOC)

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Blackboard understands the intent Agreement language, all such deviations must be listed on of this RFP to result in an award of a this attribute, with complete and detailed conditions and cooperative purchasing agreement information included. TIPS will consider any deviations in therefore, if awarded the business its proposal award decisions, and TIPS reserves the right pursuant to this RFP, Blackboard to accept or reject any proposal based upon any deviations looks forward to negotiating mutually indicated below. In the absence of any deviation entry on agreeable terms with TIPS based this attribute, the proposer assures TIPS of their full upon our standard cooperative compliance with the Vendor Agreement. 85 Texas Business purchasing agreement terms. The terms will outline the obligations between TIPS and Commerce Code § 272 SB 807 prohibits construction contracts Blackboard such as pricing, administrative fees (if any), and the process by which a member procures the relevant product/service. When a member of TIPS wishes to have provisions (No Response Required) Requirements as procure Blackboard’s products/services via this RFP award, it will be a direct agreement between Blackboard and the member based upon Blackboard’s standard licensing terms. However, if TIPS desires to negotiate standard licensing terms on behalf of 9-1-2017 requiring their members, then such terms would be based on the contract to be subject following ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/bbinc/black which are material to the laws use of another statethe Blackboard product/services. 81 Felony Conviction Notice Texas Education Code, to be required to litigate the contract in another stateSection 44.034, Notification of B. Firm not owned nor operated by Criminal History, Subsection (a), states “a person or to require arbitration in another state. A felon; per above business entity that enters into a contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, school district must give advance notice to the district if the person or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, an owner or materials suppliers. “Construction contracts” are for operator of the design, construction, alteration, renovation, remodeling, or repair business entity has been convicted of any building or improvement to real property, or for furnishing materials or equipment for the projecta felony. The term also includes moving, demolition, notice must include a general description of the conduct resulting in the conviction of a felony.” Subsection (b) states “a school district may terminate a contract with a person or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Itemsbusiness entity if the district determines that the person or business entity failed to give notice as required by Subsection (a) or misrepresented the conduct resulting in the conviction.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Organization City State Contact Name Contact Phone Benton School Districct Benton AR ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Pulaski County Special School District Little Rock AR ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Lonoke Schools Lonoke AR ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ eStem Little Rock AR ▇▇▇ ▇▇▇▇ 501-748-9335 Advanced Cabling Systems ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇. ▇▇▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ Phone ▇▇▇.▇▇▇.▇▇▇▇ Fax ▇▇▇.▇▇▇.▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ School District ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ School District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Pulaski County Circuit Clerk ▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ArcBest Technologies/ABF Freight ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Little Rock School District ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ is a premier provider of low voltage installation, design and engineering. C Squared Networks – Tech Made Easy

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Little Elm ISD ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 972-947-9340 ▇▇▇▇▇ ISD ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇.▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Paris ISD ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 903-737-7473 Rainkin ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 432-693-2455 Office Depot ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇., ▇▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 817-480-4808 ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇@workspaceinteri ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ OfficeWise ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 806-420-1237 ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Tejas Office Interiors ▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 713-864-4557 ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇ ▇▇▇▇▇ Associates ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇., Houston TX 77004 713-541-5468 Noa ▇. ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information includedincluded or attached. TIPS will consider any deviations in its proposal award decisions, and the TIPS reserves the right to accept or reject any proposal based upon any deviations indicated belowbelow or in any attachments or inclusions. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have provisions used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (No Response Required3) Requirements as references. Entity Name Contact Person Email Phone Berkeley County Schools, WV ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Johnson County Schools, KY ▇▇▇ ▇▇▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Grant County Schools, WV ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFQ 200209 CMTA, Inc. ▇▇▇▇▇▇ ▇▇▇▇▇ Project Manager CORPORATE SEAL E SIGNATUR 3/25/20 DATE CONFIDENTIAL INFORMATION SUBMITTED IN RESPONSE TO COMPETITIVE PROCUREMENT REQUESTS OF EDUCATION SERVICE CENTER REGION 8 AND TIPS (ESC8) IS GOVERNED BY TEXAS GOVERNMENT CODE, CHAPTER 552 If you consider any portion of 9-1-2017 requiring the contract your proposal to be confidential information and not subject to public disclosure pursuant to Chapter 552 Texas Gov't Code or other law(s), you must attach a copy of all claimed confidential materials within your proposal and put this COMPLETED form as a cover sheet to said materials then scan, name “CONFIDENTIAL” and upload with your proposal submission. (You must include all the laws confidential information in the submitted proposal. The copy uploaded is to indicate which material in your proposal, if any, you deem confidential in the event the receives a Public Information Request.) ESC8 and TIPS will follow procedures of another statecontrolling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law. Upon your claim and your defense to the Office of Texas Attorney General is required to make the final determination whether the information submitted by you and held by ESC8 and TIPS is confidential and exempt from public disclosure. CMTA Inc. ▇▇▇▇▇▇ ▇▇▇▇▇, Project Manager ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇., ▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 502-409-4062 I DO CLAIM parts of my proposal to be required confidential and DO NOT desire to litigate expressly waive a claim of confidentiality of all information contained within our response to the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the projectsolicitation. The term also includes moving, demolition, attached contains material from our proposal that I classify and deem confidential under Texas Gov't Code Sec. 552 or excavationother law(s) and I invoke my statutory rights to confidential treatment of the enclosed materials. BY RESPONDING ATTACHED ARE COPIES OF 89 PAGES OF CLAIMED CONFIDENTIAL MATERIAL FROM OUR PROPOSAL THAT WE DEEM TO THIS SOLICITATION, BE NOT PUBLIC INFORMATION AND WHEN APPLICABLE, THE PROPOSER AGREES WILL DEFEND THAT CLAIM TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 ATTORNEY GENERAL IF REQUESTED WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIESA PUBLIC INFORMAITON REQUEST IS MADE FOR OUR PROPOSAL. Line ItemsSignature ▇▇▇▇▇▇ ▇▇▇▇▇ Digitally signed by ▇▇▇▇▇▇ ▇▇▇▇▇ DN: C=US, ▇=▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇, O=CMTA Inc., OU=Energy Solutions, CN=▇▇▇▇▇▇ ▇▇▇▇▇ Reason: I am approving this document Date: 2020.05.05 09:54:26-04'00' Date 5/5/20 I DO NOT CLAIM any of my proposal to be confidential, complete the section below.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone State of Florida ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Unuiversity of Wisconsin Crescent Kringle ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇▇.▇▇▇ ▇▇▇ ▇▇▇-▇▇▇▇ State of Texas (TXMAS) ▇▇▇▇▇▇▇ San Jose ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Maricopa County Employee Program ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ (former Director) Ergonomist, MA CPE ASCM ▇▇▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ 360 OFFICE SOLUTIONS ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Billings MT ▇▇▇ ▇▇▇▇ ▇▇▇▇@▇▇▇-▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇-▇▇.▇▇▇/ CAPITAL OFFICE SYSTEMS ▇▇▇▇ ▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇-▇▇▇▇▇▇.▇▇▇ 907-777-1500 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇-▇▇▇▇▇▇.▇▇▇/Home CIS - CORPORATE INTERIOR SYSTEMS ▇▇▇▇ ▇ ▇▇▇▇▇▇▇▇ ▇▇. #▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 602.304.0100 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇.▇▇▇/ FACILITEC ▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇ RD. PHOENIX AZ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇-▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇-▇▇▇.▇▇▇/ GOODMANS INC ▇▇▇▇ ▇. ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇▇ 602.263.1110 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ INTERIOR SOLUTIONS- AZ ▇▇▇▇ ▇ ▇▇▇▇ ▇▇ POC: ▇▇▇▇▇ 480.223.9228 PHOENIX AZ Cat Heyn ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ OFFICE DEPOT/OFFICE MAX ▇▇▇ ▇. ▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ OMNI WORKSPACE COMPANY LLC DBAATMOSPHERE COMMERCIAL INTERIORS, LLC - AZ ▇▇▇▇ ▇.▇▇▇▇▇▇ Dr. Phoenix AZ Rock ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ RECONDITIONED SYSTEMS ▇▇▇ ▇. ▇▇▇▇ ▇▇. ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ 800-280-5000 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ TUCSON BUSINESS INTERIORS ▇▇▇ ▇ ▇▇▇▇▇▇ ▇▇▇ #▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇-▇▇▇.▇▇▇ 520.620.1555 ▇▇▇▇://▇▇▇.▇▇▇-▇▇▇.▇▇▇/ WORKSPACES - AZ ▇▇▇▇ ▇. ▇▇▇▇ ▇▇. ▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 602.956.1550 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ CORE BUSINESS INTERIORS ▇▇▇▇ ▇ ▇▇▇▇▇▇ ▇▇▇▇▇ 103 FRESNO CA ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 559.297.6400 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇▇▇ & COMPANY BMEA ENTERPRISES INC ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇ POWAY CA ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇-▇▇.▇▇▇ 858-513-6584 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇-▇▇.com/ INSIDE SOURCE/YOUNG ▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇. ▇▇▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 415-399-5300 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇.▇▇▇/ MILES ▇▇▇▇▇▇▇▇ & ASSOCIATES ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇ #▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 916.373.1800 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/ ONE WORKPLACE L. FERRARI ▇▇▇▇ ▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇ SANTA CLARA CA ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ PIVOT INTERIORS ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 657-232-9300 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ PIVOT INTERIORS ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇#▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 408-432-5600 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ SIDEMARK CORPORATE FURNITURE - SNCL ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ SANTA CLARA CA ▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 408.490.3300 ▇▇▇▇://▇▇▇▇▇▇▇▇.▇▇▇/ TANGRAM INTERIORS-SANTE FE SPGS ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ SANTA FE SPRINGS CA ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇▇▇ COMMERCIAL FURNITURE ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ #▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 213.629.0009 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇.▇▇/ CONTRACT FURNISHINGS INC - CO ▇▇▇▇ ▇. ▇▇▇▇ ▇▇▇. ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 720-956-1515 ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ OFFICESCAPES - DENVER ▇▇▇▇ ▇. ▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ WORKPLACE ELEMENTS LLC - CO DBA ELEMENTS ▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇ 303.471.4334 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ WORKPLACE RESOURCE - DEN ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/ OFFICE FURNITURE INC (OFI) CONTRACT INTERIORS ▇▇ ▇▇▇▇▇▇▇▇ ▇▇. ▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 800.283.3357 ▇▇▇▇://▇▇▇.▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇▇ Office Furnishings - CT ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇.▇▇▇/ EVENSONBEST - DC ▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 202-540-5700 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/main6/ COMPASS OFFICE SOLUTIONS ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇-▇▇▇▇▇▇.▇▇▇ 954-430-4590 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇-▇▇▇▇▇▇.▇▇▇/ EMPIRE OFFICE - FL ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇ 561.826.6868 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇.▇. ▇▇▇▇▇ OFFICE FURNITURE ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ 954-499-6677 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇.▇▇▇/ OFFICE ENVIRONMENTS AND SERVICES ▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇. ▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 850-434-1165 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/ REFURBISHED OFFICE FURNITURE ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇. ▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/ MODERN BUSINESS SYSTEMS INC. ▇▇▇▇ ▇▇▇▇▇▇ ▇▇ AUGUSTA GA ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 706.724.8700 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ NFL OFFICEWORKS- GA ▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/ FENS ASSOCIATES - GA ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 770-889-8884 ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ SAXTON ▇▇▇ ▇▇▇ ▇▇. ▇▇▇▇▇ #▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 319-365-6967 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/ FENS ASSOCIATES - MA ▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 978-372-2650 ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ PRICE MODERN LLC - DC ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 301-459-8111 ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ PRICE MODERN LLC - MD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇ BALTIMORE MD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 410-366-5500 ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ CREATIVE ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇-▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇-▇▇▇▇▇▇▇▇@▇▇▇-▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ALTERNATIVE BUSINESS FURNITURE ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ #▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 952.937.7688 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ GENERAL OFFICE PRODUCTS CO ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇.▇▇▇/ INNOVATIVE OFFICE SOLUTIONS ▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 866.574.5389 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ NORTHERN BUSINESS PRODUCTS ▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 218-726-0167 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/ OFFICE SOLUTIONS & SERVICES ▇▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ 406-541-2020 ▇▇▇▇://▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇▇▇ OFFICE SYSTEMS - NC ▇▇▇ ▇▇▇▇▇▇ ▇▇▇. Charlotte NC ▇▇▇▇ ▇▇▇▇▇▇▇▇ IV ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 704-525-7912 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇ OFFICE ENVIRONMENTS OF THETRIAD ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇.▇▇▇/ COMMERCIAL FURNITURE INTERIORS ▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇ 908.518.1670 ▇▇▇▇://▇▇▇▇▇▇▇▇▇.▇▇▇/ EVENSONBEST - NJ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ SUITE 2100 BERKELY HEIGHTS NJ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 908-663-2700 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/main6/ ▇▇▇▇▇▇▇ Office Furnishings - NJ 90 ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇. ▇▇▇, ▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇.▇▇▇/ BUSINESS ENVIRONMENTS- NM ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ EVENSONBEST - NY ▇▇▇ ▇▇▇ ▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 212-549-8000 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/main6/ ▇▇▇▇▇▇▇ Office Furnishings - NY ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇.▇▇▇/ CONTINENTAL OFFICE ENVIRONMENTS ▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 614-262-5010 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ KING BUSINESS INTERIORS ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ #D COLUMBUS OH ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ 614-430-0020 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/ RSFI RECYCLED SYSTEMS FURNITURE INC ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ RD WORTHINGTON OH 614.880.9110 ▇▇▇▇://▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇ Worksystems Inc ▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇)-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ INTERIOR OFFICE SOLUTIONS- OR ▇▇▇ ▇ ▇▇▇▇▇▇▇▇ #▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇.▇▇▇ 503.534.0200 ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ INTERIOR WORKPLACE SOLUTIONS ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇. ▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/home ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇- ▇▇ ▇▇▇▇ ▇▇▇▇▇▇'▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 267 553 1000 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇.▇▇▇/ HERALD OFFICE SYSTEMS ▇▇▇ ▇ ▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ 843-556-1007 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇'▇ OF COLUMBIA, INC ▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 803.254.1656 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ MY OFFICE PRODUCTS- OH ▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ Deal ▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ OFFICEWORKS, LLC - TN ▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇ KNOXVILLE TN ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 865.588.7280 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ HST CORPORATE INTERIORS ▇▇▇ ▇▇▇▇▇▇ ▇▇▇ NASHVILLE TN ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 615-321-9590 ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ BUSINESS INTERIORS BY STAPLES- STX ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/office-furniture/#/ BUSINESS INTERIORS- TX ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ DEBNER+COMPANY ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇.▇▇▇ 713.782.1300 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/PAGES/Home/Index.html THE OFIS BY ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇ #▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇.▇▇▇/ TURNKEY PROJECT SERVICES LLC ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇ #▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ CCG ▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 801.359.6622 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ DESIGN GROUP - UT ▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 801.363.5881 ▇▇▇▇://▇▇▇▇.▇▇▇/ INTERIOR ALLIANCE ▇▇▇ ▇▇▇▇▇▇ ▇▇▇. FARMINGTON UT ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 801-694-1855 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ MIDWEST COMMERCIAL INTERIORS ▇▇▇ ▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ COMMERCIAL OFFICE INTERIORS- WA ▇▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 206.448.7333 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ FACILITEC OF WASHINGTON ▇▇▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇-▇▇▇.▇▇▇ 206.435.7700 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇-▇▇▇.▇▇▇/ OPEN SQUARE - Seattle (WorkspaceDevelopment) ▇▇▇▇ ▇▇▇ ▇▇▇ ▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇@▇▇▇▇-▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇-▇▇.▇▇▇/ CJ & ASSOCIATES, INC. ▇▇▇▇▇ ▇. ▇▇▇▇▇▇ ▇▇. ▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 262-786-1772 ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ SCHOOL SPECIALTIES ▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇://▇▇▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Facility RX ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇ Antonio TX ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 210-690-5800 ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ Workplace Resource ▇▇▇▇ ▇. ▇▇▇ ▇▇. ▇▇▇. ▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇.▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone University of North Texas ▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas A & M Commerce ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Tarrant County College District ▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas Tech University Health Science Center ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ University of North Texas Health Science Center ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas Christian University ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇.▇.▇▇▇▇▇▇@▇▇▇.▇▇▇ 817.257.7229 Tarrant County ▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Wall ISD ▇▇▇▇ ▇▇▇▇ ▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ 325-651-7790 Texas Tech University Kallee Smith ▇▇▇▇▇▇.▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of Lubbock ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇.▇▇▇▇▇▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ BKM ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇., Ste 100, Dallas, TX 75220 214.902.7200 ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ FMG ▇▇▇▇ ▇ ▇▇▇▇▇ ▇▇▇▇., ▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 214.556.4700 ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 214-764-6400 ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ Intelligent Interiors ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇., ▇▇▇. ▇▇▇, ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 972.716.9979 ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Interior Resources ▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇., ▇▇▇., ▇▇▇, ▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 972.619.7400 ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Plano Office Supply ▇▇▇ ▇▇▇▇▇▇ ▇,▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 972-424-8561 ▇▇▇ ▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇ & ▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇▇., #300, Fort Worth, TX 76107 817.332.5424 Honor ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇-▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇ Co. ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇., #▇▇▇, ▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 214.720.0345 ▇▇▇ ▇▇▇▇▇▇ ▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Workplace Resource Group ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇., ▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 972.389.8845 ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Workplace Solutions ▇▇▇▇ ▇. ▇▇▇▇▇▇▇, Ste. 300, Dallas, TX 75201 214.741.9667 ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Officewise ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇, Lubbock, TX 79452 806.372.2236 ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Navajo ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇, Lubbock, TX 79452 806.331.1658 ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Built for Dreams ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 806.771.6806 ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Business Interiors ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 817 858 2357 ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ MeTEOR ▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇., ▇▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 352.373.7516 ▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ LetourneauKeller ▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 713.681.0033 ▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Velocity ▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇., #▇▇▇, ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 281.453.0101 ▇▇ ▇▇▇▇▇▇ ▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ Educator's Depot ▇▇▇▇ ▇▇▇▇ ▇▇▇, ▇▇▇▇▇▇▇, TX 77417 936.443.6723 ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ECFS, LLC ▇▇▇▇▇ ▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 281.255.8548 ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Jtyler ▇▇▇▇ ▇▇▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 713.468.2166 Jessy Fuller ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Costal Office Products ▇▇▇▇ ▇. ▇▇▇ ▇▇▇▇▇▇ St., Victoria, TX 77901 361.578.5392 ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Gateway Printing & Office Supply ▇▇▇ ▇. ▇▇▇▇▇▇▇ Blvd., Edinburg, TX 78539 956.383.3861 ▇▇▇▇ ▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Facility RX ▇▇▇▇ ▇. ▇▇. ▇▇▇▇'▇ ▇▇., ▇▇▇ ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 210.690.5800 ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ Cubicle Concepts ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 281.715.6362 ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Workspace Resource ▇▇▇▇▇ ▇-▇▇ ▇▇▇▇▇, ▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 936.756.1512 ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇.▇▇▇ Office Furniture Innovations ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇., ▇▇▇ ▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 713.868.2634 ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ office Pavilion ▇▇▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 713.803.0000 ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ TOPS-Texas Office Products & Supply ▇▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇, ▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ 512.497.3395 ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇.▇▇▇ via seating warranty statement via seating has one of the strongest warranties in the industry. via seating warrants to the initial purchaser, that product will be free from defects in its materials and craftsmanship found during normal single shift usages; single shift usage is five (5) days a week, eight

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ CJ Energy ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ EnerMech Logistics ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ School District ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Richland School District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Bellevue School District ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Ridgefield School District ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Portland Public Schools ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ 180202 Portable Modular Buildings Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Contract # W9124C-17-C-0015 Contract # W912L7-16-F-0112, contract # W912L7-16-F-0116, contract # W912L7-18-F-7007 ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇.▇.▇▇▇▇▇.civ@▇▇▇▇.▇▇▇ ▇▇▇▇▇ Sales ▇▇▇▇▇.▇.▇▇▇▇▇.▇▇▇@▇▇▇▇.▇▇▇ Buy # RFQ1099947, Buy # RFQ1195922 ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇.▇.▇▇▇▇▇▇▇.mil@▇▇▇▇.▇▇▇ Contract # FA4897-16-F-0014 ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇.▇▇.▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, andContracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered intAon. y person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best ohf is or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone San Antonio ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ c ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ ISD ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ Springs ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ This resellers document is for proposers to list any other companies that resell their products. Only list resellers of your products that are located in the US or Canada.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 830-334-8001 Terrebonne Parish School District ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Kerrville ISD ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 830-257-4883 Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone GSA Thais Midnight ▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ University of Oklahoma ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ US Department of State ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ County of Santa Clara, California Rene Rodriquez ▇▇▇▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ 360 OFFICE SOLUTIONS ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ BILLINGS MT 59106 ▇▇▇▇@▇▇▇-▇▇.▇▇▇ ▇▇▇▇://▇▇▇-▇▇.▇▇▇/ ABACUS COMPUTERS INC ▇ ▇▇▇▇▇ ▇▇ MIDLAND TX 79705-5512 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇-Land, Inc ▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/ ACCENT COMMERCIAL FURNITURE ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇.▇▇▇/ ACCESS ERGONOMICS - SAN ▇▇▇▇ ▇▇▇▇-▇ ▇▇▇▇▇▇▇▇ #▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ADAPTIVE LIVING ▇▇▇▇ ▇.▇. ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ADVANCED ERGONOMIC CONC. ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇-▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇-▇▇▇▇.▇▇▇/ ADVANCED OFFICE ENVIROMENTS ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ADVANTAGE OFFICE SOLUTIONS ▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ RICA GA 30180 ▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ AECOM ▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇.▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇.▇▇▇/ Affordable Office Interiors ▇▇▇ ▇. ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ AIR TECHNOLOGIES CORPORATION ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇.▇▇▇/ AK BUSINESS INTERIORS ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ GROUP INC. ▇▇▇▇▇ ▇.▇. ▇▇▇▇. ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ - GREENSBORO ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇. ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇-RALEIGH/DURHAM ▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ALIMED INC. ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇; KStran ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇/ ALL MAKES OFFICE EQUIPMENT CO ▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇.▇▇▇/ ALTERNATIVE BUSINESS FURN. ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 952937-7691 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ALTERNATIVE OFFICE SOLUTIONS ▇▇▇ ▇. ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇-▇▇▇▇▇▇.▇▇▇/ AMERICAN INTERIORS ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ OH 43615 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇; ▇▇▇▇▇▇@ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ AMERICAN ▇▇▇▇▇▇ ▇▇▇ ▇ ▇▇▇▇▇▇▇ ▇▇ BALTIMORE MD 21202 ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ AMERICAN OFFICE PRODUCTS INC. ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇ ▇▇▇▇▇'▇ OFFICE FURNITURE, INC ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ANTON GROUP, LLC ▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇.▇▇▇/ AOI - OMAHA ▇▇▇▇ ▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇.▇▇▇/ APEX FACILITY RESOURCES INC-WPFU ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ accountspayable@apexfacility.c ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ APG OFFICE FURNISHINGS ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇.▇▇▇/ APPLIED ERGONOMICS ▇▇▇▇ ▇ ▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇▇ OFFICE FURNISHINGS ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇.▇▇▇/ ARRANGED4COMFORT ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇ #▇▇ ▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇ ▇. ▇'▇▇▇▇, INC. ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ASSEMBLED PRODUCT SPECIALISTS ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ATD-AMERICAN CO ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/atd/Shop? ATLANTA OFFICE FURNITURE ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ BLVD ▇▇▇▇▇▇▇▇ GA 30071 ▇▇▇▇.CRAVEN3@ATLOFFICEFURN ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/Default.asp ATLAS DESK & ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇. ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/ ATTRONICA COMPUTERS, INC ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ GAITHERSBURG MD 20877 ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/Main.asp AUSTIN BUS FURNITURE ▇▇▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ AWE CORPORATE INTERIOR ▇▇ ▇. ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇ STREET OFFICE FURNISHINGS CO ▇.▇. ▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇ 46850-0042 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ ▇▇▇▇▇▇▇▇▇ WORKPLACE SOLUTIONS ▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇-▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ BBE OFFICE INTERIORS ▇▇▇ ▇▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇/ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone South Carolina State Government ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Wake County Public School Systems ▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Liberty County Schools ▇▇. ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFP 180306 Technology Solutions Products and Services (2) Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Coppell ISD ▇▇▇ ▇▇▇▇▇ (Assistant Superintendent) ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Southlake ▇▇▇▇▇▇▇ ISD ▇▇▇▇▇▇▇ Milller (Assistant Superintendent) ▇▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Bedford ▇▇▇▇▇ ▇▇▇▇▇▇▇ (Library Manager) ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ University of North Texas ▇▇▇▇▇▇▇▇ ▇▇▇▇ (Staff Architect) ▇▇▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ University of Texas at Dallas ▇▇▇▇ ▇▇▇▇▇▇▇ (Staff Engineer) ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Dallas ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ (Project Manager) ▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ 180203 Renewable Energy and Solar Solutions and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor We request the Indemnity section in Agreement language, all such deviations must be listed on the TIPS 180406 Vendor Agreement this attribute, with complete and detailed conditions and be modified to read: "Vendor further information included. TIPS will consider any deviations in agrees to indemnify and hold its proposal award decisions, and TIPS reserves the right harmless and defend TIPS, TIPS to accept or reject any proposal based upon any deviations Member(s), officers and employees, indicated below. In the absence of any deviation entry on from and against all claims and suits this attribute, the proposer assures TIPS of their full by third parties for injuries (including compliance with the Vendor Agreement. 85 death) to an officer, employee, agent, subcontractors, supplier or equipment lessee of the Vendor, arising out of, or resulting from, Vendor’s negligent or intentional acts performed under this Agreement." Vendor will indemnify TIPS for vendor's negligence or intentional acts performed under this agreement but believes that it is unreasonable for vendor to indemnify TIPS for negligent or intentional acts by TIPS or TIPS Members, Officers, etc. 84 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Items85 Yes - No Disadvantaged/Minority/Women Business Enterprise - No D/M/WBE (Required by some participating governmental entities) Vendor certifies that their firm is a D/M/WBE? Vendor must upload proof of certification to the ”Response Attachments” D/M/WBE CERTIFICATES section. 86 YES or NO Federal Requirements for Procurement and Contracting with small and minority businesses, women's business enterprises, and labor surplus area firms. Do you ever anticipate the possibility of subcontracting any of your work under this award if you are successful? NO 87 YES or NO If yes to #86, do you agree to comply with the following federal requirements? Federal Regulation 2 CFR

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 83 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone City of Little Rock Honorable Mayor ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 501.371.4510 City of ▇▇▇▇▇▇ Honorable Mayor ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 501.860.7004 University of Arkansas at Fayetteville ▇▇▇▇ ▇▇▇▇▇▇▇, Associate Vice Chancellor for Facilities ▇▇▇▇▇@▇▇▇▇.▇▇▇ 479.575.6192 Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Hemet Unified School District ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ St. ▇▇▇▇▇▇ County Schools ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ LaFourche Parish Public Schools ▇▇▇▇ ▇▇▇▇▇▇▇ mdelatte@mylpsd ▇▇▇-▇▇▇-▇▇▇▇ Southern Local School District ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ 330-679-2343 TKOED INCLUDES a LIFETIME PARTS REPLACEMENT WARRANTY on any desktops, notebooks, or select Chromebooks. This offer applies to both our professionally refurbished units as well as any NEW units that we are offering. For brand new equipment, our extended coverage "kicks-in" after the OEM warranty expires. All the “fine print” on our warranty can be found online as well as attached on page 2 of this document. So why should this be such a big deal for you? We all know that with any electronic equipment, components will sometimes fail. This is not debatable. What’s important is how to manage these failures and their long-term costs. The TKOED LIFETIME PARTS REPLACEMENT WARRANTY is designed to help you manage these costs. Two main goals in mind:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES - Vanguard Modular Building Systems Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone New Jersey Schools Development Authority Pemberton Township Board of Education, NJ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇. Program Officer ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Shelby County Schools Memphis, ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ Major Construction Manager ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Kenner Discovery Health Sciences Academy ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇ ▇▇▇ ▇. ▇▇▇▇ Director of Operations ▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Steelton Highspire School District Steelton, Pennsylvania ▇▇▇ ▇▇▇▇▇▇ Director of Construction ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Allentown School District Allentown, Pennsylvania ▇▇▇▇▇▇ ▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ Community Action Smithfield, North Carolina E. ▇▇▇▇▇ ▇▇▇▇▇▇ Executive Director ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ Mount Public Schools Rocky Mount, North Carolina ▇▇▇▇▇▇▇ ▇▇▇▇▇ Director of Maintenance ▇▇▇▇▇▇@▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ North Carolina Dept of Health and Human Services - Div. of Property and Construction Raleigh, North Carolina ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ Facilities Architect ▇▇▇▇.▇▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇ Public Schools Westbrook, Maine ▇▇▇▇ ▇▇▇▇▇▇▇▇ Business Manager ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Saco Public Schools Saco, Maine ▇▇▇▇ ▇▇▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of Northampton Northampton, Massachusetts ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ Director of Central Services ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Worcester State University Worcester, Massachusetts ▇▇▇▇▇▇ ▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of ▇▇▇▇▇▇ Borger, Texas ▇▇▇ ▇▇▇▇▇▇ Fire chief ▇▇▇▇▇▇▇@▇▇.▇▇▇▇▇▇.▇▇.us ▇▇▇-▇▇▇-▇▇▇▇ City of ▇▇▇▇▇ Pharr, Texas ▇▇▇▇ ▇▇▇▇▇▇▇ Purchasing Director ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇-▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Germanna Community College Fredericksburg, ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Washington County School District ▇▇▇. ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Worcester County School District ▇▇. ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ District of Columbia Public Library ▇▇. ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Mercedes Independent School District ▇▇. ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ ISD ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇, Tech Director ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇▇, Tech Director ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ISD ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇, Tech Director ▇.▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFP 180306 Technology Solutions Products and Services (2) Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ ISD ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ FRISCO ISD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ MINERAL ▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ 171001 Audio Visual Equipment, Supplies and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Texas Tech University ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Education Service Center Region 17 ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ West Texas A&M University ▇▇▇▇▇ ▇▇▇ ▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas Tech University ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas Tech University ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ 171001 Audio Visual Equipment, Supplies and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Mesquite ISD ▇▇▇▇▇ ▇▇▇▇▇, Purchasing ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ ISD ▇▇▇▇▇▇ ▇▇▇▇▇, Technology Director ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 903-433-1542 Dallas ISD ▇▇▇▇ ▇▇▇▇▇▇, Senior Buyer ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Highland Park ISD ▇▇▇▇▇ ▇▇▇▇▇, Campus Technology ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ City ISD ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Canton ISD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Brownsboro ISD ▇▇▇▇▇ ▇▇▇▇▇▇-▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Dallas Community College District ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, Technical Buyer ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone International Education Services Rico ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Brownsville Navigation District ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 956-831-4592 Brownsville Public Utilities Board Brownsville Public Utilities Board ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇-▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas Southmost College ▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Mercedes Independent School District ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ County Independent School District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 956-765-6546 City of Brownsville ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Mission Consolidated I.S.D ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Brownsville Independent School District Heriberto Castillo ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ American Surveillance Co The Texas Comptroller of Public Accounts (CPA) administers the Statewide Historically Underutilized Business (HUB) Program for the State of Texas, which includes certifying minority-, woman- and service disabled veteran-owned businesses as HUBs and facilitates the use of HUBs in state procurement and provides them with information on the state's procurement process. We are pleased to inform you that your application for certification/re-certification as a HUB has been approved. Your company's profile is listed in the State of Texas HUB Directory and may be viewed online at ▇▇▇▇▇://▇▇▇▇▇.▇▇▇.▇▇▇▇▇.▇▇.▇▇/tpasscmblsearch/index.jsp. Provided that your company continues to meet HUB eligibility requirements, the attached HUB certificate is valid for the time period specified. You must notify the HUB Program in writing of any changes affecting your company’s compliance with the HUB eligibility requirements, including changes in ownership, day-to-day management, control and/or principal place of business. Note: Any changes made to your company’s information may require the HUB Program to re-evaluate your company’s eligibility. Please visit our website at ▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇.▇▇▇▇▇.▇▇▇/procurement/prog/hub/ and reference our publications (i.e. Grow Your Business pamphlet, HUB Brochure and Vendor Guide) providing addition information on state procurement resources that can increase your company’s chances of doing business with the state. Thank you for your participation in the HUB Program! If you have any questions, you may contact a HUB Program representative at ▇▇▇-▇▇▇-▇▇▇▇ or toll-free in Texas at ▇-▇▇▇-▇▇▇-▇▇▇▇. Certificate/VID Number: 1742936956800 File/Vendor Number: 043555 Approval Date: 17-AUG-2016 Scheduled Expiration Date: 17-AUG-2020 has successfully met the established requirements of the State of Texas Historically Underutilized Business (HUB) Program to be recognized as a HUB. This certificate printed 19-AUG-2016, supersedes any registration and certificate previously issued by the HUB Program. If there are any changes regarding the information (i.e., business structure, ownership, day-to-day management, operational control, business location) provided in the submission of the business’ application for registration/certification as a HUB, you must immediately (within 30 days of such changes) notify the HUB Program in writing. The CPA reserves the right to conduct a compliance review at any time to confirm HUB eligibility. HUB certification may be suspended or revoked upon findings of ineligibility. Note: In order for State agencies and institutions of higher education (universities) to be credited for utilizing this business as a HUB, they must award payment under the Certificate/VID Number identified above. Agencies, universities and prime contractors are encouraged to verify the company’s HUB certification prior to issuing a notice of award by accessing the Internet (▇▇▇▇▇://▇▇▇▇▇.▇▇▇.▇▇▇▇▇.▇▇.▇▇/tpasscmblsearch/index.jsp) or by contacting the HUB Program at ▇▇▇-▇▇▇-▇▇▇▇ or toll-free in Texas at ▇-▇▇▇-▇▇▇-▇▇▇▇. Rev. 06/16 This Limited Warranty applies to new ASC products purchased and installed from an authorized ASC representative by the original purchaser for normal use and not for resale. ASC warrants that a covered product is free from defects in materials and workmanship, with the exceptions stated below. This limited warranty lasts for 1 year, or a fixed period from date of purchase, depending on when and where it was originally purchased. The limited warranty does not cover damage resulting from, misuse, accident, modification or alteration to hardware or software, tampering, unsuitable physical or operating environment beyond product specifications, improper maintenance, or failure caused by a product for which ASC is not responsible. There is no warranty for loss of data—you must regularly back up the data stored on your product to a separate storage product. There is no warranty for product with removed or altered identification labels. ASC DOES NOT PROVIDE ANY OTHER WARRANTIES OF ANY KIND. If you are having trouble with a product, before seeking limited warranty service, first follow the troubleshooting procedures that ASC or the consumer product provides. To obtain limited warranty service, you must first contact ASC to assure that all options have been exhausted in attempting to correct the issue. You should remove all personal information from the product prior to its return (if applicable). ASC will replace the product with a functionally equivalent replacement. ASC may replace your product with a product that was previously used, repaired and tested to meet ASC specifications. Data Recovery is not covered under this warranty and is not part of the warranty returns process. ASC warrants that the replaced products are covered for the remainder of the original product warranty or 90 days, whichever is greater. ASC AND ITS AFFILIATES, SUPPLIERS, DISTRIBUTORS, AND RESELLERS ARE NOT LIABLE FOR ANY OF THE FOLLOWING: 1) THIRD-PARTY CLAIMS AGAINST YOU FOR DAMAGES; 2) LOSS OF, OR DAMAGE TO, YOUR DATA; OR 3) SPECIAL, INCIDENTAL, OR INDIRECT DAMAGES OR FOR ANY ECONOMIC CONSEQUENTIAL DAMAGES (INCLUDING LOST PROFITS OR SAVINGS), EVEN IF INFORMED OF THE POSSIBILITY. SOME JURISDICTIONS DO NOT ALLOW LIMITATION OF LIABILITY, INCIDENTAL DAMAGES, OR CONSEQUENTIAL DAMAGES, SO THE ABOVE LIMITATIONS MAY NOT APPLY TO YOU. THIS LIMITED WARRANTY GIVES YOU SPECIFIC LEGAL RIGHTS, AND YOU MAY ALSO HAVE OTHER RIGHTS WHICH VARY FROM JURISDICTION TO JURISDICTION.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to Line Items REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have provisions used your se the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (No Response Required3) Requirements as references. Entity Name Contact Person VALID EMAIL IS REQUIRED Phone St. ▇▇▇▇▇ Public Schools ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ Public Schools ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ Public Schools Troy James ▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ FAILURE TO PROPERLY COMPLETE THIS FORM AND SUBMIT WITH YOUR RESPONSE MAY RESULT IN A WAIVER OF YOUR RIGHTS UNDER THE LAW TO MAINTAIN CONFIDENTIALITY TREATMENT OF SUBMITTED MATERIALS. If you consider any portion of 9-1-2017 requiring the contract your proposal to be confidential information and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s), you must make a copy of all claimed confidential materials within your proposal and put this COMPLETED form as a cover sheet to said materials then scan, name “CONFIDENTIAL” and upload with your proposal submission. (You must include the laws confidential information in the submitted proposal as well, the copy uploaded is to indicate which material in your proposal, if any, you deem confidential in the event the receives a Public Information Request.) ESC8 and TIPS will follow procedures of another state, controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law. Pricing of solicited product or service may be deemed as public information under Chapter 552 Texas Gov’t Code. The Office of Texas Attorney General shall make the final determination whether the information held by ESC8 and TIPS is confidential and exempt from public disclosure. I claim part of my proposal to be required confidential and DO NOT desire to litigate expressly waive any claim of confidentiality as to any and all information contained within our response to the contract in another statecompetitive procurement process (e.g. RFP, or CSP, Bid, RFQ, etc.) by completing the following and submitting this sheet with our response to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the projectEducation Service Center Region 8 and TIPS. The term also includes movingattached contains material from our proposal that I classify and deem confidential under Texas Gov't Code Sec. 552 or other law(s) and I invoke my statutory rights to confidential treatment of the enclosed materials. ATTACHED ARE COPIES OF PAGES OF CONFIDENTIAL MATERIAL FROM OUR PROPOSAL Signature Date OR_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If you do not claim any of your proposal to be confidential, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Itemscomplete the section below only.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Unless otherwise stated in the quotation, the quotation of W i l l b a n k s C o n t r a c t o r S u p p o r t . (''WCS") is just an offer to sell the goods, m a t er ials, chattels, e q u i p m e n t or machinery as described in the quotation to be provided by W C S (collectively referred to as the "Products'') to the party purchasing the Products from WCS (the "Purchaser") and the offer and stated prices therein will remain valid for a period of (30) thirty days from the date hereof, at which time it will automatically expire unless extended by a signed document issued by W C S . After s u ch thirty (30) day period, the terms a n d prices are subject to c hange. Acceptance of the offer by Purchaser must be evidenced in writing from Purchaser and acknowledged by WCS, and may not be modified unless specifically agreed by W C S . No differing terms or provisions stated by Purchaser in its proposal or response shall be binding upon WCS unless accepted by WCS in writing. Purchaser is hereby notified of W C S 's specific r e jection of any additional or different terms, and W C S 's QUOTATION AND OFFER IS EXPRESSLY L I MITED TO ACCEPTANCE UPON THE TERMS AND CONDITIONS CONTAINED HEREIN. Unless s pecifically stated in the quotation, the Purchaser's selection of sizes, types, capacities, and specifications and suitability thereof for the specific application shall be the responsibility of the Purchaser or Purchaser's representative or consultant. Except in the particulars specified by the Purchaser and expressly agreed t o i n writing by W C S , a l l Products s h a ll be produced in accordance with W C S ’ s s t a n d a r d p r a c t i c e s . WCS reserves the right to deviate from tolerances and variations in the Products without notice, provided that the substitute part(s) or deviation(s) are consistent with the usage and performance of the Products. Unless defined otherwise in the quotation, prices are F.O.B. shipping point, exclusive of freight, storage, loading or off-loading, installation s e r v i c e, startup service, extended warranty or local delivery charges, if any.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor N/A Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Pasadena ISD ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Spring Branch ISD Gabby Cruz ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Houston ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Houston ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 713-942-1400 Clear Creek ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 281-284-0211 RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone United Independent School District ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Education Service Center Region 12 ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Weslaco High School ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ University of Montevallo ▇▇▇▇ ▇▇ ▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇)-▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Grand Prairie ISD ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Arlington ISD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Brazosport ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Fabens ISD ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Coppell ISD ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ McCamey ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇.▇▇▇▇▇.▇▇▇ 432-652-3666 Nederland ISD ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ Elementary, ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ (principal) ▇▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Mina Elementary, Bastrop ISD ▇▇▇▇ ▇▇▇▇ (principal) ▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Austin Independent School District ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ (district administration) ▇▇▇▇▇.▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Cabot School District ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇@▇▇▇.▇▇.▇▇ 501.743.3583 ▇▇▇▇▇▇ Chapel School District ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 870.879.0220 Fountain Lake School District ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 501.463.2752 ▇▇▇.▇▇▇-▇▇▇.▇▇▇ • WATER AND CHEMICAL SUPPRESSION • FIRE ALARM • STRUCTURED CABLING • ACCESS CONTROL • CCTV • INTERCOM • INTRUSION • • FIBER OPTICS • TESTING AND INSPECTIONS • INTRUSION MONITORING • VIDEO MONITORING • SOUND SYSTEMS • STRUCTURED CABLING CCTV / ACCESS CONTROL BURGLAR ALARM, NURSE CALL, INTERCOM & AREA OF RESCUE SERVICE, INSPECTION, INTRUSION MONITORING, VIDEO VERFICATION TRAINING, CERTIFICATIONS AND ASSOCIATIONS Regulated by: AR board of private investigators & private security agencies / ▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇. / ▇▇▇▇▇▇ ▇▇▇▇, ▇▇ ▇▇▇▇▇ / ▇▇▇-▇▇▇-▇▇▇▇ LICENSES - AR Security: CMPY1847 / AR Contractor: 0028470418 / AR Suppression: PF-194 / TX Fire: ACR-1765467 / OK Security: 1862 ▇▇▇.▇▇▇-▇▇▇.▇▇▇ • WATER AND CHEMICAL SUPPRESSION • FIRE ALARM • STRUCTURED CABLING • ACCESS CONTROL • CCTV • INTERCOM • INTRUSION • • FIBER OPTICS • TESTING AND INSPECTIONS • INTRUSION MONITORING • VIDEO MONITORING • SOUND SYSTEMS •

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Texas A&M - Galveston ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ 409.740.4461 Fort Bend County ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 281.341.8643 Sugar Land Traffic Management ▇▇▇▇ ▇▇▇▇▇▇ 281.275.2379 ‌ The Texas Comptroller of Public Accounts (CPA) administers the Statewide Historically Underutilized Business (HUB) Program for the State of Texas, which includes certifying minority and woman-owned businesses as HUBs and is designed to facilitate the participation of minority and woman-owned businesses in state agency procurement opportunities. We are pleased to inform you that your application for certification/re-certification as a H UB has been approved. Your company's profile is listed in the State of T exas HUB Direct ory and may be vie wed online at ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇▇▇.▇▇.▇▇/procurement//cmbl/hubonly.html. Provided that your company continues to meet HUB eligibility requirements, the enclosed HUB certificate is valid for four years. You must notify the HUB Program in writing of an y changes affecting your company’s compliance with the HUB eligibility requirements, including changes in o wnership, day-to-day management, control an d/or principal place of busin ess. Note: Any changes made to your company’s information may require the HUB Program to re-evaluate your company’s eligibility. As part of the HUB Program’s mo nitoring efforts, you will be s ent a H UB Certification Eligibility Affidavit i n approximately 24 months. Failure to complete and submit the HUB Certification Eligibility Affidavit, and/or failure to notify us of changes affecting your company’s compliance with HUB eligibility requirements, may result in the revocation of your company's certification. Please reference the encl osed pamphlet for additional resources, such as the state’s Central ized Master Bidders Lis t (CMBL), th at can increase your chance of doing business with the state. Thank you for your participation in the HUB Program! If you have any questions, you may contact a HUB Program representative at (▇▇▇) ▇▇▇-▇▇▇▇ or toll-free in Texas at (▇▇▇) ▇▇▇-▇▇▇▇. Certificate/VID Number: 1741297835900 File/Vendor Number: 083800 Approval Date: 27-APR-2017 Scheduled Expiration Date: 27-APR-2021 has successfully met the establi shed requirements of the State of Texas Hist orically Underutilized Business (HUB) Program to be recogni zed as a HUB. This certificate print ed 27-APR-2017, supersedes any registration and certificate previously issued by th e HUB Program. If there are any changes regarding the i nformation (i.e., business structure, ownership, day-to-day management, operational control, business location) provided in the submission of the business’ application for registration/certification as a HUB, you must immediately (within 30 days of such changes) notify the HUB Program in writing. The CPA reserves the right to conduct a compliance review at any time to confirm HUB eligibility. HUB certification may be suspended or revoked upon findings of ineligibility. Note: In order for State agencies and institutions of higher ed ucation (universities) to be cr edited for utilizing this business as a HUB, they must award payment under the Certificate/VID Number identi fied above. Agencies and universities are encouraged to validate HUB certificati on prior to issuing a notice of award by accessing the Internet ( ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇▇▇.▇▇.▇▇/procurement/cmbl/cmblhub.html) or by contacting the HUB Program at ▇-▇▇▇-▇▇▇-▇▇▇▇ or ▇▇▇- ▇▇▇-▇▇▇▇. WBENC National WBE Certification was processed and validated by Women's Business Enterprise Alliance, a WBENC Regional Partner Organization. NAICS: 238210, 334111, 334112, 334118, 423420, 423690, 425110, 512290, 518210, 532490, 541330, 541430, 541511, 541512, 541519, 561499 UNSPSC: 43201546, 43221506, 43221522, 43233502, 43233503, 45000000, 45110000, 45111704, 45111715, 45111716, 45111800, 45111810, 45111901, 45111902, 52161500, 52161600, 55111515, 56101706, 80161507, 81112207, 81161711, 83111506, 86141702, 90111602 Warranty Information for Audio Visual Technologies Group, Inc. All manufacturer warranties are transferred to customer upon completion of work, and warranty on labor and installation is 90 days. Extended warranties on labor and installation are available, and the price of those extended warranties vary based on project scope. 041128166 CAGE: 03MA0 AVTG is a professional services company that provides system integration, custom information technology, information security, consulting, digital technology, audio visual technologies, and programming services. AVTG builds government and enterprise data solutions, ranging from business process optimization to mission-critical software systems. Our mission critical, cutting- edge solutions include Command & Control and Real-Time Operation centers for government and enterprise clients, visualization solutions for the energy industry, and distance learning solutions for educational institutions. CORE COMPETENCIES Cybersecurity Services & Support Enterprise Customer Service  Cybersecurity Compliance  Agile Software Development  Information Assurance  Help Desk & Desktop Support Services  NOC/SOC Cybersecurity Services  IT Service Management (ITSM) Development and Deployment  Risk Assessment and Mitigation  Telecommunications Support Services  Intrusion Detection, Analytics, Monitoring  Audio Visual Support Services  Incident Handling and Mitigation  Video Conferencing and Telepresence Solutions & Services  FISMA Assessment Services  SharePoint Administration Support Services  24/7 Network and Security Operations and Data Center Support  Configuration Management & Inventory Database Management Project Planning & Management Services  Administrative and Operations Support  Business Communication Process Reengineering  Planning and Support  Data Analytics  Enterprise Resource Planning  Planning and Management Information Management  Enterprise Architecture & Technology Support  LAN/WAN Management  COTS Systems Integration  Disaster Planning & Operational Continuity Support  Software Technology Demonstration/Transition  Configuration Management & Standards Support CERTIFICATIONS NAICS CODES Set Aside Programs  SBA 8(a) Program Certified  Woman-Owned Business  Small Business  Small Disadvantaged Business Industry Connections  Microsoft Certified Partner  Polycom Certified Partner  Cisco Certified Partner  PMP Certified (PMI) 041128166 CAGE: 03MA0 PAST PERFORMANCE Designed and integrated operations center for Sugar Land Public Works, which houses a dedicated workstation room that serves as the city’s traffic management center (TMC). Features include the ability to monitor the 81 traffic signals maintained by the City of Sugar Land, control of the pan-tilt- zoom cameras installed at traffic signal locations. This technology provides the ability to analyze traffic conditions real-time, which become especially useful when managing emergency situations.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your ser the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Bangor High School ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Malverne High School ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ High School ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Plano Independent School District ▇▇▇▇▇ ▇▇▇▇▇▇▇▇, CTE Coordinator ▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Frisco Independent School District ▇▇▇▇ ▇▇▇▇▇▇, District Tech Applications Coordinator ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Compton Unified School District ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇, Director of CTE Education Services ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Mohawk Regional Information Center ▇▇▇▇▇▇ ▇▇▇▇▇, Model School Coordinator & Instrcutional Technologist ▇▇▇-▇▇▇-▇▇▇▇ These Terms and Conditions apply to all web, tablets, phone, fax or postal orders placed by you with LEGO Education North America, ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇▇▇▇▇▇, ▇▇▇▇▇▇ ▇▇▇▇▇▇. (hereinafter referred to as “LEGO Education”). These Terms and Conditions only apply to consumers. Once you have ordered and paid for your goods in the LEGO Education Shop, LEGO Education will send you an e-mail confirming the receipt for your payment online, details of your order and details regarding delivery, providing that you submitted an accurate e-mail address when placing your order. We cannot guarantee that all the ordered goods are available in our inventory at all times but we will ship these as soon as possible. If you have requested delivery to a different address, prices will not be included on the in-parcel receipt since we assume that the delivery shall be a gift to the recipient. Your pricing information will however be included on your order receipt email. If an order raises security concerns, the LEGO Group reserves the right to hold or cancel an order without a prior notice or explanation.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Lower Merion SD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇, Director of Operations ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ North Penn SD ▇▇▇▇▇▇ ▇▇▇▇▇▇, Construction Manager ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Rockford SD ▇▇▇▇▇▇ ▇▇▇▇▇▇▇, Architect ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Avon Grove Charter School ▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇, CFO ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Mobilease Modular Space Inc. is a premiere source for mobile and modular buildings. We rent, lease, sell and repurchase modular buildings in the education, commercial, healthcare and industrial industries. Our experienced staff of experts, located throughout the USA, can assist with initial design and planning as well as provide full turn-key services including site work, utility connections and installation. Our services ensure a smooth project resulting in the successful addition of necessary space. Customers choose from new modular buildings delivered and installed or their site or from our well-maintained inventory of existing buildings. Our expertise facilitates an expedited process while ensuring a timely, on budget, completion of our client’s project. Please see our website which provides a complete scope of our offerings and services. ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Floor Plan/Drawing See attached as reference Description Classroom/Office Building/Dormitory Exterior Dimensions Varied Floorplan as provided in RCSP 170903 Shipping Height 14'-2" State Approvals Seal - IBC as required by different states Construction Type V-B Occupancy Classification E - Education C - Commercial Frame Type Outrigger with main rails at 72" on center or as required by code. Floor Framing 3/4" tongue and groove plywood over 2" x 8" (SPF#2) at 16" on center or as required by code. Double side rails below all exterior and mate line walls. Insulation Kraft-faced R-22 or as required by code. Bottom Board Plastic, roll type mobileflex. Floor Live Load 40 PSF or as required by code. 1/8"x12"x12" commercial grade vinyl tile (Baths & wet areas) Floor Covering 24 oz., 100% solution dyed nylon, broadloom carpet with Teklok backing as manufactured by Shaw or equal 10 yr. warranty Cove Base 4" vinyl cove base Interior Wall Covering 1/2" vinyl covered gypsum / 5/8" type x fire rated vinyl covered wall as required by code Interior Wall Finish Group II, vinyl covered gypsum. Inside and Outside Corners Vinyl covered wood battens.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Dallas ISD ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 972.925.2166 Grand Prairie ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 972.343.6394 ▇▇▇▇▇▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇.▇▇▇ 469.593.0738 DocuSign Envelope ID: 2D0468D0-98E9-4B2A-BD1B-3F64D066D389 RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 83 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Department of Labor, Job Corps ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇▇▇.▇.▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇.3@▇▇.▇▇.▇▇▇ 202−413−6431 University of North Florida ▇▇▇▇▇▇▇ ▇▇▇▇▇ 904−620−2237 ▇▇▇▇▇ County Public School System ▇▇▇▇ ▇▇▇▇▇▇ 904−390−2498 Department of Justice, FBOP ▇▇▇▇ ▇▇▇▇ 202−532−5763 Department of Homeland Security, USCG ▇▇▇ ▇▇▇▇▇▇▇ 216−902−6110 United States Air Force, Eglin AFB ▇▇▇▇▇ ▇▇▇▇▇▇ 850−882−5628 ▇. ▇. ▇▇▇▇ Engineering, Inc. May 16, 2017 ▇▇▇▇ ▇. ▇▇▇▇ ▇.▇. ▇▇▇▇ Engineering, Inc. ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇, ▇▇▇▇▇ #▇ ▇▇▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ Dear ▇▇. ▇▇▇▇: The City of Jacksonville is pleased to announce that your company has been certified as a Jacksonville Small and Emerging Business Enterprise (JSEB). This certification enables your company to compete for work and perform work as a JSEB enterprise. JSEB certification does NOT guarantee work. -42 Engineering Consulting -33 Engineer Services, Professional -36 Engineering Services (Not Otherwise Classified) -37 Facilities Design Services, Engineering -42 Foundation Engineering -55 Inspecting, General/Engineering

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 83 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Port ▇▇▇▇▇▇ ISD ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 409−989−6184 Bridge City ISD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 409−735−1581 ▇▇▇▇▇ University ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 409−790−0911 Lumberton ISD Ricci Pampolina ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 409−658−2561 ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ TACLA23943C /LA Mechanical License #60856 Industrial and Commercial Mechanical is a complete Mechanical Service Company with offices located in Beaumont, Houston, & Corpus Christi Texas. We service all of Texas and Southwest Louisiana regions. We are fully capable of servicing all makes and models of Chillers, Heating, Air Conditioning, Ventilation, and Refrigeration Equipment and all Home Service’s including, Service, Repair, Installation, and Sales. We are highly experienced in all facility types including Industrial, Manufacturing, Warehousing, Institutional, Marine, and Retail facilities. We are prepared to handle all Preventative Maintenance, Troubleshooting, Design Analysis, and Repair of all types of HVACR equipment. We also have the capacity to service most Rotating Equipment applications including Laser Alignment. We have several types of Maintenance Programs available which gives us the ability to Tailor-Fit a Complete and Cost-Effective Maintenance and Repair Program to each Customer based on an analysis of their unique individual needs and circumstances. Each member of our Staff has more than 20 years’ experience in the industry in their respective roles with the Company. The members of our Highly Experienced Staff have been directly involved with a high percentage of the Industrial and Commercial Facilities in Texas and Southwest Louisiana Regions. Our technicians are Union Members and have been trained in the latest service techniques and technology involved in the manufacture, installation, and operating of modern HVACR equipment in addition to a vast bank of knowledge and experience with older equipment. We are committed to safety and promote safety awareness through our own Safety Program in addition to training through ISTC and Safety Council of SWLA. We are available 24/7 for emergency service on request. I invite you to contact me or any of our staff and give us an opportunity to learn about your facility’s equipment and develop a Maintenance and Repair Program to increase reliability and efficiency of the equipment to increase your business profitability.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇ University ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Univ of No Texas, Health Science ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ San Francisco Public Library ▇▇▇ ▇▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ County Library District ▇▇▇▇▇ ▇▇▇ ▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Tulsa Community College ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Cloud County Community College ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ System Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone City of Dallas ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Dallas ▇▇▇ ▇▇▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Dallas ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of Dallas ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Northwest ISD ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Family Medical Group ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Texas A&M Engineering Experiment Station ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone City of Atlanta - Office of the Mayor ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Virginia Technical Institute ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Piedmont Community College ▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇. Virginia Commonwealth University ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ Young University ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇_▇▇▇▇▇@▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Forsyth County (NC) Library ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ University ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Vector Security ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor N/A Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Ector County ISD Bestsabe ▇▇▇▇▇▇▇, Director of Bilingual ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 432.456.8751 ▇▇▇▇▇ CISD ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇, Bilingual Coord. ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 832.223.000 Tacoma Public Schools ▇▇▇▇▇ ▇▇▇▇▇▇▇, Asst. Elementary Dir. ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 253.571.1115 Denver Public Schools ▇▇▇▇▇▇▇ ▇▇▇▇, Manager Strategic Lit. Initiative ▇▇▇▇▇▇▇_▇▇▇▇@▇▇▇▇▇▇.▇▇▇ 720.423.3200 Galena Park ISD ▇▇▇▇▇▇ ▇▇▇▇, Program Dir.-Elem LA ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 832.386.1055 Okapi Educational Publishing, Inc Okapi Educational Publishing ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Executive Director Field Sales April 15, 2018 X X ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Okapi Educational Publishing, Inc April 15, 2018 ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Okapi Educational Publishing, Inc. ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Executive Director Field Sales 42381 Rio Nedo ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 866.652.7436

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Dallas ISD ▇▇▇ ▇▇▇▇▇▇▇ - Director of Library Media Srvs ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Arlington ISD ▇▇▇▇▇ ▇▇▇▇▇ - Library Director ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇, Euless, Bedford ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇ - Library Director ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ABDO guarantees 100% customer satisfaction with every title. Any unsatisfactory titles may be returned to the publisher within 30 days of their receipt for exchange.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES - Vanguard Modular Building Systems Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone New Jersey Schools Development Authority Pemberton Township Board of Education, NJ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ NJSDA Sr. Program Officer ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Shelby County Schools Memphis, Tennessee ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ Major Construction Manager ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Kenner Discovery Health Sciences Academy Kenner, Louisana ▇▇▇ ▇. ▇▇▇▇ Director of Operations A ▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Steelton Highspire School District Steelton, Pennsylvania ▇▇▇ ▇▇▇▇▇▇ Director of Construction ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Allentown School District Allentown, Pennsylvania ▇▇▇▇▇▇ ▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 484-765-4000 ▇▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ Community Action Smithfield, North Carolina E. ▇▇▇▇▇ ▇▇▇▇▇▇ Executive Director ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 919-934-2145 ▇▇▇▇ ▇▇▇▇▇ Mount Public Schools Rocky Mount, North Carolina ▇▇▇▇▇▇▇ ▇▇▇▇▇ Director of Maintenance ▇▇▇▇▇▇@▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ North Carolina Dept of Health and Human Services - Div. of Property and Construction Raleigh, North Carolina ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ Facilities Architect ▇▇▇▇.▇▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Westbrook Public Schools Westbrook, Maine ▇▇▇▇ ▇▇▇▇▇▇▇▇ Business Manager f ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 207-854-0800 Saco Public Schools Saco, Maine ▇▇▇▇ ▇▇▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 207-284-4505 City of Northampton Northampton, Massachusetts ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ Director of Central Services ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Worcester State University Worcester, Massachusetts ▇▇▇▇▇▇ ▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of ▇▇▇▇▇▇ Borger, Texas ▇▇▇ ▇▇▇▇▇▇ Fire chief ▇▇▇▇▇▇▇@▇▇.▇▇▇▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of ▇▇▇▇▇ Pharr, Texas ▇▇▇▇ Brouwen Purchasing Director ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇-▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Germanna Community College Fredericksburg, Virginia ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ Director of Facilities ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇-Euless-Bedford ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Round Rock ISD ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇_▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ College Station ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information includedincluded or attached. TIPS will consider any deviations in its proposal award decisions, and the TIPS reserves the right to accept or reject any proposal based upon any deviations indicated belowbelow or in any attachments or inclusions. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business No response REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Novant Healthcare ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Flextronics Corporation ▇▇▇▇▇ ▇▇▇▇▇, Vice President of Corporate Real Estate ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ United Laboratories (UL) ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ , CEO ▇▇▇▇ ▇▇▇▇▇▇▇ , CEO TIPS RFQ 200209 XECO Response - Attachment Item #9 – WARRANTY XECO warrants the Products shall be delivered free from defects in material, workmanship and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions title and that Installation Services shall be performed in a competent, diligent manner in accordance with any mutually agreed specifications. The warranty for Products shall expire three (No Response Required3) Requirements as years from installation. The warranty for installation work shall expire (90) days from the completion of 9-1-2017 requiring the contract to be subject to the laws installation. The warranties and remedies are conditioned upon proper storage, installation, use, operation, maintenance of another stateproducts, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, and modification or repair of the Products or Services only as authorized by XECO in writing. Failure to meet any building such conditions renders the warranty null and void. Seller is not responsible for normal wear and tear. This Warranty provides the exclusive remedies for all claims based on failure of or improvement defect in Products or Services, regardless of when the failure or defect arises, and whether a claim, however described, is based on Proposal, warranty, indemnity, tort/extra- Contractual liability (including negligence), strict liability of otherwise. The warranties provided in this paragraph are exclusive and are in lieu of all other warranties, conditions and guarantees whether written, oral, implied or statutory. NO IMPLIED OR STATUTORY WARRANTY, OR WARRANTY OR CONDITION OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE APPLIES. SUCCESSFUL EXPERIENCE IN THE FIELD OF ENERGY SAVINGS PERFORMANCE CONTRACTS a. Business unit dedicated to real property, providing guaranteed energy savings programs: - XECO’s whole business and company structure is dedicated to providing guaranteed energy savings programs. b. Business unit dedicated to ensuring project performance: - All managerial and operational units within XECO are continually dedicated to ensuring project performance for every customer and client in every project and facility. c. Affiliation with energy and/or business organizations (including ISO certification and EPA or for furnishing materials DOE affiliations: - XECO has met with energy and/or business organizations (including ISO certification and EPA or equipment DOE affiliations) for the projectpurposes of possible affiliation and discussion of the benefits to our customers. The term also includes movingIt has been mutually determined that there has been no requirement for action up to this point. XEXO remains open and willing to the possibility of affiliation as required by the Energy Savings Performance Contracts program with TIPS. STAFFING/PERSONNEL a. Quality of personnel assigned to projects and degree of pertinent experience: - XECO utilizes only licensed engineers and licensed electrical contractors on all projects. Wherever possible these team members are local to the customer, demolitionfamiliar with the facilities, or excavationand have prior experience working together. BY RESPONDING TO THIS SOLICITATIONSenior project management, AND WHEN APPLICABLEoperations, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIESand executive functions are performed in-house. Line ItemsFINANCIAL STRENGTH/BONDING CAPACITY a. Demonstrable ability to bond savings through third party surety:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Twinsburg City School District ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Yuba City Unified School District ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Cascadia Community College ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone NYC Mayor's Office ▇▇▇▇▇ ▇▇▇▇▇ - Acting Agency Chief Contracting Officer ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Office of New York City Comptroller ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ - Chief Diversity Officer ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Police Department ▇▇▇▇▇▇▇ ▇▇▇▇▇ -NYPD-TARU ▇▇▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Fire Department ▇▇▇▇▇▇▇ ▇▇▇▇ - Procurement Analyst ▇▇▇▇▇@▇▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Department of Investigation ▇▇▇▇▇ ▇. ▇▇▇▇▇ - Agency Chief Contracting Officer ▇▇▇▇▇▇@▇▇▇.▇▇▇.▇▇▇ 212.825.2875 NYC Department of Investigation ▇▇▇▇▇ ▇▇▇▇▇▇ - Procurement Analyst ▇▇▇▇▇▇▇@▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Department of Investigation ▇▇▇▇▇ ▇▇▇ - Procurement Analyst ▇▇▇▇@▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Department of Information Technology & Telecommunications ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ - Sr. Director of Vendor Client Relations ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Department of Information Technology & Telecommunications ▇▇▇▇▇▇▇ ▇ ▇▇▇▇▇▇▇ ▇▇. - Purchasing Analyst ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Department of Information Technology & Telecommunications ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ - IT Procurement Analyst, Contracts/Procurement ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ NYC Department of Information Technology & Telecommunications ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ - Purchasing Analyst ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ This resellers document is for proposers to list any other companies that resell their products. Only list resellers of your products that are located in the US or Canada.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 83 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone LINCOLN SCHOOL DISTRICT NO. 48−3340 ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 479−841−1763 MOUNTAIN HOME SCHOOL DISTRICT−4210 ▇▇▇▇ ▇▇▇▇▇▇ 870−421−▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇−3350 ▇▇▇▇▇ ▇▇▇▇▇▇ 479−531−2858 SG360 COMPANY OVERVIEW Our proprietary Thorough Cleaning System sets us apart, giving our clients a 360-degree full-circle cleaning experience. We recruit our own cleaning talent – thereby hiring better, paying better, training better – all with the end goal of providing better quality, service and performance for our clients. We call that the “▇▇▇▇▇ ▇▇▇.” Whether you’re in an office building, school, manufacturing facility, hospital or anything in between, productivity matters. A thorough cleaning service keeps germs from spreading and causing illnesses that prevent your staff from doing their best work.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 83 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Richmond State School ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇▇▇.▇▇.▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇.▇▇▇▇.▇▇▇ 281−344−4381 Pasadena ISD ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 713−740−0189 ▇▇▇▇▇▇ County Facilities & Poperty Mgmt ▇▇▇ ▇▇▇▇▇ 281−620−9146

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ County, Texas ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Florida Dept of Transportation ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇.▇▇▇▇▇@▇▇▇.▇▇▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Broward County, Florida ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Arlington County, VA ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ North Carolina Courts ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇ ▇▇▇-▇▇▇▇ This resellers document is for proposers to list any other companies that resell their products. Only list resellers of your products that are located in the US or Canada.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor N/A Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Arlington ISD ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Fort Worth ISD ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ S/ A Northside ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ 210-3978184 Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Guernsey Office Interiors ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Facilities Desing Consultants ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Contract Connections Inc. ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Virginia Correctional Enterprises ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Office Images ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Authorized Reselling Company Name Full Address Main Phone Contact Contact Ph Contact Email Website Fax Guernsey Office Interiors ▇▇▇▇▇ ▇▇▇ ▇▇ ▇▇., ▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Office Images ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇. Ste. 109, Rockville, MD 20885 ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇-▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇-▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Price Modern ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.; ▇▇▇▇▇▇, MD 20706 ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ 301-459-8111 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Interiors Resource Group ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇., ▇▇▇▇▇▇ ▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇ Business Interiors ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ American Design ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇. ▇▇▇. ▇▇▇, ▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 410-823-5508 Ball Office Products ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇ ▇▇., Richmond, VA 23230 ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇ 804-204-1774 ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Tactical ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇ ▇▇., Hampton, VA 23669 ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇.▇▇▇ The Supply Room ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇ 804-412-7500 ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ JMJ Workplace Interiors ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇ ▇▇▇▇▇ 804-270-7400 ▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Creative Workplace Interiors & Technology ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇-▇▇.▇▇▇ ▇▇▇▇▇▇▇▇-▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Staples ▇▇▇▇ ▇▇▇▇▇▇ ▇▇, San Antonio TX 78216 ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ FMG ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇.▇▇▇ ▇▇▇▇▇ Rockford ▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇ 713.865.4306 ▇▇▇ ▇▇▇▇▇ 713.865.4306 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇-▇▇▇▇▇▇▇▇.com DCI Interiors ▇▇▇▇-▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇, ▇▇▇ ▇▇▇, ▇▇▇ ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ 210-521-9900 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Texas ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 210.647.3110 Wittigs ▇▇▇▇ ▇▇▇▇▇▇ ▇ ▇▇▇▇▇ ▇▇▇, ▇▇▇ ▇▇▇▇▇▇▇, ▇▇, ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Workspace Resource ▇▇▇▇▇ ▇-▇▇ ▇▇▇▇▇, ▇▇▇▇▇ ▇, ▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ 936-756-1512 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇.▇▇▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇)▇▇▇.▇▇▇▇ Intereum ▇▇▇▇ ▇▇▇ ▇▇▇ ▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 763 417 3300 ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. 180305 - Alle Designs LLC - Page 17 of 18 Line ItemsItems 180305 - Alle Designs LLC - Page 18 of 18 ALLÉ Conference Pads Desk Accessories Wastebaskets Coat Hooks Wall Clocks Litter Receptacles Recyccle Receptacles Planters Benches Crowd Control Desk & Conference Pads Alessa &Valencia Series Stitched Desk & Conference Pads

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇ ISD ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ [▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇] 281-245- 2945 ▇▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ [▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇] 830.914.1084 Mcalester High School ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇, ▇▇▇▇ [▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇] 918-424- 5809 Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ County Schools ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 770-787-1330 Lincoln Public Schools ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇.▇▇▇ 402-436-1072 Duncanville ISD ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Audio Enhancement, Inc., (“Provider”) is pleased to offer a standard Five (5) year limited manufacturer’s warranty (“Limited Warranty”) against malfunction due to manufacturing defects in materials or workmanship on the IR and XD teacher and student microphone, IR-Satellite (TLD100) Dome Sensor/Receiver, the external infrared sensors, XD receiver (K-SRC14), ▇▇-▇▇, ▇▇-▇▇▇, ▇▇-▇▇▇, ▇▇▇▇▇ ▇▇, ▇▇▇▇▇▇▇▇ (▇▇, ▇▇▇▇, ▇▇▇), Achiever, Elite, ▇▇-▇▇▇, ▇▇- ▇▇▇, and Ceiling and Wall speakers (“Provider Products”). Optional accessories are warranted under the same terms for a period of 1 year (see 1 year warranty). The ‘AA’ NiMH and lithium ion batteries supplied by Audio Enhancement, Inc., carry a 90-day warranty from date of purchase. The Limited Warranty applies only if: (1) the Provider Products are installed according to Provider’s instruction provided to Customer and (2) the Provider Products are not misused or abused, and there is no evidence of mishandling, neglect, modification or repair without the approval of Provider, or damage done to Provider’s Products by anyone other than Provider. The following is not included under this Limited Warranty: (1) Misuse or abuse by the Customer; (2) normal wear and tear; and (3) physical damage to Provider’s Products as a result of unreasonable use and/or negligence. This Limited Warranty is provided by Provider, and it contains the only express warranty provided to Customer by Provider. Provider does not authorize any other person, including distributors, to give any other warranties on Provider’s behalf. The repair or replacement as provided under the express limited warranty is the sole and exclusive remedy of the Customer and Provider’s sole and exclusive liability hereunder. Provider disclaims any express warranty not provided herein and any implied warranty, guaranty or representation as to performance, quality and absence of hidden defects, and any remedy for breach of contract, which but for this provision, might arise by implication, operation of law, custom of trade or course of dealing, including implied warranties of merchantability and fitness for a particular purpose. In no event shall Provider be liable, whether in contract, tort (including negligence) or otherwise, for damages in excess of the purchase price of the product giving rise to the damages, or for any direct, indirect, incidental, special, punitive, exemplary, or consequential damages of any kind. Provider further disclaims any responsibility for losses, expenses, inconveniences, special, indirect, secondary, or consequential, incidental, and contingent damages whatsoever, including damages arising from ownership or use of provider’s products. Provider shall bear no responsibility or obligation with respect to the manner of use of any equipment sold by Provider. Provider specifically disclaims and negates any warranty of fitness for a particular purpose of such equipment including, without limitation, any warranty that the use of such equipment for any purpose will comply with applicable laws and regulations or overcome any specific hearing/auditory processing deficit. When returning units for service, use adequate packaging to prevent shipping damage. Shipping damage is not covered under warranty. ▇▇▇▇▇ ▇. ▇▇▇▇▇▇▇ ▇▇., ▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ • Phone ▇.▇▇▇.▇▇▇.▇▇▇▇ • ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ DC-19000.04 One Guiding Principle: If students can’t hear the lesson, they can’t understand what’s being taught. Providing classrooms with distributed sound solutions helps students hear the lesson from anywhere in the room. Thousands of students and teachers are seeing the benefits of Classroom Audio Systems nationwide.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Line Items REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your service the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person VALID EMAIL IS REQUIRED Phone Copperas Cove ISD ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as State Technical College Waco Selby Holder ▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Killeen ISD ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Hill Junior College ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Fairfield ISD ▇▇▇ ▇▇▇▇▇▇ ▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ FAILURE TO PROPERLY COMPLETE THIS FORM AND SUBMIT WITH YOUR RESPONSE MAY RESULT IN A WAIVER OF YOUR RIGHTS UNDER THE LAW TO MAINTAIN CONFIDENTIALITY TREATMENT OF SUBMITTED MATERIALS. If you consider any portion of 9-1-2017 requiring the contract your proposal to be confidential information and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s), you must make a copy of all claimed confidential materials within your proposal and put this COMPLETED form as a cover sheet to said materials then scan, name “CONFIDENTIAL” and upload with your proposal submission. (You must include the laws confidential information in the submitted proposal as well, the copy uploaded is to indicate which material in your proposal, if any, you deem confidential in the event the receives a Public Information Request.) ESC8 and TIPS will follow procedures of another state, controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law. Pricing of solicited product or service may be deemed as public information under Chapter 552 Texas Gov’t Code. The Office of Texas Attorney General shall make the final determination whether the information held by ESC8 and TIPS is confidential and exempt from public disclosure. I claim part of my proposal to be required confidential and DO NOT desire to litigate expressly waive any claim of confidentiality as to any and all information contained within our response to the contract in another statecompetitive procurement process (e.g. RFP, or CSP, Bid, RFQ, etc.) by completing the following and submitting this sheet with our response to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the projectEducation Service Center Region 8 and TIPS. The term also includes movingattached contains material from our proposal that I classify and deem confidential under Texas Gov't Code Sec. 552 or other law(s) and I invoke my statutory rights to confidential treatment of the enclosed materials. ATTACHED ARE COPIES OF PAGES OF CONFIDENTIAL MATERIAL FROM OUR PROPOSAL Signature Date OR_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If you do not claim any of your proposal to be confidential, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Itemscomplete the section below only.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to Line Items REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have provisions used your servic the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (No Response Required3) Requirements as references. Entity Name Contact Person VALID EMAIL IS REQUIRED Phone Grant County Court House ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ CASA Womens Shelter ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Metropollitan Housing Alliance Melvin Ousley ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ FAILURE TO PROPERLY COMPLETE THIS FORM AND SUBMIT WITH YOUR RESPONSE MAY RESULT IN A WAIVER OF YOUR RIGHTS UNDER THE LAW TO MAINTAIN CONFIDENTIALITY TREATMENT OF SUBMITTED MATERIALS. If you consider any portion of 9-1-2017 requiring the contract your proposal to be confidential information and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s), you must make a copy of all claimed confidential materials within your proposal and put this COMPLETED form as a cover sheet to said materials then scan, name “CONFIDENTIAL” and upload with your proposal submission. (You must include the laws confidential information in the submitted proposal as well, the copy uploaded is to indicate which material in your proposal, if any, you deem confidential in the event the receives a Public Information Request.) ESC8 and TIPS will follow procedures of another state, controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law. Pricing of solicited product or service may be deemed as public information under Chapter 552 Texas Gov’t Code. The Office of Texas Attorney General shall make the final determination whether the information held by ESC8 and TIPS is confidential and exempt from public disclosure. I claim part of my proposal to be required confidential and DO NOT desire to litigate expressly waive any claim of confidentiality as to any and all information contained within our response to the contract in another statecompetitive procurement process (e.g. RFP, or CSP, Bid, RFQ, etc.) by completing the following and submitting this sheet with our response to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the projectEducation Service Center Region 8 and TIPS. The term also includes movingattached contains material from our proposal that I classify and deem confidential under Texas Gov't Code Sec. 552 or other law(s) and I invoke my statutory rights to confidential treatment of the enclosed materials. Platinum Roofing, demolitionLLC ▇▇▇▇▇ ▇▇▇▇▇▇▇, or excavationSr. BY RESPONDING TO THIS SOLICITATIONDirector of Operations ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇, AND WHEN APPLICABLE▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇ ▇▇▇▇▇ 870-917-2119 Address City State ZIP Phone COPIES OF PAGES OF CO ATTACHED ARE COPIES OF 1 PAGES OF CONFIDENTIAL MATERIAL FROM OUR PROPOSAL Signature Date 8/7/18 _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ OR_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If you do not claim any of your proposal to be confidential, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Itemscomplete the section below only.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone City of Carrollton ▇▇▇ ▇▇▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇> 972.466.9835 Irving Independent School District Clint Roddy ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 972.600.5000 Grapevine-Colleyville Independent School District ▇▇▇ ▇▇▇▇▇▇ ▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 817.251.5200 ▇▇▇▇▇▇▇▇▇▇ Independent School District ▇▇▇▇▇▇ Slovak ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇.▇▇▇ 469.593.0120 RFP 180102 Emergency Responder Supplies and Equipment Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor n/a Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. City of San Antonio (COSA) (TX) ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 210.207.6939 City of Deer Park (TX) ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 281.420.7229 City of Houston Public Works (TX) ▇▇▇▇ Bac ▇▇▇▇.▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 832.395.4992 Boston Water and Sewer Commission (BWSC) (Boston, MA) ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ 617.989.7000 Vortex Companies, LLC This resellers document is for proposers to list any other companies that resell their products. Only list resellers of your products that are located in the US or Canada.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor N/A Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Albany Independent School District ▇▇. ▇▇▇▇▇ ▇▇▇▇▇▇, Superintendent ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇▇▇.▇▇▇ 325.762.3974 Childress Regional Medical Center Mr. ▇▇▇▇ ▇▇▇▇▇▇▇▇▇, CEO ▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ Consolidated Independent School District ▇▇. ▇▇▇▇ ▇▇▇▇▇▇, Superintendent ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇▇▇.▇▇▇ 940.864.2602 ext 104 QUICK CHECKLIST

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor N/A Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your ser the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Town of Little Elm ▇▇▇▇▇ Westenhoeffer s ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Grand Prairie ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Commerce ISD ▇▇ ▇▇▇▇▇ a ▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ City of ▇▇▇▇▇▇ ▇▇▇▇▇ Kirby k ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Rockwall ISD ▇▇▇▇▇ ▇▇▇▇▇▇ r ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Eagle Mountain-Saginaw ISD ▇▇▇▇ ▇▇▇▇▇▇▇ m ▇▇▇▇▇▇▇@▇▇▇-▇▇▇.▇▇▇ Lake Dallas ISD ▇▇▇▇ ▇▇▇▇▇▇ m ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇.▇▇▇ The Texas Comptroller of Public Accounts (CPA) administers the Statewide Historically Underutilized Business (HUB) Program for the State of Texas, which includes certifying minority and woman-owned businesses as HUBs and is designed to facilitate the participation of minority and woman-owned businesses in state agency procurement opportunities. We are pleased to inform you that your application for certification/re-certification as a HUB has been approved. Your company's profile is listed in the State of Texas HUB Directory and may be viewed online at ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇▇▇.▇▇.▇▇/procurement//cmbl/hubonly.html. Provided that your company continues to meet HUB eligibility requirements, the enclosed HUB certificate is valid for four years. You must notify the HUB Program in writing of any changes affecting your company’s compliance with the HUB eligibility requirements, including changes in ownership, day-to-day management, control and/or principal place of business. Note: Any changes made to your company’s information may require the HUB Program to re-evaluate your company’s eligibility. Please reference the enclosed pamphlet for additional resources, such as the state’s Centralized Master Bidders List (CMBL), that can increase your chance of doing business with the state. Thank you for your participation in the HUB Program! If you have any questions, you may contact a HUB Program representative at ▇▇▇-▇▇▇-▇▇▇▇ or toll-free in Texas at ▇-▇▇▇-▇▇▇-▇▇▇▇. Certificate/VID Number: 1272802338800 File/Vendor Number: 465973 Approval Date: 10-APR-2015 Scheduled Expiration Date: 10-APR-2019 has successfully met the established requirements of the State of Texas Historically Underutilized Business (HUB) Program to be recognized as a HUB. This certificate printed 29-MAY-2015, supersedes any registration and certificate previously issued by the HUB Program. If there are any changes regarding the information (i.e., business structure, ownership, day-to-day management, operational control, business location) provided in the submission of the business’ application for registration/certification as a HUB, you must immediately (within 30 days of such changes) notify the HUB Program in writing. The CPA reserves the right to conduct a compliance review at any time to confirm HUB eligibility. HUB certification may be suspended or revoked upon findings of ineligibility.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇▇▇ ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇-▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Comanche ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Somerville ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Dallas ISD ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Fort Worth ISD ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 817-814-2000 Fort Bend ISD Carmela Levy-David ▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 281-634-5985 Please provide a list of resellers the proposing company desires to be authorized to sell their products and services under the TIPS Agreement, if awarded. Authorized Reselling Company Name Full Address Main Phone Contact Contact Ph Contact Email Website Fax Emtec Interstate South Commerce Center Suite 8 ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇ Jacksonville, FL 32256 ▇▇▇-▇▇▇-▇▇▇▇ Summer Vyne 904-739-7676 ▇▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Birdville ISD Accounts Payable ▇▇▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Mission CISD ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Frisco Independent School District Accounts Payable ▇▇▇▇_▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Waco Independent School District ▇▇▇▇▇▇ ▇▇▇▇▇▇ , C.P.A., CTSBO, Director of Business Services ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ofc: (▇▇▇) ▇▇▇-▇▇▇▇ SpaceX ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇.▇▇▇ cel: (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇ Independent School District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ cel: (▇▇▇) ▇▇▇-▇▇▇▇ Blooming Grove Independent School District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ cel: (▇▇▇) ▇▇▇-▇▇▇▇ Magnolia Market ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ cel: (▇▇▇) ▇▇▇-▇▇▇▇ Mexia Independent School District ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ cel: (▇▇▇) ▇▇▇-▇▇▇▇ City of Waco, Texas ▇▇▇ ▇▇▇▇▇▇ ▇▇▇_▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ cel: (▇▇▇) ▇▇▇-▇▇▇▇ City of Woodway, Texas ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ cel: (▇▇▇) ▇▇▇-▇▇▇▇ City of ▇▇▇▇▇▇▇▇, Texas ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇-▇▇▇▇▇.▇▇▇ cel: (254) 258-8171 February 12, 2018 RE: ▇▇▇▇▇▇-▇▇▇▇▇▇/ ▇▇▇▇▇▇▇▇, Inc. Bonding TIPS RFP 180101 Comprehensive HVAC Solutions and Services To Whom It May Concern: Please accept this letter on behalf of ▇▇▇▇▇▇-▇▇▇▇▇▇/ ▇▇▇▇▇▇▇▇ (▇▇▇▇▇▇-▇▇▇▇▇▇) as verification of their fine standing with our agency. They have demonstrated a proven ability to deliver quality projects on time and in an expeditious manner. We at ▇▇▇▇▇▇▇-▇▇▇ Agency consider it a privilege to have ▇▇▇▇▇▇-▇▇▇▇▇▇ as a client. My understanding is that ▇▇▇▇▇▇-▇▇▇▇▇▇ is bidding on the above referenced solicitation. ▇▇▇▇▇▇-▇▇▇▇▇▇ is currently sufficiently supported by Merchants Bonding Company, an A Rated (Excellent), and U. S. Treasury listed company. Subject to the normal review of contract terms and conditions and any related underwriting items at the time of the request, we will consider bonds up to a single item limit of $3MM and an aggregate capacity of $6MM. ▇▇▇▇▇▇-▇▇▇▇▇▇ has been bonded with ▇▇▇▇▇▇▇ and Merchants Bonding for 5 years and there have been No Claims (open or closed) filed against them. Any specific request for bonds will be underwritten on its own merits and any arrangement for bonds required by any contract is a matter between the contractor and the surety and we assume no liability to you or your third parties, if for any reason we do not execute these bonds. Bonds will be provided when the project/task order in question is agreeable to both parties and proper contracts are in place. Again, we can highly recommend ▇▇▇▇▇▇-▇▇▇▇▇▇ to you, and would be happy to provide any additional information that you may require. Please feel free to contact me at any time at ▇▇▇- ▇▇▇-▇▇▇▇. Best Regards, Attorney-In-Fact Merchants Bonding Company The Texas Comptroller of Public Accounts (CPA) administers the Statewide Historically Underutilized Business (HUB) Program for the State of Texas, which includes certifying minority and woman-owned businesses as HUBs and is designed to facilitate the participation of minority and woman-owned businesses in state agency procurement opportunities. We are pleased to inform you that your application for certification/re-certification as a HUB has been approved. Your company's profile is listed in the State of Texas HUB Directory and may be viewed online at ▇▇▇▇://▇▇▇.▇▇▇▇▇▇.▇▇▇▇▇.▇▇.▇▇/procurement//cmbl/hubonly.html. Provided that your company continues to meet HUB eligibility requirements, the enclosed HUB certificate is valid for four years. You must notify the HUB Program in writing of any changes affecting your company’s compliance with the HUB eligibility requirements, including changes in ownership, day-to-day management, control and/or principal place of business. Note: Any changes made to your company’s information may require the HUB Program to re-evaluate your company’s eligibility. Please reference the enclosed pamphlet for additional resources, such as the state’s Centralized Master Bidders List (CMBL), that can increase your chance of doing business with the state. Thank you for your participation in the HUB Program! If you have any questions, you may contact a HUB Program representative at ▇▇▇-▇▇▇-▇▇▇▇ or toll-free in Texas at ▇-▇▇▇-▇▇▇-▇▇▇▇. Certificate/VID Number: 1742619642800 File/Vendor Number: 036191 Approval Date: 27-FEB-2015 Scheduled Expiration Date: 27-FEB-2019 has successfully met the established requirements of the State of Texas Historically Underutilized Business (HUB) Program to be recognized as a HUB. This certificate printed 27-FEB-2015, supersedes any registration and certificate previously issued by the HUB Program. If there are any changes regarding the information (i.e., business structure, ownership, day-to-day management, operational control, business location) provided in the submission of the business’ application for registration/certification as a HUB, you must immediately (within 30 days of such changes) notify the HUB Program in writing. The CPA reserves the right to conduct a compliance review at any time to confirm HUB eligibility. HUB certification may be suspended or revoked upon findings of ineligibility.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ City Public Schools ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇ Public Schools ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ Technology Centers Skip ▇▇▇▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Austin ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇, CTO ▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Cypress-▇▇▇▇▇▇▇▇▇ ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇, CTO ▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇ ISD ▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇, Dir of Technology ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Pasadena ISD ▇▇▇▇▇▇ ▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Round Rock ISD ▇▇▇▇ ▇▇▇▇▇▇▇▇, CTO ▇▇▇▇_▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Temple ISD ▇▇▇▇▇ ▇▇▇▇▇▇, Dir of Technology ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ San Antonio ISD ▇▇▇▇▇▇▇▇ ▇▇▇▇▇, CIO ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ TIPS RFP 180201 ERATE Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Farmersville ISD ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Lake Dallas ISD ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 940-497-4039 ▇▇▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ 972-837-4530 Ecoroq filters are a combination of two natural minerals, Guerite and Saugin. Guerite is a multi- sorted natural mineral compound. Both minerals are 100% natural, environmentally friendly, non-toxic and completely recyclable . Guerite is mined from an area of the Mojave Desert in the United States , which is the only known location and source on Earth of this unique mineral compound. The characteristics of the Guerite mineral are such that it strives to live in conditions of between 80% - 90% relative humidity. This humidity range is also the optimum conditions for the preservation and storage of foods. In effect, the mineral actually controls the humidity by absorbing or desorbing moisture particles in refrigerated environments, as it strives to maintain conditions between 80% - 90% relative humidity. In addition to controlling the humidity, Ecoroq filters also remove bacteria and odors from refrigerated environments. As the moisture particles move around, they attract bacteria and odor particles, including ethylene gas. The moisture particles - along with the bacteria, odor particles and ethylene gas - are absorbed and held by the mineral. If conditions in the refrigerated environment start to drop below 80% relative humidity, then the purified moisture particles are squeezed out of the mineral, while the bacteria, odor and ethylene gas particles remain trapped. The mineral acts like a molecular sieve. After approx. 1 month of use, the Ecoroq filters will require changing and new, revitalized filters will be put in. By removing these filters we are, in effect, removing the bacteria, odors and gases from the environment and all Ecoroq filters go through a special revitalization process, which removes all bacteria, odors and gases. After this process, the Ecoroq filters are ready to be used again. In a nutshell, an Ecoroq filter will pay for itself through a combination of several changes you will see in your walk-in coolers and freezers.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Line Items REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person VALID EMAIL IS REQUIRED Phone City of Denton Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as ▇▇▇▇▇ ▇▇▇▇▇▇, CMSM Economic Development Program Administrator ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of 9San Marcos Texas ▇▇▇▇▇ ▇. ▇▇▇▇▇, AICP Economic Development & Downtown Administrator ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-1▇▇▇-2017 requiring the contract ▇▇▇▇ City of Rosenberg Texas ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇, CPRP, Director Dept of Parks & Recreation ▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ 832-595-3960 FAILURE TO PROPERLY COMPLETE THIS FORM AND SUBMIT WITH YOUR RESPONSE MAY RESULT IN A WAIVER OF YOUR RIGHTS UNDER THE LAW TO MAINTAIN CONFIDENTIALITY TREATMENT OF SUBMITTED MATERIALS. If you consider any portion of your proposal to be confidential information and not subject to the laws public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s), you must make a copy of another stateall claimed confidential materials within your proposal and put this COMPLETED form as a cover sheet to said materials then scan, name I claim part of my proposal to be required confidential and DO NOT desire to litigate expressly waive any claim of confidentiality as to any and all information contained within our response to the contract in another statecompetitive procurement process (e.g. RFP, or CSP, Bid, RFQ, etc.) by completing the following and submitting this sheet with our response to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the projectEducation Service Center Region 8 and TIPS. The term also includes movingattached contains material from our proposal that I classify and deem confidential under Texas Gov't Code Sec. 552 or other law(s) and I invoke my statutory rights to confidential treatment of the enclosed materials. ATTACHED ARE COPIES OF PAGES OF CONFIDENTIAL MATERIAL FROM OUR PROPOSAL Signature Date OR_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If you do not claim any of your proposal to be confidential, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Itemscomplete the section below only.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone University of Texas Health Science Center at ▇▇▇▇▇▇▇ ▇▇▇▇▇ Coffey ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇.▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Edgenuity ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ 877-202-0338 Pearson Evaluation Systems ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFP 180302 Academic Curriculum, Instructional Materials and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Leander ISD ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇.▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Garland ISD ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Lewisville ISD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 83 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Texas A & M Commerce ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ 903−468−8759 Santee School District ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ 619−258−2323 Del Mar Union School District ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ 847−404−7863

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Organization City State Contact Name Contact Phone Texas Can Academy Dallas TX ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Forestburg ISD Foredtburg TX ▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Cars For Kids Dallas TX ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ RFP 180101 Comprehensive HVAC Solutions and Services Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇▇ Public Schools ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Lake ▇▇▇▇▇▇▇▇ School District ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Crowleys Ridge ESC ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Mayflower School District ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ¾Texarkana Arkansas School District ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ Public Schools ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ NAICS: 423430, 541519 UNSPSC: 43210000, 43211500 WBENC National WBE Certification was processed and validated by Women's Business Development Center - Council of Florida, a WBENC Regional Partner Organization. Authorized by ▇▇▇▇▇ ▇▇▇▇▇, President & CEO Women's Business Development Center - Council of Florida Altec Lansing Creative Labs Cyber Acoustics GN Netcom Inland JVC Kensington Logitech LTB Audio Micro Innovations Panasonic Plantronics Razer RCA Sakar Sennheiser Shure Skull Candy SoG Trading Sony Targus Tekkeon Tritton TurtleBeach Zalman Aten Belkin Cables to Go Targus Cases & Enclosures Cooler Master ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ Kingwin Sabrent SilverStone Supermicro Thermaltake Ultra Communication Blackberry Cellular Phones Corded & Cordless Phones Motorola Polycom VOIP Phones Balt Buddy Products Datamation Edsal Leda Desk Nexel Mayline Safco Acer Dell HP IBM Lenovo Sony Cisco Argus Canon DXG Fuji HP JVC Kodak Olympus Panasonic Pentax Samsung Sanyo Sony Asus Garmin HP/Compaq Ipaq Magellan Mio Nokia Pharos Beyond Micro Fujitsu Hitachi Kanguru LaCie Maxtor Seagate WesternDigital NAS & SAN Boxes Kensington Logitech MicrosoG Targus Wacom Xtatix KVM Switches ATEN Belkin Cables to Go D-Link HP Iogear Trendnet Tripplite Zonet Acer Dell HP IBM Lenovo LG Sony Toshiba MicrosoG Surface iPAD Samsung Galaxy Displays Acer AOC Benq Gvision HannsG HP IBM I-inc LG Megavision NEC Niko Norcent Panasonic Peerless Philips Planar Samsung Sceptre Sony Toshiba Viewsonic Vizio Westinghouse HP Imation Maxell Memorex Sony TDK Memory Corsair A-Data Crucial K-byte Kingston Lexar OCZ PNY Sandisk Transcend Ultra US Modular AMD Asus ATI BFG Biostar Connect 3D Evga HIS Intel MSI PNY Visiontek IBM Kensignton Samsonite Swiss Gear Targus Vanguard 3M Acer Benq Canon Epson Hitachi Infocus Interlink Mitsubishi NEC Optoma Panasonic Planar Sanyo Sharp Sony Toshiba ViewSonic Kanguru Lexar Memorex Plextor Sandisk Transcend Ultra Xtatix Scanners & Bar Code Microtek Wasp Zebra Servers Systemax Cyberton HP IBM Visionman Adobe CA/Computer Assoc. Corel Intuit McAfee MicrosoG Norton ScansoG Symantec EMC Oracle Sophos Trend Micro Vmware USA net Sonicwall Extreme Networks Cisco D-Link HP Linksys Netgear SMC Trendware Zonet TRENDnet AVG BitDefender Checkpoint Computer Associates Kaspersky McAfee Novell Panda PGP Red Condor Sonic Wall Sophos St ▇▇▇▇▇▇▇ Symantec Trend Micro Websense Webroot IBM RedHat Acronis Corel Double-Take Diskeeper Hewlett Packard Symantec Steel Eye VMware Adobe Systems ACT Acresso Business Objects CA Corel IBM lntuit MicrosoG My SOL Novell Oracle Sonic WALL WebTrends Adobe Systems Autodesk Punch! Corel MicrosoG Quark Sony Adobe Systems CA Corel Datawatch Filemaker Embarcadero Hewlett Packard MicrosoG Nuance Communications Oracle RedHat Sybase IBM MicrosoG Nero Roxio Blackberry/RIM Corel IBM lpswitch MicrosoG Novell Oracle Symantec Trend Micro ▇▇▇.▇▇▇ Attachmate CA Citrix Systems Ericom SoGware EMC Hewlett Packard Hummingbird IBM lpswitch Juniper Networks McAfee MicrosoG NetManage Novell Oracle Red Hat RSA Securtty SolarWinds SonicWALL Symantec Trend Micro VMware LSI Brocade Adobe Systems Corel Filemaker Hewlett Packard IBM MicrosoG MindJET Nuance Communications Oracle RedHat Hewlett Packard IBM MicrosoG Novell Red Hat SCO SonicWALL MicrosoG Trend Micro ▇▇▇.▇▇▇ Acronis Corel Fujitsu Hewlett Packard IBM New Boundary Novell Nuance Oracle RedHat ScanDisk Trend Micro VMware Citrix Parallels SCO Virtual Iron Vizioncore VMware

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Vista Unified School District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Mabank Independent School District ▇.▇. ▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ City of ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Pulaski County Special School District ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ RFP 180304 Telephone and Communications Data Systems and Solutions Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. You may provide more than three (3) references. Gulf Coast Trades Center ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇ Independent School District ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ De Marillac Academy ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇_▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ Detroit Public Schools Community District ▇▇▇ ▇▇▇▇▇ ▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇ School District 4 ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ County Schools ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ RFP 180304 Telephone and Communications Data Systems and Solutions Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor NA Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Port ▇▇▇▇▇▇ ISD ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Bridge City ISD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇ University ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ISD Ricci Pampolina ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ TACLA23943C /LA Mechanical License #60856 Industrial and Commercial Mechanical is a complete Mechanical Service Company with offices located in Beaumont, Houston, & Corpus Christi Texas. We service all of Texas and Southwest Louisiana regions. We are fully capable of servicing all makes and models of Chillers, Heating, Air Conditioning, Ventilation, and Refrigeration Equipment and all Home Service’s including, Service, Repair, Installation, and Sales. We are highly experienced in all facility types including Industrial, Manufacturing, Warehousing, Institutional, Marine, and Retail facilities. We are prepared to handle all Preventative Maintenance, Troubleshooting, Design Analysis, and Repair of all types of HVACR equipment. We also have the capacity to service most Rotating Equipment applications including Laser Alignment. We have several types of Maintenance Programs available which gives us the ability to Tailor-Fit a Complete and Cost-Effective Maintenance and Repair Program to each Customer based on an analysis of their unique individual needs and circumstances. Each member of our Staff has more than 20 years’ experience in the industry in their respective roles with the Company. The members of our Highly Experienced Staff have been directly involved with a high percentage of the Industrial and Commercial Facilities in Texas and Southwest Louisiana Regions. Our technicians are Union Members and have been trained in the latest service techniques and technology involved in the manufacture, installation, and operating of modern HVACR equipment in addition to a vast bank of knowledge and experience with older equipment. We are committed to safety and promote safety awareness through our own Safety Program in addition to training through ISTC and Safety Council of SWLA. We are available 24/7 for emergency service on request. I invite you to contact me or any of our staff and give us an opportunity to learn about your facility’s equipment and develop a Maintenance and Repair Program to increase reliability and efficiency of the equipment to increase your business profitability.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Monroe Township School District ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ 732-521-6042 ▇▇▇▇▇▇▇▇▇▇▇ College ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇ State University ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Extron’s return policy is as follows: This 30-Day Product Satisfaction Guarantee limits our responsibility for refunds to unsatisfactory performance only. Cable Performance Warranty Limited Lifetime. Extron Cable Products will be free from defects in material and workmanship for as long as you or your customer own the cable. A restocking fee is not intended as a penalty or punishment to our customers. Extron does not profit from these charges. The restocking fee is intended to cover a portion of the costs incurred in processing returned items. The costs we incur include:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 83 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. City of Humble, TX ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ 281−446−▇▇▇▇ ▇▇▇▇ ▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇ ▇▇▇▇▇ 512−990−6125 College of the Ozarks ▇▇▇ ▇▇▇▇▇▇ 417−230−5935 February 28, 2018 To Whom it May Concern: Please consider this letter as confirmation that ArCom Systems, Inc. is a valued client of this agency. ArCom Systems, Inc. has an excellent reputation within the construction community for their past work. We are in a position of issuing single project performance and payment bonds up to $500,000 with an aggregate work program of $1,000,000. Each individual project is considered on its own merits as it relates to ArCom Systems, Inc.'s existing work load. Considered items include, but are not limited to, ArCom Systems, Inc.'s financial condition at the time of contract bid and/or award, proof of construction funding, contract terms and conditions, length of project and penalties, just to name a few. Please feel free to contact me should you have any questions regarding this matter. Sincerely, ▇▇▇▇ ▇▇▇▇▇▇▇ /ph

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems If ▇▇▇▇▇▇ Publishing, LLC make a mistake, we will work with the customer until the situation is resolved to their satisfaction. The customer can contact us at ▇▇▇-▇▇▇-▇▇▇▇. For defective items (materials printed upside down, covers separating, spines separating, etc.), we unconditionally guarantee the workmanship of our books and materials for the lifetime of the product. Defective items will be replaced as long as the title is still in print and was purchased directly from ▇▇▇▇▇▇ Publishing, LLC. Please contact customer service at 800-398-2504 to resolve any problems. If the customer makes a mistake in ordering, we will accept returns on books and materials in new condition for up to one year. Please contact customer service at 800-398-2504 and we will arrange to have the items picked up and the credit or exchange issued. Should the customer want to send back materials for other reason, we will accept returns on books and materials in new condition for up to one year. Please contact customer service at 800-398-2504 and we will arrange to have the items picked up and the credit or exchange issued.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone ▇▇▇▇▇ ISD ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Dothan City Schools ▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Mount ▇▇▇▇▇ Township Schools ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇.▇▇.▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Insight System Exchange 2NDGEAR has highly trained and specialized technicians on staff to provide customer support on products, setup, warranty, and solutions for all of your technical needs. You will our staff, friendly approachable, and ready to answer your questions. We have a 24/7 web portal, equipped with a new ticketing system that is easy to use, allowing for an efficient queue system. Additionally, the team can be reached by phone at ▇-▇▇▇-▇▇▇-▇▇▇▇, Monday – Friday from 7am-4pm PST. Options available within our 24/7 web portal are requests for service, support, and replacement of units. The portal is located at ▇▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇.▇▇▇. Convenient YouTube channel for our Customer Service Walkthrough: ▇▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇.▇▇▇/watch?v=xXsuhH3Ry3M&feature=▇▇▇▇▇.▇▇ 2NDGEAR’s standard warranty is a 3 year advance replacement. We ship the replacement part or unit before receiving the faulty part/unit. We also provide the return call tag for the return part/unit. 2NDGEAR offers a flexible menu offering, inclusive 90 Day Warranty up to a Life Time Warranty, and an on hand parts closet as well. With our consultative approach, we learn your environment, see how we can work together to ▇▇▇▇▇▇ a great working relationship. Creating the best and most effective warranty term your needs is a top priority. The average life cycle for most computers and IT equipment is between 3-4 years. Most companies throw away IT equipment at the end of this cycle and simply deal with the loss of their original investment. But there’s another way to deal with end-of-life IT equipment, and make money in the process.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Line Items REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person VALID EMAIL IS REQUIRED Phone Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions Department of Transport ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ City of Southlake Mayor ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇.▇▇▇▇▇▇▇▇▇.▇▇.▇▇ 817-748-8400 University of North Texas ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇-▇▇▇▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Gateway Charter Academy Dr. ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (No Response Required▇▇▇) Requirements as ▇▇▇-▇▇▇▇ FAILURE TO PROPERLY COMPLETE THIS FORM AND SUBMIT WITH YOUR RESPONSE MAY RESULT IN A WAIVER OF YOUR RIGHTS UNDER THE LAW TO MAINTAIN CONFIDENTIALITY TREATMENT OF SUBMITTED MATERIALS. If you consider any portion of 9-1-2017 requiring the contract your proposal to be confidential information and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s), you must make a copy of all claimed confidential materials within your proposal and put this COMPLETED form as a cover sheet to said materials then scan, name “CONFIDENTIAL” and upload with your proposal submission. (You must include the laws confidential information in the submitted proposal as well, the copy uploaded is to indicate which material in your proposal, if any, you deem confidential in the event the receives a Public Information Request.) ESC8 and TIPS will follow procedures of another state, controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law. Pricing of solicited product or service may be deemed as public information under Chapter 552 Texas Gov’t Code. The Office of Texas Attorney General shall make the final determination whether the information held by ESC8 and TIPS is confidential and exempt from public disclosure. I claim part of my proposal to be required confidential and DO NOT desire to litigate expressly waive any claim of confidentiality as to any and all information contained within our response to the contract in another statecompetitive procurement process (e.g. RFP, or CSP, Bid, RFQ, etc.) by completing the following and submitting this sheet with our response to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the projectEducation Service Center Region 8 and TIPS. The term also includes movingattached contains material from our proposal that I classify and deem confidential under Texas Gov't Code Sec. 552 or other law(s) and I invoke my statutory rights to confidential treatment of the enclosed materials. ATTACHED ARE COPIES OF PAGES OF CONFIDENTIAL MATERIAL FROM OUR PROPOSAL Signature Date OR_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If you do not claim any of your proposal to be confidential, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Itemscomplete the section below only.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone TAMU - School of Public Health Maggie Acosta ▇▇▇▇▇▇@▇▇▇.▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Alamo Community College District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Austin Community College ▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Texas A&M University Sybil Popham ▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇ Houston State University ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ 247 Ergo, LLC ▇▇▇▇▇ (▇▇▇) ▇▇▇▇▇▇▇▇ 800-958-6670 ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ABI Office Furniture ▇▇▇▇▇ ▇▇▇▇▇ 858-549-3355 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Accent Commercial Furniture, Inc. ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Admiral Express, Inc ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 918-249-4000 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Advanced Ergonomics Concepts, Inc ▇▇▇▇▇▇ ▇▇▇▇ 314-994-0500 ▇▇▇▇▇▇@▇▇▇▇▇-▇▇▇▇.▇▇▇ Advanced Office Environments ▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Advantage Office Products, LLC ▇▇▇▇▇▇▇ Spencer ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Aegis Business Solutions, LLC ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 816-471-7999 ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇ AFD Contract Furniture Inc. ▇▇▇ ▇▇▇▇▇ 212-721-7100 ▇▇▇▇▇▇@▇▇▇-▇▇▇.▇▇▇ Affordable Office Interiors LLC ▇▇▇▇▇ Padriatzik 314-534-5900 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Agile OFIS Interiors ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇.▇. ▇▇▇▇▇ Business Interiors, Inc. ▇▇ ▇▇▇▇▇ 814-835-8217 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ APG Office Furnishings, Inc ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ 513-621-9111 ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ AliMed, Inc ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ All Makes Office Equipment ▇▇▇▇ ▇▇▇▇▇▇▇ 515-282-2166 ▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Alternative Business Furniture ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ Ambience Dore, Inc. Mar Dore ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ American Office, Inc ▇▇▇ ▇▇▇▇▇▇▇▇ 410-539-7529 ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ American Interiors, Inc ▇▇▇▇ Proshel 419-535-1808 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ American Business Interiors ▇▇▇▇▇▇ ▇▇▇▇▇▇ 321-723-5003 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ American Office Products ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇.▇▇▇ American West Office Interiors, LLC ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ AOI Corporation ▇▇▇▇ ▇▇▇▇▇▇ 402-896-5520 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Arbee Associates ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 732-424-3900 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ARC Ergonomics ▇▇▇ ▇▇▇▇▇ 6198287001 ▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Catalyst ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ 714-916-3635 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Arctic Office Products, Inc ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 907-276-2322 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇ Office Furnishings, Inc ▇▇▇▇ ▇▇▇▇▇▇▇▇ 212-633-2400 ▇▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇▇▇▇ Office Furnishings, Inc ▇▇▇▇▇ ▇▇▇▇ 212-633-2400 ▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇▇▇▇ Office Furniture ▇▇▇▇▇ ▇▇▇▇▇▇▇ 858-453-2411 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇ & Associates Interiors, Inc ▇▇▇▇▇▇ ▇▇▇▇▇▇ 225-343-2702 ▇▇▇▇▇▇▇@▇▇▇▇▇▇-▇▇▇▇▇▇▇▇▇▇.▇▇▇ Arranged4Comfort ▇▇▇▇▇ ▇▇▇▇▇▇ 650-453-3396 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Associates Purchasing ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ 310-286-1800 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Associated Office Systems of Louisiana ▇▇▇▇▇▇ ▇▇▇▇ 504-561-8400 Atrium Facilities & Interiors ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Austin Business Furniture ▇▇▇ ▇▇▇▇▇ 512-832-6400 ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Avens Development Services LLC DBA The Avens Grou ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Ball Office Products ▇▇▇▇▇▇▇ ▇▇▇▇ 804-204-1774 ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Workspace Development, LLC dba OpenSquare ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇-▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇ Workplace Solutions ▇▇▇▇ ▇▇▇▇▇▇ 601-354-4960 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Barneston Group, Inc ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇▇▇ Office Equipment, Inc. ▇▇▇ ▇▇▇▇ 724-846-5330 ▇▇▇▇▇@▇▇▇▇▇▇-▇▇.▇▇▇ BBE Office Interiors ▇▇▇ ▇▇▇▇▇▇▇ 413-442-8217 ▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ BAG Contract (Beaux-Arts Group) ▇▇▇▇ ▇▇▇▇▇ 813-880-8686 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ BEH Furnishings, LLC ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Belnick, Inc ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ Benhar Office Interiors, LLC ▇▇▇▇▇▇ Cambridge 212-481-6666 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Beyond The Office Door, LLC ▇▇▇▇ ▇▇▇▇▇▇▇▇ 866-733-0698 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ The ▇▇▇▇▇▇ Corp of Maryland- ▇▇▇▇▇▇ Environments ▇▇▇▇ ▇▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Red Thread Spaces, LLC ▇▇▇ ▇▇▇▇▇ 617-439-4900 ▇▇▇▇▇▇@▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇▇'▇ Business Products ▇▇▇▇▇▇ Uritt 510-483-3600 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇'▇ Commercial Interiors ▇▇▇▇▇ ▇▇▇▇ 7722834608 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ The Blind Company dba Resource One ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Trope Group, Inc. ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ Blue Hen, Inc ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 888-258-3436 ▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Blue Skies Furniture ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ The Body at Work ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ OfficeMax (Workplace | Interiors) ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ BC Interiors, Inc ▇▇▇▇▇ ▇▇▇▇▇▇▇ 303-443-3666 ▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Broadway Office Interiors, Inc ▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ 4137348911 ▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇ Office Interiors, Inc ▇▇▇▇▇ ▇▇▇▇▇▇ 612-331-6300 ▇▇▇▇▇▇▇▇▇ Group ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 210-224-6220 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Building Service, Inc. ▇▇▇▇▇ ▇▇▇▇▇▇ 4143533600 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Bulldog Office Products, Inc. (▇▇▇▇▇) ▇▇▇▇ 412-787-3333 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇ & Co. Inc ▇▇▇▇▇ ▇▇▇▇▇▇▇ 205-870-7853 ▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Burketts Office Supply ▇▇▇▇▇ ▇▇▇▇ 916-387-8900 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Business Interiors Northwest, Inc (BiNW) ▇▇▇▇▇ ▇'▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Business Interiors ▇▇▇▇▇ ▇▇▇▇▇ 817-858-2000 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ BFI (Business Furniture, Inc) ▇▇▇▇▇ ▇▇▇▇▇▇ 908-355-3400 Business Interiors, Inc ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 205-939-1008 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Business e-Environments, LLC ▇▇▇▇ ▇▇▇▇▇▇▇ 973-335-7700 ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Business Interiors, Inc ▇▇▇▇▇ ▇▇▇▇▇ 601-969-1000 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ California Office Furniture ▇▇▇▇ ▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ California Office Furniture ▇▇▇▇▇▇ ▇▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇ Business Interiors, LLC ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 605-339-1411 Capitol Business Interiors ▇▇▇▇▇ ▇▇▇▇▇ 304-343-7551 ▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Qub'd Int'l dba Capital Office Systems ▇▇▇▇▇ ▇▇▇▇▇ 907-777-1500 Carolina Office Xchange, LLC ▇▇▇▇▇ ▇▇▇▇ 919-377-0240 Carolina Office Xchange, LLC ▇▇▇▇ ▇▇▇▇▇ 919-377-0240 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Chair Pros ▇▇▇▇ ▇▇▇▇ ▇▇▇▇@▇▇▇▇▇-▇▇▇▇.▇▇▇ CI Select ▇▇▇▇▇ ▇▇▇▇▇▇ 314-909-1990 Citron Work Spaces ▇▇▇▇ ▇▇▇▇▇▇ 303-665-7676 ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Class Commercial Furniture & Interiors, LLC ▇▇▇▇▇▇▇▇ Class ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇ Service Company dba CME ▇▇▇▇▇▇▇ Chervette ▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Contract Office Group (COG) ▇▇▇▇▇ ▇▇▇▇ 408-213-1790 ▇▇▇▇▇ CFI ▇▇▇▇ ▇▇▇▇▇▇▇ 503-226-4151 Commercial Office Interiors ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 206-448-7333 Commercial Furniture Services, Inc (CFS) ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 952-922-6683 ▇▇▇▇.▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ Commercial Design Services, Inc ▇▇▇▇▇▇▇ ▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Commercial Interiors, Inc ▇▇▇▇▇ ▇▇▇▇▇ 228-452-9540 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Commercial Business Interiors, Inc ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ 601-268-9998 ▇▇▇▇▇▇▇▇▇▇▇@▇▇▇-▇▇.▇▇▇ Commercial Interiors Direct, Inc ▇▇▇▇▇▇ ▇▇▇▇▇▇ 973-839-8394 Commercial Furniture Solutions, Inc ▇▇▇▇▇▇ (▇▇▇▇▇) ▇▇▇▇ 254-931-6230 ▇▇▇▇▇▇@▇▇▇-▇▇▇.▇▇▇ CSG ▇▇▇▇▇ ▇▇▇▇▇▇ 512-833-6688 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Concepts Office Furnishings, Inc ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Connecting Elements, Inc ▇▇▇▇ ▇▇▇▇▇▇▇ 803-779-3442 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Connect People and Spaces, LLC ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Contract Associates, Inc ▇▇▇▇▇ ▇▇▇▇▇▇-▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Contract Resource Group, Inc ▇▇▇▇ ▇▇▇▇ 509-458-0411 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Contract Furnishings Inc ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ 720-956-1515 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Contemporary Business Interiors, LLC (CBI) ▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Contract Furniture Group, LLC (CFG) ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ CRI ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ 415-989-0773 ▇▇▇▇▇▇▇@▇▇▇-▇▇.▇▇▇ ▇▇▇▇▇▇▇'▇ Office Center, LLC ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇'▇ Office Center, LLC ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Core Business Solutions, Inc ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇-▇▇.▇▇▇ Cornerstone Office Systems ▇▇▇ ▇▇▇▇ 703-764-8874 Corporate Interior Systems, Inc. ▇▇▇▇ ▇▇▇▇▇▇▇ 602-304-0100 ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Corporate Environments of Georgia, Inc. ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Business Interiors By Staples (US) ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Corporate Concepts, Inc ▇▇▇▇▇ ▇▇▇▇▇▇ 803-758-2900 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Facilities of NJ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 215-279-9999 Corporate Environments International, LLC ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Furniture Solutions ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Environments of Oregon ▇▇▇▇▇ ▇▇▇▇▇▇▇ 5032363600 Corporate Interiors & Sales, Inc ▇▇▇▇▇▇▇▇ ▇▇▇▇▇ 910-483-7000 ▇▇▇▇▇▇▇▇▇.▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇ ▇▇▇▇▇ 954.354.1711 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 904.365.4200 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ 727-539-7544 ▇▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇ ▇▇▇▇▇ 727-539-7544 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group Ecko ▇▇▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇ ▇▇▇▇▇▇ 954.354.1711 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇▇ ▇▇▇▇▇▇ 727-539-7544 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇ ▇▇▇▇▇ 727-539-7544 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇ ▇▇▇▇ 904.365.4200 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ 727-539-7544 ▇▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ 954.354.1711 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 904.365.4200 ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇▇ Sve 727-539-7544 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇ ▇▇▇▇▇▇▇ 727-539-7544 ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 904.365.4200 ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Interiors, Inc - The CI Group ▇▇▇▇ ▇▇▇▇▇▇ 727-539-7544 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Corporate Environments ▇▇▇▇▇ ▇▇▇▇▇▇ 610-974-7990 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Corporate Concepts, Inc ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 630-691-8800 ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Corporate Source, LTD ▇▇▇ ▇▇▇▇▇ 214-468-0468 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Correct Products, Inc. ▇▇▇▇▇ ▇▇▇▇▇▇ 972-690-6645 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ COS Business Products & Interiors H.H. Ireland III 423-624-0011 ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ County Business Systems, Inc ▇▇▇▇ ▇▇▇▇▇▇▇ 609-935-0180 ▇▇▇▇▇▇▇▇@▇▇▇-▇▇.▇▇▇ Creative Office Environments ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇-▇▇.▇▇▇ Creative Office Pavilion ▇▇▇▇▇▇ ▇▇▇▇▇▇▇ 617-956-4100 The Creative Office ▇▇▇ ▇▇▇▇▇▇▇ 360-754-1732 ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ Creative Supports, Inc ▇▇▇▇▇▇▇▇▇ ▇▇▇▇ (▇▇▇) ▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Creative Interiors, Inc ▇▇▇▇ ▇▇▇▇▇ 505-983-3384 ▇▇▇▇@▇-▇▇▇▇▇▇▇▇▇.▇▇▇ Creative Business Interiors ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 414-545-8500 Crest Office Furniture ▇▇▇▇▇ ▇▇▇▇ 818-333-3160 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ CSI Ergonomics, Inc ▇▇▇ ▇▇▇▇▇▇ 952-215-0700 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Wayfair, LLC ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Cube Solutions ▇▇▇▇ ▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Cubicle by Design, LLC ▇▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇▇▇.▇▇▇ Mitchell Kirsch ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇ Contract, Inc dba Interior Innovations ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Dancker, ▇▇▇▇▇▇ & ▇▇▇▇▇▇▇, Inc Don Kolterjon 9082311600 Atmosphere Commercial Interiors, LLC ▇▇▇▇ ▇▇▇▇▇▇ 612-343-0868 DC Interiors, LP ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ 210-521-9900 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ Debner & Company ▇▇▇ ▇▇▇▇▇▇ 713-782-1300 Decorative Finishes ▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ Decorative Finishes ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ Delaware School & Office, LLC ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ 302-996-0652 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Delta Office Systems & Furnishings, Inc ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Design Associates, Inc ▇▇▇▇ ▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇ ▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ DesignTeam Plus, LLC ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Desks, Incorporated ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇@▇▇▇▇▇-▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ & Son ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ 361-293-3791 Diversified Office Systems, Inc ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇ 949-786-1358 ▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Diversified Resource Group, Inc (DRG) ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ 678-282-0760 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ Diversification, Inc dba Workpointe ▇▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ D&R Office Works, Inc ▇▇▇▇▇▇▇ ▇▇▇▇ 626-454-4660 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇ Office Solutions ▇▇▇▇ ▇▇▇▇▇▇ 308-382-8026 ▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇ & ▇▇▇▇▇▇, Inc ▇▇▇▇▇ ▇▇▇▇▇▇ 412-795-4482 ▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Eau Claire Business Interiors ▇▇▇▇▇ ▇▇▇▇▇▇▇ 715-833-2300 ▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Ebony Office Interiors ▇▇▇▇▇▇ Small 253-874-1866 ▇▇▇▇▇▇▇▇@▇▇▇.▇▇▇ Edge Ergonomics ▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇ & ▇▇▇▇ Office Furniture ▇▇▇▇ ▇▇▇▇ 410-884-8450 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Electronic Office Environments ▇▇▇▇▇ ▇▇▇▇▇▇ 651-224-0344 ▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Elev8 Office Summer ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇▇▇▇ Business Interiors, LLC ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇ ▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Empire Office, Inc ▇▇▇▇▇▇ ▇▇▇▇▇ 212-607-5500 ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Empire Office Machines ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ EOI, Inc, dba Medical Resources ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇▇ 740-201-3300 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Encompas ▇▇▇▇ ▇▇▇▇▇▇ 816-300-1122 Environments at Work ▇▇▇ ▇▇▇▇▇▇▇ 617-830-5300 ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Ergo Works, Inc ▇▇▇▇ ▇▇▇▇▇▇ 650-322-9775 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ Ergonomic Accessories ▇▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇@▇▇▇.▇▇▇ Ergonomically Correct ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ Ergonomic Seating & Products, Inc ▇▇▇ ▇▇▇▇ 925-736-6176 ▇▇▇.▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ ErgoForm, LLC ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ 703-738-5678 ▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ Ergowise - aka Active Ergonomics ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ 919-676-8211 ▇▇▇▇▇▇▇@▇▇▇▇▇▇▇.▇▇▇ Ergo Direct ▇▇▇▇ ▇▇▇▇▇▇▇ 650-654-4300 ▇▇▇▇@

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor N/A Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Maplewood Career Center OH ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇.▇▇ 330-296-2892 Del Mar College TX ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Judson TX ISD ▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Applicable to Grants, Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds. Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that:

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to have provisions (No Response Required) Requirements as of 9-1-2017 requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line ItemsItems REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (3) references. Entity Name Contact Person Email Phone Amarillo ISD Technology Service ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇.▇▇▇ (▇▇▇)▇▇▇-▇▇▇▇ Clarendon ISD ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇)▇▇▇-▇▇▇▇ ▇▇▇▇▇▇▇-▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇ ISD ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ (▇▇▇)▇▇▇-▇▇▇▇ DJI DRONE PLATFORMS Empower your organization to meet the needs of tomorrow’s workplace with DJI’s innovative drone platforms. Utilizing a range of all-in-one and industrial drone platforms, DJI provides you with robotic tools to improve efficiency, safety and accuracy across a variety of tasks.

Agreement Exceptions/Deviations Explanation. If the proposing Vendor desires to deviate form the Vendor Agreement language, all such deviations must be listed on this attribute, with complete and detailed conditions and information included. TIPS will consider any deviations in its proposal award decisions, and TIPS reserves the right to accept or reject any proposal based upon any deviations indicated below. In the absence of any deviation entry on this attribute, the proposer assures TIPS of their full compliance with the Vendor Agreement. 85 Texas Business and Commerce Code § 272 SB 807 prohibits construction contracts to Line Items REFERENCES Please provide three (3) references, preferably from school districts or other governmental entities who have provisions used your services within the last three years. Additional references may be required. DO NOT INCLUDE TIPS EMPLOYEES AS A REFERENCE. You may provide more than three (No Response Required3) Requirements as references. Entity Name Contact Person VALID EMAIL IS REQUIRED Phone Spring Independent School District ▇▇▇▇▇▇▇ ▇▇▇▇▇▇ d ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇ Houston Independent School District ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇ Fort Bend Independent School District ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇.▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇.▇▇▇ ▇▇▇ ▇▇▇ ▇▇▇▇ FAILURE TO PROPERLY COMPLETE THIS FORM AND SUBMIT WITH YOUR RESPONSE MAY RESULT IN A WAIVER OF YOUR RIGHTS UNDER THE LAW TO MAINTAIN CONFIDENTIALITY TREATMENT OF SUBMITTED MATERIALS. If you consider any portion of 9-1-2017 requiring the contract your proposal to be confidential information and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s), you must make a copy of all claimed confidential materials within your proposal and put this COMPLETED form as a cover sheet to said materials then scan, name “CONFIDENTIAL” and upload with your proposal submission. (You must include the laws confidential information in the submitted proposal as well, the copy uploaded is to indicate which material in your proposal, if any, you deem confidential in the event the receives a Public Information Request.) ESC8 and TIPS will follow procedures of another state, controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law. Pricing of solicited product or service may be deemed as public information under Chapter 552 Texas Gov’t Code. The Office of Texas Attorney General shall make the final determination whether the information held by ESC8 and TIPS is confidential and exempt from public disclosure. I claim part of my proposal to be required confidential and DO NOT desire to litigate expressly waive any claim of confidentiality as to any and all information contained within our response to the contract in another statecompetitive procurement process (e.g. RFP, or CSP, Bid, RFQ, etc.) by completing the following and submitting this sheet with our response to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the projectEducation Service Center Region 8 and TIPS. The term also includes movingattached contains material from our proposal that I classify and deem confidential under Texas Gov't Code Sec. 552 or other law(s) and I invoke my statutory rights to confidential treatment of the enclosed materials. ▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇▇ ▇▇ ▇▇▇-▇▇▇-▇▇▇▇ Address City State ZIP Phone ATTACHED ARE COPIES OF PAGES OF CONFIDENTIAL MATERIAL FROM OUR PROPOSAL Signature Date 12/13/18 OR_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If you do not claim any of your proposal to be confidential, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. Line Itemscomplete the section below only.