Modifications To Time For Performance Clause Samples

The "Modifications To Time For Performance" clause establishes the conditions under which the deadlines or schedules set out in a contract may be changed. Typically, this clause outlines the process for requesting extensions or adjustments, such as requiring written notice and mutual agreement between the parties. It may apply to delivery dates, project milestones, or completion deadlines. The core function of this clause is to provide a clear mechanism for adapting timelines in response to unforeseen circumstances, thereby reducing disputes and ensuring both parties understand how changes to performance periods are managed.
Modifications To Time For Performance. The General Contractor shall determine and promptly notify the Owner and the Professional(s) in writing when it believes adjustments to the required dates of Substantial Completion or Final Completion, or other milestone dates required by the Owner, if any, are necessary, but no such adjustments shall be effective unless approved in writing by the Owner and Professional(s).
View SourceView Similar (10)
Modifications To Time For Performance. The DB shall determine and promptly notify the Owner, in writing, when it believes adjustments to the expected dates of Substantial Completion or Final Completion, or other milestone dates required by the Owner, if any, are necessary, but no such adjustments shall be effective unless approved in writing by the Owner.
View SourceView Similar (4)
Modifications To Time For Performance. The Construction Manager shall determine and promptly notify the County and the Professional in writing when it believes adjustments to the required dates of Substantial Completion or Final Completion, or other milestone dates required by the County, if any, are necessary, but no such adjustments will be effective unless approved in writing by the County and Professional.
View SourceView Similar (3)
Modifications To Time For Performance. The CM shall determine and promptly notify the Owner and the Design Professional, in writing, when it believes adjustments to the expected dates of Substantial Completion or Final Completion, or other milestone dates required by the Owner, if any, are necessary, but no such adjustments shall be effective unless approved in writing by the Owner and the Design Professional.
View SourceView Similar (2)

Related to Modifications To Time For Performance

  • Modifications to service This Auction Site reserves the right to modify or discontinue the Service with or without notice to user. This Auction Site shall not be liable to users or any third party should this Auction Site exercise its right to modify or discontinue the Service.

  • MODIFICATIONS TO LEASE Notwithstanding any other provisions in the Lease, during the term of this Contract Owner and Tenant mutually agree that:

  • CONDITIONS TO GRANT TO HAVE AND TO HOLD the above granted and described Property unto and to the use and benefit of Lender, and the successors and assigns of Lender, forever; PROVIDED, HOWEVER, these presents are upon the express condition that, if Borrower shall well and truly pay to Lender the Debt at the time and in the manner provided in the Note and this Security Instrument, shall well and truly perform the Other Obligations as set forth in this Security Instrument and shall well and truly abide by and comply with each and every covenant and condition set forth herein and in the Note, these presents and the estate hereby granted shall cease, terminate and be void.

  • Conditions to Obligations of Each Party Under This Agreement The respective obligations of each party to effect the Merger and the other transactions contemplated herein shall be subject to the satisfaction at or prior to the Effective Time of the following conditions, any or all of which may be waived, in whole or in part, to the extent permitted by applicable Law:

  • Conditions to ▇▇▇▇▇’▇ Obligations The obligations of ▇▇▇▇▇ hereunder with respect to a Placement will be subject to the continuing accuracy and completeness of the representations and warranties made by the Company herein, to the due performance by the Company of its obligations hereunder, to the completion by ▇▇▇▇▇ of a due diligence review satisfactory to ▇▇▇▇▇ in its reasonable judgment, and to the continuing satisfaction (or waiver by ▇▇▇▇▇ in its sole discretion) of the following additional conditions: