DISPUTE RESOLUTION, BETTERMENT, AND COMMUNICATIONS Sample Clauses

DISPUTE RESOLUTION, BETTERMENT, AND COMMUNICATIONS. 3.1 DISPUTE RESOLUTION A/E and CLIENT agree to negotiate all disputes between them in good faith for a minimum of 30 days from the date of notice. Should such negotiations fail, A/E and CLIENT agree that any dispute between their arising out of, or relating to, this Agreement shall be submitted to non-binding mediation prior to the filing of any lawsuit or arbitration proceeding relating to the dispute, unless the parties mutually agree otherwise in writing. The mediation shall be conducted remotely and by electronic video conference means, unless the parties agree in writing to mediate in person at a mutually agreeable location. The parties agree that conducting mediation by remote means shall constitute a mediation in the state where the Project is located, provided that each of the parties shall have one representative participating in the mediation while the representative is situated in the state where the Project is located. Each party shall assume its own costs associated with the mediation. The mediator’s compensation and expenses and any administrative fees or costs associated with the mediation proceeding shall be borne equally by the parties, unless otherwise agreed in writing. Notwithstanding the foregoing, none of the above Dispute Resolution processes shall prevent or deter a party from protecting or acting upon lien rights, or from seeking immediate, emergency or injunctive relief from a court of competent jurisdiction and as may be available at law or in equity.
View SourceView Similar (3)

Related to DISPUTE RESOLUTION, BETTERMENT, AND COMMUNICATIONS

  • Dispute Resolutions Parties agree to arbitration of dispute in Houston, Texas, USA.

  • Applicable Law; Dispute Resolution i. This Agreement, and all claims, disputes or disagreements arising out of or connected with this Agreement, its validity or any breach thereof, shall be governed by the laws in effect in the State of Texas (excluding conflicts of laws provisions), and to the extent applicable to maritime issues, the maritime laws of the United States (excluding conflict of laws provisions). ii. PHA and Carrier desire to resolve any dispute, which may arise in connection with the Agreement in a timely and efficient manner. The parties therefore agree that the parties will attempt to resolve disputes arising hereunder in accordance with the following procedures. iii. Either party may request the other to attend a meeting for the purpose of resolving any dispute or disagreement arising from the provisions specified in the Agreement. Said meeting shall be held either in person in Houston, Texas, or by telephone within five (5) business days of receipt of written request specifying a brief description of the dispute, the monetary amount involved if known, and the remedies sought. iv. If the matter is not resolved in such meeting, or if such meeting is not held, either party may make written demand to attempt to resolve such dispute by non-binding mediation. Within seven (7) days after service of written notice on the other party demanding mediation, the parties in dispute shall jointly agree upon a mediator, and within thirty (30) days thereafter the parties shall undertake such mediation in Houston, Texas. In no event shall the parties be obligated to pursue mediation that does not resolve the issue within thirty

  • Governing Law; Dispute Resolution (a) This Limited Guarantee shall be interpreted, construed and governed by and in accordance with the Laws of the State of New York without regard to the conflicts of law principles thereof that would subject such matter to the Laws of another jurisdiction other than the State of New York. (b) Any disputes, actions and proceedings against any party or arising out of or in any way relating to this Limited Guarantee shall be submitted to the Hong Kong International Arbitration Centre (the “HKIAC”) and resolved in accordance with the Arbitration Rules of HKIAC in force at the relevant time (the “Rules”) and as may be amended by this Section 10(b). The place of arbitration shall be Hong Kong. The official language of the arbitration shall be English and the arbitration tribunal shall consist of three arbitrators (each, an “Arbitrator”). The claimant(s), irrespective of number, shall nominate jointly one Arbitrator; the respondent(s), irrespective of number, shall nominate jointly one Arbitrator; and a third Arbitrator will be nominated jointly by the first two Arbitrators and shall serve as chairman of the arbitration tribunal. In the event the claimant(s) or respondent(s) or the first two Arbitrators shall fail to nominate or agree on the joint nomination of an Arbitrator or the third Arbitrator within the time limits specified by the Rules, such Arbitrator shall be appointed promptly by the HKIAC. The arbitration tribunal shall have no authority to award punitive or other punitive-type damages. The award of the arbitration tribunal shall be final and binding upon the disputing parties. Any party to an award may apply to any court of competent jurisdiction for enforcement of such award and, for purposes of the enforcement of such award, the parties irrevocably and unconditionally submit to the jurisdiction of any court of competent jurisdiction and waive any defenses to such enforcement based on lack of personal jurisdiction or inconvenient forum. (c) Notwithstanding the foregoing, the parties hereto consent to and agree that in addition to any recourse to arbitration as set out in Section 10(b), any party may, to the extent permitted under the Laws of the jurisdiction where application is made, seek an interim injunction from a court or other authority with competent jurisdiction and, notwithstanding that this Agreement is governed by the Laws of the State of New York, a court or authority hearing an application for injunctive relief may apply the procedural Law of the jurisdiction where the court or other authority is located in determining whether to grant the interim injunction. For the avoidance of doubt, this Section 10(c) is only applicable to the seeking of interim injunctions and does not restrict the application of Section 10(b) in any way.

  • Submission to Dispute Resolution (i) Notwithstanding anything to the contrary in this Warrant, in the case of a dispute relating to the Exercise Price, the Closing Sale Price, the Closing Bid Price, Black Scholes Consideration Value, Event of Default Black Scholes Value, Black Scholes Value or fair market value or the arithmetic calculation of the number of Warrant Shares (as the case may be) (including, without limitation, a dispute relating to the determination of any of the foregoing) (the “Warrant Calculations”), the Company or the Holder (as the case may be) shall submit the dispute to the other party via electronic mail (A) if by the Company, within two (2) Trading Days after the occurrence of the circumstances giving rise to such dispute or (B) if by the Holder, at any time after the Holder learned of the circumstances giving rise to such dispute. If the Holder and the Company are unable to agree upon such determination or calculation within two (2) Trading Days following such initial notice by the Company or the Holder (as the case may be) of such dispute to the Company or the Holder (as the case may be), then the Holder may, at its sole option, submit the dispute to an independent, reputable investment bank or independent, outside accountant selected by the Holder (the “Independent Third Party”), and the Company shall pay all expenses of such Independent Third Party. (ii) The Holder and the Company shall each deliver to such Independent Third Party (A) a copy of the initial dispute submission so delivered in accordance with the first sentence of this Section 15(a) and (B) written documentation supporting its position with respect to such dispute, in each case, no later than 5:00 p.m. (New York time) by second (2nd) Business Day immediately following the date on which the Holder selected such Independent Third Party (the “Dispute Submission Deadline”) (the documents referred to in the immediately preceding clauses (A) and (B) are collectively referred to herein as the “Required Dispute Documentation”) (it being understood and agreed that if either the Holder or the Company fails to so deliver all of the Required Dispute Documentation by the Dispute Submission Deadline, then the party who fails to so submit all of the Required Dispute Documentation shall no longer be entitled to (and hereby waives its right to) deliver or submit any written documentation or other support to such Independent Third Party with respect to such dispute and such Independent Third Party shall resolve such dispute based solely on the Required Dispute Documentation that was delivered to such Independent Third Party prior to the Dispute Submission Deadline). Unless otherwise agreed to in writing by both the Company and the Holder or otherwise requested by such Independent Third Party, neither the Company nor the Holder shall be entitled to deliver or submit any written documentation or other support to such Independent Third Party in connection with such dispute, other than the Required Dispute Documentation. (iii) The Company and the Holder shall cause such Independent Third Party to determine the resolution of such dispute and notify the Company and the Holder of such resolution no later than five (5) Business Days immediately following the Dispute Submission Deadline. The fees and expenses of such Independent Third Party shall be borne solely by the Company, and such Independent Third Party’s resolution of such dispute shall be final and binding upon all parties absent manifest error.

  • Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager. 2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation. 3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief. 4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.