No Extension of Time Sample Clauses

The "No Extension of Time" clause establishes that the deadlines set forth in the contract are fixed and cannot be extended, regardless of any delays or obstacles encountered. In practice, this means that if a party is late in performing its obligations, it cannot request additional time to complete them, even if the delay was caused by unforeseen circumstances such as bad weather or supply chain issues. The core function of this clause is to ensure strict adherence to the agreed schedule, thereby allocating the risk of delay to the performing party and providing certainty for project timelines.
POPULAR SAMPLE Copied 4 times
No Extension of Time. If Owner’s determination proves valid that good cause existed to believe a violation had occurred, Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures.
View SourceView Similar (105)
No Extension of Time. If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the CM-at-Risk is not entitled to an extension of time for any delay arising directly or indirectly from of the arbitration procedures set forth herein.
View Source
No Extension of Time. If the Owner determines that good cause exists to believe a violation has occurred, the Contractor shall not be entitled to an extension of time for any delay arising directly or indirectly from of the procedures set forth in this section.
View SourceView Similar (79)
No Extension of Time. The period of time within which any Right of First Offer may be exercised shall not be extended or enlarged by reason of Tenant’s inability to exercise the Right of First Offer.
View SourceView Similar (5)
No Extension of Time. If ODR’s determination proves valid that good cause existed to believe a violation had occurred, Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures.
View Source
No Extension of Time. Design-Builder shall not be entitled to an extension of time for any delay arising indirectly from any investigation of a violation if Owner’s investigation reveals good cause existed for the
View Source
No Extension of Time. Nothing in this Section 30 shall extend any time for cure or performance by RCM, and if a Leasehold Mortgagee exercises its rights under this Section 30, the City may tender any further performance under this Agreement to such Lender, rather than RCM.‌
View Source
No Extension of Time or waiver or relaxation of any of the provisions or terms of this Agreement or any agreement, ▇▇▇▇ of exchange or other document issued or executed pursuant to or in terms of this Agreement, shall operate as an estoppel against a Party in respect of its rights under this Agreement. 22.5 It is agreed between the Parties, that notwithstanding the provisions of the Electronic Communications and Transactions ▇▇▇, ▇▇▇▇, any amendment to this Agreement shall only be effective if it is reduced to writing on paper and signed by all the Parties. 22.6 No failure by any Party to enforce any provision of this Agreement shall constitute a waiver of such provision or affect in any way such Party’s right to require the performance of such provision at any time in the future, nor shall a waiver of a subsequent breach nullify the effectiveness of the provision itself. 22.7 Nothing in this Agreement, express or implied, is intended to confer upon any person not a party to this Agreement any rights or remedies under or by reason of this Agreement. 22.8 If any clause or term of this Agreement should be invalid, unenforceable, defective or illegal for any reason whatsoever, then the remaining terms and provisions of this Agreement shall be deemed to be severable therefrom and shall continue in full force and effect unless such invalidity, unenforceability, defect or illegality goes to the root of this Agreement.
View Source

Related to No Extension of Time

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • Extension of Time; Waiver At any time prior to the Effective Time, the parties may, by action taken or authorized by their respective Boards of Directors, to the extent permitted by applicable Law, (a) extend the time for the performance of any of the obligations or acts of the other parties, (b) waive any inaccuracies in the representations and warranties of the other parties set forth in this Agreement or any document delivered pursuant hereto or (c) subject to applicable Law, waive compliance with any of the agreements or conditions of the other parties contained herein; provided, however, that after the Company Stockholder Approval has been obtained, no waiver may be made that pursuant to applicable Law requires further approval or adoption by the Stockholders without such further approval or adoption. Any agreement on the part of a party to any such waiver shall be valid only if set forth in a written instrument executed and delivered by a duly authorized officer on behalf of such party. No failure or delay of any party in exercising any right or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right or power, or any abandonment or discontinuance of steps to enforce such right or power, or any course of conduct, preclude any other or further exercise thereof or the exercise of any other right or power. The rights and remedies of the parties hereunder are cumulative and are not exclusive of any rights or remedies which they would otherwise have hereunder.