PERFORMANCE SECURITY, PERFORMANCE GUARANTEE AND RETENTION MONEY Clause Samples

PERFORMANCE SECURITY, PERFORMANCE GUARANTEE AND RETENTION MONEY. 5.1 The Contractor shall, for the performance of its obligations hereunder, provide to the Authority, an irrevocable and unconditional performance bank guarantee for a sum equivalent to Rs. [●] (5% (Five) of the Contract Price) as per the format specified in Part A of Schedule 8 A ("Performance Security"). The Contractor shall maintain and keep in force the Performance Security valid for a period of 3 (three) months from the Project Completion Date. Till the time the Performance Security is provided by the Contractor pursuant to this clause 5.1 and the same comes into effect, the Bid Security shall remain in force and effect, and upon such provision of the Performance Security pursuant hereto, the Authority shall release the Bid Security to the Contractor. 5.2 The Performance Security shall be in a form and manner as may be prescribed by or approved by the Authority and shall be subject to provisions of Clauses 3.2. and 3.
PERFORMANCE SECURITY, PERFORMANCE GUARANTEE AND RETENTION MONEY 

Related to PERFORMANCE SECURITY, PERFORMANCE GUARANTEE AND RETENTION MONEY

  • Performance Guarantee 9.4.1 The Concessionaire shall, for the performance of its obligations hereunder during the Concession Period, provide to the Authority no later than [90] days prior to expiry of the Performance Security, an irrevocable and unconditional guarantee from a Bank for a sum equivalent to Rs. ***** crore (Rupees ***** crore)7 in the form set forth in Schedule-FF (the “Performance Guarantee”). Until such time the Performance Guarantee is provided by the Concessionaire pursuant hereto and the same comes into effect, notwithstanding anything contained in clause 9.3 the Performance Security shall remain in force and effect, and upon such provision of the Performance Guarantee pursuant hereto, the Authority shall release the Performance Security to the Concessionaire. 9.4.2 Notwithstanding anything to the contrary contained in this Agreement, in the event Performance Guarantee is not provided by the Concessionaire within a period of [90] days prior to expiry of the Performance Security, the Authority may invoke and encash the Performance Security and appropriate the proceeds thereof as Damages, and thereupon all rights, privileges, claims and entitlements of the Concessionaire under or arising out of this Agreement shall be deemed to have been waived by, and to have ceased with the concurrence of the Concessionaire, and this Agreement shall be deemed to have been terminated by mutual agreement of the Parties.

  • Performance Obligations The Purchaser shall have performed in all respects all obligations required to be performed by it under this Agreement at or prior to the Closing.

  • Performance Guaranty Parent hereby guarantees the due, prompt and faithful performance and discharge by, and compliance with, all of the obligations, covenants, terms, conditions and undertakings of Merger Sub under this Agreement in accordance with the terms hereof, including any such obligations, covenants, terms, conditions and undertakings that are required to be performed, discharged or complied with following the Effective Time by the Surviving Corporation.

  • Performance Security 47.1 Within twenty-one (21) days of the receipt of Letter of Acceptance from the Procuring Entity, the successful Tenderer, if required, shall furnish the Performance Security in accordance with the GCC 18, using for that purpose the Performance Security Form included in Section X, Contract Forms. If the Performance Security furnished by the successful Tenderer is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Tenderer to be acceptable to the Procuring Entity. A foreign institution providing a bond shall have a correspondent financial institution located in Kenya, unless the Procuring Entity has agreed in writing that a correspondent financial institution is not required. 47.2 Failure of the successful Tenderer to submit the above-mentioned Performance Security or sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the Tender Security. In that event the Procuring Entity may award the Contract to the Tenderer offering the next lowest Evaluated Tender. 47.3 Performance security shall not be required for a contract, if so specified in the TDS.

  • Performance Obligation 11.1 Interconnection Customer's Interconnection Facilities 11.2 Participating TO's Interconnection Facilities 11.3 Network Upgrades and Distribution Upgrades