PI PROCESS Sample Clauses

The PI Process clause defines the procedures and requirements for managing and processing personal information (PI) within the context of an agreement. It typically outlines how personal data should be collected, stored, used, and protected, often referencing compliance with relevant data protection laws such as GDPR or CCPA. For example, it may specify security measures, data access controls, and protocols for reporting data breaches. The core function of this clause is to ensure that both parties handle personal information responsibly and legally, thereby reducing the risk of data misuse and regulatory penalties.
PI PROCESS. PI’s process technologies, which are implemented in the SUPPLIER wafer fabrication facility to produce the WAFERS, and of which the detailed specification is specified in the COMMON SPECIFICATIONS, plus all PI IMPROVEMENTS.
View SourceView Similar (9)

Related to PI PROCESS

  • Complaints Process The School shall establish and adhere to a process for resolving public complaints which shall include an opportunity for complainants to be heard. The final administrative appeal shall be heard by the School's Governing Board, except where the complaint pertains to a possible violation of any law or term under this Contract. The complaints process shall be readily accessible from the School’s website, as described in Section 11.4.1.

  • Change Order Process 12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5. 12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof. 12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.

  • Grievance Process (a) Either party, with the agreement of the other party, may submit a grievance to Grievance Mediation at any time within ten (10) working days after the Employer’s decision has been rendered at the step prior to arbitration. Where the matter is so referred, the mediation process shall take place before the matter is referred to Arbitrator. (b) Grievance Mediation shall be scheduled within twenty (20) working days of the grievance being submitted to mediation, or longer period as agreed by the parties. (c) No matter may be submitted to Grievance Mediation which has not been properly carried through the grievance procedure, provided that the parties may extend the time limits fixed in the grievance procedure. (d) The parties shall agree on a mediator. (e) Proceedings before the Mediator shall be informal. Accordingly, the rules of evidence will not apply, no record of the proceedings shall be made and legal counsel shall not be used by either party, unless otherwise mutually agreed. (f) If possible, an agreed statement of facts will be provided to the Mediator, and if possible, in advance of the Grievance Mediation Conference. (g) The Mediator will have the authority to meet separately with either party. (h) If no settlement is reached within five (5) working days following Grievance Mediation, the parties are free to submit the matter to Arbitration in accordance with the provisions of the collective agreement. In the event that a grievance which has been mediated subsequently proceeds to arbitration, no person serving as the Mediator may serve as an Arbitrator, unless otherwise mutually agreed. Nothing said or done by the mediator may be referred to Arbitration. (i) The Union and Employer will share the cost of the Mediator, if any.

  • Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.

  • Ordering Process 6.4.1 CLEC, or CLEC's agent, shall act as the single point of contact for its End User Customers' service needs, including without limitation, sales, service design, order taking, Provisioning, change orders, training, maintenance, trouble reports, repair, post-sale servicing, Billing, collection and inquiry. CLEC's End User Customers contacting Qwest in error will be instructed to contact CLEC; and Qwest's End User Customers contacting CLEC in error will be instructed to contact Qwest. In responding to calls, neither Party shall make disparaging remarks about each other. To the extent the correct provider can be determined, misdirected calls received by either Party will be referred to the proper provider of local Exchange Service; however, nothing in this Agreement shall be deemed to prohibit Qwest or CLEC from discussing its products and services with CLEC's or Qwest's End User Customers who call the other Party seeking such information. 6.4.2 CLEC shall transmit to Qwest all information necessary for the ordering (Billing, Directory Listing and other information), installation, repair, maintenance and post-installation servicing according to Qwest's standard procedures, as described in the Qwest Product Catalog (PCAT) available on Qwest's public web site located at ▇▇▇▇://▇▇▇.▇▇▇▇▇.▇▇▇/wholesale/pcat. Information shall be provided using Qwest's designated Local Service Request (LSR) format which may include the LSR, End User Customer and resale forms. 6.4.3 Qwest will use the same performance standards and criteria for installation, Provisioning, maintenance, and repair of services provided to CLEC for resale under this Agreement as Qwest provides to itself, its Affiliates, its subsidiaries, other Resellers, and Qwest retail End User Customers. The installation, Provisioning, maintenance, and repair processes for CLEC's resale service requests are detailed in the Access to OSS Section of this Agreement, and are applicable whether CLEC's resale service requests are submitted via Operational Support System or by facsimile. 6.4.4 CLEC is responsible for providing to Qwest complete and accurate End User Customer Directory Listing information including initial and updated information for Directory Assistance Service, white pages directories, and E911/911 Emergency Services. The Ancillary Services Section of this Agreement contains complete terms and conditions for Directory Listings for Directory Assistance Services, white pages directories, and E911/911 Emergency Services. 6.4.5 If Qwest's retail End User Customer, or the End User Customer's New Service Provider orders the discontinuance of the End User Customer's existing Qwest service in anticipation of the End User Customer moving to a New Service Provider, Qwest will render its closing ▇▇▇▇ to the End User Customer, discontinuing Billing as of the date of the discontinuance of Qwest's service to the End User Customer. If the Current Service Provider, or if the End User Customer's New Service Provider orders the discontinuance of existing resold service from the Current Service Provider, Qwest will ▇▇▇▇ the Current Service Provider for service through the date the End User Customer receives resold service from the Current Service Provider. Qwest will notify CLEC by Operational Support System interface, facsimile, or by other agreed-upon processes when an End User Customer moves from the Current Service Provider to a New Service Provider. Qwest will not provide the Current Service Provider with the name of the New Service Provider selected by the End User Customer. 6.4.6 CLEC shall provide Qwest and Qwest shall provide CLEC with points of contact for order entry, problem resolution and repair of the resold services. These points of contact will be identified for both CLEC and Qwest in the event special attention is required on a service request. 6.4.7 Prior to placing orders on behalf of the End User Customer, CLEC shall be responsible for obtaining and having in its possession Proof of Authorization (POA), as set forth in the POA Section of this Agreement. 6.4.8 Due Date intervals for CLEC's resale service requests are established when service requests are received by Qwest through Operational Support Systems or by facsimile. Intervals provided to CLEC shall be equivalent to intervals provided by Qwest to itself, its Affiliates, its subsidiaries, other Resellers, and to Qwest's retail End User Customers.