Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)
Appears in 6 contracts
Sources: Construction Contract (Danaos Corp), Construction Contract (Danaos Corp), Construction Contract (Danaos Corp)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date DELIVERY DATE which the Arbitration Board ARBITRATION BOARD may deem appropriate. (End appropriate and/or a determination by the ARBITRATION BOARD as to whether a delay is classified as permissible or non-permissible for the purpose of Article)Article VIII hereof and/or Article V hereof.
Appears in 4 contracts
Sources: Shipbuilding Contract (Quintana Maritime LTD), Shipbuilding Contract (Quintana Maritime LTD), Shipbuilding Contract (Quintana Maritime LTD)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSELDRILLSHIP, the award may include any postponement adjustment of the Delivery Date which that the Arbitration Board may deem appropriate. (End of Article).
Appears in 3 contracts
Sources: Construction Contract (DryShips Inc.), Contract for Construction and Sale of a Drillsip (DryShips Inc.), Construction Contract (DryShips Inc.)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article).
Appears in 3 contracts
Sources: Shipbuilding Contract (Scorpio Bulkers Inc.), Ship Sales Contract (Scorpio Bulkers Inc.), Ship Building Contract (Danaos Corp)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board Arbitrators may deem appropriate. (End of Article).
Appears in 3 contracts
Sources: Ship Sale Contract (Globus Maritime LTD), Ship Sale Contract (Globus Maritime LTD), Ship Sale Contract (Globus Maritime LTD)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date Date, which the Arbitration Board may deem appropriate. (End of Article).
Appears in 2 contracts
Sources: Shipbuilding and Construction Agreement (Stolt Nielsen S A), Shipbuilding and Construction Agreement (Stolt Nielsen S A)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement adjustment of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)
Appears in 2 contracts
Sources: Contract for Construction and Sale of Vessel (R&b Falcon Corp), Construction Contract (R&b Falcon Corp)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSELDRILLS HIP, the award may include any postponement adjustment of the Delivery Date which that the Arbitration Board may deem appropriate. (End of Article).
Appears in 2 contracts
Sources: Construction Contract (DryShips Inc.), Construction Contract (DryShips Inc.)
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of the matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date DELIVERY DATE which the Arbitration Board ARBITRATION BOARD may deem appropriate. (End of Article).
Appears in 1 contract
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSEL, the award may include any postponement of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)) 44
Appears in 1 contract
Sources: Construction Contract
Alteration of Delivery Date. In the event of reference to arbitration of any dispute arising out of matters occurring prior to delivery of the VESSELDRILLSHIP, the award may include any postponement adjustment of the Delivery Date which the Arbitration Board may deem appropriate. (End of Article)) ------------------------------------------
Appears in 1 contract
Sources: Contract for Construction and Sale of a Drilling Ship (R&b Falcon Corp)