Impediments and Delays Clause Samples

The 'Impediments and Delays' clause defines how situations that hinder or postpone the performance of contractual obligations are managed. It typically outlines the process for notifying the other party of any obstacles or delays, specifies acceptable reasons for such delays (like force majeure events or third-party actions), and may set out the consequences or remedies available. This clause ensures that both parties have a clear understanding of their responsibilities and the steps to take if progress is disrupted, thereby minimizing disputes and providing a framework for handling unforeseen setbacks.
Impediments and Delays. If timely performance of the Services is affected due to impediments or delays caused by the Company or any third parties engaged by the Company: the Contractor shall promptly notify the Company of the circumstances and probable effects of such impediment or delay on the performance of the Services (if not notified in timely manner, the Contractor shall lose its right to make any claim in this respect); and the Parties shall in good faith discuss such allegation of the Contractor, and, if agreed, the duration of the Services (including the term for delivery of any pending Services) shall be extended by the number of days directly affected by such impediment or delay.
View SourceView Similar (21)
Impediments and Delays. If the Service, or any part thereof, is impeded or delayed by the Principal or any third party engaged by the Principal so as to increase the duration of the Service: (a) the Service Provider shall inform the Principal of the circumstances and probable effects of such impediment or delay upon the agreed schedule of Service specified in accordance with Annex C: Schedule of Service; and the duration of the Service shall be amended, if possible.
View SourceView Similar (13)
Impediments and Delays. If the Study, or any part thereof, is impeded or delayed by the Principal or any third party engaged by the Principal so as to increase the duration of the Study: (a) the Contractor shall inform the Principal of the circumstances and probable effects of such impediment or delay upon the agreed Schedule of Study specified in accordance with Annex C: (b) the duration of the Study shall be increased, and any Study Milestones affected by the impediment or delay shall be extended accordingly.
View SourceView Similar (9)
Impediments and Delays. If the provision of the Services, or any part thereof, is impeded or delayed by the Principal or any third party engaged by the Principal, and as a result of that additional time is needed to execute the Assignment: 7.7.1 the Service Provider shall inform the Principal of the circumstances and probable effects of such impediment taking into consideration the Assignment; and 7.7.2 the time initially allocated for the execution of the Assignment shall be increased, and any Milestone affected by the impediment or delay shall be extended accordingly.
View SourceView Similar (5)
Impediments and Delays. If the Services, or any part thereof, is impeded or delayed by the Principal and it has or may affect any Completion Cate of the Services Milestones: a) the Contractor shall inform the Principal of the circumstances and probable effects of such impediment or delay upon the agreed Services Schedule and the Time Schedule; and b) the duration of the Services shall be prolonged, and any Milestones affected by the impediment or delay shall be extended accordingly by the Principal.
View Source

Related to Impediments and Delays

  • Delays If no event of Force Majeure shall have occurred and be continuing and in the event that a delay shall have been caused by the negligence or willful misconduct of the Custodian in carrying out an Instruction to credit or transfer cash, the Custodian shall be liable to the Fund: (a) with respect to Principal Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Custodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected; and, (b) with respect to Agency Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Subcustodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected. The Custodian shall not be liable for delays in carrying out Instructions to transfer cash which are not due to the Custodian's own negligence or willful misconduct.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Debts and Delinquencies Contractor agrees that any payments due under this Contract shall be applied towards any debt or delinquency that is owed to the State of Texas.

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.