Informal Dispute Resolution Process Sample Clauses
POPULAR SAMPLE Copied 2 times
Informal Dispute Resolution Process. 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager.
2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation.
3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief.
4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
Informal Dispute Resolution Process. Unless the Parties agree upon another dispute resolution process, or unless an aggrieved Party has initiated administrative proceedings or suit in Federal court, the Parties may use the following process to attempt to resolve disputes:
(a) The aggrieved Party will notify the other Parties of the provision that may have been violated, the basis for contending that a violation has occurred, and the remedies it proposes to correct the alleged violation.
(b) The Party alleged to be in violation will have 30 days, or such other time as may be agreed, to respond. During this time it may seek clarification of the information provided in the initial notice. The aggrieved Party will use its best efforts to provide any information available to it that may be responsive to such inquiries within the allotted time.
(c) Within 30 days after such response was provided or was due, representatives of the Parties having authority to resolve the dispute will meet and negotiate in good faith toward a solution satisfactory to all Parties, or will establish a specific process and timetable to seek such a solution.
(d) If any issues cannot be resolved through such negotiations, the Parties will consider non-binding mediation and other alternative dispute resolution processes and, if a dispute resolution process is agreed upon, will make good faith efforts to resolve all remaining issues through that process.
Informal Dispute Resolution Process. The Parties may agree to informal dispute resolution proceedings to fairly and expeditiously resolve disputes related to the interpretation or enforcement of, or compliance with, the provision of this Agreement ("Disputes"). These dispute resolution proceedings may include: (a) procedures developed by the County for expeditious interpretation of questions arising under development agreements; or (b) any other manner of dispute resolution that is mutually agreed upon by the Parties.
Informal Dispute Resolution Process. 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager.
Informal Dispute Resolution Process. If you are dissatisfied with our Services for any reason, please contact PeopleMedia Customer Service first so we can try to resolve your concerns without the need of outside assistance. If you choose to pursue a dispute, claim or controversy against PeopleMedia, these terms will apply. For purposes of this Dispute Resolution Process and Arbitration Procedures set forth in Section 15, “PeopleMedia” shall include our affiliates, employees, licensors, and service providers. PeopleMedia values its relationship with you and appreciates the mutual benefit realized from informally resolving Disputes (as defined below). Before formally pursuing a Dispute in arbitration or small claims court, you agree to first send a detailed notice (“Notice”) to Match Group Legal, ▇.▇. ▇▇▇ ▇▇▇▇▇, ▇▇▇▇▇▇, ▇▇▇▇▇ ▇▇▇▇▇, ▇▇▇. If PeopleMedia has a Dispute with you, PeopleMedia agrees to first send a Notice to you at your most recent email address on file with us, or if no email address is on file, other contact information associated with your account. Your Notice must contain all of the following information: (1) your full name;
Informal Dispute Resolution Process. All non-monetary matters and monetary claims, disputes or issues involving less than $50,000.00 shall be disposed of in the following manner:
(1) The claimant must first comply with all contractual procedures, requirements, and deadlines before seeking any dispute resolution under this provision. If the claimant fails to comply with any contractual procedure or requirement and any applicable deadline has not passed, then CM shall advise claimant to comply with the contractual procedure or requirement. If claimant complied with the contractual procedures and/or requirements but was untimely in seeking dispute resolution under this provision, CM, at its discretion, may waive the untimely submission for good cause shown by claimant and/or a determination that it is in the best interest to consider the submission if doing so will progress the Project to completion. If a claimant failed to comply with the contract requirements and an applicable deadline, then the submission shall be automatically rejected absent good cause shown and the claimant’s failure to comply with the contract requirements and deadline were caused by events or persons outside claimant’s control (negligence of claimant’s employees or representatives shall constitute good cause). Owner will afforded greater leniency when considering issues of noncompliance with contract requirements and deadlines than Contractor.
(2) The claimant shall submit to CM a short written statement of the claim, dispute or issue and/or attach the document reflecting or containing the claim, dispute or issue (e.g., rejected change order request, rejected request for time extension and a schedule narrative/time impact analysis supporting a delay claim, notice of deficiency or non-conforming work, request for information, unpaid invoice or payment application, audit finding, etc.).
(3) CM shall investigate the claim, dispute or issue within ten (10) calendar days and the investigation may include but is not limited to: requesting a written response from any party to the claim, dispute or issue within this time period; requesting a conference call or meeting with all parties to the claim, dispute or issue; and/or consult with Commerce on issues involving CDBG-DR compliance.
(4) After the investigation, CM shall issue a summary decision disposing of the claim, dispute or issue with a notice informing the claimant and respondent(s) on how to appeal CM’s decision to NCORR.
(5) If claimant or respondent elects to appeal CM...
Informal Dispute Resolution Process. The District and Provider shall attempt to resolve any dispute that may arise under this Agreement. If the dispute cannot be resolved locally, an appeal may be made to the Commissioner pursuant to N.J.A.C. 6A:3 et seq., Controversies and Disputes. XIII Subcontracting and Assignment The Provider shall not subcontract and/or assign services to be provided pursuant to Section I of this Agreement, without written approval from the District and the Commissioner. The Provider agrees to make all records of any subcontractor available to the District, the DOE, the DCF and any federal agency whose funds are expended in the course of this Agreement for the purpose of review. All subcontracts entered into by the Provider shall include a provision whereby the Subcontractor acknowledges its obligation to make all pertinent records available to the District, the DOE, the DCF and any federal agency whose funds are expended in the course of this Agreement. XIV Indemnification The Provider shall assume all risk of and responsibility for, and agrees to indemnify, defend and save harmless the State of New Jersey and its employees from and against any and all claims, demands, suits, actions, recoveries, judgments and costs, and expenses in connection therewith on account of the loss of life, property or injury or damages to the person, body or property of any person or persons, whatsoever, which shall arise from or result directly or indirectly from (1) the work, service or materials provided under this Agreement; or (2) any failure to perform the Provider’s obligations under this Agreement or any improper or deficient performance of the Provider’s obligations under this Agreement. This indemnification obligation is not limited by, but is in addition to, the insurance obligations contained in this Agreement. Furthermore, the provisions of this indemnification clause shall in no way limit the obligations assumed by the Provider under this Agreement, nor shall they be construed to neither relieve the Provider from any liability nor preclude the State from taking other actions available to it under any other provision of this Agreement or at law. The Provider shall assume all risk of and responsibility for, and agrees to indemnify, defend and save harmless the District and its employees from and against any and all claims, demands, suits, actions, recoveries, judgments and costs, and expenses in connection therewith on account of the loss of life, property or injury or damages t...
Informal Dispute Resolution Process. The District and Head Start Grantee shall attempt to resolve any dispute that may arise under this Agreement. If the dispute cannot be resolved locally, an appeal may be made to the Commissioner pursuant to N.J.A.C. 6A:3
Informal Dispute Resolution Process. If you are dissatisfied with our Services for any reason, please contact POF Customer Service first so we can try to resolve your concerns without the need of outside assistance. If you choose to pursue a dispute, claim or controversy against POF, these terms will apply. For purposes of this Dispute Resolution Process and Arbitration Procedures set forth in Section 15, “POF” shall include our affiliates, employees, licensors, and service providers. POF values its relationship with you and appreciates the mutual benefit realized from informally resolving Disputes (as defined below). Before formally pursuing a Dispute in arbitration or small claims court, you agree to first send a detailed notice (“Notice”) to Match Group Legal, P.O. Box 25458, Dallas, Texas 75225, USA. If POF has a Dispute with you, POF agrees to first send a Notice to you at your most recent email address on file with us, or if no email address is on file, other contact information associated with your account. Your Notice must contain all of the following information: (1) your full name; (2) information that enables POF to identify your account, including a picture or screenshot of your profile, your address, mobile phone number, email address, and date of birth you used to register your account if any; and (3) a detailed description of your Dispute, including the nature and factual basis of your claim(s) and the relief you are seeking with a corresponding calculation of your alleged damages (if any). You must personally sign this Notice for it to be effective. POF’s Notice must likewise set forth a detailed description of its Dispute, which shall include the nature and factual basis of its claim(s) and the relief it is seeking, with a corresponding calculation of our damages (if any). You and POF agree to then negotiate in good faith in an effort to resolve the Dispute. As part of these good faith negotiations, if POF requests a telephone conference with you to discuss your Dispute, you agree to personally participate, with your attorney if you’re represented by counsel. Likewise, if you request a telephone conference to discuss POF’s Dispute with you, ▇▇▇ agrees to have one representative participate. This informal process should lead to a resolution of the Dispute. However, if the Dispute is not resolved within 60 days after receipt of a fully completed Notice and the Parties have not otherwise mutually agreed to an extension of this informal dispute resolution time period, you or POF ...
Informal Dispute Resolution Process. Neither you nor we may commence, join, or be joined to any judicial action (as either an individual litigant or a member of a class) arising from the other party’s actions relating in any way to your account or alleging that the other party has breached any provision of, or any duty owed by reason of, any agreement with OnPoint, until you or we have notified the other party pursuant to the notice procedures for the informal dispute-resolution process described in this section, and have given the other party a reasonable period to take corrective action (if corrective action is appropriate). You and we agree that a reasonable period to take corrective action will be 60 days from the date the required notice was given unless applicable law specifies a shorter period for corrective action to be taken, in which case the time specified under applicable law will be deemed to be reasonable for purposes of this section. You must provide this notice once you become aware of a claim and within the time required under applicable law. All notices given in connection with this informal dispute resolution process by either you or us must be in writing. If we provide notice to you in connection with this informal dispute-resolution process, the notice will be considered to have been given to you when it is mailed to your address by first-class mail or when it is actually delivered to your address if sent by other means. The notice address will be the address associated with your account at the time of the notice. There may be only one designated notice address under this informal dispute-resolution section at any one time. Any notice you provide to us shall be given by delivering it or by mailing it by first-class mail to our address as designated in this Agreement and will be considered given when we actually receive the notice. If any notice required by this informal dispute-resolution process is also required under applicable law, the applicable law requirement will satisfy the corresponding notice requirement under this informal dispute-resolution process.