Test Results The employer, upon request from an employee or former employee, will provide the confidential written report issued pursuant to 4.9 of the Canadian Model in respect to that employee or former employee.
Data Access Access to Contract and State Data The Contractor shall provide to the Client Agency access to any data, as defined in Conn. Gen Stat. Sec. 4e-1, concerning the Contract and the Client Agency that are in the possession or control of the Contractor upon demand and shall provide the data to the Client Agency in a format prescribed by the Client Agency and the State Auditors of Public Accounts at no additional cost.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Data Access Control Persons entitled to use data processing systems gain access only to the Personal Data that they have a right to access, and Personal Data must not be read, copied, modified or removed without authorization in the course of processing, use and storage.
Compatibility 1. Any unresolved issue arising from a mutual agreement procedure case otherwise within the scope of the arbitration process provided for in this Article and Articles 25A to 25G shall not be submitted to arbitration if the issue falls within the scope of a case with respect to which an arbitration panel or similar body has previously been set up in accordance with a bilateral or multilateral convention that provides for mandatory binding arbitration of unresolved issues arising from a mutual agreement procedure case. 2. Nothing in this Article and Articles 25A to 25G shall affect the fulfilment of wider obligations with respect to the arbitration of unresolved issues arising in the context of a mutual agreement procedure resulting from other conventions to which the Contracting States are or will become parties.”.