Possession for Fit Sample Clauses

Possession for Fit. Out: In case the Allottee seeks permission for carrying out Fit- Out within his Unit, he will be permitted to do so only upon receiving the Completion Certificate(or at least after application for grant of CC is made) and upon payment of the entire consideration and Extras and Deposits as provided herein and also the requisite Stamp Duty and Registration charges payable on registration which shall be kept deposited by the Promoter in a designated Account till registration. During this time the Allottee will not be entitled to use the Unit till Occupation
View SourceView Similar (6)
Possession for Fit. Out: In case the Allottee seeks permission for carrying out Fit-Out within his Apartment, he will be permitted to do so only upon payment of the entire consideration and Extras and Deposits as provided herein and also the requisite Stamp Duty and Registration charges payable on registration which shall be kept deposited with the Owners/Vendors without any interest. During this time the Allottee will not be entitled to
View SourceView Similar (5)
Possession for Fit out:- In case the allottee seeks permission for carrying out Fit- out within his apartment, he will be permitted to do so only upon receiving the completion certificate (or at least after application for grant of CC is made) and upon payment of the entire consideration and Extras and Deposits as provided herein. During this time the allottee will not be entitled to live in the apartment till Occupation certificate or Completion Certificate or Partial Occupation Certificate or Partial Completion Certificate as the case may be, is received and Deed of Conveyance is executed and registered.
View SourceView Similar (2)
Possession for Fit. Out: In case the Allottee seeks permission for carrying out Fit -Out within his Row House/ Bungalow, he will be permitted to do so only upon receiving the Completion Certificate(or at least after application for grant of CC is made) and upon payment of the entire consideration and Extras and Deposits as provided herein and also the requisite Stamp Duty and Registration charges payable on registration which shall be kept deposited by the Promoter in a designated Account till registration. During this time the Allottee will not be entitled to use the Row House/ Bungalow till Occupation / Completion Certificate is received and Deed of Conveyance is executed.
View Source
Possession for Fit. Out: In case the Allottee seeks permission for carrying out Fit-Out within his Apartment, he will be permitted to do so only upon receiving the Completion Certificate(o r at least after application for grant of CC is made) and upon payment of the entire consideration and Extras and Deposits as provided
View Source
Possession for Fit out : In case the allottee seeks permission for carrying out Fit- out within his apartment, he will be permitted to do so only upon receiving the completion certificate (or at least after application for grant of CC is made) and upon payment of the entire consideration and Extras and Deposits as provided herein as provided in Schedule-L. During this time the allottee will not be entitled to live in the apartment till Occupation certificate or Completion Certificate or Partial Occupation Certificate or Partial Completion Certificate as the case may be, is received and Deed of Conveyance is executed and registered. Failure of Allottee to take Possession of the Apartment: Upon receiving a written intimation from the Promoter as per para 7.2, the Allottee shall take possession of the Apartment from the Promoter by executing necessary indemnities, undertakings and such other documentation as prescribed in this Agreement and the Promoter shall give possession of the Apartment to the Allottee. In case the Allottee fails to take possession within the time provided in para 7.2, such Allottee shall continue to be liable to pay maintenance charges as specified in para 7.2. Further, irrespective of whether the Allottee takes possession of the Apartment or not, given its possession for non-registration of the conveyance, it shall be bound to pay guarding charges at the rate of Rs.10,000/- per month. Possession by the Allottee: After obtaining the occupancy certificate, the completion certificate, the partial occupancy certificate or the partial completion certificate, as the case may be, for the Said Phase and handing over physical possession of the Apartment to the Allottees, it shall be the responsibility of the Promoter to handover the necessary documents and plans, including common areas, to the association of the Allottees and/or Association or the Competent Authority, as the case may be, as per the applicable laws.
View Source
Possession for Fit. Out: In case the Allottee seeks permission for carrying out Fit-Out within his Apartment, he will be permitted to do so only upon receiving the Completion/ Occupancy Certificate and upon payment of the Total Price, other charges/amounts and deposits as provided herein and also the requisite Stamp Duty and registration and other charges payable on registration which shall be kept deposited by the Promoter in a designated Account till registration. During this time the Allottee will not be entitled to use the Apartment till Completion/ Occupancy Certificate is received and Deed of Conveyance is executed. The entire process relating to Fit-out has to be followed as explained in Schedule -K hereunder written.
View Source
Possession for Fit. Out: As soon as the Said Shop/Apartment is ready for fit-out, the Developer shall serve a notice on the Transferee (Fit-Out Possession Notice), calling upon the Transferee to take physical possession for the limited purpose of fit-out of the Said Shop/Apartment. Before such delivery of possession for fit-out, the Transferee shall pay to the Developer all amounts due and payable towards the Total Price, Extras and other charges and the Transferee shall not claim possession of the Said Shop/Apartment and Appurtenances for fit-out till such payments are made in full. Within 15 (fifteen) days from the date of the Fit-Out Possession Notice (Date Of Fit-Out Possession Notice), the Transferee shall be bound to complete snagging of the Said Apartment, failing which it shall be deemed that the Transferee has taken satisfactory possession for fit-out on the 16th day of the Date Of Fit-Out Possession Notice (date of actual or deemed limited physical possession for fit-out, Date of Fit-Out Possession). It is clarified that the Date of Fit-Out Possession is different from the Date of Possession and the modalities ancillary thereto as more fully described in Clause f) (ii) below.
View Source
Possession for Fit. Out: In case the Allottee seeks permission for carrying out Fit- Out within his Apartment
View Source

Related to Possession for Fit

  • Procedure for taking possession The Promoter, upon obtaining the occupancy certificate or completion certificate (which may be partial), whichever be applicable, from the competent authority shall offer in writing the possession of the Apartment, to the Allottee in terms of this Agreement to be taken within 2 (two) months from the date of issue of such certificate Subject To the terms of the Agreement and the Allottee making payment of the entire balance consideration and all other amounts and deposits payable by the Allottee to the Promoter hereunder and fulfilling all his other covenants / obligations herein. [Provided that, in the absence of local law, the conveyance deed in favour of the Allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy / completion certificate subject to the Allottee making payment on account of stamp duty, registration fee etc., Provided Further That the Promoter shall not be liable to deliver possession of the Apartment to the Allottee nor to execute or cause to be executed any Sale Deed or other instruments until such time the Allottee makes payment of all amounts agreed and required to be paid hereunder by the Allottee and the Allottee has fully performed all the terms conditions and covenants of this Agreement and on the part of the Allottee to be observed and performed until then]. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfillment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee, after taking possession, agree(s) to pay the maintenance charges as determined by the Promoter/ association of allottees, as the case may be, after the issuance of the completion certificate for the project. The Promoter shall handover the copy of the occupancy certificate / completion certificate of the apartment to the Allottee at the time of conveyance of the same. 7.2.1 It is clarified that the Promoter shall be deemed to have duly complied with all its obligations in case the Promoter issues notice of completion to the Allottee on or before the date mentioned in Clause 7.1 above.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Possession by the Allottee After obtaining the occupancy certificate* and handing over physical possession of the [Apartment/Plot] to the Allottees, it shall be the responsibility of the Promoter to hand over the necessary documents and plans, including common areas, to the association of Allottees or the competent authority, as the case may be, as per the local laws. [Provided that, in the absence of any local law, the promoter shall handover the necessary documents and plans, including common areas, to the association of allottees or the competent authority, as the case may be, within thirty days after obtaining the completion certificate].

  • Occupancy After Foreclosure Any sale of the Mortgaged Property or any part thereof will divest all right, title and interest of Mortgagor in and to the property sold. Subject to applicable law, any purchaser at a foreclosure sale will receive immediate possession of the property purchased. If Mortgagor retains possession of such property or any part thereof subsequent to such sale, Mortgagor will be considered a tenant at sufferance of the purchaser, and will, if Mortgagor remains in possession after demand to remove, be subject to eviction and removal, forcible or otherwise, with or without process of law.

  • New Application for Licensure Any time after the three-month period has lapsed from the Effective Date of this Agreement and Respondent has paid the Administrative Penalty set forth in Section III, Paragraph 1 of this Order, Respondent may apply for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement in any or all of the Participating States with the understanding that each State Mortgage Regulator reserves the rights to fully investigate such application for licensure or petition for reinstatement of an MLO Activity Endorsement and may either approve or deny such application or petition pursuant to the normal process for such licensing or endorsement investigations. No license application or petition described in this paragraph will be denied solely based on the facts, circumstances, or consensual resolution provided for in this Agreement. Respondent further agrees that Respondent must satisfy the Administrative Penalty provision prior to submitting an application for a new mortgage loan originator license or, as applicable, petition for the reinstatement of an MLO Activity Endorsement.