Common use of COOPERATION BETWEEN CONTRACTORS Clause in Contracts

COOPERATION BETWEEN CONTRACTORS. During the course of completing the work on this Contract the Contractor may be required to work in close proximity to any adjacent projects (▇▇▇▇▇▇▇▇ Phase 13) and any other Contractor(s). The Contractor shall make every reasonable effort to schedule their activities so as not to bring them into conflict with the work of other Contractor(s). Should conflict arise the Project Engineer shall arbitrate any such disputes. The decision of the Project Engineer shall be final. Delays incurred due to this situation shall not constitute a claim on the part of the Contractor for damages or for any loss of anticipated profits.

COOPERATION BETWEEN CONTRACTORS. During the course of completing the work on this Contract the Contractor may be required to work in close proximity to any adjacent projects (▇▇▇▇▇▇▇▇ Phase 13) and any other Contractor(s). The Contractor shall make every reasonable effort to schedule their activities so as not to bring them into conflict with the work of other Contractor(s). Should conflict arise the Project Engineer shall arbitrate any such disputes. The decision of the Project Engineer shall will be final. Delays incurred due to this situation shall not constitute a claim on the part of the Contractor for damages or for any loss of anticipated profits.