Sub-Total Change Order Work Change Clause Samples

Sub-Total Change Order Work Change. Order No. 1 Change Order No. 2 Change Order No. 3 Change Order No. 4 Change Order No. 5 Total To Date Total of all prior Change Orders Change Orders approved this month Total Additive/Deductive Changes to Date Continuation Sheet of Name of Claimant: Name of Customer: Job Location: Owner: Through Date: This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for labor and service provided, and equipment and material delivered, to the customer on this job through the Through Date of this document. Rights based upon labor or service provided, or equipment or material delivered, under a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. This document is effective only on the claimant’s receipt of payment from the financial institution on which the following check is drawn: Maker of Check: Amount of Check: $ Check Payable to: This document does not affect any of the following:
View SourceView Similar (2)

Related to Sub-Total Change Order Work Change

  • Change Order The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • Change Order Process 12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5. 12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof. 12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.

  • Alternate Work Schedule An alternate work schedule is any work schedule where an employee is regularly scheduled to work five (5) days per week, but the employee’s regularly scheduled two (2) days off are NOT Saturday and Sunday.

  • Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones: 6.1 Substantial Site work completed. On or before July 1, 2021, Interconnection Customer must demonstrate completion of at least 20% of project site construction. At this time, Interconnection Customer must submit to Interconnected Transmission Owner and Transmission Provider initial drawings, certified by a professional engineer, of the Customer Interconnection Facilities. 6.2 Delivery of major electrical equipment. On or before July 15, 2021, Interconnection Customer must demonstrate that all generating units have been delivered to Interconnection Customer’s project site.