Alteration of Delivery Date Clause Samples

Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)
View SourceView Similar (28)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the DELIVERY DATE which the Arbitrator or the Arbitration Board may deem appropriate. To the maximum extent possible and provided the arbitration proceedings or the subject matter of the dispute do not affect the construction of the VESSEL, work under this CONTRACT shall continue during the arbitration of any dispute.
View SourceView Similar (14)
Alteration of Delivery Date. In the event that any dispute or difference is referred either to arbitration or to an expert, the arbitration tribunal or expert, as the case may be, shall, where the dispute requires, include a finding as to whether or not the Delivery Date of the VESSEL should, as a result of such dispute, be in any way altered thereby.
View SourceView Similar (7)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the SELLER shall not be entitled to extend the Delivery Date as defined in ARTICLE VII hereof and the BUYER shall not be entitled to postpone its acceptance of the VESSEL on the Delivery Date or on such newly planned time of delivery of the VESSEL as declared by the SELLER. However, if the construction of the VESSEL is affected by any arbitration or court proceeding, the SELLER shall then be permitted to extend the Delivery Date as defined in ARTICLE VII and the decision or the award shall include a finding as to what extent the SELLER shall be permitted to extend the Delivery Date. (end of Article)
View SourceView Similar (4)
Alteration of Delivery Date. In the event of arbitration of any dispute arising from any matters occurring prior to delivery of the VESSEL EQUIPMENT, all delays in delivery of the VESSEL EQUIPMENT due to such arbitration shall be deemed to be permissible delays and the delivery date shall be automatically postponed and/or extended for the period of time occupied by such arbitration commencing with the notice to arbitrate and concluding with the publication of the award.
View SourceView Similar (3)
Alteration of Delivery Date. In the event of arbitration of any dispute arising or occurring prior to delivery of the VESSEL, an award of the arbitrators shall include a finding as to whether or not the delivery date of the VESSEL is in any way altered thereby.
View SourceView Similar (2)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the SELLER shall not be entitled to extend the Delivery Date as defined in Article VII hereof and the BUYER shall not be entitled to postpone its acceptance of the VESSEL on the Delivery Date or on such newly planned time of delivery of the VESSEL as declared by the SELLER. However, if the construction of the VESSEL is affected by any arbitration, the SELLER shall then be permitted to extend the Delivery Date as defined in Article VII and the decision or the award shall include a finding as to what extent the SELLER shall be permitted to extend the Delivery Date. Shipbuilding Contract Hull No.H1596
View Source

Related to Alteration of Delivery Date

  • Delivery Date the date (or period) for delivery of the Goods or Services as specified and agreed in the Contract.

  • Events Requiring Notice to the Representative The Company shall use its best efforts to cause the Registration Statement to remain effective with a current prospectus for at least nine (9) months after the Applicable Time, and shall notify the Representative immediately and confirm the notice in writing: (i) of the issuance by the Commission of any stop order or of the initiation, or the threatening, of any proceeding for that purpose; (ii) of the issuance by any state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (iv) of the receipt of any comments or request for any additional information from the Commission; and (v) of the happening of any event during the period described in this Section 3.5 that, in the judgment of the Company, makes any statement of a material fact made in the Registration Statement, the Pricing Disclosure Package or the Prospectus untrue or that requires the making of any changes in (a) the Registration Statement in order to make the statements therein not misleading, or (b) in the Pricing Disclosure Package or the Prospectus in order to make the statements therein, in light of the circumstances under which they were made, not misleading. If the Commission or any state securities commission shall enter a stop order or suspend such qualification at any time, the Company shall make every reasonable effort to obtain promptly the lifting of such order.

  • DATE OF DELIVERY OF PUT NOTICE A Put Notice shall be deemed delivered on (i) the Trading Day it is received by facsimile or otherwise by Investor if such notice is received on or prior to 12:00 noon New York time, or (ii) the immediately succeeding Trading Day if it is received by facsimile or otherwise after 12:00 noon New York time on a Trading Day or at anytime on a day which is not a Trading Day.

  • Delivery Dates If the due date of any notice, certificate or report required to be delivered by the Manager hereunder falls on a day that is not a Business Day, the due date for such notice, certificate or report shall be automatically extended to the next succeeding day that is a Business Day.

  • Date of Delivery of Advance Notice An Advance Notice shall be deemed delivered on (i) the Trading Day it is received by facsimile or otherwise by the Investor if such notice is received prior to 12:00 noon Eastern Time, or (ii) the immediately succeeding Trading Day if it is received by facsimile or otherwise after 12:00 noon Eastern Time on a Trading Day or at any time on a day which is not a Trading Day. No Advance Notice may be deemed delivered on a day that is not a Trading Day.