Manner of Construction Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises that required the consent of Landlord, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, subcontractors, materials, mechanics and materialmen approved in advance by Landlord (which approval shall not be unreasonably withheld, conditioned or delayed), or the requirement that Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and, if applicable, pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority), all in conformance with Landlord's reasonable construction rules and regulations; provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord's design parameters and code compliance issues. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the "Base Building," as that term is defined below, then Landlord shall, at Tenant's expense, make such changes to the Base Building. The "Base Building" shall include the structural portions of the Building, including the roof, foundation and exterior walls and windows), and the exit stairwells and the systems and equipment located in the internal core of the Building. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to materially obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to materially obstruct the business of Landlord or other tenants in the Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations (or repairs), Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations, if any, as well as copies of any permits, approvals and other documents issued by any governmental agency in connection with the Alterations.
ICIF Construction The ICIF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Parties agree on another mutually acceptable deadline, Interconnection Customer shall deliver to Transmission Provider and Transmission Owner “as-built” drawings, information and documents for the ICIF, such as: a one-line diagram, a site plan showing the Generating Facility and the ICIF, plan and elevation drawings showing the layout of the ICIF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer’s step-up transformers, the facilities connecting the Generating Facility to the step-up transformers and the ICIF, and the impedances (determined by factory tests) for the associated step-up transformers and the Generating Facility. Interconnection Customer shall provide Transmission Provider and Transmission Owner with Interconnection Customer’s specifications for the excitation system, automatic voltage regulator, Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.
DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.
Cost of Construction 1. During the Schematic Design, Design Development, and Construction Document Phases, the ARCHITECT’s estimates of Construction Cost shall be reconciled against the Budget approved by the DISTRICT pursuant to Article IV, Section 2. 2. The PROJECT’s “Construction Cost,” as used in this AGREEMENT, means the total cost to the DISTRICT of all work designed or specified by the ARCHITECT, which includes the total award from the initial construction Contract(s) plus the work covered by approved change orders and/or any alternates approved by the DISTRICT. The Construction Cost shall not include any costs that are not specifically referenced in this Article V, Section 2, as approved costs. Costs excluded from the Construction Cost include, but are not limited to, payments to the ARCHITECT or other DISTRICT consultants, costs of inspections, surveys, tests, and landscaping not included in PROJECT. 3. If the PROJECT is using the multiple-prime delivery method of construction, the Construction Manager’s fees and/or general conditions will only be included in the total Construction Cost used to calculate the ARCHITECT’s fee only if agreed upon in writing by the DISTRICT. Absent any written agreement, the Construction Manager’s fees or general conditions shall not be included in the total Construction Cost used to calculate the ARCHITECT’s fee. 4. When labor or material is furnished by the DISTRICT below its market cost, the Construction Cost shall be based upon current market cost of labor and new material. 5. The Construction Cost shall be the acceptable estimate of Construction Costs to the DISTRICT as submitted by the ARCHITECT until such time as bids have been received, whereupon it shall be the bid amount of the lowest responsible responsive bidder. 6. Any Budget or fixed limit of Construction Cost shall be adjusted if the bidding has not commenced within ninety (90) days after the ARCHITECT submits the Construction Documents to the DISTRICT to reflect changes in the general level of prices in the construction industry between the date of submission of the Construction Documents to the DISTRICT and the date on which bids are sought for the PROJECT. 7. If the lowest bid received exceeds the Budget: a. The DISTRICT may give written approval of an increase of such fixed limit and proceed with the construction of the PROJECT; b. The DISTRICT may authorize rebidding of the PROJECT within a reasonable time; c. If the PROJECT is abandoned, the DISTRICT may terminate this AGREEMENT in accordance with Article VIII, Section 2; d. The DISTRICT may request the ARCHITECT prepare, at no additional cost, deductive change packages that will bring the PROJECT within the Budget; or e. The DISTRICT may request the ARCHITECT cooperate in revising the PROJECT scope and quality as required to reduce the Construction Cost. 8. If the DISTRICT chooses to proceed under Article V, Section 7(e), the ARCHITECT, without additional charge, agrees to redesign the PROJECT until the PROJECT is brought within the Budget set forth in this AGREEMENT. Redesign does not mean phasing or removal of parts of the PROJECT unless agreed to in writing by the DISTRICT. Redesign means the redesign of the PROJECT, with all its component parts, to meet the Budget set forth in this AGREEMENT.
Certain Matters of Construction The terms “herein,” “hereof,” “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular section, paragraph or subdivision. Any pronoun used shall be deemed to cover all genders. In the computation of periods of time from a specified date to a later specified date, “from” means “from and including,” and “to” and “until” each mean “to but excluding.” The terms “including” and “include” shall mean “including, without limitation” and, for purposes of each Loan Document, the parties agree that the rule of ejusdem generis shall not be applicable to limit any provision. Section titles appear as a matter of convenience only and shall not affect the interpretation of any Loan Document. All references to (a) laws or statutes include all related rules, regulations, interpretations, amendments and successor provisions; (b) any document, instrument or agreement include any amendments, waivers and other modifications, extensions or renewals (to the extent permitted by the Loan Documents); (c) any section mean, unless the context otherwise requires, a section of this Agreement; (d) any exhibits or schedules mean, unless the context otherwise requires, exhibits and schedules attached hereto, which are hereby incorporated by reference; (e) any Person include successors and assigns; (f) time of day mean time of day at Agent’s notice address under Section 14.3.1; or (g) discretion of Agent, Issuing Bank or any Lender mean the sole and absolute discretion of such Person. All calculations of Value, fundings of Loans, issuances of Letters of Credit and payments of Obligations shall be in Dollars and, unless the context otherwise requires, all determinations (including calculations of Borrowing Base and financial covenants) made from time to time under the Loan Documents shall be made in light of the circumstances existing at such time. Borrowing Base calculations shall be consistent with historical methods of valuation and calculation, and otherwise satisfactory to Agent (and not necessarily calculated in accordance with GAAP). Borrowers shall have the burden of establishing any alleged negligence, misconduct or lack of good faith by Agent, Issuing Bank or any Lender under any Loan Documents. No provision of any Loan Documents shall be construed against any party by reason of such party having, or being deemed to have, drafted the provision. Whenever the phrase “to the best of Borrowers’ knowledge” or words of similar import are used in any Loan Documents, it means actual knowledge of a Senior Officer, or knowledge that a Senior Officer would have obtained if he or she had engaged in good faith and diligent performance of his or her duties, including reasonably specific inquiries of employees or agents and a good faith attempt to ascertain the matter to which such phrase relates.