Limitations on Quantity Adjustments in Rolling Forecasts Clause Samples

Limitations on Quantity Adjustments in Rolling Forecasts. In addition to the limitations on the percentage decrease and increase of aggregate monthly PO Product Quantities set forth in Section 2.2.1, Buyer shall not submit Rolling Forecasts that are (a) less than *** percent (***%) of the quantity that was set forth in the Rolling Forecast for such calendar month when a Delivery Month was the second and third calendar month in the Rolling Forecast Period; or (b) more than *** percent (***%) of the quantity that was set forth in the Rolling Forecast for such calendar month when such Delivery Month was the second and third calendar month in the Rolling Forecast Period. For purposes of clarifying the above language, the following table is provided: *** Portions of this page have been omitted pursuant to a request for Confidential Treatment and filed separately with the Commission. *** Portions of this page have been omitted pursuant to a request for Confidential Treatment and filed separately with the Commission.
View SourceView Similar (2)
Limitations on Quantity Adjustments in Rolling Forecasts. In addition to the limitations on the percentage decrease and increase of aggregate monthly PO Product Quantities set forth in Section 2.2.1, Buyer shall not submit Rolling Forecasts that are (a) less than *** percent (***%) of the quantity that was set forth in the Rolling Forecast for such calendar month when a Delivery Month was the second and third calendar month in the Rolling Forecast Period; or (b) more than *** percent (***%) of the quantity that was set forth in the Rolling Forecast for such calendar month when such Delivery Month was the second and third calendar month in the Rolling Forecast Period. For purposes of clarifying the above language, the following table is provided:
View Source

Related to Limitations on Quantity Adjustments in Rolling Forecasts

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Billing Limitations a. DSHS shall pay the Contractor only for authorized services provided in accordance with this Contract. b. DSHS shall not pay any claims for payment for services submitted more than twelve (12) months after the calendar month in which the services were performed. c. The Contractor shall not bill and DSHS shall not pay for services performed under this Contract, if the Contractor has charged or will charge another agency of the state of Washington or any other party for the same services.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Rolling Forecasts The Client shall provide Patheon with a written non-binding [ * ] forecast of the volume of each Product that the Client then anticipates will be required to be produced and delivered to the Client during each [ * ] of that [ * ] period. Such forecast will be updated by the Client [ * ] on or before the [ * ] day of each [ * ] on a rolling [ * ] basis. The most recent [ * ] forecast shall prevail.

  • Certain Calculations and Tests (a) Notwithstanding anything to the contrary herein, but subject to Sections 1.10(b) and (c) and Section 1.11, all financial ratios and tests (including the Total Leverage Ratio, the First Lien Leverage Ratio, the Secured Leverage Ratio, the Interest Coverage Ratio and the amount of Consolidated Total Assets and Consolidated Adjusted EBITDA) contained in this Agreement that are calculated with respect to any Test Period during which any Subject Transaction occurs shall be calculated with respect to such Test Period and each such Subject Transaction on a Pro Forma Basis. Further, if since the beginning of any such Test Period and on or prior to the date of any required calculation of any financial ratio or test (i) any Subject Transaction has occurred or (ii) any Person that subsequently became a Restricted Subsidiary or was merged, amalgamated or consolidated with or into the Borrower or any of its Restricted Subsidiaries or any joint venture since the beginning of such Test Period has consummated any Subject Transaction, then, in each case, any applicable financial ratio or test shall be calculated on a Pro Forma Basis for such Test Period as if such Subject Transaction had occurred at the beginning of the applicable Test Period (it being understood, for the avoidance of doubt, that solely for purposes of (x) calculating compliance with Section 6.12(a) and (y) calculating the First Lien Leverage Ratio for purposes of the definitions of “Applicable Rate” and “Commitment Fee Rate”, in each case, no Subject Transaction occurring after the end of the relevant Test Period shall be taken into account). (b) For purposes of determining the permissibility of any action, change, transaction or event that requires a calculation of any financial ratio or test (including, without limitation, Section 6.12(a), any First Lien Leverage Ratio test, any Secured Leverage Ratio test, any Total Leverage Ratio test and/or any Interest Coverage Ratio test, the amount of Consolidated Adjusted EBITDA and/or Consolidated Total Assets), such financial ratio or test shall be calculated at the time such action is taken (subject to Section 1.11), such change is made, such transaction is consummated or such event occurs, as the case may be, and no Default or Event of Default shall be deemed to have occurred solely as a result of a change in such financial ratio or test occurring after the time such action is taken, such change is made, such transaction is consummated or such event occurs, as the case may be. (c) Notwithstanding anything to the contrary herein, with respect to any amounts incurred or transactions entered into (or consummated) in reliance on a provision of this Agreement (including any covenant or the definition of “Incremental Cap”) that does not require compliance with a financial ratio or test (including, without limitation, Section 6.12(a), any First Lien Leverage Ratio test, any Secured Leverage Ratio test, any Total Leverage Ratio test and/or any Interest Coverage Ratio test) (any such amounts, the “Fixed Amounts”) substantially concurrently with any amounts incurred or transactions entered into (or consummated) in reliance on a provision of this Agreement (including any covenant or the definition of “Incremental Cap”) that requires compliance with a financial ratio or test (including, without limitation, Section 6.12(a), any First Lien Leverage Ratio test, any Secured Leverage Ratio test, any Total Leverage Ratio test and/or any Interest Coverage Ratio test) (any such amounts, the “Incurrence-Based Amounts”), it is understood and agreed that the Fixed Amounts shall be disregarded in the calculation of the financial ratio or test applicable to the Incurrence-Based Amounts.