Claims for Additional Fees Sample Clauses

The "Claims for Additional Fees" clause establishes the process by which a party, typically a contractor or service provider, can request extra payment beyond the original contract sum. This clause outlines the circumstances under which additional fees may be claimed, such as unforeseen work, changes in project scope, or delays caused by the client, and usually requires the claimant to submit timely written notice and supporting documentation. Its core function is to provide a clear and fair mechanism for addressing and compensating legitimate cost overruns, thereby reducing disputes and ensuring both parties understand how extra charges will be handled.
POPULAR SAMPLE Copied 1 times
Claims for Additional Fees. Any claim for additional fees shall be made to the Owner no more than twenty calendar days after the occurrence of the event giving rise to the claim. If the Owner and the Design Professional cannot agree on the additional fee requested, the dispute will be resolved in accordance with Section 5.
View SourceView Similar (61)
Claims for Additional Fees. Any claim for additional fees shall be made to the Owner no more than twenty (20) calendar days after the occurrence of the event giving rise to the claim. The Owner may not honor claims made after twenty
View SourceView Similar (6)

Related to Claims for Additional Fees

  • CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order. 12.3.2 If the Contractor claims that additional cost is involved because of, but not limited to, (1) any order by the State to stop the Work pursuant to Paragraph 3.3 of these General Conditions where the Contractor was not at fault, or (2) failure of payment by the State pursuant to Paragraph 9.7(of these General Conditions), the Contractor shall make such claim as provided in Subparagraph 12.3.1 of this agreement. 12.3.3 The Architect will have authority to order minor changes in the Work not involving an adjustment in the Contract Sum or an extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the State and Contractor within 10 days unless the Contractor or the State objects to the change in writing.

  • Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary. § 14.1.6.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably anticipated, and had an adverse effect on the scheduled construction.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Payment of Additional Costs If termination of this contract is due to the failure of the Engineer to fulfill its contract obligations, the State may take over the project and prosecute the work to completion, and the Engineer shall be liable to the State for any additional cost to the State.

  • Indemnification for Additional Expenses Without limiting the generality or effect of the foregoing, the Company shall indemnify and hold harmless Indemnitee against and, if requested by Indemnitee, shall reimburse Indemnitee for, or advance to Indemnitee, within five business days of such request accompanied by supporting documentation for specific Expenses to be reimbursed or advanced, any and all actual and reasonable Expenses paid or incurred by Indemnitee in connection with any Claim made, instituted or conducted by Indemnitee for (a) indemnification or reimbursement or advance payment of Expenses by the Company under any provision of this Agreement, or under any other agreement or provision of the Constituent Documents now or hereafter in effect relating to Indemnifiable Claims, and/or (b) recovery under any directors’ and officers’ liability insurance policies maintained by the Company; provided, however, if it is ultimately determined that the Indemnitee is not entitled to such indemnification, reimbursement, advance or insurance recovery, as the case may be, then the Indemnitee shall be obligated to repay any such Expenses to the Company; provided further, that, regardless in each case of whether Indemnitee ultimately is determined to be entitled to such indemnification, reimbursement, advance or insurance recovery, as the case may be, Indemnitee shall return, without interest, any such advance of Expenses (or portion thereof) which remains unspent at the final disposition of the Claim to which the advance related.