Non-Union Workmen Sample Clauses

The Non-Union Workmen clause defines the terms and conditions under which workers who are not members of a labor union may be employed on a project or by a company. Typically, this clause outlines the rights, responsibilities, and protections afforded to non-union employees, such as wage rates, working hours, and dispute resolution procedures, ensuring they are clearly established and do not conflict with union agreements. Its core practical function is to provide clarity and prevent misunderstandings regarding the employment of non-union labor, thereby reducing the risk of labor disputes and ensuring smooth project operations.
Non-Union Workmen. Members will not be allowed to work with non-union workmen of any craft except under the instruction of the President or an appointee of the Union.
View SourceView Similar (26)
Non-Union Workmen. Members will not be allowed to work with non-union workmen of any craft except under the instruction of the Business Manager of the Union or his Deputy. No Shop ▇▇▇▇▇▇▇, or employee shall be discriminated against or jeopardized in standing or suffer loss of on account of membership or activity in the Union. The Union reserves the right to discipline its members for violation of its laws, rules or agreement. No provision this Agreement shall be used to remove working conditions or reduce wages presently force. No may be disciplined writing, suspended, or discharged without the presence of a shop ▇▇▇▇▇▇▇. If a verbal warning is noted in the employee's records, the employee will be advised by the Employer, in writing Employees shall be entitled to review their employee records and discipline files, upon request and with reasonable notice of at least one (1) week to the Employer. The Employer shall remove all discipline offenses from the employee's file that are two years or older, except for those offenses considered serious by the Employer.
View Source

Related to Non-Union Workmen

  • Contractors All LAUSD Contractors and their Representatives are expected to conduct any and all business affiliated with LAUSD in an ethical and responsible manner that fosters integrity and public confidence. A “Contractor” is any individual, organization, corporation, sole proprietorship, partnership, nonprofit, joint venture, association, or any combination thereof that is pursuing or conducting business with and/or on behalf of LAUSD, including, without limitation, consultants, suppliers, manufacturers, and any other vendors, bidders or proposers. A Contractor’s “Representative” is also broadly defined to include any subcontractors, employees, agents, or anyone else who acts on a Contractor’s behalf.

  • Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows: (a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge. (b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request. (c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor. (d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.

  • Sub-Contractors Transfer Agent may, without further consent on the part of Customer, subcontract with other subcontractors for telephone and mailing services as may be required from time to time; provided, however, that the Transfer Agent shall be as fully responsible to the Customer for the acts and omissions of any subcontractor as it is for its own acts and omissions.

  • Shift Workers All shift workers (i.e. workers whose shift commences at or after the end of the ordinary day work hours) presenting for work when the temperature is at or over 35°C will remain on site in air conditioned amenities for a minimum two hours, holding themselves available to commence work should the temperature fall below 35°C.

  • Contractor’s Staff 1. The Contractor shall maintain adequate staff to meet the Contractor’s obligations under this Agreement. 2. This staff shall be available to the State for training and meetings which the State may find necessary from time to time.