MSRP List and Product Adjustments Clause Samples

The "MSRP List and Product Adjustments" clause defines how the Manufacturer's Suggested Retail Price (MSRP) for products is established and how changes to the product lineup or pricing are managed. Typically, this clause outlines the process for updating the MSRP list, such as requiring written notice to the other party before any price changes take effect, and may specify how new products are added or discontinued. Its core function is to ensure both parties have a clear and consistent understanding of current product offerings and pricing, reducing the risk of disputes over unexpected changes.
MSRP List and Product Adjustments. The Contractor shall submit a complete MSRP List that includes all Commodities (i.e. Base Equipment; OEM Options, Parts, Accessories, and Implements; and Non-OEM Options, Parts, Accessories, and Implements) for each Manufacturer/ Brand Name and Sub-Group (or Group, for Groups that do not include Sub-Groups) for which the Contractor received an award; the Commodities listed on the MSRP must match the Commodities listed on the price sheet. The MSRP List is subject to the Department’s approval. The MSRP List shall include the following for each Commodity: The Manufacturer/Brand Model Number, the Manufacturer/Brand Item Description, and the MSRP. The Contractor shall include a cover page, which shall provide the applicable Group, Sub-Group (for Groups that include Sub-Groups), Manufacturer/Brand Name, and MSRP List date. The Department shall be the final arbiter of MSRPs if an MSRP on the Contractor’s MSRP List differs from the published MSRP. The Contractor shall be responsible for removing all non-eligible and unacceptable Commodities under the Contract from the Contractor’s MSRP List. The Contractor may add products to the MSRP List at any time during the life of the Contract by submitting a complete and revised MSRP List. Products added must be from a Manufacturer/Brand Name for which the Contractor received an award and fall within the scope of a Sub-Group (or Group, for Groups that do not include Sub-Groups) for which the Contractor received an award. The Contractor shall be responsible for removing all non-eligible and unacceptable Commodities under the Contract from the Contractor’s MSRP List. The Contractor may update existing product’s MSRPs on the MSRP List to match the MSRPs published by the Manufacturer no earlier than twelve (12) months after the start date of the Contract and, thereafter, or no earlier than twelve (12) months after the date of the previous MSRP update. The Contractor may update the existing product’s MSRPs on the MSRP List by submitting a complete and revised MSRP List for Department review and approval. Revised MSRP Lists, regardless of whether the Contractor is adding products or updating existing product’s MSRPs, must be accompanied by a revised price sheet, as described in the ‘Price Sheet and Price Adjustments’ section of the Scope of Work, as well as a list of all changes made from the previously submitted version of the MSRP List.
View SourceView Similar (39)

Related to MSRP List and Product Adjustments

  • SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.

  • Cost Adjustments Both parties agree that contracted prices shall be fixed for the first 12 months of this Contract. Contractor must submit to District any proposed cost adjustments at least 60 days before the proposed effective date of such increases with a detailed explanation for each adjustment. District alone reserves the right to reject any changes to this Contract it deems unacceptable.

  • Recovery Schedule 4.5.1 If at any time, the Work on any Critical Path item is delayed for a period which exceeds the greater of either 30 days in the aggregate or that number of days in the aggregate equal to 5% of the days remaining until a Completion Deadline (including delays to which DB Contractor may be entitled to a time extension under Section 13), then DB Contractor, upon TxDOT’s request, shall prepare and submit to TxDOT for review and approval with the next Project Status Schedule Update a Recovery Schedule demonstrating DB Contractor’s proposed plan to regain lost schedule progress and to achieve the contractual milestones as they may be extended in accordance with this Agreement, including Substantial Completion by the Substantial Completion Deadline and Final Acceptance by the Final Acceptance Deadline. 4.5.2 TxDOT shall notify DB Contractor within 14 days after receipt of each such Recovery Schedule whether the Recovery Schedule is deemed accepted or rejected. Within seven days after any rejection by ▇▇▇▇▇ of the Recovery Schedule, DB Contractor will resubmit a revised Recovery Schedule incorporating TxDOT’s comments. When TxDOT accepts DB Contractor’s Recovery Schedule, DB Contractor shall, within five days after TxDOT’s acceptance, incorporate and fully include such schedule into the Project Schedule, deliver the same to TxDOT and proceed in accordance with the approved Recovery Schedule. 4.5.3 All costs incurred by DB Contractor in preparing, implementing and achieving the Recovery Schedule shall be borne by DB Contractor and shall not result in a change to the Price, except to the extent that the Recovery Schedule is in lieu of a time extension and a change in the Price is permitted for Acceleration Costs in accordance with Section 13. 4.5.4 If DB Contractor fails to provide an acceptable Recovery Schedule as required herein and in addition to any other rights and remedies in favor of TxDOT arising out of such failure, DB Contractor shall have no right to receive progress payments until such time as DB Contractor has prepared and TxDOT has approved such Recovery Schedule. Any failure or delay in the submittal or approval of a Recovery Schedule shall not result in any time extension under the Contract Documents.