Mandatory Notice of Delay Clause Samples

Mandatory Notice of Delay. Not later than five days after the start of any delay in the performance of the Work, regardless of the cause of the delay, and regardless of whether the delay is then ongoing, the Contractor must provide written notice of the delay to the District and the Architect (“Notice of Delay”). In any case that the Contractor fails to timely provide a Notice of Delay: (i) if it thereafter gives a Notice of Delay, the Contractor shall be deemed and construed to have waived and released any and all rights to an extension of time or additional compensation with respect to any time more than five days prior to the date the District actually receives the Notice of Delay; and (ii) the District may hold the Contractor responsible for any delays and/or increased costs that the District reasonably might have mitigated had the District received a timely
View Source
Mandatory Notice of Delay. Not later than seven days after the start of any delay in the performance of the Work, regardless of the cause of the delay, and regardless of whether the delay is then ongoing, the Contractor must provide written notice of the delay to the District and the Architect (“Notice of Delay”). In any case that the Contractor fails to timely provide a Notice of Delay: (i) if it thereafter gives a Notice of Delay, the Contractor shall be deemed and construed to have waived and released any and all rights to an extension of time or additional compensation with respect to any time more than seven days prior to the date the District actually receives the Notice of Delay; and (ii) the District may hold the Contractor responsible for any delays and/or increased costs that the District reasonably might have mitigated had the District received a timely Notice of Delay. A Notice of Delay must set forth the cause(s) of the delay and be accompanied by documentation reasonably evidencing and supporting the Contractor’s position with respect to the cause(s) of the delay. The District or the Architect may request that the Contractor provide any additional or more detailed information regarding the delay, which the Contractor must provide within five days of request. THE GIVING OF A NOTICE OF DELAY IN CONNECTION WITH A DELAY SHALL BE DEEMED AND CONSTRUED AS A MANDATORY PREREQUISITE FOR ANY EXTENSION OF TIME AND/OR ADDITIONAL COMPENSATION TO THE CONTRACTOR ON ACCOUNT OF SUCH DELAY.
View Source

Related to Mandatory Notice of Delay

  • Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.

  • NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • Notice of Decision If the Plan Administrator denies part or all of the claim, the Plan Administrator shall notify the claimant in writing of such denial. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth: (a) The specific reasons for the denial; (b) A reference to the specific provisions of the Agreement on which the denial is based; (c) A description of any additional information or material necessary for the claimant to perfect the claim and an explanation of why it is needed; (d) An explanation of the Agreement’s review procedures and the time limits applicable to such procedures; and (e) A statement of the claimant’s right to bring a civil action under ERISA Section 502(a) following an adverse benefit determination on review.

  • Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.