EVENTS OF DEFAULTS AND CONSEQUENCES Subject to the Force Majeure clause, the Promoter shall be considered under a condition of Default, in the following events:
(i) Promoter fails to provide ready to move in possession of the [Apartment/Plot] to the Allottee within the time period specified. For the purpose of this clause, 'ready to move in possession' shall mean that the apartment shall be in a habitable condition which is complete in all respects;
(ii) Discontinuance of the Promoter's business as a developer on account of suspension or revocation of his registration under the provisions of the Act or the rules or regulations made thereunder. In case of Default by Promoter under the conditions listed above, Allottee is entitled to the following:
(i) Stop making further payments to Promoter as demanded by the Promoter. If the Allottee stops making payments, the Promoter shall correct the situation by completing the construction milestones and only thereafter the Allottee be required to make the next payment without any penal interest; or
(ii) The Allottee shall have the option of terminating the Agreement in which case the Promoter shall be liable to refund the entire money paid by the Allottee under any head whatsoever towards the purchase of the apartment, along with interest at the rate specified in the Rules within forty-five days of receiving the termination notice: Provided that where an Allottee does not intend to withdraw from the project or terminate the Agreement, he shall be paid, by the promoter, interest at the rate specified in the Rules, for every month of delay till the handing over of the possession of the [Apartment/Plot]. The Allottee shall be considered under a condition of Default, on the occurrence of the following events:
(i) In case the Allottee fails to make payments for consecutive demands made by the Promoter as per the Payment Plan annexed hereto, despite having been issued notice in that regard the allottee shall be liable to pay interest to the promoter on the unpaid amount at the rate specified in the Rules.
(ii) In case of Default by Allottee under the condition listed above continues for a period beyond consecutive months after notice from the Promoter in this regard, the Promoter shall cancel the allotment of the [Apartment/ Plot] in favour of the Allottee and refund the amount money paid to him by the allottee by deducting the booking amount and the interest liabilities and this Agreement shall thereupon stand terminated.
Default and Consequences of Default 10.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and one half percent (2.5%) per calendar month and such interest shall compound monthly at such a rate after as well as before any judgment.
10.2 If the Customer defaults in payment of any invoice when due, the Customer shall indemnify the Creditor from and against all costs and disbursements incurred by the Creditor in pursuing the debt including legal costs on a solicitor and own client basis and the Creditor’s debt collection costs.
10.3 Without prejudice to any other remedies the Creditor may have, if at any time the Customer is in breach of any obligation (including those relating to payment), the Creditor may suspend or terminate the supply of Goods and/or Services to the Customer and any of its other obligations under the terms and conditions. The Customer acknowledges and agrees that the Creditor will not be liable to the Customer for any loss or damage the Customer suffers because the Creditor has exercised its rights under this clause.
10.4 If any account remains overdue after thirty (30) days then an amount of the greater of twenty dollars ($20.00) or ten percent (10.00%) of the amount overdue (up to a maximum of two hundred dollars ($200.00)) shall be levied for administration fees which sum shall become immediately due and payable.
10.5 Without prejudice to the Creditor’s other remedies at law the Creditor shall be entitled to cancel all or any part of any order of the Customer which remains unfulfilled and all amounts owing to the Creditor shall, whether or not due for payment, become immediately payable in the event that;
(a) any money payable to the Creditor becomes overdue, or in the Creditor’s opinion the Customer will be unable to meet its payments as they fall due; or
(b) the Customer becomes insolvent, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
(c) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Customer or any asset of the Customer.
Consequences of Events of Default (a) If an Event of Default of the type described in Section 3.1(a) or (b) has occurred and continued for 15 days or any other Event of Default has occurred, the interest rate on this Note will increase immediately by an increment of two percentage points to the extent permitted by law. Thereafter, until such time as no Event of Default exists, the interest rate on this Note will increase automatically at the end of each succeeding fiscal quarter by an additional increment of one percentage points to the extent permitted by law (but in no event will the interest rate exceed 18 percent per annum). Any increase of the interest rate resulting from the operation of this Section 3.2(a) will terminate as of the close of business on the date on which no Events of Default exist (subject to subsequent increases pursuant to this Section).
(b) If an Event of Default of the type described in Section 3.1(d) has occurred, the principal amount of this Note (together with all accrued interest thereon and all other amounts payable in connection therewith) will become immediately due and payable without any action on the part of the Holder, and the Companies will immediately pay to the Holder all amounts due and payable with respect to this Note.
(c) If an Event of Default of the type described in Section 3.1(a) or (b) has occurred and continued for 15 days and if an Event of Default of the type described in Section 3.1(b) has occurred and continued for 30 days, or any other Event of Default (other than under Section 3.1(d)) has occurred, the Holder may declare all or any portion of the outstanding principal amount of this Note (together with all accrued interest thereon and all other amounts due in connection therewith) due and payable and demand immediate payment of all or any portion of such amount. If the Holder demands immediate payment and all or any portion of the amounts due under this Note, the Companies will immediately pay to the Holder all amounts demanded to be paid with respect to this Note.
(d) The Holder will also have any other rights which it may have been afforded under any contract or agreement at any time and any other rights which the Holder may have pursuant to applicable law.
(e) Each Company hereby waives diligence, presentment, protest and demand and notice of protest and demand, dishonor and nonpayment of this Note, and expressly agrees that this Note, or any payment hereunder, may be extended from time to time and that the Holder may accept security for this Note or release security for this Note, all without in any way affecting the liability of the Companies hereunder.
Consequences of Event of Default (a) Upon the occurrence of an Event of Default, the Company shall promptly deliver written notice thereof to the Holder. If one or more Events of Default shall have occurred and be continuing (whatever the reason for such Event of Default and whether it shall be voluntary or involuntary or be effected by operation of law or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any Governmental Authority), then, and in each and every such case (other than an Event of Default specified in Section 2.4(h) or Section 2.4(i) with respect to the Company or any of its Significant Subsidiaries), unless the principal of the Note shall have already become due and payable, the Holder may by notice in writing to the Company, declare 100% of the outstanding principal of, and accrued and unpaid interest on, the Note to be due and payable immediately, and upon any such declaration the same shall become and shall automatically be immediately due and payable. If an Event of Default specified in Section 2.4(h) or Section 2.4(i) with respect to the Company or any of its Significant Subsidiaries occurs and is continuing, 100% of the outstanding principal of, and accrued and unpaid interest on, the Note shall become and shall automatically be immediately due and payable without any action on the part of the Holder.
(b) Subsection (a) above, however, is subject to the conditions that if, at any time after the outstanding principal of the Note shall have been so declared due and payable, and before any judgment or decree for the payment of the monies due shall have been obtained or entered as hereinafter provided, the Company shall pay or shall deposit with the Holder a sum sufficient to pay installments of accrued and unpaid interest upon the Note and the outstanding principal of the Note that shall have become due otherwise than by acceleration (with interest on overdue installments of accrued and unpaid interest to the extent that payment of such interest is enforceable under applicable Law, and on such principal at the rate per annum borne by the Note plus one percent), and if (1) rescission would not conflict with any judgment or decree of a court of competent jurisdiction and (2) any and all existing Events of Default under the Note, other than the nonpayment of the principal of and accrued and unpaid interest on the Note that shall have become due solely by such acceleration, shall have been cured or waived, then and in every such case the Holder, by written notice to the Company, may waive all default or Events of Default with respect to the Note and rescind and annul such declaration and its consequences and such default shall cease to exist, and any Event of Default arising therefrom shall be deemed to have been cured for every purpose of the Note; but no such waiver or rescission and annulment shall extend to or shall affect any subsequent Event of Default, or shall impair any right consequent thereon.
Financial Consequences The Department reserves the right to impose financial consequences when the Contractor fails to comply with the requirements of the Contract. The following financial consequences will apply for the Contractor’s non-performance under the Contract. The Customer and the Contractor may agree to add additional Financial Consequences on an as-needed basis beyond those stated herein to apply to that Customer’s resultant contract or purchase order. The State of Florida reserves the right to withhold payment or implement other appropriate remedies, such as Contract termination or nonrenewal, when the Contractor has failed to comply with the provisions of the Contract. The Contractor and the Department agree that financial consequences for non-performance are an estimate of damages which are difficult to ascertain and are not penalties. The financial consequences below will be paid and received by the Department of Management Services within 30 calendar days from the due date specified by the Department. These financial consequences below are individually assessed for failures over each target period beginning with the first full month or quarter of the Contract performance and every month or quarter, respectively, thereafter. Deliverable Performance Metric Performance Due Date Financial Consequence for Non-Performance Contractor will timely submit completed Quarterly Sales Reports All Quarterly Sales Reports will be submitted timely with the required information Reports are due on or before the 30th calendar day after the close of each State fiscal quarter $250 per Calendar Day late/not received by the Contract Manager Contractor will timely submit completed MFMP Transaction Fee Reports All MFMP Transaction Fee Reports will be submitted timely with the required information Reports are due on or before the 15th calendar day after the close of each month $100 per Calendar Day late/not received by the Contract Manager