Improvements to the Subleased Premises Sample Clauses

The "Improvements to the Subleased Premises" clause defines the rules and responsibilities regarding any alterations, additions, or upgrades made to the property by the subtenant. Typically, this clause outlines whether the subtenant is allowed to make improvements, if prior consent from the sublandlord or landlord is required, and who owns the improvements once the sublease ends. For example, it may specify that any fixtures installed by the subtenant become the property of the landlord upon lease termination. The core function of this clause is to manage expectations and prevent disputes over property modifications, ensuring both parties understand their rights and obligations concerning changes to the premises.
Improvements to the Subleased Premises. Subtenant shall be allowed to only make alterations, additions or nonstructural improvements (hereinafter referred to as “Alterations”) to the Subleased Premises, subject to its first obtaining the prior written consent of both (i) Master Landlord in accordance with Paragraph 23 of the Master Lease, and (ii) Sublandlord, which consent by Sublandlord shall not be unreasonably withheld, conditioned or delayed. All Alterations by Subtenant shall be performed in accordance with the terms and conditions of the Master Lease at Subtenant’s sole cost and expense (except as provided in Section 6 above) and shall be made in a good and workmanlike manner, lien free and in accordance with all applicable laws and regulations. All Alterations by Subtenant shall be conducted in such a manner as to minimize any disruption to the business of Sublandlord or any other tenants in the Building. Subtenant will indemnify, hold harmless and defend Sublandlord, its officers, employees, and agents (with counsel reasonably acceptable to Sublandlord) against all claims, judgments, damages, penalties, fines, costs, fees, losses, liabilities and expenses (including, without limitation, the reasonable fees and out-of-pocket expenses of consultants, attorneys, and experts) arising out of or in connection with the removal of any such Alterations or any violation of the foregoing provisions of this paragraph or any violation of the Master Lease in connection with any Alterations.
View SourceView Similar (2)
Improvements to the Subleased Premises. Sublessee hereby agrees to accept the Subleased Premises in its “AS-IS” condition. Sublessee hereby acknowledges that Sublessor shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Subleased Premises. Sublessee also acknowledges that Sublessor has made no representation or warranty regarding the condition of the Subleased Premises. Sublessee hereby agrees that the Subleased Premises shall be taken "AS-IS", "with all faults" of every kind and nature, which may now or hereafter exist, whether latent or patent, without any representations or warranties, and Sublessee hereby agrees and warrants that it has investigated and inspected the condition of the Subleased Premises and the suitability of same for Sublessee's purposes.
View SourceView Similar (2)
Improvements to the Subleased Premises. Sublessee acknowledges and agrees that Sublessor has no obligation with regard to any improvements made or required to be made by Landlord to the Subleased Premises. Sublessee shall not make any improvements, alterations or additions to the Subleased Premises without the prior written consent of and approval of the plans and specifications therefore by (a) Sublessor, whose consent shall not be unreasonably withheld, and (b) if required under the Base Lease, Landlord.
View Source

Related to Improvements to the Subleased Premises

  • Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.

  • Subleased Premises Sublandlord does hereby sublease to Subtenant, and Subtenant does hereby sublease and rent from Sublandlord, (i) the Space and (ii) all permanent improvements within the Space constructed by Landlord or by or on behalf of Sublandlord (collectively, the “Subleased Premises”). Subtenant shall have the right to use in common with Sublandlord and others entitled thereto the common areas of the Project pursuant to the Lease. In addition, subject to the terms, covenants and conditions of this Sublease, Subtenant shall have the exclusive right to use during the Sublease Term (defined below), free of charge, the furniture, fixtures and equipment more particularly described on Schedule A annexed hereto and made a part hereof (the “Personal Property”) located in the Space. Subtenant shall have no obligation whatsoever to repair, replace or maintain the Personal Property, unless any damage thereto is caused by the negligence or willful misconduct of Subtenant. Provided that there is no change in the size of the Subleased Premises between the date of this Sublease and the Commencement Date (defined below) (e.g., there has been no change in the size of the Subleased Premises by reason of any damage or destruction to or condemnation of the Subleased Premises), the parties hereby (i) stipulate that the Space shall be deemed to contain approximately 19,997 rentable square feet upon delivery of the Space by Sublandlord to Subtenant (the “Space Measurement”), (ii) agree that neither party shall have any right to dispute the Space Measurement and (iii) waive any claim in connection with the Space Measurement, regardless of whether the Space is found to have contained more or less than 19,997 rentable square feet upon delivery of the Space to Subtenant. Sublandlord represents and warrants for the benefit of Subtenant that the rentable square footage of the Space was not remeasured pursuant to Section 4 of the Second Amendment and that Sublandlord pays Base Rental for the Space under the Lease and Tenant’s Forecast Additional Rental and Tenant’s Additional Rental for the Space under the Lease on the basis of the Space consisting of 19,997 rentable square feet.

  • Landlord Improvements Prior to Tenant’s occupancy, Landlord shall complete the Landlord Improvements. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by the Anticipated Rent Commencement Date. (a) As of November 4, 2011, after consultation with Tenant, Landlord has provided Tenant with Landlord’s proposed plans and specifications (defined below in subpart (c))for the Landlord Improvements (such plans and specifications, as amended in accordance with the provisions of this Rider 101, are hereafter called “Plans and Specifications”). (b) The Plans and Specifications have been accepted by both Tenant and Landlord, the Plans and Specifications are incorporated herein by reference and made a part hereof for all purposes. (c) Landlord and Tenant acknowledge that the plans dated November 4, 2011, by Page ▇▇▇▇▇▇▇▇▇▇▇ Page, LLP have been approved by both parties and shall constitute the “Plans and Specifications.” (d) Promptly upon approval of the Plans and Specifications, Landlord has caused general contractors to bid for construction of the Landlord Improvements. All bids have been opened together, with Landlord selecting the general contractor with the lowest bid to construct the Landlord Improvements (the “General Contractor”), subject to the reasonable approval of Tenant. Landlord shall enter into a guaranteed maximum price construction contract with the General Contractor in the amount of its bid (the “Approved Bid”) and shall not modify such contract without Tenant’s consent, which shall not be unreasonably withheld, delayed or conditioned. Landlord and Tenant have reviewed the Plans and Specifications and the bids and have agreed upon the scope of work to be constructed at a cost of construction not to exceed the Landlord’s Contribution.

  • Access to Leased Premises Landlord may enter the Leased Premises after business hours, upon twenty-four (24) hour notice to Tenant (and at any time and without notice in case of emergency), for the purposes of (a) inspect the Leased Premises, (b) exhibiting the Leased Premises to prospective purchasers, lenders or, within one hundred eighty (180) days of the end of the Term, prospective, (c) determining whether Tenant is complying with all of its obligations hereunder, (d) supplying janitorial service and any other services to be provided by Landlord to Tenant hereunder, (e) post notices of non-responsibility, and (f) make repairs required of Landlord under the terms hereof or repairs to any adjoining space or utility services or make repairs, alterations or improvements to any other portion of the Building. For such purposes, Landlord shall at all times have and retain a key with which to unlock all of the doors in, on or about the Leased Premises (excluding Tenant’s vaults, safes, storage facilities for sensitive materials, confidential patient files and similar areas designated in writing by Tenant in advance); and Landlord shall have the right to use any and all means which Landlord may deem proper to open said doors in any emergency in order to obtain entry to the Leased Premises. If, as a result of any such inspection or for any reason, Landlord reasonably determines that Tenant has failed to meet its obligations under Section 5.2 hereof, Landlord shall so notify Tenant and Tenant shall immediately commence to cure any such failure. In the event Tenant refuses or neglects to commence and complete such cure within a reasonable time, Landlord may make or cause to be made such repairs. In such event, Landlord’s cost to make such repairs shall constitute an Advance.

  • LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.