Incomplete Works In the event the Contractor fails to complete the Works in accordance with the Project Completion Schedule, including any Time Extension granted under this Agreement, the Contractor shall endeavour to complete the balance work expeditiously and shall pay Damages to the Authority in accordance with the provisions of Clause 10.3 (ii) for delay of each day until the Works are completed in accordance with the provisions of this Agreement. Recovery of Damages under this Clause shall be without prejudice to the rights of the Authority under this Agreement including the right to termination under Clause 23.1.
Nonconforming Work 5.6.1 Rejection, Removal and Replacement of Nonconforming Work
Casualty Loss If in Owner’s reasonable judgment the premises or the Property is materially damaged by fire or other casualty, Owner may terminate this Agreement within a reasonable time after such determination, by written notice to Resident, in which case Owner will refund prorated, pre-paid rent and all deposits less lawful deductions unless Resident and/or Resident’s guest(s) caused the casualty, in which case all funds on account will be applied to all applicable charges related to the damages and Resident will be responsible for the balance of all charges for repairs. If following a fire or other casualty Owner has not elected to terminate this Agreement, Owner will rebuild the damaged areas within a reasonable time, and during such reconstruction, Resident will be provided a reasonable rent reduction for the unusable portion of the premises unless Resident and/or Resident’s guest(s) caused the casualty.
ACCEPTANCE OF INCOMPLETE OR NON-CONFORMING DELIVERABLES If, instead of requiring immediate correction or removal and replacement of defective or non- conforming deliverables, the City prefers to accept it, the City may do so. The Contractor shall pay all claims, costs, losses and damages attributable to the City’s evaluation of and determination to accept such defective or non-conforming deliverables. If any such acceptance occurs prior to final payment, the City may deduct such amounts as are necessary to compensate the City for the diminished value of the defective or non-conforming deliverables. If the acceptance occurs after final payment, such amount will be refunded to the City by the Contractor.
Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected. 35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.