OVERTIME AND SPECIAL WORK SCHEDULE Sample Clauses
OVERTIME AND SPECIAL WORK SCHEDULE. A. BUILDING SENIORITY: Overtime shall be offered on a seniority rotation basis, within a building, to those employees who desire such overtime.
Plans and Specifications After Landlord receives and approves Tenant’s Space Plan as provided above, Tenant will cause Tenant’s Architect to prepare the Plans and Specifications for the Tenant Improvements. Landlord will approve or disapprove (specifically describing any reasons for disapproval) the Plans and Specifications in writing within ten (10) Business Days after receiving them. If Landlord disapproves the Plans and Specifications, Tenant will provide appropriately revised Plans and Specifications to Landlord for approval (or disapproval) within five (5) Business Days on the same basis as set forth above. After Landlord’s approval, Tenant will submit the Plans and Specifications for permits and construction bids. No deviation from the Building Standard will be permitted in the Space Plan or the Plans and Specifications, provided reasonable deviations with respect to the ceiling, lighting, painting, flooring and wall covering may be permitted with Landlord’s approval. Landlord will not approve any deviations which Landlord believes (a) do not conform to applicable codes, ordinances and other Laws or are disapproved by any governmental agency, (b) require services beyond the level normally provided to other tenants in the Building, or (c) are of a nature or quality that are inconsistent with Landlord’s overall plan or objectives for the Building. No approval by Landlord of any deviation constitutes an acknowledgment by Landlord that such deviations are in conformance with applicable codes, ordinances and other Laws. In the event that Landlord’s approval shall be required in this Tenant Improvements Agreement, then notwithstanding anything to the contrary set forth in the Lease, Landlord’s approval shall not be unreasonably withheld, conditioned, or delayed.
Tenant’s Work Section 5.1 Tenant will not make any changes to the Premises, the Building, the Building systems, or any part thereof (collectively, “Tenant’s Work”), without Landlord’s consent. Tenant’s Work will be performed, at Tenant’s expense, in a professional manner using new materials of first class quality as reasonably determined by Landlord and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2). Section 5.2 Prior to performing any Tenant’s Work which, pursuant to this Article, requires Landlord’s consent, Tenant will, at Tenant’s expense (a) deliver to Landlord, detailed plans and specifications for Tenant’s Work in form reasonably satisfactory to Landlord prepared and certified by a registered architect or licensed engineer, and suitable for filing with the applicable Authority, if filing is required by Law (“Tenant’s Plans”), (b) obtain Landlord’s approval of Tenant’s Plans (which will not be unreasonably withheld or delayed to the extent Landlord’s consent to Tenant’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article), (c) obtain (and deliver to Landlord copies of) all required authorizations of any Authority, (d) deliver to Landlord certificates (in form reasonably acceptable to Landlord) of worker’s compensation insurance (covering all persons to be employed by Tenant, and all contractors and subcontractors performing any Tenant’s Work), commercial general liability insurance (naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds) and Builder’s all risk insurance (issued on a completed value basis), in form, with companies, for periods and in amounts reasonably required by Landlord, naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds. Tenant will promptly reimburse Landlord for any reasonable out-of-pocket expenses incurred by Landlord in connection with Landlord’s review of Tenant’s Plans and inspection of Tenant’s Work, including outside experts retained by Landlord for that purpose. Following the completion of Tenant’s Work, Tenant will, at Tenant’s expense, obtain and deliver to Landlord copies of all authorizations of any Authority required upon the completion of Tenant’s Work and “as-built” plans and specifications for Tenant’s Work prepared as reasonably required by Landlord. Section 5.3 If, in connection with Tenant’s Work or any other act or omission of Tenant or Tenant’s employees, agents or contractors, a mechanic’s lien, financing statement or other lien or violation is filed against Landlord, or any part of the Premises, the Building or Tenant’s Work, Tenant will, at Tenant’s expense, have it removed by bonding or otherwise within 30 days after Tenant receives notice of the filing. Section 5.4 Tenant will not employ, or permit the employment of, any contractor, subcontractor or other worker for purposes of conducting physical work in the Premises, whether in connection with Tenant’s Work or otherwise, if such employment will, in Landlord’s reasonable judgment, interfere or cause conflict with other contractors, subcontractors or workers in the Building. Section 5.5 At Tenant’s request, Landlord will join in any applications for any authorizations required from any Authority in connection with Tenant’s Work (to which Landlord has consented, if required pursuant to this Article), and otherwise cooperate with Tenant in connection with Tenant’s Work, but Landlord will not be obligated to incur any expense or obligation in connection with any such applications or cooperation. Section 5.6 Tenant will not place a load on any floor of the Premises exceeding the floor load per square foot which the floor was designed to carry and which is allowed by any Law. Section 5.7 On or before the Expiration Date, Tenant will, at Tenant’s expense, remove from the Premises and the Building (a) Tenant’s trade fixtures, equipment and personal property which are removable without material damage to the Premises or the Building (“Tenant’s Property”), and (b) any Tenant’s Work which is not an ordinary nonstructural office installation and which Landlord designates for removal in a notice given by Landlord to Tenant on or before the date which is 90 days prior to the Fixed Expiration Date (or five days prior to the Earlier Expiration Date, if applicable), and repair any damage to the Premises or the Building caused by the installation or removal of Tenant’s Property or Tenant’s Work. If, at the time Tenant requests Landlord’s consent to Tenant’s Plans, Tenant requests Landlord to designate the portions of Tenant’s Work which must be removed pursuant to this Section, Landlord will make that designation on the date Landlord gives Landlord’s consent to Tenant’s Plans. Except as expressly provided in this Section, Tenant’s Work will not be removed and will, on the Expiration Date, become the property of Landlord. Any Tenant’s Property or Tenant’s Work (which Tenant was required to remove) which is not removed by Tenant by the Expiration Date will be deemed abandoned and may, at Landlord’s option, be retained as Landlord’s property or disposed of by Landlord at Tenant’s expense.
Work Schedule (A) Where an employee has an established schedule, a change in workdays or shifts will be posted no less than 14 calendar days in advance and will reflect at least a two workweek schedule; however, the state will make a good faith effort to reflect a one month schedule. (B) In the event of a declared emergency the notice requirement of this Section may be void. (C) The state will continue to observe the scheduling structures currently in place at each agency and agrees to bargain any change in the overall practice of how schedules are established.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter: a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications). b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows: (i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and (ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ of ▇▇▇▇▇ ▇▇▇▇ LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises. c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.